title: Master Services Agreement (MSA) – Major Periodic Refresh tender (2022)

description:
Sydney Trains is seeking responses from experienced, suitably qualified suppliers who have a demonstrative ability to meet the requirements across Geotechnical, Signalling and Electrical disciplines as set out in this tender.

The Major Works (MW) Master Services Agreement (MSA) is established to facilitate the engagement of pre-qualified contractors by Sydney Trains (ST) to deliver periodic maintenance services.

Sydney Trains is seeking qualified tenderers to participate in the Major Periodic Refresh to be considered as a potential Contractor under the following MSA categories:

1. Geotech discipline

1.1. Tender Name: MSA Major Periodic Refresh Tender 2022 – Geotech Devegetation

Description: Geotechnical Works - Devegetation and Rock removal panel

To qualify for this discipline, the tenderer must meet the following three Geotechnical qualifications but not limited to:

1.1.1. Rope Access Operators (RAO)

1.1.2. Working at Heights (WAH)

1.1.3. ChemCert AQF 3

1.2. Tender name: MSA Major Periodic

Refresh Tender 2022 – Geotech Rockfall Description: Geotechnical Works - Rockfall protection and Rockbolting panel

To qualify for this discipline, the tenderer must meet the following two Geotechnical qualifications but not limited to:

1.2.1. Rope Access Operators (RAO)

1.2.2. Working at Heights (WAH)

2.Signalling discipline

Tender name: MSA Major Periodic Refresh Tender 2022 – Signalling

2.1. Train stops panel

2.2. Track Circuits panel

2.3. Signal maintenance panel

3.Electrical discipline

Tender name: MSA Major Periodic Refresh Tender 2022 – Electrical

3.1. OHW Adjustments panel

3.2. Supplementary crews panel

To qualify for this discipline, the tenderer must have the following three Electrical qualifications:

3.2.1. MEL 53 Accredited OHW Worker

3.2.2. MEL 55 Accredited OHW Assembler

3.2.3. MEL 56 Accredited Aerial line worker

submissionMethodDetails:
In order to gain access to the Request for Tender documents, Tenderers are required to register their interest by sending an email to tss.bidder@transport.nsw.gov.au and include the following information:

1) Tender No and Title (e.g. 1. Geotech, 2. Signalling, 3. Electrical), 2) RFT  ID , 3) Organisation Name, 4) ACN/ ABN, 5) Contact Name, 6) Organisation/Contact Postal Address, 7) Contact Email Address (preferably an email address with the contact person's name), 8) Contact Phone number

To gain access to the tender documents in Ariba over the internet once access is provided, please ensure that you are using PC with web browser:

• Google Chrome 54+ (64 –bit)

• Microsoft Internet Explorer 7-11(32-bit)

• Mozilla Firefox 24 or 27(ESR)

• Safari 9+ (64-bit)

• Microsoft Edge (32-bit)

conditionsForParticipation: As detailed in tender documentation


scheme: UNSPSC

description: Management and Business Professionals and Administrative Services

title: More Trains More Services Stage 2 and Stage 3A - Signalling Construction Manager

status: complete

RFTAccess: Open

title: IPD-22-12938 MTMS 2 and 3A Signalling Construction Manager Confidentiality Deed Poll.pdf

format: application/pdf

documentType: tenderNotice

title: IPD-22-12938 MTMS 2 and 3A Signalling Construction Manager ITT.pdf

title: IPD-22-12938 MTMS 2 and 3A Signalling Construction Manager Tender Schedules.docx

tenderType: Open Tenders

description:
Transport for NSW (TfNSW) is seeking to engage an experienced and capable Professional Services Contractor to provide Signalling Construction Manager Services for the More Trains More Services Stage 2 and Stage 3A Projects.

The Signalling Construction Manager is required to be a licensed Signal Engineer under the ASA signalling competency standards and must be able to issue Signalling Permit to Work.  The Signalling Construction Manager will be accountable for providing TfNSW staff and contractors expert advice, leadership and direction for signalling and commissioning activities.

eTenderStatus: published

inheritanceType: RFT

scheme: xNSWRegions

Identifiers:
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney

submissionMethod: written ElectronicSubmission

procurementMethod: open

addressForLodgement: Tenders must be lodged electronically via the eTendering website.

submissionMethodDetails: Interested parties must complete and submit the Confidentiality Deed Poll via email to the Contact Officer. Only organisations deemed to be a bona fide Tenderer will be provided access to the tender documents.

eTenderProcurementMethod: Open Tenders

conditionsForParticipation:
Tenderers must submit their response as two (2) separate files only. The first is to consist of the completed "Non-Commercial Schedules" and is to exclude any reference to pricing. The second file is to consist of the completed "Commercial Schedules". Multiple separated documents will not be accepted, unless you obtain prior approval from TfNSW.

This ensures that Tenders are complete and accurate, are presented in the manner intended by the Tenderer, and allows for timely distribution of Tenders to the Tender Assessment Committee.

initiationType: tender


items: Restricted Tender

title: Content Management System (CMS)

status: Restricted Tender

RFTAccess: Restricted Tender

amendments: Restricted Tender

tenderType: Restricted Tender

description: Restricted Tender

tenderPeriod: Restricted Tender

eTenderStatus: Restricted Tender

inheritanceType: Restricted Tender

deliveryLocation: Restricted Tender

submissionMethod: Restricted Tender

multiAgencyAccess: Restricted Tender

procurementMethod: Restricted Tender

timeframeDelivery: Restricted Tender

coveredProcurement: Restricted Tender

addressForLodgement: Restricted Tender

submissionMethodDetails: Restricted Tender

eTenderProcurementMethod: Restricted Tender

conditionsForParticipation: Restricted Tender


description: Landscaping services

title: Great Western Highway Upgrade Program: Railway Parade Medlow Bath Landscaping

title: GWHUP Railway Parade Landscaping RFT Docs.zip

format: zip

region: NSW

countryName: AUSTRALIA

streetAddress: Suite 1A, Level 2, 802 Pacific Highway, Gordon

legalName: Axial Construction Pty Ltd

streetAddress: 2 Lillian Crescent, Schofields

legalName: MB Landscaping Pty Ltd

Daracon Landscaping

streetAddress: 20 Kullara Close, Beresfield

legalName: Paramount Landscaping Pty Ltd

streetAddress: 2/30 Park Road, Mulgrave

legalName: Regal Innovations Pty Ltd

title: 21.0000139266.0372 GWHUP Railway Parade Verge Planting - RFT Addendum 1.pdf

format: pdf

documentType: amendments

title: A-01.zip

rationale:
Addendum 1

This addendum is issued for the Request for Tender (RFT) for the proposed Minor Physical Works and Services (Contract) as part of the Landscaping Works on Railyway Parade for the Great Western Highway Upgrade Program. This addendum is and shall be read and construed as part of the said RFT and Attachments to the RFT.

description:
Transport for NSW (TfNSW) invites Tenders for landscaping works along Railway Parade in Medlow Bath as part of Great Western Highway Upgrade Program.

The work includes clearing, grubbing and cultivation followed by installation and maintenance of screening trees, shrubs and turf.

A pre-tender site inspection will be held at 11am on 2 June 2022 at Railway Parade Medlow Bath. Attendance is mandatory to submit a conforming tender.

All tenderers must comply with the NSW Government Procurement Policy Framework (NSW Framework), NSW Government Supplier Code of Conduct (NSW Code) and New South Wales Industrial Relations Guidelines: Building and Construction Procurement (NSW Guidelines).

