description: Landscaping services

title: Redevelopment of Playing Field at Graf Park - Yagoona

title: T19-13 Graf Park - Field Redevelopment.zip

description:
The works at Graf Park are to include the elimination of the existing turf and removal of the concrete wicket..  This will be followed by milling of the turf mat and using a rotary hoe to incorporate the dead material into the soil.  Bulk laser grading shall then establish the specified design surface levels.  The sub soil sand slit drainage shall be coordinated with the installation of the new irrigation and water harvesting systems.  After these installations, a final laser levelling shall occur to obtain the specified design which shall allow for the laying of new turf to take place.  The works shall require careful turf establishment practices as specified.  There shall also be a need to remove all waste material from the site.

A full description of the nature and extent of the services required by Council are set out in section 3 of this request.  Refer to the attached drawings & technical specifications.

addressForLodgement:
Preferably by electronic lodgement at: www.tenders.nsw.gov.au/wsroc/

Or by post or hand delivery to:

Tender No: T19-13

The Tender Box

Upper Ground Floor

Bankstown City Council

66-72 Rickard Road

BANKSTOWN NSW 2200

Or by Fax to: 02 9707 9495

submissionMethodDetails:
A mandatory site briefing will be held on Tuesday 13th   November 2012 at 10.00 am.

Graf Park – George Street, Yagoona (UBD ref 251 - P11)

Council will not consider a Tender lodged by a Tenderer who fails to attend this briefing, or fails to ensure that a representative of the Tenderer attends on its behalf.


scheme: UNSPSC

description: Light emitting diodes LEDs

title: LED Upgrade Of Quartz Halogen (QH) Traffic Signal Sites

status: complete

RFTAccess: Open

title: LED Upgrade RTA.zip

format: zip

documentType: tenderNotice

region: NSW

countryName: AUSTRALIA

streetAddress: 7 Langlands Road, Annangrove

legalName: Corrigan Electrics Pty. Ltd.

streetAddress: Cnr. Sunny Corner Road & Falnash Street, Portland

legalName: Curran & Curran Pty. Ltd.

region: ACT

streetAddress: 93 Tennant Street, Fyshwick

legalName: ECOWISE Services

streetAddress: 59 Bennu Circuit, Albury

legalName: GPE Electrical & Communications Contractor Pty. Ltd.

streetAddress: 17 Orana Road, Kenthurst

legalName: Plant Power Pty. Ltd.

CNJ Electrical Services

streetAddress: 8 Enterprise Drive, Glendenning

legalName: Pyofile Pty. Ltd.

Allied Traffic Services

region: QLD

streetAddress: Unit 4, 50 French Street, Eagle Farm

legalName: Rainmont Pty. Ltd.

Sydney Traffic Services

streetAddress: 129a Orchardleigh Street, Yennora

legalName: Roads & Maritime Services

streetAddress: Unit 13, 141-143 Hartley Road, Smeaton Grange

legalName: TASK Engineering Pty. Ltd.

streetAddress: 136 Pebbly Hill Road, Maraylya

legalName: WISPKHAN Pty

title: Addendum_1.zip

documentType: amendments

rationale: Minutes of Industry brief and Pre-Tender meeting.

title: Addendum2.zip

rationale: Addendum2 - Details enclosed.

tenderType: Open Tenders

description:
This is a Quality Assurance Contract.

Tenders are invited for the participation in a State-wide Work as Ordered Panel Contract for work consisting of the Supply, Installation and/or Retrofit activities for the LED upgrade of the remaining QH Traffic Signals lanterns at sites throughout NSW. Pre-qualified Traffic Signals (TS) contractors at Traffic Signals Class TS02 or higher are to perform the installation work.  Tenders from non pre-qualified contractors are eligible though it is a requirement of the Tender that the Installation work must be performed by TS pre-qualified contractors.

A pre-tender meeting will be held at 10:00am on Monday, 26 November 2012, at the RMS Blue Mountain Rooms, Level 3, 27 Argyle Street, Parramatta. Attendance is mandatory to submit a conforming tender. An industry briefing will be held at the start of this pre-tender meeting.

All tenderers must comply with the NSW Government Code of Practice for Procurement.

eTenderStatus: published

inheritanceType: RFT

name: Transport for NSW (Transport Infrastructure Projects)

scheme: xNSWRegions

procurementMethod: open

addressForLodgement: Tenders are to be lodged in the tender box at RMS, Level 6, 27 Argyle Street, Parramatta.

submissionMethodDetails:
Important information

To obtain a copy of the full tender documentation online payment is required.  Complete all of the following steps:

1. Select the link below, DOWNLOAD A SOFT COPY. Log in or register and follow the prompts to make your payment. At the end of the payment transaction your receipt number will be displayed.

2. Complete the order by clicking on the link PLEASE CLICK THIS LINK TO COMPLETE THE TRANSACTION.

3. Download the documents by clicking on the file name. Please read & follow the instructions and note that you will need WinZip to unzip the files.

eTenderProcurementMethod: Open Tenders

initiationType: tender


description: Fire or rescue trucks

title: Urban Pumper Fire Fighting Vehicles Class 2 for Fire & Rescue NSW

title: RFT_1001836_Tender_Pack fin.zip

streetAddress: 17 Homedale Rd, Bankstown

legalName: Aqua Assets Pty Ltd

streetAddress: 125 Fourth Avenue, Austral

legalName: Habib Bros Pty Ltd

streetAddress: 120 Ham Street, South Windsor

legalName: Kuipers Engineering Pty Ltd

streetAddress: 340 South Pine Road, Brendale

legalName: Mills-Tui Australia Pty Ltd

streetAddress: 65 Backhouse Place, Eagle Farm

legalName: Sasgar Fire & Rescue Pty Ltd

region: VIC

streetAddress: 17 Trewin Street, Wendouree

legalName: SEM Fire and Rescue Pty Ltd

SVM Qld

streetAddress: 1 Magnesium Street, Narangba

legalName: SVM QLD Pty Ltd as the Trustee for the SVM Unit Trust

streetAddress: 100 Silverwater Road, Silverwater

legalName: Westrucks- Phillips Fabrications Pty Ltd

title: 1001836Addendum1.doc

format: doc

rationale: Addendum 1 - amendments

title: Addendum2.docx

format: docx

rationale: Addendum No 2: Clarifications

title: addendum3.docx

rationale: Addendum No 3: Extension of closing time to 9.30am 15th March 2012

title: addendum4.docx

rationale: Addendum No 4; Clarifications

title: addendum5.docx

rationale: Addendum No 5: Clarifications

description:
This is an open RFT for the establishment of a Panel Contract for:

* Construction of Class 2 Urban Pumper Fire Fighting Vehicles;
* Fit out of Cab Chassis and Re Mount Recycled Class 2 Body and Pump Module;
* Fit out Cab Chassis only (to make ready to re mount recycled class 2 body and pump module).

Class 2 pumpers are 4x2 crew cab pumping vehicles located in rural/regional or metropolitan areas where community infrastructure is of an immediate hazard level.

The vehicle can be configured to undertake primary rescue roles.

They have a pump capacity of a minimum of 3000 litres per minute.

The Class 2 Pumper is an emergency response vehicle that provides fire fighting protection for infrastructure.

submissionMethod: written ElectronicSubmission

addressForLodgement: Via this web site only

submissionMethodDetails:
Pre-Tender Briefing

A Tenderer  briefing will be held at:

Fire & Rescue New South Wales
Logistic Support Division
Amarina Ave, Greenacre NSW

Thursday 2 February, 2012 @ 10:00am

Tanker Drawings
A copy of the Tanker drawings are provided on a CD. To obtain a copy of the Drawings please contact:

Mr Mick Delman
Manager Contracts & Supply
Fire & Rescue NSW
mick.delman@fire.nsw.gov.au

OBTAINING RFT DOCUMENTS:
Only a downloadable SOFTCOPY version of this RFT is available.
No CD or Hardcopy available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT/EOI and any FUTURE related Amendments that may be issued, you must download to your computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY - Free link at the bottom of this page and follow the on-screen instructions.

LODGE A RESPONSE:
Your completed Tender response should be lodged as required by the RFT documents.
It can be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.

Electronic Tender Box Security
During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site  “electronic tender box”.

All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed.
This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
A detailed system generated electronic receipt is issued for all responses received successfully.

PC SOFTWAER REQUIREMENTS:
To be able to open and read or view the downloaded files for this RFT you may require certain software listed below to be installed on your PC:

· Adobe Acrobat Reader  5.0 (or more recent).  Free trial version is available from Adobe web site.
· WinZip 7.0 (or more recent) or equivalent.  Please click here http://www.winzip.com/ WinZip to be taken to a free evaluation download site now.

Additional software which may also be required, including the following, depending on the file types provided:

*  Microsoft  Word 2003
*  Microsoft  Excel 2003

Other requirements:
**  An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browsers.

The minimum requirements are as follows - IE version 5.5 or later, Firefox 1.0, Netscape Navigator Ver 4.7 or later with Cipher Strength = 128bit. Suggested minimum monitor resolution is 800x600.

Your web browser MUST be set to accept cookies. You will not be able to Register or access the documents if cookies have not allowed.

The Tenderer is responsible for the provision and installation of the necessary software.

Having Problems?
Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ section under the On-line ?HELP button in the tool bar at the top of this page.


description: Building and Facility Construction and Maintenance Services

title: Marco Avenue, Revesby & Greenacre Road, Greenacre Rehabilitation

title: T15-13 Marco Ave Greenacre Rd RFT.zip

title: T15-13 Addendum 2.zip

rationale: Addendum 2

title: T15-13 Addendum 1.pdf

format: pdf

title: T15-13 BOQ for Part A B Final Version 1.xlsx

format: xlsx

rationale:
Addendum 1

New revised bii of quantities.

description:
This is a Quality Control, Lump Sum Contract. The works include, but are not limited to, the following components:

(1)        PRELIMINARIES

(a)           Preparation of a traffic control plan (TCP), prior to commencement of any work, in accordance with Technical Specification 201 Control of Traffic. The TCP shall meet RTA’s requirements regarding the work items that will have an impact on the existing traffic signals.