Copies of the NSW Framework and NSW Code are available at www.buy.nsw.gov.au. The NSW Guidelines are available at www.industrialrelations.nsw.gov.au.

This project is jointly funded by the Australian Government.

The Code for the Tendering and Performance of Building Work 2016 applies to this project. This document is available at https://www.legislation.gov.au/Details/F2019C00289. By submitting an ROI for this project you will become subject to the Code for the Tendering and Performance of Building Work 2016.

name: Transport for NSW (Transport Infrastructure Projects)

addressForLodgement: Electronic lodgement only.


description: Data services

title: Request for Proposal for Provision of Mobility Data for TfNSW

rationale: As per Preets email on 28/11/2022 requests to change description

rationale: Amend email address

title: WS3681525690  - Provision of Mobility Data for TfNSW - Addendum No. 3.pdf

rationale: Extending end date and add addendum

description:
Transport for NSW (TfNSW) invites innovative and suitably experienced organisations who have access to multiple mobility data sources within NSW to participate in a request for proposal to supply anonymised location-based mobility data across the three (3) streams listed below:
1. Mobile phone apps and telco-based data
2. Vehicle location telemetry data (including Connected Vehicles IoT data)
3. Mobility as a service/Point 2 Point Provider Data

Mobility data refers to collected data of activities, events, and transactions through devices or services that track real-time mobility. This data is recorded through points of spatial location (latitude and longitude) over a period. Essentially, mobility data is a key source of insights and information for TfNSW Operations, Strategy and Planning.

TfNSW places a high value on data to understand patronage trends in the network, meet transport demands and deliver a positive customer experience.

The solution for mobility data platform for TfNSW must have multiple data sources to gain access and insights to data within NSW to support the initiatives of TfNSW Future Transport Strategy.

All applicants must comply with the NSW Government Policy Framework, available at: Procurement Policy Framework.

Note: Participants are requested to submit their expression of interest via Ariba Portal.

Without any obligation to do so, where the integrity of the tender process is not compromised, TfNSW may determine (at its discretion) that it is appropriate to consider a late tender submission.

Identifiers:
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

addressForLodgement:
Once registered, proposals must be lodged electronically via TfNSW's equip supplier portal (Ariba).

https://supplierportal.erp.transport.nsw.gov.au

login details will be provided upon registration

submissionMethodDetails:
Additional details/Instructions: (For ARIBA tenders only)
 In order to gain access to the Request for Tender documents, Tenderers are required to register their interest by sending an email: TSS.Bidder@transport.nsw.gov.au and include the following:
1) Tender No and Title, 2) RFT ID, 3) Organisation Name, 4) ACN/ABN, 5) Contact Name, 6) Organisation/contact postal address, 7) Contact email address (preferably an email address with the contact person's name), 8) Contact phone number.

To gain access to the tender documents in Ariba over the internet once access is provided, please ensure that you are using PC with web browser:

There are no files to be downloaded from this website. All documents/information relevant to this project must be obtained via TfNSW's equip supplier portal (Ariba).
• Google Chrome 54+ (64 –bit)
• Microsoft Internet Explorer 7-11(32-bit)
• Mozilla Firefox 24 or 27(ESR)
• Safari 9+ (64-bit)
• Microsoft Edge (32-bit)

Note:

In addition, if your organisation is awarded a contract as the result of this procurement, your organisation must be an approved advanced NSW ICT services provider to contract with TfNSW. TfNSW recommends the Proponents to start the registration process as soon as possible using the following link below and click “How to apply”. It takes 4-6 weeks to complete the registration.

https://buy.nsw.gov.au/schemes/ict-services-scheme


description: Building and Facility Construction and Maintenance Services

title: Jane Street / Mulgoa Road Stage 2 Carpark & Safety Works

title: Final RFT Documents.zip

title: Drawings.zip

title: Specifications.zip

Athassel Civil Pty Ltd

streetAddress: 24 Hewlett St, Bronte

legalName: Athassel Civil Pty Ltd

CA&I Pty Ltd

streetAddress: 10 Regent Street, Chippendale, Sydney

legalName: CA&I Pty Ltd

streetAddress: 24 Boronia Road, Glenorie

legalName: D.S.A. Contracting Pty Ltd

streetAddress: 142 Sunnyholt Road, Blacktown

legalName: Devcon Civil Pty Ltd

streetAddress: 1/15 Blackmore Road, Smeaton Grange

legalName: Menai Civil Contractors Pty Ltd

Milestone Civil Australia

streetAddress: 30/15-23 Kumulla Road, Miranda

legalName: Milestone Construction Group Pty Ltd

North Shore Paving Co Pty Ltd

streetAddress: 16 Moore Avenue, Lindfield West

legalName: North Shore Paving Co Pty Ltd

streetAddress: 20B/1 Maitland Place, Baulkham Hills

legalName: SD Civil Engineering Pty Ltd

streetAddress: Suite 101, 35 Spring Street, Bondi Junction

legalName: Vaughan Civil Pty Ltd

title: Addendum 6 Letter.pdf

rationale: Published Addendum 6

title: Addendum 7.zip

rationale: Published Addendum 7

title: Addendum 2.zip

rationale: Published Addendum 2

title: Addendum 3.zip

rationale: Published Addendum 3

title: Addendum 1.zip

rationale: Issued Addendum 1

title: Addendum 4.zip

rationale: Published Addendum 4

title: Addendum 5.zip

rationale: Published Addendum 5

description:
Tenders are being sought from Contractors who are Prequalified with TfNSW to R2 and F5.

The works for the construction of the Stage 2 Car Park include:

Earthworks; Stormwater drainage; Kerb and gutter;

Pavement works; Signposting; Line marking; Footpaths;

Lighting; CCTV; Modular wall; Landscaping; Fencing.

The Contract will also include the following minor safety works:

Pavement rectification; Minor drainage works; Fencing;

Minor footpath and kerb rectification; Installation of

safety devices including handrails and bus stop

tactile indicators.

A Mandatory site inspection will be held at 10:30 am on 28 January 2022 at the Council car park behind the tennis courts at the intersection of Mulgoa Rd and Jane St, Penrith.

addressForLodgement: Electronic lodgements only


title: Establishment of a Panel of Business Mentor Consultants

title: Invitation to Request for Proposal.docx

tenderType: Request for Proposals

Identifiers:
ACT
NT
QLD
SA
TAS
VIC
WA
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

procurementMethod: selective

multiAgencyAccessType: All Agencies

submissionMethodDetails:
Proposal documents must be accessed and submissions lodged online at

https://360providers.apetsoftware.com.au/request/open/BMCCPro3(“Electronic Tender Box)

eTenderProcurementMethod: Request for Proposals

conditionsForParticipation:
The Conditions for Participation are mandatory requirements, which describe minimum standards that Suppliers must meet for their Quotes to be considered. If Suppliers do not meet the Conditions of Participation, they will be excluded from the evaluation process.

The Conditions for Participation are:

·          Suppliers must be an acceptable legal entity. It is Council’s policy not to trade with any organisation that does not hold a registered ABN;

·          Suppliers must not be bankrupt or insolvent;

·          Suppliers must declare and provide details of any occurrence, within 5 years prior to submitting a Quote, where the Supplier has been found guilty of breaching any Act or Regulation.

·          Suppliers must have the minimum level of insurance cover specified in the Contract; and

·          Suppliers must comply with the New South Wales Government Code of Procurement.


description: Information Technology Broadcasting and Telecommunications

title: Website

title: Website_RFQ Part A - Introduction and Description of the Requirement_V6.docx

title: Website_RFQ Part B - Conditions of Quotation.docx

title: Website_RFQ Part C - Quotation.docx

title: Website_RFQ Part E - Dictionary.docx

title: Website_RFQ Part A - Attachment 1 - Technical Requirements v6.xlsx

title: Website_RFQ Part A - Attachment 2 - Solution design and integration approach.pdf

title: Addendum 4 - Website Build.pdf

rationale: Addendum 4 - Website Build

title: Attachment 2 - High level solution design and integration approach.pptx

format: pptx

title: eTendering Addendum 2.doc

format: doc

title: Legal Aid NSW - Website Governance Roles.pptx

title: Website RFQ Vendor Briefingv1.pptx

rationale:
1. High Level interation approach - Attachement 2

2. Addendum 2

3. Website Governance Roles

4. RFQ Website Vendor Briefing

title: eTendering Addendum v2.docx

format: docx

rationale: Addendum 1 - Website Build

title: Addendum 3 - Website Build.pdf

rationale: Addendum 3 - Website Build

description: Legal Aid NSW is seeking a vendor to build the new website, train and support users in managing the new website and the use of Adobe Experience Manager, and to provide ongoing support and maintenance for the website. Migration of data/content from the two legacy websites is not included in the scope of this RFQ.

coveredProcurement: Y

submissionMethodDetails:
Legal Aid NSW has procured Adobe Experience Manager as the Content management System for the new website.

The engagement must commence before 30 June 2022 and we anticipate a go live date within 28 weeks from commencement.


description: Sale of commercial or industrial land

title: Expressions of Interest - Light Industrial Lots - Munibung Road, Cockle Creek

RFTAccess: Restricted - Public View Detailed

title: Light Industrial Sites Cockle Creek - Expression of Interest.pdf

rationale: Updated contact details and provide passcode

description:
HCCDC is calling for Expressions of Interest for the sale and development of two light industrial sites at Cockle Creek.

The lots are approximately 2ha and 4ha and located on Munibung Road, adjacent to the Cardiff Industrial Area, in Lake Macquarie City Council area. HCCDC are seeking uses which generate employment, involve new technology or support the government's Net Zero Plan.

name: Hunter Central Coast Development Corporation

submissionMethodDetails:
The passcode required to access the documents and to respond to this EOI is:

J2ZafpYMwQ

Colliers are appointed as sales agents and can be contacted through:

Trent Robertson, National Director Industrial - M: 0401 717 795, or E: trent.robertson@colliers.com

Peter Macadam, National Director Investment Services - M: 0402 074 159 or E: peter.macadam@colliers.com


description: Occupational health or safety services

title: Request for Proposal-Occupational Hygiene Services Panel

rationale: Adding additional comments

description:
TfNSW is seeking to establish a Panel of suppliers to undertake a range of occupational hygiene Services.

TfNSW aims to prevent occupational illness and disease by promoting and preserving the health of workers through the development and implementation of a best practice fit for purpose approach.

TfNSW is committed to maintaining the health and safety of its workers, contractors, visitors, and members of the public through the effective management of occupational hygiene. This commitment includes minimising workplace exposure through the anticipation, recognition, evaluation, and control of occupational health hazards.

TfNSW is seeking to establish a Panel of suppliers (Panel Members) to undertake a range of occupational hygiene services supporting both metropolitan and regional NSW.

submissionMethodDetails:
Additional details/Instructions: (For ARIBA tenders only)

In order to gain access to the Request for Tender documents, Tenderers are required to register their interest by sending an email:

TSS.Bidder@transport.nsw.gov.au and include the following:

1) Tender No and Title,

2) RFT ID,

3) Organisation Name,

4) ACN/ABN,

5) Contact Name,

6) Organisation/contact postal address,

7) Contact email address (preferably an email address with the contact person's name),

8) Contact phone number

To gain access to the tender documents in Ariba over the internet once

access is provided, please ensure that you are using PC with web browser:

• Google Chrome 54+ (64 –bit)

• Microsoft Internet Explorer 7-11(32-bit)

• Mozilla Firefox 24 or 27(ESR)

• Safari 9+ (64-bit)

• Microsoft Edge (32-bit)

TfNSW planning to release the documentation in ARIBA (around 2nd week of June) after due ARIBA registration process of all the interested vendors in the This stage.  All the vendors will be given enough time to respond in the next procurement stage.


description: Residential building construction services

title: Construction - 40 Naveena Street and 18 Cato Street BREWARRINA

title: 1 RFT and 2 Response Schedule BREWARRINA 40 Naveena and 18 Cato.pdf

title: 2 Response Schedules BREWARRINA 40 Naveena and 18 Cato.docx

title: 3 MW21 Conditions of Contract BREWARRINA 40 Naveena and 18 Cato.pdf

title: 4A Principals Project Requirement BREWARRINA 18 Cato Street.pdf

title: 4A Principals Project Requirement BREWARRINA 40 Naveena Street.pdf

title: 4B Project Specific Documents.zip

title: 5 DPIE Statement of Business Ethics.PDF

rationale: Provide more detail of project deliverable in Title

description:
Design and Construction (D&C) to deliver a project home type construction single storey dwelling  with two bedrooms (1 X 2 bedrooms), one and half (1.5) bathroom including a separate water closet which may be included in the laundry and associated site works on vacant land at the following sites in BREWARRINA NSW 2839:

40 Naveena Street

18 Cato Street.

submissionMethodDetails: Please submit Response Schedules as your RFT submission.


description: Civil engineering

title: Araluen Road Slips - Road Repair and Stabilisation

title: RFT-10054691 Tender Documents.pdf

title: QPRC Araluen Road Concept Options.pdf

title: RFT-10054691 - Drawings.pdf

title: RFT-10054691 Tender Schedules envelope 1.docx

title: RFT-10054691 Tender Schedules envelope 2.docx

title: 660.30186.000 Safety In Design Register - VR001 Araluen v1.0.pdf

title: RFT-10054691 Addendum No.1.pdf

rationale:
Notice to All Tenderers - Addendum No. 1

This addendum is to advise that the time for the mandatory meeting is amended to 10:00 AM on the Wednesday the 14th December 2022.

title: RFT-10054691 Araluen Rd Land Slips - Addendum 2.pdf

title: RFT-10054691 Araluen Rd Land Slips - Pretender Meeting Minutes.pdf

rationale:
Notice to All Tenderers - Addendum No. 2

The attached addendum includes the pre tender meeting minutes and is part of the RFT Documents and will form part of the Contract.

description: Slope stabilisation of the 10 landslips along Araluen Road, NSW and reinstatement of the road as shown on the drawings.

timeframeDelivery: 40 weeks

addressForLodgement:
Electronic Tender box is at -   https://tenders.nsw.gov.au

Tenderers are to lodge their tender response via this website including acknowledgement of any addenda issued. Addenda are also to be noted on the tender form in the space provided. If you have a problem lodging your response, please contact 1800 NSW BUY (1800 679 289) before the advertised closing time for the tender.

submissionMethodDetails:
NOTES TO PARTICIPATING FIRMS

Two-envelope system tender

Please note this is a 2 envelope tender. The tender schedules are marked as envelope 1 and envelope 2. They must be submitted as two separate files when you lodge your response.

Mandatory Pre-Tender Meeting *(SEE ADDENDUM NO.1 - Meeting time amended to 10:00 AM).

A mandatory pre-tender meeting is proposed for Wednesday, 14th December, 2022 at 8:00 AM. The meeting is being held at the Intersesction of Araluen Road and Sawyers Ridge Road.

Documentation available for this RFT

A softcopy only of the whole specification including a separate softcopy of the returnable schedules is available for downloading by following the instructions below.