(b)           Notification in writing (form approved by the Superintendent) of all directly affected property/business owners/occupiers for a minimum of 48 hours prior to commencing works outside their frontages.

(c)           Site establishment and disestablishment.

(d)           Preparation of and submission of a dilapidation report to the Superintendent in the form of a report and photographs of all site features, adjacent properties, shop entrances, etc prior to the commencement of any work. This report must be provided prior to grant of site possession to Contractor.

(e)           Erosion and sedimentation control of the Works, including stockpile areas. The locations of stockpile areas will be discussed between Council and the contractor and agreed upon prior to commencement of works.

(f)            Setting out of the works.

(g)           Liaison with public and/or private service authorities and/or companies.

(h)           Regular weekly meetings between the Contractor’s representatives and Council’s representatives during construction at the Contractor’s site office. The frequency of these meetings may vary should the need arise.

(i)            Protection and/or support of existing services.

(j)            Site clearing and grubbing including removal and disposal of redundant vegetation.

(k)           Suppression of dust during construction

(l)            Ongoing maintenance of the work in terms of rectifying an hazards, erosion control, etc during the course of contract to practical completion

(m)          Site clean-up and restoration upon completion of works.

(n)           Rubbish and graffiti shall be removed. Any damage to function or appearance of the works shall be rectified by the Contractor without delay at the Contractor's cost.

(2)        CIVIL WORKS (both sites)

(a)           Sawcutting, excavation, demolition and disposal of kerb and gutter, footpaths, drainage structures and vehicular crossings.

(b)           Excavation and laying of RC drainage pipes including reconstruction of drainage pits.

(c)           Reconstruction of concrete kerb and gutter, several vehicular crossings & sections of concrete footpaving.

(d)           Reconstruction of several stormwater lintels including placement of Bike Safe Grates (BSG).

(e)           Supply and lay of 50mm top soil and turf behind new kerb and gutter lines and in all disturbed areas within nature strip.

Works  NOT INCLUDED in this Contract-

(f)            Asphalt pavement works other than restoration in front of newly laid kerb and gutter and extension of pavement at Greenacre Road.

(g)            Linemarking and signage.

addressForLodgement:
Preferably by electronic lodgement at: www.tenders.nsw.gov.au/wsroc/

Or by post or hand delivery to:

Tender No: T 15-13

The Tender Box

Upper Ground Floor

Bankstown City Council

66-72 Rickard Road

BANKSTOWN NSW 2200

Or by Fax to: 02 9707 9495


title: Maclean High School - Block C Toilet Upgrade

title: Maclean HS - MW21_Title Page and conditions_of_tendering.pdf

format: application/pdf

title: Maclean HS - MW21_tender_schedulesx.pdf

title: Tender Schedules.docx

title: Maclean HS - MW21_general_conditions.pdf

title: Maclean HS - MW21_preliminaries.pdf

title: Tech Spec RFT.pdf

title: Architectural Plans.pdf

title: 8362_ASB_101012_AsbestosRegister.pdf

title: Maclean HS addendum3.pdf

rationale:
Addendum #3
Addendum 3 consists of one (1) page to be bound into the tender documents regarding clarification of scope.

title: Addendum No.1.pdf

rationale:
Addendum #1
Addendum 1 consists of four (4) pages to be bound into the tender documents regarding clarifications arising from the pre-tender meeting.

title: addendum 2.pdf

rationale:
Addendum #2
Addendum 2 consists of eight (8) pages to be bound into the tender documents regarding clarifications, photos and site layout plans.

tenderType: Pre-Qualified / Invited

description: Upgrade the existing Block C Girls toilets to meet current code requirements.

procurementMethod: selective

timeframeDelivery: 10 Weeks

addressForLodgement: Tenders will ONLY be considered by the following submissions: Hard Copy Submissions to: NSW Public Works, TENDER BOX, 120 Dalley Street, Lismore 2480 Facsimile Submissions to: NSW Public Works TENDER FAX NUMBER (02) 6626 5690 Electronic Submissions ONLY via NSW Government eTendering website: https://tenders.nsw.go.au

submissionMethodDetails: A Non-Mandatory Meeting will be held at Maclean HS on Monday 5 November 2012 at 9:30 AM

eTenderProcurementMethod: Pre-Qualified / Invited

conditionsForParticipation:
Tenders will only be considered from the following Invited Tenderers:

Robin Snow Constructions Pty Ltd

Van Mal Group Pty Ltd

Simpson Building Group

Robert Shone Constructions Pty Ltd


description: Engineering and Research and Technology Based Services

title: Detailed Design services for Fishway at Tyreel Regulator - RFT - Doc11-30896.pdf

title: Detailed Design Services for Fishway at Tyreel Regulator - RFT - Tender Schedules.doc

format: application/msword

title: Letter from DPI dated 1st September 2011 on the URS Concept Design Report.PDF

title: URS -  Lower Gwydir Fishway Investigations - Concept Design Report 28 Jan 2011.PDF

description:
State Water Corporation manages a sub-program titled “Better Delivery of Environmental Water” that contributes to the NSW Rivers and Environmental Restoration Program (RERP), supported by both Commonwealth and State funding. This encompasses a suite of activities including investigations and construction work on fish barriers, leading to recognition that the lower Gwydir area presents substantial ecological and fish-passage issues that require attention.

Copeton Dam Upgrade triggered provisions under Section 218 of the NSW Fisheries Management Act (1994), which empower the Minister for DPI to require provision of fish passage when impoundments are modified. Inter-departmental discussions under the Fishway Offset Process resulted in a decision that, rather than pursuing the option of a fishway at the dam, fish passage should be reinstated at four Gwydir Wetlands sites as an offset, including Tyreel Weir, Tyreel Regulator, Boolooroo Weir and Tareelaroi Weir.

State Water engaged URS to undertake detailed concept designs of fishways at the above structures, as part of Copeton Dam Upgrade fishway offsets. URS completed the works, and their report has been provided with this RFT as background information.

URS recommended:

·  a Full Width Rock Ramp (FWRR) to be constructed along the old Gwydir River bed

·  a bridge to provide access to Tyreel Regulator and Tyreel Weir

·  a migration barrier in the form of low level weir beyond the downstream end of the rock ramp to ensure that the fish migration takes place towards the fishway, not to the regulator

The above report has been reviewed by DPI, and their comments have been highlighted in their letter (attached) dated 1st Sept 2011. DPI reinforced the following aspects, which were recommended by URS to consider during the detailed design:

·  change the present undershot regulator to an overshot regulator to avoid mass mortalities of juvenile fish due to pressure changes that burst the swim bladder of the fish as they pass under the gates

·  install a trash boom to collect floating debris upstream of the fishway

·  set out an acoustic array monitoring program to determine at what flows large bodied fish are able to migrate upstream using the fishway

Under this engagement, the works will include, but not limited to, all the above aspects recommended by URS and further highlighted by DPI.

The scope of this work is to undertake Detailed Design and Documentations of the proposed full-width rock ramp fishway at Tyreel Regulator as outlined in this brief.

timeframeDelivery: 16 weeks from the day of approval to proceed,

addressForLodgement: eTendering


title: Sydney Cricket Ground - Enabling WorksContract: Stage 2 Redevelopment.

RFTAccess: Restricted - Public View Detailed

title: 1102601 SCG Stage Two Enabling Works Contract.zip

title: Addendum 7.zip

rationale: Addendum No. 7

title: 1102601 SCG Enabling Works Addendum 8.pdf

rationale: Addendum No. 8

title: 1102601 SCG Enabling Works Addendum 9.pdf

rationale: Addendum No. 9

title: 1102601 SCG Enabling Works Addendum 10.zip

title: 1102601 SCG Enabling Works Addendum 11.zip

rationale: Addendum No's 10 and 11

title: Addendum 12.zip

title: Addendum 13.zip

rationale: Addendum No's 12 and 13

title: Addendum 14.zip

rationale: Addendum No. 14

title: 1102601 SCG Enabling Works Addendum 15.pdf

rationale: Addendum No. 15

title: 1102601 SCG Enabling Works Addendum 16.pdf

rationale: Addendum No. 16

title: Addendum 17.zip

rationale: Addendum No. 17

title: 1102601 SCG Enabling Works Addendum 18.pdf

rationale: Addendum No. 18 - Closing Date Extended.

title: Addendum 19.zip

rationale: Addendum No. 19

title: Addendum 20.zip

title: 1102601 SCG Enabling Works Addendum 21.pdf

rationale: Addendums No's 20 and 21

title: 1102601 SCG Enabling Works Addendum 22.pdf

rationale: Addendum No. 22

title: 1102601 SCG Enabling Works Addendum 1.doc

title: Addendum 1.zip

rationale:
Addendum No. 1

Tenderers may experience difficulty opening files that are included in the folder titled “Drawings and Technical Docs listed in Scope of Enabling Works”.

title: 1102601 SCG Enabling Works Addendum 2.doc

title: 1102601 SCG Enabling Works Addendum 3.doc

rationale: Addendums No's 2 and 3.

title: 1102601 SCG Enabling Works Addendum 4.doc

title: 1102601 SCG Enabling Works Addendum 5.doc

title: Attachment 1 Addendum 5 TrustSchedule of Events - 08 December 2011.pdf

rationale: Addendums No. 4 and 5.

title: 1102601 SCG Enabling Works Addendum 6.doc

rationale: Addendum No. 6

tenderType: Selective Tenders

description:
Sydney Cricket and Sports Ground Trust (SC&SGT) is inviting Tenders on a selective basis from suitably experienced, competent, and skilled construction contractors to deliver enabling works for Stage 2 - Noble, Bradman & Messenger Stand Redevelopment.