Obtaining RFT Documentation

First time visitors to this web site who wish to download, or order documents will need to self-register on this web site to gain access to the documents.

Softcopy Document

An electronic version of the specification and returnable schedules can be downloaded from this web site free of charge.

To obtain the provided specification and schedules from this web site download all the provided files by clicking on the "DOWNLOAD A SOFT COPY" link at the bottom of this page and following the on screen instructions.

Hardcopy Copy is not available for this Document

Submitting your response - Electronic Lodgement

When you have completed your response you can lodge it electronically via this Web Site.

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC Software requirements:

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe ® Acrobat Reader ® 8.0 (or more recent)

WinZip ® 10.0 (or more recent) or equivalent

Additional software may also be required, including the following, depending on the file types provided:

Microsoft Word 2010 (or more recent) or equivalent

Microsoft Excel 2010 (or more recent) or equivalent

Other requirements

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows – IE version 8 or later with Cipher Strength = 128bit.

Cookies.

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software

Still having problems?

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ” section under the On-line HELP button.

conditionsForParticipation:
Attendance is mandatory for the pre-tender meeting on Wednesday, 14th December, 2022 at 8:00 AM.

*(SEE ADDENDUM NO.1 - Meeting time amended to 10:00 AM).


description: Printing and Photographic and Audio and Visual Equipment and Supplies

title: RFP-Conditions-Part-A Production and Delivery of SafeWork and Fair Trading Licences.pdf

title: RFP-Response-Part-B Production and Delivery of SafeWork and Fair Trading Licences.docx

title: RFP-Part-C Production and Delivery of SafeWork and Fair Trading Licences Contract.pdf

title: BRD_7032 Production and Delivery of SafeWork and Fair Trading Licences - Addendum_1.pdf

rationale: Change of date and time for Supplier briefing session.

title: BRD_7032 Production and Delivery of SafeWork and Fair Trading Licences - Addendum_2.pdf

rationale: Questions and Answers from the industry briefing session on 7 July 2022.

description: The objective is to source a supplier who can meet the requirements for printing Card Consumables for Safework and NSW Fair Trading.

timeframeDelivery: 31 January 2023


description: Passenger marine transportation

title: Manly Fast and Lane Cove River Ferry Services

title: confidentiality-deed-poll-template tender WS3253564210.docx

title: Tenderer Registration Form WS3253564210.docx

rationale: Please be advised that the tender closing date/time has been extended to February 11 at 12:00 noon.

description:
Transport for NSW is seeking tenders to operate:

fast ferry services between Manly and the city, and

ferry services along the Lane Cove River.

Tenderers are required to be genuine public transport operators who have the capacity to enter into a contract with TfNSW.

Operators will be required to transition to zero or low emissions technology during the course of the contract, and to encourage suitable proposals TINSW is offering a contract of up to 15 years, dependent on continued satisfactory performance.

submissionMethodDetails:
There will be a briefing for registered tenderers on 3 December 2021. Invitations will be sent to those parties who have registered before that date. Attendance at the briefing is not compulsory.

Proponents are required to register by completing the attached confidentiality deed poll and sending by email to: ferries@transport.nsw.gov.au

The email must include the following Documents to be accessed through the Tender website:

1. Tenderer Registration Form

2. Confidentiality Deed Poll

TfNSW will send an email to registered persons providing on-line access to the tender documents as soon as correctly completed forms are received and verified as part of this process.

All individuals on the Tenderer Registration form will be issued with an invitation to the Tender Briefing on 3 December 2021.

TNSW is offering up to two interactive sessions with each Tenderer where ideas and issues can be confidentially discussed with a view to improving the quality of the Tenders submitted. Sessions will be held mid-December 2021 and Mid-January 2022. Process for registration is set out in the tender documents.

Tenders will close on 28 January 2022 12:00 Noon with a view to commencement of the services on 1 July 2022


description: Highway and road construction services

title: RfT MSC Installations WPC.pdf

title: Schedule of Prices Package 3 MSC Installations WPC.pdf

title: Tender Form WPC.pdf

title: Tender Commercial Docs WPC.zip

title: Scope of Works Western Parkland City.zip

title: RFT Preview Document

streetAddress: Suite 1a, Level 2, 802 Pacific Highway, Gordon

DM Roads

streetAddress: 50 Eastern Creek Drive, Sydney

legalName: Downer EDI Works Pty Ltd

Ezypave

streetAddress: 6A Jellicoe Street, Lidcombe NSW 2141, Lidcombe

legalName: Ezypave

streetAddress: 6/35 Leighton Place, PO box 209, Hornsby

legalName: Hunt Civil P/L

Mack Civil Pty Ltd

streetAddress: 209, Chuters Avenue, Sans Souci

legalName: Mack Civil Pty Ltd

Renville Contractors Pty Ltd

streetAddress: 6/24-26 Clyde St, Rydalmere

legalName: Renville Contractors Pty Ltd

Superb Civil Group Pty Ltd

streetAddress: 22 Daisy St, REVESBY

legalName: SUPERB CIVIL GROUP

title: Addendum 1 22.0000139283.0134 WPC 1.pdf

title: R143  Signposting  MSC Installations.pdf

rationale: Addendum 1

description:
Transport for NSW is inviting suitably experienced, qualified and accredited Contractor to participate in the tender process for the Supply and Installation of Mobile Speed Camera (MSC) Fixed Signs – Western Parkland City

This advertisement invites the submission of a tender from any organisation that meets the minimum participation requirements.

The purpose of the NSW Mobile Speed Camera (MSC) Program is to deter drivers from speeding on every trip through enforcement anywhere, anytime – reducing speeds across the road network, not just at identified high risk locations.

In November 2020 the Government announced enhancements to the NSW MSC Program towards best practice and national consistency, proven to reduce road trauma.

The works to be carried out under this contract involve the site investigation, supply and installation of three different sizes of Mobile Speed Camera (MSC) Fixed Signs at various locations (Approximately 315 Signs across 3 packages) within Greater Sydney area including State and Local Roads as detailed in the Request for Tender. The works are to be installed near live traffic, pedestrians and businesses. The works are to be undertaken with appropriate traffic management, suitable for the adjacent traffic speeds, to ensure the safety of both workers and road users. The works under the contract is to be carried out with the least possible disruption to traffic, road users and communities.

Separate ROL applications need to be submitted for each site by contractors undertaking sign installation works.

All site investigation and potholing required ahead of work commences and during to identify any clashes with existing services.

The signage installations under overhead power lines is to be in accordance with Safe work NSW ‘Work near overhead power lines: Code of practice;

All sign installations, including supply of materials, plant, supervision, coordinating and sequencing required in the performance of the Works;

establishment and maintenance of all work sites including all mobilisation, demobilisation, clean-up and required amenities and on-site services;

Undertake all other activities and works necessary to complete the Works.

The Contractor general obligations include but are not limited to:

Providing a skilled team, which will work collaboratively with TFNSW, councils, utility companies and key stakeholders to deliver contract works in line with agreed documentations and programme requirements.

To successful participate in the tender process for the Project, organisations:

Must execute (to the satisfaction of TfNSW) the Confidentiality Deed Poll to receive the tender documents and must return to TfNSW via Tejas.Mistry@transport.nsw.gov.au by 5:00pm (AEST) Friday 11 February 2022

Must provide evidence of National Pre-qualification System for Civil (Road and Bridge) compliance with R1 level or greater.

Without any obligation to do so, where the integrity of the tender process is not compromised, TFNSW may determine (in its absolute discretion) that it is appropriate to consider a late tender submission.

All tenderers must comply with the NSW Government Procurement Policy Framework (NSW Framework), NSW Government Supplier Code of Conduct (NSW Code) and New South Wales Industrial Relations Guidelines: Building and Construction Procurement (NSW Guidelines).

Copies of the NSW Framework and NSW Code are available at www.buy.nsw.gov.au.  The NSW Guidelines are available at www.industrialrelations.nsw.gov.au.

Identifiers:
Cumberland/Prospect
Inner West
South West Sydney

addressForLodgement: "Electronic lodgement only"


description: Mining services

title: Annual Report Release Policy (ARRP) formerly known as Sunset Clause; Digitisation of Historic Exploration Data

title: 20-2002-1 - Tender Documents.zip

title: 20-2002-1 - Additional Documents.zip

title: 20-2002-1 - Addendum 2 - Q and A.pdf

rationale: 20-2002-1 - Addendum 2 - Q and A

title: 20-2002-1 - Addendum 3 - Q and A.pdf

rationale: 20-2002-1 - Addendum 3 - Q and A

title: 20-2002-1 - Addendum 1 - Question and Answer.pdf

description:
The Agency requires the provision of services to extract, digitise and validate historical exploration data from our DIGS record system. The Agency is forming a panel of pre-approved consultants to be involved in the project. The deliverables of the project are:

•Company exploration data to be captured from data that was provided to the GSNSW in hard copy reports including;

osurface geochemical data from stream sediment, soil and rock chip sampling: and

odrilling data from auger, RAB, aircore, RC/percussion and diamond drilling.

•Validation (QA/QC) checks are undertaken as part of the process.

•Exploration data supplied in GSNSW database structure (SQL format).

name: Mining, Exploration & Geoscience (Regional NSW)


description: Building construction management

title: NSW Telco Authority: Telecommunications Construction Delivery Services - CCEP

title: Telecommunications Construction Services - CCEP - EOI-Conditions-Part-A.pdf

title: Telecommunications Construction Services - CCEP - EOI-Conditions-Part B.docx

title: RFT - 10048601 Q and A 3.pdf

rationale: Add RFT - 10048601 Q and A 3

title: RFT-10048601 Q and A 1.pdf

rationale: Add RFT - 10048601 Q and A 1

title: RFT - 10048601 Q and A 4.pdf

rationale: Add RFT - 10048601 Q and A 4

title: RFT-10048601 EOI CCEP PMO Tender briefing 2022_FINAL.pdf

rationale: Add Industry Briefing presentation pack "RFT-10048601 EOI CCEP PMO Tender briefing 2022"

title: Telecommunications Construction Services - CCEP - EOI-Conditions-Part BV2.docx

title: RFT - 10048601 Q and A 2.pdf

rationale:
Add Telecommunications Construction Services - CCEP - EOI-Conditions-Part BV2 - Part B has been reissued as Version 2, 24/02/2022 – with section 4 updated to be consistent with Part A.

Add RFT - 10048601 Q and A 2.

title: RFT - 10048601 Q and A 5.pdf

rationale: Add RFT - 10048601 Q and A 5

title: RFT - 10048601 Q and A 6.pdf

rationale: Add RFT - 10048601 Q and A 6

description:
To deliver the Critical Communication Enhancement Program (CCEP), the NSW Telecommunications Authority (the Principal) continues to evolve its long-term core capabilities. The Principal will continue to require services from third party organisations to provide subject matter and project management expertise and additional resourcing for the volume of work related to CCEP.

Changes to the current delivery model are required due to an uplift in the Principal’s internal capability.

Key goals that this expression of interest and subsequent procurement activity will facilitate:

• the engagement of a Delivery Management Services Provider with strong telecommunications construction and project management expertise to be accountable for the delivery of the post-SAED functions of the CCEP (refer to 6.3Appendix C: CCEP High Level Construction Management Process)

• provide a strong project management focus on outcomes necessary to exceed the project schedule baseline

• provide the Principal with Flex* required to manage new initiatives

• support and work with the Principal’s internal teams with project management capabilities

The scope of services reflects current and future workstreams. Potential future scope may include additional CCEP projects and additional Principal projects.

submissionMethodDetails: This service will be contracted via SCM10611 Consultants in Construction above $9m. Note you do not have be on this scheme to be able to participate in this EOI.

conditionsForParticipation: Please fullfil all the requirements in Telecommunications Construction Services - CCEP - EOI-Conditions-Part-A and Part- B


description: Uniforms

title: Supply of Uniforms

description: Council is calling for responses to establish a panel of suitable and capable suppliers to provide the range of Penrith City Council Workwear required for several departments across the organisation, including but not limited to Rangers, Childcare and Depot

submissionMethodDetails: All enquiries are to be sent through the Apet360provider tender portal. These enquiries will be addressed via an addendum


description: Community and social services

title: Wilson Park Foreshore Community Hub Tenancy

title: TRSOPA22511_Tender Document.pdf

title: TRSOPA22511_Returnable Schedule A.docx

title: TRSOPA22511_Returnable Schedule B.docx

title: RFT Preview Document

Addventageous

streetAddress: 14 B Perigee St, Doonside

legalName: Charlene Bordley

description: SOPA is seeking Expressions of Interest to occupy newly renovated premises in Millennium Parklands and partner with SOPA in the development and provision of community engagement programs from suitably qualified and experienced program providers

Identifiers:
Cumberland/Prospect
Inner West

timeframeDelivery: Minimum 12-month tenancy on review

submissionMethodDetails:
Returnable Schedules A & B must be submitted for the EOI to be evaluated.

Submit tenders electronically only via www.tenders.nsw.gov.au

Submit all completed tender schedules as a single combined pdf file.

Submit all supporing information as a single combined pdf file.

Hard copy tenders will not be accepted.

Do not send tenders to any SOPA officer, including email copies.

Tenders that do not comply with the above requirements may be deemed non-conforming and be passed over.

conditionsForParticipation: Extensive experience in the community program development.


description: Mobile internet services software

title: Mobile Application Development and Support - TAP App - Host, Maintain and Enhance Tender

description:
The Department has had a prototype application developed which is known as TAP Smartphone Application (TAP App). The application is designed to synthesise evidence-based practices with emerging technologies to reduce offender-users’ risk of re-offending, and support positive behaviour change.

The development of the application is now at a stage where a production version is required. In addition to the work on the application the Department is seeking on-going support for the completed product and a commitment to continue enhancing the application on an ad-hoc basis as existing and new practices are recognised to further its effectiveness. The Department's requirements include mandatory items which, if not substantially complied with, will invalidate responses and a best and fairest offer process is not currently envisaged.

The upcoming tender opportunity can only be accessed and responded via the Department’s end to end procurement system, Procurement Central. Any submission lodged outside of Procurement Central will not be considered by the Department.

To participate in the tender opportunity, please register on https://justice.bravosolution.com/web/login.html.

Organisations who have not registered on Procurement Central will not be able to access the tender information.

If you have already registered on Procurement Central, you are not required to register again.

If you require assistance with registering on Procurement Central, you may contact the Customer Support via below methods.

If you are in Australia please call: 02 8074 8627

If you are outside of Australia, please click here for overseas phone numbers.

E-mail: customersupport@jaggaer.com

name: NSW Department of Communities and Justice

Identifiers:
Central Coast
Cumberland/Prospect
Nepean
South West Sydney
Illawarra

submissionMethodDetails: As per Advance Notice published on eTenders Prj_4310_AN on December 15 2021


description: Business cases

title: Swan Hill Moveable Span Bridge Project – Early Market Engagement

tenderType: Notice

description:
Transport for NSW (TfNSW) is seeking early market engagement for the Swan Hill moveable span bridge project to help develop a strategic business case for this project.