The Principal is seeking to expedite delivery of the new grandstand and is therefore tendering an Enabling Works Package in order to progress these works concurrent with finalising the design for the new grandstand construction contract. The construction contract will be based on the NSW Government’s GC21 General Conditions of Contract.

The Enabling Works Package comprises:

a)       Relocations of existing functions in grandstands and other areas to be demolished including:

-         modular buildings to temporarily accommodate catering staff and grounds staff amenities,

-         new steel framed sheds to accommodate grounds materials

-         construction of a new properties office, mechanical workshop, maintenance workshop within existing structures

-         upgraded change room facilities

-         a number of minor fit outs

b)       Services diversion including:

-         high voltage electrical

-         low voltage electrical

-         fire

-         hydraulic

-         mechanical

c)       Demolition comprising:

-         demolition of the grandstands

-         demolition of other minor buildings and structures.

Access to this RFT documentation is restricted to invited firms only.

Those Firms (shown below) have been issued with the special Access PassCode required by this RFT.

 The invited firms are:

ADCO Constructions Pty Ltd - North Sydney

Lipman Pty Ltd - North Sydney

Project Co-ordination (Australia) Pty Limited - Unanderra

Richard Crookes Constructions Pty Limited - Naremburn

 Electronic Tender responses will only be accepted from the above listed invited firms.

name: Sydney Cricket Ground & Sports Ground Trust

name: Tony Osborne (Mace Australia Proprietary Limited)

addressForLodgement: All responses to be lodged on this website.

submissionMethodDetails:
NOTES TO INVITED FIRMS
To access the RFT files and to lodge a response you must use the Access PassCode provided to you by the contact officer.

Obtaining the RFT Documents.
Click on the DOWNLOAD A SOFT COPY - Free link at the bottom of the page, use the Access Passcode provided to gain access, then register your firm in the system (if not previously registered), and follow onscreen instructions to download the RFT document files provided.

Lodging a Response
Your completed tender should be lodged electronically via this web page.

As the tenderer you must be a current Registered user of this web site.

Click on the blue LODGE ON RESPONSE link at the bottom of this page, using the Access Passcode, then using your registered system Login Username and Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Electronic Tender Box Security.
During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.

All responses that are received successfully can only be accessed, decrypted,retrieved and opened after the RFT has officially closed.

RFT Response - receipt/confirmation.
A detailed system generated electronic receipt is issued for all submitted responses files received successfully.

Software Requirements.
To be able to view the requirements within the RFT you will require the following software to be installed on your PC:

* Adobe Acrobat Reader 5.0 (or more recent) - Please click here

Adobe Acrobat Reader to be taken to their free download site now.

* Winzip 7.0 (or more recent) or equivalent - Please click here

Winzip to be taken to their free evaluation download site now.

The RFT also requires the following software:

* Microsoft - Word 2003

* Microsoft - Excel 2003

Other requirements:
* Internet connection to lodge completed tender response

The tenderer is responsible for the provision and installation of the necessary software.

eTenderProcurementMethod: Selective Tenders


title: Roof Replacement

title: Q91_11 Specification_Documents.zip

title: Q91_11 Returnable_Documents.zip

title: Q91_11 Reference Documentation and Drawings.zip

title: Q91-11 Addendum 1.zip

rationale: Clauses 6.5 and 10.1.2 have been amended, and two reference documents have been re-issued with the latest versions.

description: Replacement of the central building asbestos roofs and all other associated building works at the Principal's Sydney West Substation/metropolitan Area Centre located at 200 Old Wallgrove Road Eastern Creek NSW.

submissionMethodDetails: A compulsory site inspection for the work is to be held on Thursday 2nd February 2012 commencing at 10:00am at the Principal's Metropolitan Area Centre/Sydney West Substation, which is located at 200 Old Wallgrove Road, Eastern Creek NSW.


description: Economic or financial evaluation of projects

title: Redfern Waterloo Preliminary Masterplanning Project - Financial feasibility model

title: Redfern Waterloo financial fesibility model RFQ.pdf

title: Redfern Waterloo financial fesibility model - Addendum 1.pdf

rationale: Addendum 1 amends the scope of works, clarifies the Request for Quotation and provides a copy of the pre-tender briefing presentation.

description: Redfern Waterloo Preliminary Masterplanning Project involves the major concentration of Housing NSW properties in the suburbs of Redfern and Waterloo. The project is funded through the Housing Affordability Fund (HAF). Services sought include a financial feasibility model to help deliver outcomes for the masterplanning project.

addressForLodgement: NSW Government tendering website

conditionsForParticipation:
Three firms from the Department of Finance and Services panel of prequalified services providers are invited to prepare and submit tenders for these services. The firms are:

Deloitte Touche Tohmatsu

KPMG

PricewaterhouseCoopers

Tenders from organisations not invited will not be considered.


items: Restricted Tender

title: Electronic Security Upgrade - Katoomba Court House

status: Restricted Tender

RFTAccess: Restricted Tender

tenderers: Restricted Tender

tenderType: Restricted Tender

description: Restricted Tender

tenderPeriod: Restricted Tender

eTenderStatus: Restricted Tender

inheritanceType: Restricted Tender

deliveryLocation: Restricted Tender

submissionMethod: Restricted Tender

multiAgencyAccess: Restricted Tender

numberOfTenderers: Restricted Tender

procurementMethod: Restricted Tender

timeframeDelivery: Restricted Tender

coveredProcurement: Restricted Tender

addressForLodgement: Restricted Tender

submissionMethodDetails: Restricted Tender

eTenderProcurementMethod: Restricted Tender

conditionsForParticipation: Restricted Tender


title: DAGJ Total Asset Management Plan

description: Restricted Tender


description: Community and social services

title: OOHC Open Tender 2012

title: SECTION 1 Statement of Requirements 7.2.12.pdf

title: SECTION 2 - Conditions of Tender 07.02.12.pdf

title: SECTION 3 App Form 07.02.12.docx

title: Section 4 Returnable Schedules.07.02.12.doc

title: OT SECTION 1 Statement of Requirements 7 2 12.pdf

title: presentation for new providers.pdf

rationale:
Amendment to Section 1 ‘Statement of Requirements’, Part 5.2 – Table 1.1

The data in table 1.1 which provides information on the ‘Number of children and young people in CS Statutory Foster or Statutory Relative/Kinship Care as at 30 June 2011’, has been updated.

Office of Communities Children's Guardian Presentation:

The presentation is now available for download and reveiw.

title: FAQs 2 at 9 March 2012.pdf

rationale: The second FAQ's document is now available for review.

title: endorsed  service providers OT Presentation 010312.pdf

title: FAQs 3 at 23 March 2012.pdf

rationale:
The presentation given at the Service Providers Briefing Session is now available for review. To see the speaker notes in this presentation, hover your curser over the top left hand corner of each slide.

The third FAQ's document is also available for review.

title: 111205 Unit cost announcement Facts Sheet .pdf

rationale: A Fact Sheet outlining information on OOHC Unit Costs has been uploaded for your information

rationale: Amendment made to Section 2 document due to Tenders NSW change of Department Name.

title: FAQs at 2 March 2012.pdf

rationale: The Frequently Asked Questions (FAQ's) document is now available for viewing.

description:
In Stage 2 of the Procurement Plan, Open Tender submissions are sought from new OOHC providers, including non-program funded Header providers of both placement and non-placement services under Individual Client Agreements (ICAs).  The aim of the Open Tender is to establish the pre-qualified lists and proposed growth placements in each Community Services region.

Two Service Provider Briefing Sessions for the Open Tender will be held as detailed below:

A Service Provider Briefing specifically for Aboriginal Services will be held on:

Date: Wednesday 7th March

Registration: 1pm

Briefing: 1.30pm – 5.00pm

Location:  FACS, Community Services, Level 4,  168 Liverpool Rd, Ashfield

A Service Provider briefing will be held on:

Date: Thursday 8th March

Registration: 1pm

Briefing: 1.30 pm- 5.00pm

Location: FACS, Community Services, 4-6 Cavill Avenue, Ashfield.

A further follow up briefing session for the Open Tender is scheduled to occur on Tuesday 20th March 2012, 4-6 Cavill Avenue, Ashfield 2-5.30pm .

Please register for Briefings at OOHCtender@facs.nsw.gov.au by COB 6th March 2012.

timeframeDelivery: To be established as part of the selection process.

submissionMethodDetails: Applications will only be accepted in electronic format via the NSW E-Tendering website.  Applications will not be accepted by email or fax.  Exceptions to this shall only apply where Community Services has provided written permission to an applicant to lodge an application or part thereof by hardcopy, some other physical form.  Such permission shall only be granted in circumstances, deemed exceptional by Community Services (The Convenor), at its absolute discretion.

conditionsForParticipation:
A two staged Procurement Strategy will be used for the establishment of a pre-qualified OOHC service provider list (prequalified list) in each Community Services region and the purchase of OOHC placement services from the NGO sector.

In this Open Tender stream new OOHC providers may apply, including non-program funded Header providers of both placement and non-placement services under Individual Client Agreements (ICAs).

The service provider must meet the legal entity requirements of the Community Services Service Agreement (available from the Community Services Website).

Section 1 – Statement of Requirements, 1.4 Accreditation, provides information on the  requirements for Accreditation as an OOHC provider.

Section 2 – Conditions of Tender, 1.10 Acceptable Legal Entities, provides further information on acceptable legal entities.


title: Dubbo Sch of Dist Ed - Design & Const New Covered Walkway

title: Documentation.zip

title: Addendum No 1.pdf

rationale: ADDENDUM 1 is now available to download.  It contains clarification on Soffit Lining

description: Design and construct a covered walkway between Blocks G & R

timeframeDelivery: 8 weeks

addressForLodgement: This website https://tenders.nsw.gov.au/dfs or as specified in the tender documents.

submissionMethodDetails:
OBTAINING RFT DOCUMENTS

First time visitors to this website who wish to obtain a copy of the RFT will need to self-register on this website to gain access to any documents.