TfNSW, in partnership with the Victorian Department of Transport, is planning to replace the 125-year-old table lift span bridge over the Murray River between the border towns of Swan Hill in Victoria and Murray Downs in NSW.

This will be the first new full-size moveable span bridge constructed in NSW in 63 years and is believed to be the first constructed in Australia in 14 years.

This project presents an opportunity to improve road safety, traffic and freight capacity, reliability, and traffic delays due to lift span operation, pedestrian and cyclist accessibility, and facilitate foreshore improvements and further development in Swan Hill and Murray Downs.

TfNSW is developing a strategic business case for this project, and is seeking industry feedback to understand the market’s capability and to inform project staging and design.

This early market engagement will take the form of one-on-one interviews, and/or workshops, or online responses with invited organisations.

submissionMethodDetails:
To register your interest in taking part in this process, please complete this form.

If you would like more information, please contact ied@transport.nsw.gov.au

eTenderProcurementMethod: Notice


title: TZ Amphibian & Reptile Conservation Centre Main Construction Works

description: Restricted Tender

Restricted Tender

Paul De Alwis

mobile: Restricted Tender


description: Drainage system construction service

title: T30-23 DOCUMENTS.ZIP

description:
Council is seeking tenders from suitably qualified and experienced Tenderers for T30-23 Allegra Avenue and Jindalee Place Drainage Works. The work is divided into two separable portions.

Separable portion 1: Allegra Avenue Drainage Works

Separable portion 2: Jindalee Place Drainage Works

A full description of the nature and extent of the services required by Council are set out in Section 3 of this Request.

addressForLodgement: Electronic lodgement at: https://360providers.apetsoftware.com.au/request/open/CBCity

submissionMethodDetails:
Please note Council is now using APET for all electronic lodgements and lodging by NSW e-tendering will no longer be available.

If you're not already registered with Apet360. We strongly recommend that you register online with Apet360 upon downloading the tender documents from e-tendering.

The URL for electronic lodgement is:  https://360providers.apetsoftware.com.au/request/open/CBCity

Apet users guide has been attached to our documents for lodgement.

Note: Submissions lodged via email are not acceptable.


description: Geotechnical or geoseismic engineering

title: Landslip Stabilisation - Bingleburra Road

title: RFT-10051081-Tender Documentation.zip

title: ADDENDUM 1 -  RFT-10051081 Bingleburra Stabilisation Tender Addendum 1.docx

rationale:
Addendum No.1 - Notice to All Tenderers

Provision of travel directions and details ahead of Mandatory Pre-Tender Meeting held tomorrow at Bingleburra Road Site at 11:00AM on 14 July 2022. Ensure to read prior to attending

Tenderers should ensure to review all information including any comments and attachments provided in this Addendum, and where instructed incorporate into tender submission.

END OF ADDENDUM NO.1

title: Addendum 2 RFT-10051081.zip

rationale:
Addendum No.2 - Notice to All Tenderers

Clarification of Advice from Pre-Tender Meeting provided

Change of RFT Contact - Peter Davis. Contact Details updated in tender contact details below.

Tenderers should ensure to review all information including any comments and attachments provided in this Addendum, and where instructed incorporate into tender submission.

END OF ADDENDUM NO.2

description:
The extent of works for this contract includes but is not limited to:

Undertake proposed measures to stabilise Road Slip at 6 discrete sections on Bingleburra Road

The works comprise all work shown on the drawings and included in the specification.

A mandatory pre-tender site meeting will be held at Bingleburra Road Site [approximately 12 km to the East of East Gresford] 11:00AM on 14 July 2022. Attendance at the meeting is compulsory. Tenders received from contractors not in attendance at the site meeting will not be considered for acceptance.

timeframeDelivery: 12 Weeks from Date of Letter of Award

addressForLodgement: Tenderers are to lodge their tender response via this website including acknowledgement of any addenda issued. Addenda are also to be noted on the tender form in the space provided. If you have a problem lodging your response, please contact 1800 NSW BUY (1800 679 289) before the advertised closing time for the tender.

submissionMethodDetails:
OBTAINING RFT DOCUMENTS:

SOFTCOPY DOCUMENT

Only a downloadable SOFTCOPY version of the RFT is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT/EOI and any FUTURE related Amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY link at the bottom of this page and follow the on-screen instructions.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

Your completed Tender response is to be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.
 Electronic Tender Box Security
 During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site “electronic tender box”. All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed. This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
 A detailed system generated electronic receipt is issued for all responses received successfully.


description: Language schooling

title: Ninganah No More –  Gamilaraay/Yuwaalaraay/Yuwaalayaay  Aboriginal Language Hub

title: DOE03147-22 - PART A - Conditions of Tendering GYY.pdf

title: DOE03147-22 - PART B - Specifications GYY.pdf

title: DOE03147-22 - PART C - Tender Response Schedules - Non-Price GYY.docx

title: DOE03147-22 - PART C - Tender Response Schedules - Price GYY.xlsx

title: DOE03147-22 - PART D - Human Services Agreement GYY.pdf

title: DOE03147-22 - Addendum 2.pdf

title: DOE03147-22 - GYY Language Hub - Procurement Briefing.pdf

rationale:
Attached is Addendum 2 with the pre-tender market briefing presentation.

Please note, pre-tender market briefing presentation will be held at the following times and date:

Friday 28 October at 9:00 am. Please RVSP by 27 October at 3:00 pm.

title: DOE03147-22 - Addendum 1.pdf

rationale:
Please note, pre-tender market briefing presentations will be held at the following times and dates:

Monday 24 October at 2:00 pm. Please RVSP by 21 October at 5:00 pm.

Friday 28 October at 9:00 am. Please RVSP by 27 October at 3:00 pm.

The presentations will cover the same material and there is no expectation that you need to attend both.

description:
Establishment of an early childhood education Aboriginal language hub for the Gamilaraay/Yuwaalaraay/Yuwaalayaay language region. The hub will coordinate Gamilaraay/Yuwaalaraay/Yuwaalayaay language teaching in early childhood education services across the region.

The provision of Gamilaraay/Yuwaalaraay/Yuwaalayaay language teaching services through multiple early childhood education services across the Gamilaraay/Yuwaalaraay/Yuwaalayaay region.

The tenderer will provide the Department with a Hub Establishment Plan that meets the deliverables outlined in this specifications document.

The successful tenderer will be required to undertake effective community engagement, language teaching program development and coordination of language teaching activity across the Gamilaraay/Yuwaalaraay/Yuwaalayaay region so as to ensure a successful language teaching program in preschools in the region.

timeframeDelivery: Refer to Part B - Specifications

addressForLodgement: Refer to Part A - Conditions

submissionMethodDetails: Refer to Part A - Conditions and Part B - Specifications

conditionsForParticipation: Refer to Part A - Conditions


description: Building and Facility Construction and Maintenance Services

title: New 500,000l Glass Fused Steel Water Tank and Associated Works

title: P22-4470 - MW21 Tender Documents.zip

title: P22-4470 - Addendum 1 - Meeting Minutes Site Survey and Location Report.zip

rationale:
P22-4470 - Addendum 1

Tenderers Meeting Minutes 24.11.2022

Site Survey

OzDetect - services location report

description:
The design, supply and installation of a new 500,000l Glass Fused Water Tank and including all associated works and a new bladder to the existing reinforced concrete tank and interconnecting plumbing & telemetry works, for the Elizabeth Macarthur Agriculture Institute, Menangle NSW.

The works must be completed by Mid June 2023.