To obtain the RFT/EOI and any future amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY – Free link at the bottom of this page and follow the on-screen instructions.

REGISTER FOR FREE NOTIFICATIONS

Potential tenderers are encouraged to register with the NSW eTendering system to receive email notifications or new relevant business opportunities.

New users can register by selecting the register link on the top left toolbar.  When registering, please select all relevant business categories to ensure you receive the appropriate notifications.

DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document(s) and returnable schedules is available for downloading by following the instructions below.  Hardcopies of the RFT document will be available at a charge determined by the size of the document, arrange via “Contact Person” listed in the RFT Full Details.

An EXHIBITED HARDCOPY of this RFT is available for public viewing at NSW Public Works, 34 White Street, Dubbo NSW during normal business hours.

LODGING A RESPONSE

Your completed response should be lodged as required by the RFT documents.  It can be lodged electronically via this web page.

During the lodgement process all responses are encrypted for security.  Any responses that are received can only be accessed, decrypted and opened after the RFT has officially closed.

A system generated electronic receipt is issued to the submitter for each response transmitted successfully.

PC SOFTWARE REQUIREMENTS

To be able to open and read or view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader  5.0 (or more recent)

WinZip 7.0 (or more recent) or equivalent

Additional software may also be required, including the following, depending on the file types provided:

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

Other requirements

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browser.

Cookies

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

HAVING PROBLEMS?

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ” section under the On-line ?HELP button at the top of this page.


title: RFQ for training programs from RTO's to be delivered in-house at DAGJ

description: Restricted Tender


title: Campbelltown TAFE: Autobody Refinishing Spray Booths (Two).

title: 1200326_Campbelltown TAFE.zip

description:
NOTE - This is an Invited tender.

Removal of existing spray booths and the design, supply, installation and commissioning of two new spray booths to meet TAFE Standards

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Malcolm Rolls 02 9852 0219.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Invited Tenderers are:

Lowbake Australia Pty Ltd, 20 Luisa Street, Dandenong VIC 3175

Monarch Industries (Aust.) Pty. Ltd., 132 Mooringe Avenue, North Plympton SA 5037

Pan Spraybooths Australia, Unit 1, No. 13 Exchange Parade, Narellan NSW 2567

Tenders from the above contractors ONLY will be accepted.


description: Photographic services

title: Development of 3D Spatial Products using ADS40 Photogrammetric Data

title: EOI ADS40 3D Products  final.doc

title: Clarification 1.doc

rationale:
Clarification 1

Note new closing date and time

tenderType: Expression of Interest For Pre-Qualification

description: To produce a range of 3D spatial products using existing elevation data sourced from a Leica ADS40 or similar photogrammetric sensor.


description: Landscaping services

title: Landscaping Construction and Maintenance Selective Tender

title: C12-2012 Selective Tender Documents.pdf

title: C12-2012 LANDSCAPING - Response Forms.xls

title: C12-2012 LANDSCAPING - Schedule of Rates Forms.xls

title: C12-2012 Specifications.pdf

Acacia Landscapes

streetAddress: 15b Alamar Crescent, Quakers Hill

legalName: A & K Landscapes Pty Ltd

streetAddress: Level 1 150 Jolimont Road, East Melbourne

legalName: Citywide Service Solutions Pty Ltd

Design Landscapes Pty Ltd

streetAddress: 586 Willoughby Road, Willoughby, Sydney

legalName: Design Landscapes Pty Ltd

ESD Landscape Contractors Pty Ltd

streetAddress: 204 Forest Way, Belrose

legalName: ESD Landscape Contractors Pty Ltd

streetAddress: 2E / 802 Pacific Hwy , Gordon, Gordon

legalName: Hargraves Landscapes Pty Ltd

Lamond Contracting

streetAddress: 84 Wilton Rd, Wilton

legalName: Lamond Contracting Pty Ltd

streetAddress: 16 Distribution Place, Seven Hills

legalName: Landscape Solutions Pty Ltd

streetAddress: 9 Bangalow Place, Baulkham Hills

legalName: Perfection Landscape Services

Regal Innovations Pty Ltd

streetAddress: 249 Annangrove Road, Annangrove

legalName: Regal Innovations Pty Ltd

undercover landscapes

streetAddress: 6 Bannerman Road, Kenthurst

legalName: undercover landscapes

rationale:
Addendum No 2

Closing date changed from 28 March to 12.00 noon on Wednesday 18 April 2012

Additional Schedule of Rates form was emailed to each tenderer.

description:
This tender is for Contract No. 12 / 2012 – Landscaping Construction and Maintenance for Blacktown City Council with the method of payment being Schedule of Rates, subject to Rise and Fall in costs.

The works under the contract will generally include:

·       Construction of landscaping works anywhere within the Blacktown City Council area with the type and extent of the works varying for each project as allocated by Council. It is expected that contractors construct both smaller and larger landscaping works.

·       Maintenance of landscape areas constructed under this contract after the establishment period and certain existing landscaped areas constructed by others but not maintained under another contract, anywhere within the Blacktown City Council area with the type and extent of the works varying for each project as allocated by Council. It is expected contractors maintain both smaller and larger landscaped areas.

·       The works may be located within parks and reserves, on central medians of major roads, on roundabouts, along minor roads, at Council buildings or other public areas.

·       The works may be allocated at any time during the contract term as and when required. There will be no guarantee for the size, quantity or frequency of any works allocated to any contractor. Contractors will be expected to carry out all types and sizes of work under the contract.

·       Traffic Control will be required for works on or near roads.

The Schedule of Rates provides pay items for the types of works that may or not be encountered under this contract.

Works will be allocated for construction based on Council’s approved Works Improvement Program of works that commences each financial year on 1 July.

Works will be allocated for maintenance of landscaping as and when required but is subject to approved funding.

addressForLodgement: Tenders may be submitted either by use of electronic means via the website, https://tenders.nsw.gov.au/wsroc/ or by hardcopy form in a sealed envelope and placed in the tender box located on the ground floor of Blacktown City Council Civic Centre, 62 Flushcombe Road, Blacktown.

conditionsForParticipation:
Only those respondents to the Expression of Interest, C12/2011 Landscaping Construction and Maintenance and who have been invited by Council to tender by letter from Council may download the documents and submit a tender.

The Passcode provided in the letters to accepted respondents will be required to download the documents, and to upload the tender submission into the eTender tender box.


description: Commercial and Military and Private Vehicles and their Accessories and Components

title: Request for Information - Supply and Delivery of Bus Parts for State Transit Authority of NSW

title: RFI Bus Parts.pdf

tenderType: Invitation To Respond

description: The objective of the Request of Information is to gather data on the current state of the bus parts market in Australia as the first step of a multi-stage procurement process. State Transit is seeking information from suitable suppliers to gain a better understanding of what drives prices and what constraints exist in the bus parts market in Australia to fine-tune its procurement activities in relation to bus parts for its fleet of buses.

Identifiers: ACT NT QLD SA TAS VIC WA

addressForLodgement:
Responses to the Request for Information are to be submitted electronically via NSW Government eTendering website:

e-Tenders https://tenders.nsw.gov.au/

eTenderProcurementMethod: Invitation To Respond


title: HSSN_LC12_122HNET - Instructions to Tenderers.pdf

title: HSSN_LC12_122HNET - Guyra GP Consult Rooms RFT Specifications.pdf

title: HSSN_LC12_122HNET - Site Plan Sheet Set.pdf

title: HSSN_LC12_122HNET - Engineering Drawings.pdf

title: HSSN_LC12_122HNET - Tender Form.pdf

Boulus Constructions Pty Ltd

streetAddress: 121 Rusden Street, Armidale

legalName: Boulus Constructions Pty Ltd

Castlereagh Group

streetAddress: 3/168 King Street, Newtown

legalName: Castlereagh Building & Construction Pty Ltd

streetAddress: 74 Anderson Road, Mortdale

legalName: Degnan Constructions Pty.Ltd.

as above

streetAddress: 35 Avro St Tamworth NSW 2340, PO Box 7087 NEMSC Tamworth NSW 2348, Tamworth

legalName: Dillons Plumbing PTY LTD

ted edmonds construction

streetAddress: 126, toms drive, inverell

legalName: lecoin distributors pty ltd

streetAddress: 3 Ollera Street, Guyra

legalName: McFarlane Building

Patterson Building Group Pty Limited

streetAddress: Suite 703, Level 7, 5-13 Rosebery Avenue, Rosebery

legalName: Patterson Building Group Pty Limited

as Above

streetAddress: 76 Showground Rd, Tamworth

legalName: PJ Truman Constructions Pty Ltd

Rice Construction Group Pty Ltd

streetAddress: Po Box 1404, Armidale

legalName: Rice Construction Group Pty Ltd

Robin Snow Constructions Pty Ltd

streetAddress: 18 Keona Circuit, Coffs Harbour

legalName: Robin Snow Constructions Pty Ltd

SJ & LJ Burey

streetAddress: Lot 2 Stevenson Street, GUYRA

legalName: SJ & LJ Burey

title: Amendment 1.pdf

title: Engineering Addenda 1 for Guyra GP Clinic.pdf

title: Amended Construction Drawings.zip

title: As Built Drawings.zip

rationale: This Amendment 1 provides information on an extension to the closing date, amended diagrams and an Addenda to the RFT regarding the Specification and requirements for the abovementioned tender.

rationale: Extension of closing date updated on eTender site to reflect Amendment 1.

description: Health Support Services Newcastle, on behalf of Hunter New England  Local Health District is inviting tender submissions for the following: HSSN_LC12_122HNET - Construction of GP Clinic Rooms at Guyra Hospital

name: HealthShare NSW - Local Tender and Contracts

addressForLodgement: Tenders must be completed and submitted in electronic format via this eTendering portal

submissionMethodDetails:
Tenderers should inspect the site before tendering and check all data and examine all features as may affect the tender.

An optional site visit has been coordinated for Wednesday 3rd October 2012 between 11.00am and 1.00pm at the Guyra Hospital.

Please register your interest in attending this site visit by contacting the Manager Minor Works, Hunter New England Local Health District, Mrs Gail Carter on (02) 6767 8070 or 0429 002 758 at least 24 hours prior to Wednesday 3rd October 2012. Site visit is restricted to a maximum of two representatives per company.


description: Engine components and accessories

title: Supply of Mechanical Spare Parts

title: 21-2012 Supply Mechanical Spare Parts Tender Document.pdf

title: C21-2012 Tender Submission Forms.xls

description:
This tender is for Contract No. 21 / 2012 –Supply of Mechanical Spare Parts For Commercial Veicles to Blacktown City Council with the method of payment being Schedule of Prices, subject to price adjustment after a period of twelve (12) months has elapsed.

The supply of mechanical spare parts for commercial vehicles must comply with the relevant and current standards including price,quality, delivery to Blacktown City Council’s Depot located at Station Street, Rooty Hill NSW 2766.

Blacktown City Council operates a fleet of approximately 300 commercial vehicles, including garbage collection, construction and maintenance light & heavy trucks.

The duration of this contract will be for a minimum of twelve (12) months and may be extended for a further 12 months subject to satisfactory performance by the contractor to a maximum of 3 years.

Council shall have the option to extend the contract giving two (2) months prior notice in writing to the contractor.

Council reserves the right to award all or part of the contract to one (1) tenderer or several tenderers.

The tenderer shall provide the following:

·       Stock availability as and when required, available 6 days per Week.

·       On-Time Delivery / Number of Deliveries per Day

·       One Stop Shop for all geniune or accredited heavy vehicle spare parts.

·       Vehicle Off the Road – Urgent Spares.

Any additional services offered not included above are to be stated and information provided.

addressForLodgement:
Tenders must be submitted by hardcopy form, by printing the completed tender submission documents and placing in a sealed envelope and placed in the tender box located on the ground floor of Blacktown City Council Civic Centre, 62 Flushcombe Road, Blacktown.

All tenders shall be received before the closing time and date for tenders as indicated in the advertisement.

The submission of tenders by facsimile or email shall not be accepted by Council.

submissionMethodDetails:
The evaluation criteria in assessing all conforming tenders, not necessarily in order of importance, shall be:

·       Tendered Prices.

·       Experience and Knowledge

·       Support, service and supply

·       Ecological and Environmental Sustainability

·       Work Health and Safety

·       Equal Employment Opportunity and Fair Employment

The lowest or any tender will not necessarily be accepted.


description: Compressors

title: Air Compressor Maintenance

rationale: Condact email address amended

description:
This plant is composed of five Station Air Compressors, two Station Air Dryers, Station Compressed Air ancillary equipment and four Emergency Air Compressors. In addition, Coal Combustion Products (CCP) Handling Plant Compressors and associated Air Dryers are included as an Option.

The order shall be for an initial period of 24 months with a Principal option to extend for 2 x 24 month periods (totalling 6 years)

addressForLodgement:
Tenders are conducted electronically and may be downloaded from eraring Energy's internat Tendering Site:

http:/360prop3.apetsoftware.com.au/Public/04/PublicJobs.aspx.

The site contains support information should assistance be required.

Closing date: Tenders are to be uploaded to the Apet360pro Tender site prior to 2pm on 4th April 2012.

Enquiries may be made direct to Teresa Hudson, Procurement Specialist via e-mail: teresa.hudson@eraring-energy.com.au

submissionMethodDetails:
    Location of Site

The Site is located within the grounds of Eraring Energy's Eraring Power Station.

Eraring Power Station is located off the Sydney? Newcastle Expressway, between Morisset and Toronto, near Dora Creek, approximately 150 km north of Sydney, New South Wales.

 Site Inspection

Visitors to Eraring Energy power station sites are required to wear safety eyewear, hard hat long sleeves & long trousers, enclosed footwear and a high visibility vest. Some areas may require hearing protection.

Note Eraring Energy will not accept any costs pertaining to attendance of the site inspection.

Site inspection is mandatory. A common Site Inspection will be held for all prospective Tenderers at 10am Wednesday 14th March 2012. Tenderers are to note any special access or other requirements to the Works and allow for this in the Tender. Pre-registration of attendees is recommended by emailing the Contact Officer with the names of those attending at least 24 hours prior to the site inspection.


description: Building and facility maintenance and repair services

title: Glendale High School - Lift Stage 2

currency: AUD

title: 1201616_Specification.pdf

title: 1201616_Appendix_Drawings.zip

title: 1201616_02_tender_schedules.docx

description:
The extent of works for this contract includes but is not limited to:

Install lift shaft, lobbies and lift car.

The works comprise all work shown on the drawings and included in the specification.

addressForLodgement:
Electronically: Via this website

Physical Tender Box Address: Level 2, 117 Bull Street, Newcastle West

Postal Address: PO Box 2297, Dangar NSW 2309

Fax: (02) 4908 4879

submissionMethodDetails:
Tenders are invited from those companies prequalified in Hunter-New England Region for Building Works between the amounts of $250,001 and $500,000.

Degnan Constructions Pty Ltd, Mortdale

Parmenter Jiear Builders Pty Ltd, Belmont

Baxter Building Co (NSW) Pty Ltd, Erina

Paintrite Management Pty Ltd, Dubbo

Tender responses from the above prequalified tendering companies ONLY will be accepted.

OBTAINING RFT DOCUMENTS:

SOFTCOPY DOCUMENT

Only a downloadable SOFTCOPY version of the RFT is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT/EOI and any FUTURE related Amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY link at the bottom of this page and follow the on-screen instructions.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

Your completed Tender response should be lodged as required by the RFT documents.
It can be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.
Electronic Tender Box Security
During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site “electronic tender box”. All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed. This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
A detailed system generated electronic receipt is issued for all responses received successfully.

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

OTHER REQUIREMENTS:

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browsers.

The minimum requirements are as follows - IE version 5.5 or later, Firefox 1.0, Netscape Navigator Ver 4.7 or later with Cipher Strength = 128bit. Suggested minimum monitor resolution is 800x600.

Your web browser MUST be set to accept cookies. You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation: This tender panel was formed on 14/09/2012.


description: Healthcare Services

title: Employee Assistance Program

title: INSTRUCTIONS TO TENDERERS.doc

title: RFT Part 1.DOC

title: RFT Part 2A.DOCX

title: RFT Part 2B.XLS

title: RFT Part 2C.doc

title: RFT Part 3 - Deed Services - Final.doc

AccessEAP

streetAddress: Level 1, 261 George St, Sydney

legalName: Access Programes Aust

name: Converge International is a trading name of ITIM Australia Limited

region: WA

streetAddress: 5 Durley Way, Butler

legalName: Converge International

streetAddress: lvl 3, 44 Market St, Sydney

legalName: Davidson Trahaire Corpsych

Drake WorkWise

streetAddress: Level 13, 77 King Street, Sydney

legalName: Drake WorkWise

Mentor Services

streetAddress: 50 Church St, Wollongong

legalName: Mentor Services

streetAddress: Level 6, 130 Elizabeth St, Sydney

legalName: PPC Worldwide

title: Amendment 1.doc

title: Annual Report ISLHD specific 10-11.doc

rationale: This amendment provides answers to requests for clarification regarding the Specification and requirements for the abovementioned tender.

title: Amendment 2.doc

description: The Purpose of this tender is to locate and contract for the supply of an Employee Assistance Program (EAP) for employees of the Illawarra Shoalhaven Local Health district (ISLHD), their spouses and immediate family as part of the Local Health District (LHD) obligation and commitment to provide a broad range of assistance and support services for employees.

addressForLodgement: Online lodgement only through eTendering


description: Tennis court equipment

title: The License to Manage the Operations at Coleman Park and Smith Park Tennis Courts

title: EOI07-12 Tennis Courts at Coleman and Smith Parks.pdf

title: EOI07-12 Returnable Schedules.doc

Sportsmax Tennis

streetAddress: 109 Arundel Street, Glebe

legalName: Blueglow Pty Ltd

streetAddress: PO Box 346, Panania

legalName: Canterbury Bankstown Tennis Association Inc.

Tennis First Coaching Centre

streetAddress: PO BOX 3291, Bangor

legalName: DI LUCCA, DANIEL

title: EOI07-12 Addendum 1.pdf

rationale:
Addendum 1

See attached.

description:
Council is seeking Expression of Interests (EOI) from suitably qualified and experienced Respondents for licensing the management of operation for either or both Facilities located at:

1.    Coleman Park Tennis Courts, Corner Henry Lawson Drive and Rabaul Road Georges Hall; and

2.    Smith Park Tennis Courts, 2 Lehn Road East Hills.

eTenderProcurementMethod: Expression of Interest For Pre-Qualification


description: Catering services

title: Expression of Interest - Gallery Cafe

title: 17.09 EOI Ultimo Gallery Cafe 2012.pdf

title: 17.09EOI Schedule A.docx

description: Opportunity to establish a Gallery based food and coffee outlet. Stand out from the crowd.

submissionMethodDetails: Closing 2 pm 26 October 2012


description: Residential building construction services

title: LAHC - Construction of 2x2br & 2x3br duplexes at Brewarrina

title: 01 Project Specific Tender Documents-BG642.pdf

title: 02 Standard Tender Documents-BG642.pdf

title: 03 Tender Drawings- Architectural and Survey-BG642.pdf

title: 04 Tender Drawings- Structural Hydraulic and Electrical-BG642.pdf

title: 05 Returnable Tender Form and Schedules-BG642.DOC

as above

streetAddress: PO BOX  710, SPRINGWOOD

legalName: ALPALL p/l BUILDERS

Stanaway Pty Ltd

streetAddress: Douglas Mawson Road, Dubbo

legalName: David Payne Constructions

BDM Constructions

streetAddress: 2/81 High Street, Wauchope

legalName: Magbuild Pty Ltd

streetAddress: Unit B 18-30 Mountbatten Drive, Dubbo

legalName: Murdi Paaki Regional Enterprise Corporation

your id

streetAddress: 78-84 garfield road, horsley park

legalName: rofra p/l

Starjest Constructions

streetAddress: PO Box 1835, Dubbo

legalName: Starjest Pty Ltd

description: Construction of 2x2br & 2x3br duplexes including site works at 115-117 Bathurst St, Brewarrina

addressForLodgement: Electronic tender responses through this site ONLY

submissionMethodDetails:
DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

A passcode (10 alphanumeric character) is required to access the link which has been issued to selected tenderers by letter/email.