Assessment will be informed by Tenderer's demonstrated experience and expertise in the delivery of commercial GFS tanks , demonstrated design capability and expertise, demonstrated technical capacity and ability to meet program requirements."

timeframeDelivery: 5 months

submissionMethodDetails:
A tenderer’s meeting is scheduled for 9.00am on Thursday 24th November 2022, at the Elizabeth Macarthur Agriculture Institute, Woodbridge Rd, Menangle NSW 2568.

Tenderer’s are to meet at the reception area of the administration block.

Tenderer’s must register their attendance for the Tenderer’s Meeting by contacting David Currie at david.currie@dpi.nsw.gov.au


description: Fire station construction service

title: NSW RFS - New Brigade Station Boomi

title: RFT-10052241 Tender Documentation NSW RFS-Namoi Gwydir Region-Rural Brigade Station .zip

description:
The extent of works for this contract includes but is not limited to:

The demolition and re building of a new Brigade Station shed at Boomi.

The works comprise all work shown on the drawings and included in the specification.

Identifiers:
New England
Hunter

submissionMethodDetails:
OBTAINING RFT DOCUMENTS:

SOFTCOPY DOCUMENT

Only a downloadable SOFTCOPY version of the RFT is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT and any FUTURE related Amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY link at the bottom of this page and follow the on-screen instructions.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

Your completed Tender response is to be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.
 Electronic Tender Box Security
 During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site “electronic tender box”. All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed. This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
 A detailed system generated electronic receipt is issued for all responses received successfully.


description: Concrete curb

title: Tender Documents.zip

title: Tender Submission Package.pdf

legalName: Axial Construction Pty Ltd

Civil and Civic

region: ACT

streetAddress: 169/50 Eyre St, KINGSTON

legalName: Civil and Civic

Conex Group P/L

streetAddress: Unit 11, 14-16 Stanton Road, Seven Hills

legalName: Conex Group Pty Ltd

Josh Small Concreting

streetAddress: 5/35 Essington St, Mitchell

legalName: JSC Pty Ltd

Ladex Construction Group Pty Ltd

streetAddress: 35 Bomen Road, Bomen

legalName: Ladex Construction Group Pty Ltd

TSS

streetAddress: 49 Wedderburn Road, ST HELENS PARK

legalName: Total Slipforming Solutions Pty Ltd

title: Addendum 1 - 22.0000129161.0388.pdf

title: Addendum 1 - Drawings.zip

rationale: Addendum 1 - Request for information / clarification and drawings.

description:
Tenders are invited for the Construction of SO Type Kerbing at the Vittoria East Project, West of Bathurst.

The scope of the work involves Construction of SO and SB Type kerbing (including a subsoil trench), No fines concrete platform.

All tenderers must comply with the NSW Government Procurement Policy Framework (NSW Framework), NSW Government Supplier Code of Conduct (NSW Code) and New South Wales Industrial Relations Guidelines: Building and Construction Procurement (NSW Guidelines).

Copies of the NSW Framework and NSW Code are available at www.buy.nsw.gov.au. The NSW Guidelines are available at www.industrialrelations.nsw.gov.au.

addressForLodgement: Electronic lodgment only


description: Fisheries and aquaculture

title: Woolooware Bay Aquaculture Precinct - Tenants & Operators - Market Engagement

rationale: Closing date of Notice amended from 31 October 2022 to 14 November 2022

description:
Transport for NSW (TfNSW) is currently progressing a proposal to demolish and replace the existing overwater and land-based structures at “The Oyster Farm” located on Captain Cook Drive, Woolooware Bay. Concurrent with this, TfNSW is seeking to engage with potential tenants and operators, by way of a market sounding, to understand market capability, appetite and potential offerings for creation of a reimagined Woolooware Bay Aquaculture Precinct.

Oyster faming has operated from the site at Woolooware Bay for several decades and TfNSW together with the Department of Primary Industries (DPI Fisheries) want to continue to support the Aquaculture industry at the site.

Aquaculture is one of the fastest-growing industries in the world. Already, 54% of seafood consumed worldwide is produced through aquaculture. According to the United Nations’ Food and Agriculture Organization (FAO), in 2018 aquaculture in the Oceanic Region represented 12.7 percent of total fish production compared to the 46 percent world aquaculture contributed to global fish production.

A reimagined Woolooware Bay Aquaculture Precinct represents a unique opportunity to:

Celebrate and share the history of this location as a valuable source of food;

Increase aquaculture production and employment in the region to previous historic levels; and

Support ongoing ecological and environmental research.·

TfNSW invites a wide-range of potential tenants and operators to register their interest to participate in this market sounding. This may include those engaged directly with aquaculture production of oysters, mussels, finfish as well as tourism, heritage, retail and food and beverage operators, who recognise the unique opportunity this location presents.

The market sounding will include individual discussions with interested parties and will be conducted in a manner that ensures:

• content we provide is consistent and accessible;

• the process will not detail any future tender process, but will rather seek feedback and information from the market in relation to the proposed opportunity; and

• the process is in full compliance with NSW Government and TfNSW procurement policies and overseen by a probity advisor.

The market engagement process is not part of any tender process and is not a request for a proposal to deliver services of any kind.

Information provided or discussed during market engagement will not in any way be taken into account or impact any future evaluation or award decision.

Participants in the market engagement acknowledge and agree that TfNSW will not be liable for any costs or expenses incurred as a result of its participation in this market engagement exercise.

Further information can be found on the project webpage:

https://roads-waterways.transport.nsw.gov.au/maritime/projects/woolooware-bay-aquaculture-precinct/index.html

addressForLodgement: No lodgement via eTender is required at this stage of the process.

submissionMethodDetails: Please register your interest to participate in this market sounding by sending a request by email to: wooloowarebayaquacultureprecinct@transport.nsw.gov.au. A member of the team will then contact you to arrange a suitable time to meet with members of our project team to discuss the opportunity in more detail.


description: Software

title: EOI - Digital Project Management Toolkit – Local Government

title: P22-3779 - EOI Documents.zip

title: P22-3779 - Addendum 1 - Amendment to Close Date and link.pdf

rationale:
P22-3779 - Addendum 1

Amendment to Close Date

Part A - Amendment to Close Date details

Part C - Updated link

title: P22-3779 - Addendum 2 - Updated Attachment D.pdf

title: Attachment D - EOI Requirements - Digital PM Toolkit - Local Government - UPDATED.xlsx

format: xlsx

rationale: P22-3779 - Addendum 3 - Attachment from last addendum (2) was omitted. Attachment has now been included. Apologies for the inconvenience.

rationale: Inclusion of 'EOI' in the title.

tenderType: Expression of Interest For Pre-Qualification

description:
This document invites Expressions of Interest (EOI) for the provision of a Digital Construction Management Toolkit for Local Councils to manage construction projects. The solution is to be a: simple, cloud-based, ‘off the shelf’ solution.

The intention of the software is to digitise a current ‘opt-in’ suite (toolkit) of documents to provide users with a systems guided journey, project reporting and document automation throughout the life of a project. This ‘opt-in’ solution is for the Department of Regional New South Wales with oversight by NSW Public Works.