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

Steps for submitting your tender:

1.       Click LODGE A RESPONSE and follow the instructions to attach your files for lodgement.

“LODGE A RESPONSE” button appears straight after the publishing at the bottom of RFT under “Participation Instructions” which just below the “DOWNLOAD A SOFTCOPY – Free” button.

“LODGE A RESPONSE” button also appears on the particular RFT advertisement on the “Current Tender List” page a week before the tender closes for tenderer’s quick access.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)


description: Telecom equipment maintenance or support

title: Telecommunications Network Infrastructure Maintenance and Support

title: NSWPF Part A - Conditions of Tender.doc

title: NSWPF Part B - Agreement.doc

title: NSWPF Part C.zip

title: NSWPF Part D - Supplier Response.doc

streetAddress: Level 7, 26 College Street, Darlinghurst

legalName: Communications Design & Management Pty Ltd

NCR

streetAddress: 8-20 Napier Street, North Sydney

legalName: NCR Australia Pty Ltd

NEC Australia

streetAddress: 26 Rodborough Road, Frenchs Forest

legalName: NEC Australia

streetAddress: 28/320 pitt street, sydney

legalName: telstra

title: 2012 LAN WAN Industry Brief Presentation - Final.ppt

format: ppt

rationale: Industry Brief Presentation

title: Addenda 1- RFT29102010 .doc

title: 11.NSWPF Part C Sch 11 - Site Equipment List Updated 21032012- Attachment A.xls

format: xls

rationale: Addenda 1 with updated Site Equipment List

title: Addenda 2 - RFT29102010.doc

rationale: Addenda notifying vendors that the tender close date is now the 11th April 2012

title: Addenda 3 - RFT29102010.doc

title: Addenda 3 - HWInvent.xls

rationale: Addenda 3

title: Confidentiality Deed Poll Agreement.DOC

format: DOC

rationale: Confidentiality Deed Poll Agreement

description:
Request for Tender to engage a vendor to supply Network Infrastructure Maintenance and Monitoring services to the NSWPF.

Services include providing monitoring and maintenance of network infrastructure hardware, software, performance maintenance and monitoring telecommunication services.

addressForLodgement:
New South Wales Police Force

Tender Box

1 Charles Street

Parramatta NSW 2150


title: REQUEST FOR DESIGN & PRICE REVISION - Incident Control Vehicles

amendments: Restricted Tender

description: Restricted Tender


description: Building and Facility Construction and Maintenance Services

title: Taree TAFE: Stage 3 Campus Upgrade – Primary Consultancy Services.

title: 1201802_Taree TAFE.zip

title: 1201802_Taree TAFE_A01.pdf

rationale:
Addendum No.1

Clarifications

description:
NOTE - This is a Selective Tender.

Primary Consultant Services for construction of new and refurbished facilities at Taree TAFE Campus Upgrade Stage 3 including Nursing, Aged care, Electro-technology and Automotive facilities.

Site investigation, design and documentation of detailed construction documents, suitable for use with a GC21 commercial conditions of contract.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Melissa Alt 0434 568 471.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

Brewster Hjorth Pty Limited as the Trustee for Brewster Hjorth Unit Trust t/as Brewster Hjorth Architects, First Floor, 85 Commonweath Street, Sydney NSW 2000

Perumal Pedavoli Pty Ltd, Level 2, 458 Wattle Street, Ultimo NSW 2007

Suters Architects Pty Limited, Suite 2, 19 Harris Street, Pyrmont NSW 2009

Tender responses from the above pre registered tendering companies ONLY will be accepted.


description: Information technology consultation services

title: Development of an iSMART Master Plan

title: Request for Tender - Development of an iSMART Master Plan.zip

title: iSMART Master Plan Tender -  iSMART Strategic Plan.ZIP

title: iSMART Master Plan Tender -  Telemetry Communication.ZIP

title: iSMART Master Plan Tender - Final Design -  Coastal Dams - Control System Upgrade Designs.ZIP

title: iSMART Master Plan Tender - Final Design -  Murrumbidgee Weirs Designs.ZIP

title: iSMART Strategic Plan Project Briefing -  CEO - January 2010.PPT

format: unknown

description:
State Water Corporation has identified the need for a new technology iSMART Master Plan as a fundamental step towards achieving its strategic plan and future operational vision in line with the current technology.

The main objective of this master plan will be to capture the information management strategy that will support the definition of the future operational vision of SWC.

The iSMART Master Plan (to be developed under this engagement) will need to complement the current technological vision that has resulted in the deployment of the very successful iSMART system.

The Consultant is to provide an all encompassing iSMART Master Plan, which will allow SWC to achieve the iSMART Strategic Plan and future operational vision in line with the current technology.

A comprehensive report is to be provided containing the iSMART Master Plan and all aspects relevant to the Master Plan.

timeframeDelivery: 10 weeks from the award of contract.

addressForLodgement: Not applicable.

submissionMethodDetails: None.


title: Griffith Court House Upgrade

description: Restricted Tender


title: Plattsburg Public School - Toilet Conversion

title: 1201819_Specification_Final.pdf

title: 1201819_Tender_Schedules.docx

description:
The extent of works for this contract includes but is not limited to:

Convert existing toilet to disabled toilet.

The works comprise all work shown on the drawings and included in the specification.

submissionMethodDetails:
Tenders are invited from those companies prequalified in Hunter-New England Region for Building Works between the amounts of $50,001 and $100,000.

Ausway Fabrications and Constructions Pty Ltd, Wadalba

MCD Group Pty Ltd, Toronto

DCB Development & Construction Pty Ltd, Warners Bay

Tender responses from the above prequalified tendering companies ONLY will be accepted.

OBTAINING RFT DOCUMENTS:

SOFTCOPY DOCUMENT

Only a downloadable SOFTCOPY version of the RFT is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT/EOI and any FUTURE related Amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY link at the bottom of this page and follow the on-screen instructions.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

Your completed Tender response should be lodged as required by the RFT documents.
It can be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.
Electronic Tender Box Security
During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site “electronic tender box”. All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed. This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
A detailed system generated electronic receipt is issued for all responses received successfully.

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

OTHER REQUIREMENTS:

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browsers.

The minimum requirements are as follows - IE version 5.5 or later, Firefox 1.0, Netscape Navigator Ver 4.7 or later with Cipher Strength = 128bit. Suggested minimum monitor resolution is 800x600.

Your web browser MUST be set to accept cookies. You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation: This tender panel was formed on 10/09/2012.


title: Kingscliff TAFE: Campus Refurbishment.

title: 1201698_V1_Tendering.zip

title: 1201698_V2_SB_SC.zip

title: 1201698_V2_Section D_Appendices_Issue 1.zip

title: 1201698_V3_01_ARCHITECTURAL TENDER ISSUE.zip

title: 1201698_V3_02_STRUCTURAL TENDER ISSUE.zip

title: 1201698_V3_03_05.zip

title: 1201698_V3_06_07.zip

title: 1201698_V3_08_10.zip

title: Kingscliff TAFE 1201698 Addendum No 1 041012.pdf

title: 302471 3 tenderschedules 120910.doc

title: 1201698 Vol 2.zip

title: 1201698 Vol 3.zip

rationale:
Addendum No. 1 consists of:

Clarifications and Additions

title: 1201698_Addendum 2_signed.pdf

title: 1201698_Mechanical Specification_Add2.zip

title: 1201698_Drawings_Add2.zip

rationale:
Addendum No.2

Changes to Specification & Drawings

title: Addendum No. 3 - Contract No. 1201698.pdf

title: Appendices Cover_Issue 03.pdf

title: Hazmat Report Cover and Report for Block B Murwillumbah.pdf

rationale:
Addendum No.3

Changes to Appendices

Hazardous Materials Report for Block B, Murwillumbah Campus

title: 1201698_Addendum No 4.pdf

rationale:
Addendum No.4

Clarifications

description:
NOTE - This is a Selective Tender.

Kingscliff TAFE - New facilities for Automotive & Aboriginal Student Services, refurbishment (part) BL B & C, new car parking and demolition of Building B @ Murwillumbah TAFE.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Julie Paton 0412 178 720.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

ADCO Constructions Pty Ltd, 23 Graham Street, Milton NSW 4064

Glenzeil Pty Ltd, Level 2, 47 Watts Drive, Stephens NSW 4227

Project Co-ordination (Australia) Pty Limited, 2 Lady Penrhyn Drive, Unanderra NSW 2526

TF Woollam & Son Pty Ltd t/as Woollam Constructions, 31 De Havilland Crescent, Ballina NSW 2478

Ware Building Pty Ltd, 9/10 - 1 Sands Street, Tweed Heads NSW 2485

Tender responses from the above pre registered tendering companies ONLY will be accepted.


title: LAHC - Construction of a five bedroom Group Home at Orange

title: Notice to Tenderer COMB 032012NOTGC21.doc

title: 01 Project Specific Documents A-BG8RW.pdf

title: 02 Project Specific Documents-BG8RW.pdf

title: 03 Standard Documents-BG8RW.pdf

title: 04 Architectural Drawings-BG8RW.pdf

title: 05 Consultants Drawings-BG8RW.pdf

title: 06 Consultants Drawings-BG8RW.pdf

title: 07 Returnable Tender Form and Schedules-BG8RW.DOC

streetAddress: Unit 20 133-149 Beauchamp Rd, Matraville

legalName: Buri Building & Design Pty Ltd

streetAddress: 96 Keppell Street, Bathurst

legalName: Hines Constructions Pty Ltd

streetAddress: 16 Nicholson Street, Kempsey

legalName: Lahey Constructions

title: BG8RW -Tender Addendum No 1.pdf

title: BG8RW - Tender Addendum No 1 - Minutes of pre tender telephone meeting - 20120927.pdf

title: BG8RW- Tender Addendum No 1 - Q and A.pdf

rationale: Minutes of Pre tender telephone meeting and Q & A

description: Construction of a five bedroom group home and associated external works for Ageing, Disability & Home Care at 46 Bletchington St, Orange


description: Fencing

title: Cooling Water Canal Safety Fencing Replacement

description: Location of Site The Site is located within the grounds of Eraring Energy's Eraring Power Station. Eraring Power Station is located off the Sydney- Newcastle Expressway (F3), between Morisset and Toronto, near Dora Creek, approximately 150 km north of Sydney, 2264 New South Wales. Site inspection is mandatory. A common Site Inspection will be held for all prospective Tenderers at 10am Wednesday 21st November 2012 departing from Eraring Power Station, Main Entrance. Any special access or other requirements to the Works shall be noted and shall be allowed for in the Tender. Further details regarding this Site Inspection shall be obtained by contacting the Contact Officer. Note Eraring Energy will not accept any costs pertaining to attendance of the site inspection. Name(s) of those attending should be forwarded to the Contact Officer at least 24 hours prior to the site inspection to enable arrangements to be made. Visitors to Eraring Energy power station sites are required to wear safety eyewear, hard hat long sleeves & long trousers, enclosed footwear and a high visibility vest. Some areas may require hearing protection

submissionMethodDetails: Eraring Energy utilises response software to assist with evaluation and probity of Tenders. Tenderers must register and respond in Eraring Energy's e-Tendering website http://360prop3.apetsoftware.com.au/Public/04/PublicJobs.aspx


description: Environmental planning

title: Planning & Assessment Services, Lord Howe Island Board

title: Part A Planning and Assessment Services Contract 061112.pdf

title: Part B Planning and Assessment Service Contract 061112.pdf

title: LHIB Model Code of Conduct 092009.pdf

All About Planning

streetAddress: 14 Cross Street, Port Macquarie

legalName: All About Planning Pty Ltd

Aurecon

streetAddress: 116 Military Road, Neutral Bay

legalName: Aurecon Australia Pty Ltd

de Witt Consulting

streetAddress: 7 Canberra Street, Charlestown

legalName: Bernie de Witt Consulting Pty Ltd

Blueprint Planning Consultants

streetAddress: 6 Braeroy Drive, Port Macquarie

legalName: Blueprint Planning Consultants

streetAddress: level 1 364, Kent Street, Sydney

legalName: city plan strategy and development pty ltd

streetAddress: 11, dartford road, thornleigh

legalName: don fox planning

Burton Environmental Consulting

streetAddress: 12 Caravan Head Road, Oyster Bay

legalName: Envirok

streetAddress: 23 Gordon St, Coffs Harbour

legalName: GeoLINK Consulting Pty Ltd

streetAddress: 230 Harbour Drive, Coffs Harbour

legalName: GHD Pty Ltd

streetAddress: Level 10, 133 Mary Street, Brisbane

legalName: Harrison Grierson Consultants Pty Limited

streetAddress: L 3 75 Elizabeth Street, Sydney

legalName: HOADLEY BUDGE OLPHERT & EDWARDS MADIGAN TORZILLO BRIGGS (AUSTRALIA) PTY. Limited.

KI STUDIO Pty Ltd

streetAddress: The Cooperage, Studio 303, 56 Bowman Street, Pyrmont

legalName: KI STUDIO Pty Ltd

md Planning Group

streetAddress: 2 Glenview Street, Greenwich

legalName: Laima Pty Ltd

streetAddress: Level 1, 34 hunter st, Sydney

legalName: MacroPlan Dimasi

streetAddress: PO Box 726, Newcastle

legalName: Monteath and Powys

streetAddress: 2-24 Rawson Place, Sydney

legalName: NSW Public Works

streetAddress: 1/16-22 Willock Avenue, Miranda

legalName: Planning Ingenuity

streetAddress: Cnr Lord an Burrawan streets, Port Macquarie

legalName: Port Macquarie-Hastings Council

RPS

streetAddress: Suite 17C, Level 2, Cnr Brunswick & Martin Streets, Fortitude Valley

legalName: RPS Australia East Pty Ltd

streetAddress: GPO Box 4507, Sydney

legalName: Urban Perspectives Environmental Solutions Pty Ltd

streetAddress: 103/155 Avoca St, Randwick

legalName: Willana Associates Pty Ltd

description: The Lord Howe Island Board is seeking tenders from appropriately qualified persons to provide planning and assessment services, in its capacity as alocal government authority, and a consent authority under the Environmental Planning & Assessment Act 1979.

Lord Howe Island Board

name: Dave Kelly - LHIB Manager Environment & Community Development

addressForLodgement: OEH eTender Website at: https://tenders.nsw.gov.au/oeh/

submissionMethodDetails:
Please dial ext 18 if you need to contact the Officer for this Tender.

02 6563-2066 - ext 18


description: Public Utilities and Public Sector Related Services

title: Airds Bradbury public private partnership–industry engagement & feedback period

title: Airds Bradbury information document.pdf

title: Figure3.jpg

title: Notice No2- Airds Bradbury update.pdf

rationale:
Notice No.2
This is an update on the industry engagement process for the Airds Bradbury public private partnership.

title: Airds Bradbury PPP industry briefing presentation.pdf

rationale:
Notice No.1
Industry Briefing Presentation

tenderType: Notice

description:
                             THIS IS NOT A TENDER

This is a Notice to Industry for an opportunity  to provide feedback before the proposed Expression of Interest process for this project proceeds.

PROJECT DESCRIPTION
The Airds Bradbury Renewal Project (the Project) involves the comprehensive renewal of the Airds Bradbury social housing estate (the Estate).
The Project will be jointly procured by Department of Finance and Services (DFS) and Housing NSW (the Agencies).
DFS is managing the Project on behalf of the Agencies.

The Estate currently comprises approximately 1470 social housing dwellings (94%) and approximately 90 private dwellings (6%). The site is located approximately fifty kilometres south-west of the Sydney CBD and is situated within the Campbelltown local government area.
The proposed concept plan increases the total dwellings to 2100 of which 30% will be social housing dwellings and 70% private dwellings.

The Project is an exciting opportunity for a private partner to:

·  sell approximately 525 existing dwellings, refurbished as necessary, to private buyers

·  develop approximately 325 new dwellings for social housing

·  develop approximately 855 new dwellings for purchase by private buyers

·  acquire (or develop) in the local and surrounding areas approximately 840 dwellings off-estate for social housing purposes

·  provide community building, consultation and communication services

provide tenancy, facilities management, social and support services to social housing tenants.

Before inviting expressions of interest, the Agencies wish to engage with industry and seek feedback. The purpose of the industry engagement and feedback period is to:

·  provide general information about the Project and increase awareness

·  set out details for the engagement process and identify areas in relation to which the Agencies would like to receive views from the industry

·  set out details for the procurement process.

The Agencies have prepared an information document (available to download) that outlines the project, information about possible commercial structures and key challenges along with information about the procurement process including the details about the industry briefing, how interested participants can provide their feedback and/or meet with project representatives, the proposed EOI process and consortium formation.

timeframeDelivery:
Any resulting PPP contract is likely to be for a period of about 30 years with development services over a 15-year period and the other services for a further 15 years.
Feedback is sought from industry as to the optimal term for the agreement.

submissionMethodDetails:
Briefing Session
Interested participants are invited to a briefing session.
At the briefing interested participants will meet the key team members and have the opportunity to ask questions.
See the information document for details.

OBTAINING THE DOCUMENTS:
Only a downloadable SOFTCOPY version is available.
No CD or Hardcopy available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

PC SOFTWAER REQUIREMENTS:
To be able to open and read or view the downloaded files for this RFT you may require certain software listed below to be installed on your PC:

· Adobe Acrobat Reader  5.0 (or more recent).  Free trial version is available from Adobe web site.
· WinZip 7.0 (or more recent) or equivalent.  Please click here http://www.winzip.com/ WinZip to be taken to a free evaluation download site now.

Additional software which may also be required, including the following, depending on the file types provided:

*  Microsoft  Word 2003
*  Microsoft  Excel 2003

Other requirements:
**  An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browsers.

The minimum requirements are as follows - IE version 5.5 or later, Firefox 1.0, Netscape Navigator Ver 4.7 or later with Cipher Strength = 128bit. Suggested minimum monitor resolution is 800x600.

Your web browser MUST be set to accept cookies. You will not be able to Register or access the documents if cookies have not allowed.

The Tenderer is responsible for the provision and installation of the necessary software.

Having Problems?
Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ section under the On-line ?HELP button in the tool bar at the top of this page.

eTenderProcurementMethod: Notice


description: Marine construction services

title: Expression of Interest for Design & Construct engagement for Burrendong Dam Floating Curtain

title: EOI - D_C engagement for Burrendong Dam Floating Curtain.pdf

title: Returnable Schedules - Design and Construct engagement for Burrendong Dam Floating Curtain.DOC

title: Addendum__Notice No.1.pdf

title: Appendix A - Intake Tower Photos.pdf

rationale: Please find the attached Addendum No. 1 - Appendix A: Intake Tower Photos as mntioned in the EOI document.

description:
Pre-qualifying potential Contractors for  a design and construct engagement to fabricate and install an innovative floating curtain solution to curb "Cold Water Pollution" for the releases into the Macquarie River. Tenders will be invited from the pre-qualified Contractors, following an Early Tenderers Involvement process to deliver the following scope:

design, and install a water quality monitoring system in the storage around the intake tower;

review and modify the concept design of the floating curtain system developed by AMOG;

identify and undertake gap investigations optimising the curtain system to mitigate Cold Water Pollution and algal issues:

detail design, fabricate, install and commission the floating curtain system, ancillary maintenance equipment  in compliance with environmental and WHS requirements;

monitor the water quality and make necessary adjustments to the floating curtain system.

timeframeDelivery: 50 Weeks

addressForLodgement: eTendering only

submissionMethodDetails: This is an Expression of Interest to pre-qualify potential Contractors.

conditionsForParticipation: Potential Contractors shall be willing to participate in the Early Tenderer Process


title: Richmond River HS - Art Unit Upgrade

title: RFT1202249 Tender Schedules.doc

title: RFT1202249 Tender Doc.pdf

title: RFT1202249 Attachments.zip

title: RFT1202249 Addendum01.pdf

rationale:
Addendum No.1

Addendum No.1 consisting of 1 page (including this page) is part of the Tender Documents

description: Install a new wall to BR1019 to create a corridor and remove wall between BR1019 & BR1020 and between BR1020 & BR1021 to create a function GLS Type 4.  Re-furbish BR1005 & BR1004 and convert from old science room into a compliant visual arts Learning Space.

addressForLodgement:
Hard Copy Submissions to : NSW Public Works, TENDER BOX, 120 Dalley Street, Lismore 2480

Facsimile Submissions to : NSW Public Works TENDER FAX NUMBER (02) 6626 5690

Electronic Submissions ONLY via NSW Government eTendering website :https://tenders.nsw.gov.au

conditionsForParticipation:
Tenders will be considered from the following tenderers ONLY -

Hucks Pty Ltd

Farpoint Pty Ltd

Ross Binney Pty Ltd

Sibtex Pty Ltd


title: Illawarra Partners in Education Trade Training Centres

title: Tender schedules.doc

title: Volume1.pdf

title: Volume2.pdf

title: Volume3.pdf

title: Volume4.pdf

streetAddress: 8A Commerce Drive, Warilla

legalName: Camarda & Cantrill Pty Ltd

streetAddress: 125-127 Woodpark Road, Smithfield

streetAddress: 74 Anderson Road, Mortdale

legalName: Degnan Constructions Pty Ltd

streetAddress: 57 Beach Road, Batemans Bay

legalName: Edwards Constructions (NSW) Pty. Limited

streetAddress: 2 Lady Penrhyn Drive, Unanderra

title: Addendum3.pdf

rationale:
Addendum 3 -
Extend closing date to 9:30am 31st January 2012,

Inclusions to tender document

Please delete references to smoke/thermal detectors for each of the schools.

title: 1101887_iPie Addendum1.zip

rationale: Addendum 1 - Tender period extended to 9.30 am Tuesday 24 January 2012 and document inclusions.

rationale: Extend closing date to 9:30am 24 January 2012 (Addendum 1)

title: Addendum2.pdf

rationale: Addendum 2 - Revised Drawings and Specification

description:
THIS IS NOT A OPEN TENDER

Figtree High School

Refurbishment of existing Block D for the Provision of a Hospitality Trade Training Centre (TTC).

Refurbishment of existing Block M for the Provision of a Metals TTC.

Illawarra Sports High School

Demolition of existing Block J facility as specified

Construction of a new Metals TTC

Warrawong High School

Refurbishment of existing Block F for the Provision of a Hospitality TTC.

Refurbishment of existing Block D for the Provision of a Wood Workshop TTC.

addressForLodgement: As stated in the tender documents

submissionMethodDetails:
Non-mandatory meeting to be held in December 2011 - date TBA

Access restricted to the operational school. Refer to conditions of tendering for gaining access to the school.

OBTAINING the RFT.
The Selective Tenderers can download a copy of the RFT from this Web Site.
To download click on the DOWNLOAD A SOFT COPY - free link at the bottom of this page & follow the on screen instructions.

Selective Tenderers requiring additional hard copies, and Potential Sub Contractors and Suppliers wanting to obtain the RFT may order a hardcopy of this RFT from:

·  This Web Site - To order click on the ORDER CD/HARD COPY link & follow the on screen instructions to receive the RFT in hard copy by post to the address that you are registered with on this site. Payment will be required by credit card.

An exhibited copy of the RFT can be viewed by prior appointment with the contact officer

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site. .
You must be a registered user in order to submit a response.

Click on the LODGE A RESPONSE link at the bottom of this page and follow the on-screen instructions.

Electronic Tender Box
During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.
All responses that are received successfully can only be accessed, decrypted, retrieved and opened after the RFT has officially closed by a controlled process.

RFT Response - receipt/confirmation
A detailed system generated electronic receipt is issued to the respondent for all submitted responses files received successfully.

PC Software Requirements:
To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·  Adobe - Acrobat Reader - 5.0 (or more recent) - Please click here
Adobe  Acrobat Reader to be taken to a free download site now.

·  WinZip ®  7.0 (or more recent) or equivalent - Please click here
WinZip to be taken to a free evaluation download site now.

Additional software may also be required, including the following, depending on the file types provided:

·    Microsoft - Word 2003 (or more recent) or equivalent

·    Microsoft - Excel 2003 (or more recent) or equivalent

Other requirements:

·  An Internet connection to lodge completed responses.

·  This web site has been optimised for the Microsoft Internet Explorer and Netscape Navigator web browsers.

The minimum requirements are as follows : IE version 5.5 or later, Netscape Navigator Ver 4.7 or later with Cipher Strength = 128bit.

The tenderer is responsible for the provision and installation of the necessary software.

Still having Problems?
Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ”   section under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
Tender responses will ONLY be considered  from the below listed invited firms;

·  Edwards Constructions (NSW) Pty.Limited 57 Beach Road BATEMANS BAY, NSW 2536

·  Project Co-ordination (Australia) Pty Limited 2 Lady Penrhyn Drive UNANDERRA, NSW 2526

·  Camarda & Cantrill Pty Ltd 8A Commerce Drive WARILLA, NSW 2528

·  Commercial Industrial Contractors (NSW) Pty Limited 125-127 Woodpark Road SMITHFIELD, NSW 2164

·  Degnan Constructions Pty Ltd 74 Anderson Road MORTDALE, NSW 2223


description: Medical Equipment and Accessories and Supplies

title: Discount Price Revision - Standing Offer Agreement - Nuclear Medicine

title: Vendor Disc PR Website Letter.docx

description: As per Clause 3.6.2, Part D, the Principal may at any time during the Standing Offer Agreement, request submission of bulk purchase discounts and other discounts, and if accepted by the Principal, the Standing Offer Agreement will be varied accordingly.


title: Northern Sydney Institute of TAFE

description:
Northern Sydney Institute - MEADOWBANK COLLEGE  OF TAFE - VARIOUS TOILET UPGRADES. Contract No: DETNS/11012

Tenders are invited for the refurbishment and upgrade of Toilet Areas in Buildings D, G and V at Meadowbank College of TAFE.

To obtain further details and to obtain the tender documents, contact Mark Weekes on 9472 1335 or 0425 256 169.

Tender documents are only available from the Asset Management Unit, Room DLG07, Building D, Hornsby College, 205 Pacific Highway, Hornsby between the hours of 9.00am and 4:00pm Monday to Friday. A fee of $120 (cheque, Eftpos or credit card) is payable on collection of the tender documents.

Tenders close:  2:00pm Tuesday 7th February 2012.

addressForLodgement:
Tenders close:  2:00pm Tuesday 7th February 2012.

Tenders must be submitted in the Tender Box at:

Asset Management Unit

Room DLG07, Ground Level Building D

Hornsby College

205 Pacific Highway, Hornsby NSW


description: Building and Facility Construction and Maintenance Services

title: Lithgow High School - Lift & Ramp to Block B

title: Contract Documentation.pdf

title: Technical Spec.pdf

title: Drawings.ZIP

title: Tender Schedules.doc

title: Addendum 1.pdf

title: Amended Ramp Drawings A1 and S1.pdf

title: Amended Schedule 2.doc

rationale:
Addendum 1 is now available to download.  It contains:

Amended Ramp Drawings A1 and S1

Replacement Tender Schedule

Clarification on various scope items

description: Works include, but not limited to the modification of specific portions of the existing building (Block B) to provide lift access to upper floors and modification of the existing western first floor access way to provide ramp access to the first floor.

timeframeDelivery: 17 weeks

submissionMethodDetails:
OBTAINING RFT DOCUMENTS

First time visitors to this website who wish to obtain a copy of the RFT will need to self-register on this website to gain access to any documents.

To obtain the RFT/EOI and any future amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY – Free link at the bottom of this page and follow the on-screen instructions.

REGISTER FOR FREE NOTIFICATIONS

Potential tenderers are encouraged to register with the NSW eTendering system to receive email notifications or new relevant business opportunities.

New users can register by selecting the register link on the top left toolbar.  When registering, please select all relevant business categories to ensure you receive the appropriate notifications.

DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document(s) and returnable schedules is available for downloading by following the instructions below.  Hardcopies of the RFT document will be available at a charge determined by the size of the document, arrange via “Contact Person” listed in the RFT Full Details.

An EXHIBITED HARDCOPY of this RFT is available for public viewing at NSW Public Works, Level 2, 140 William Street, Bathurst NSW during normal business hours.

LODGING A RESPONSE

Your completed response should be lodged as required by the RFT documents.  It can be lodged electronically via this web page.

During the lodgement process all responses are encrypted for security.  Any responses that are received can only be accessed, decrypted and opened after the RFT has officially closed.

A system generated electronic receipt is issued to the submitter for each response transmitted successfully.

PC SOFTWARE REQUIREMENTS

To be able to open and read or view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader  5.0 (or more recent)

WinZip 7.0 (or more recent) or equivalent

Additional software may also be required, including the following, depending on the file types provided:

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

Other requirements

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browser.

Cookies

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

HAVING PROBLEMS?

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ” section under the On-line ?HELP button at the top of this page.