The aim of this EOI is for Public Works to get a better picture of what software solutions are available and the various support, cost, and delivery models on offer to best meet the needs of both Local Councils and NSW Public Works.

conditionsForParticipation: Must be a pre-qualified supplier on the ICT Services Scheme SCM0020 (Category M – Systems and solutions)


title: Blue Lake Boardwalk Construction

title: 3. Tender Schedules.docx

title: RFT No. 10032161.pdf

title: 10032161 Addendum 01.pdf

title: 3. Tender Schedules_B.docx

rationale:
Addendum No. 1 consists of:

Response to tenderer's RFI's

Pre-tender meeting minutes (including attendance register and meeting slides)

Tender Schedules Revision B

Blue Lake Boardwalk REF

title: 10032161 Addendum 02.pdf

rationale:
Addendum No. 2 consists of:

Clarifications regarding works

Response to tenderer's RFI's

title: 10032161 Addendum 03.pdf

rationale:
Addendum 3 consists of:

Revision of tender close date to the 3rd May 9:30am.

Response to tenderer's RFI's

tenderType: Pre-Qualified / Invited

description: Construction of elevated boardwalk, viewing platforms and events spaces at the Jenolan Caves Blue Lake. Works also include landscaping and track refurbishments.

addressForLodgement: This website:  https://tenders.nsw.gov.au/dfs/

submissionMethodDetails:
Invited Tenderers

Fleetwood Urban

Steelworks Engineering

JK Williams Contracting

Soil Conservation Services

DSL Constructions

Pre-tender Site Meeting:

March 18th, at 9:30am at Jenolan Caves Road and Kanangra Boyd Road intersection.

eTenderProcurementMethod: Pre-Qualified / Invited


description: Residential building construction services

title: Construction - 31 Walgett Street BREWARRINA

title: 1 RFT and 2 Response Schedule BREWARRINA 31 Walgett Street.pdf

title: 2 Response Schedules BREWARRINA 31 Walgett Street.docx

title: 3 MW21 Conditions of Contract BREWARRINA 31 Walgett Street.pdf

title: 4A Principal Project Requireemnts BREWARRINA 31 Walgett Street.pdf

title: 4B Project Specific Documents.zip

title: 5 DPIE Statement of Business Ethics.PDF

rationale: Provide more detail of project deliverable in Title

description: Design and Construction (D&C) to deliver a project home type construction for two single storey dwellings (duplex); each with two bedrooms (2 X 2 bedrooms), one and half (1.5) bathroom of including a separate water closet and associated site works on vacant land at 31 Walgett Street BREWARRINA NSW 2839


description: Healthcare Services

title: Provision of Childcare Services

currency: AUD

title: RFT Part A - Tender Overview and Terms and Conditions of Tender Final.docx

title: RFT Part B - Tender Specification Final.docx

title: RFT Part C - Tender Response Final.docx

title: RFT Part D - Proposed Contract Final.DOCX

title: RFT Part E - Proposed Lease Agreement..pdf

title: RFT Appendices Final.xlsx

title: RFT Attachments.zip

title: NBM_2210451 Child Care Services Addendum_1.docx

rationale: This is an addendum to all prospective tenderers to confirm the Supplier Tender Briefing Session shall be held on Tuesday 15th November 2022 at 3pm via Microsoft Teams.

title: NBM_2210451 - Addendum 2.pdf

title: Prospective Tenderer Declaration -  Additional information access.pdf

rationale: This Addendum 2 contains information and attachments relating to the above Request for Tender (RFT). It is the responsibility of the tenderers to be aware of this Addendum and its contents, taking these factors into consideration for inclusion when developing an offer for this tender.

title: NBMLHD_2210451 - Addendum 4.pdf

title: Somerset_Cottage_Child_Care_Centre Waitlist.pdf

rationale: Addendum 4 contains responses to requests for clarification.

title: NBMLHD_2210451 - Addendum 3.pdf

title: Architectural Plans with statement of accommodation measurements.pdf

title: NBMLHD Childcare CCTV Security Cameras.pdf

rationale: Addendum 3 contains further responses to requests for clarification.

description: Nepean Blue mountains Local Health District (NBMLHD) currently owns and operates Somerset Cottage, Nepean Hospital Childcare Centre. The LHD's objective is to identify a qualified and experienced external operator and transfer the operation of the Childcare Centre to a private party under a Service and tenancy agreement.

name: HealthShare NSW - Local Tender and Contracts

submissionMethodDetails: This tender is in conjunction with the Nepean Blue Mountains Local Health District (NBMLHD)


description: Lease and rental of property or building

title: Lease of Floor Space within the Wingecarribee Animal Shelter

title: EOI-2022-1 Request For EOI.docx

description: Council (the Principal) invites interested parties to lodge an expression of interest to lease floor space within the proposed Wingecarribee Animal Shelter to be constructed at 1 Bowman Road, Moss Vale (being part Lot 2 DP 1249526). The proposed initial lease period is for five (5) years.

addressForLodgement:
Council's Nominated Electronic Tender Box: https://tenders.nsw.gov.au/ (preferred method of lodgement)

Council's physical Tender Box: Wingecarribee Shire Council Civic Centre, Elizabeth Street Moss Vale 2577

PO Box 141 Moss Vale NSW 2577

conditionsForParticipation:
On eTendering, do you want me to put it in the “Conditions of Responding”:

Evaluation Criteria

The information required by the Respondent in will be used to evaluate responses in accordance with pre-established Mandatory Participation Criteria, Non-Cost Criteria, and Cost Criteria.

Mandatory Participation Criteria will be assessed on a Yes/No basis and MUST be met by the Respondent. If a response fails to fully comply with any of the outlined Mandatory Criteria, Council may deem the Response to be non-conforming and therefore not be eligible to be shortlisted or progress any further in the evaluation process.

Non-Cost and cost criteria will be evaluated as weighted criteria by the Evaluation Panel for determining an overall value for money evaluation of the Respondent’s submission. Failure to fully comply with Non-Cost and Cost Criteria may reduce the Respondent’s overall score but will not result in the exclusion of the Response from further consideration.

For further information, please see Conditions of Responding – Council Expressions of Interest.


description: Mining and oil and gas services

title: Stage 2 NSW CO2 Storage Assessment Program - Provision of cementing services

title: P22-3674 - Parts A B C and D - 4 documents.zip

title: P22-3674 - Attachments 1 to 5.zip

title: P22-3674 Addendum 3 Extn to tender closing date now 09062022 10am.pdf

rationale:
Addendum 3 is published 11:30 AM 02/06/2022 and advises the tender closing date is being extended to Thursday June 9, 2022 at 10:00 AM.

Tenderers are advised to review all tender documentation including Addenda prior to submitting tender responses.

title: P22-3674 Addendum 1 Published 04052022.pdf

rationale:
Addendum 1 is issued 04/05/2022 and responds to questions.

All questions must be lodged in writing to tenders@regional.nsw.gov.au

title: P22-3674 Addendum 2 Extn to tender closing date.pdf

rationale:
Addendum 2 is published 4.15 PM 20/05/2022 and advises the tender closing date is being extended to Monday June 6, 2022 at 10:00 AM.

Tenderers are advised to review all tender documentation including Addenda prior to submitting tender responses.

description: The Geological Survey of NSW is issuing this Request for Tender to procure cementing services for exploration activities in Stage 2 of the NSW CO2 Storage Assessment Program. Suppliers are invited to submit a tender for the provision of all equipment (e.g. cementing unit and accessories), materials (e.g. cement) and personnel for the provision of cementing services to support of the drilling of three exploration wells.

timeframeDelivery: Contract Delivery Period - August 2022 to February 2023

addressForLodgement:
Online via the eTenders Procurement Portal only.

Tenderers are advised to lodge their tender responses well in advance of the tender closing time due to tender gateway traffic.

submissionMethodDetails:
Invitation to register and lodge a submission.

This procurement is a procurement to which the Enforceable Procurement Provisions Direction 2019 (NSW) applies.

conditionsForParticipation:
Suppliers must:

1. comply with the Enforceable Procurement Provisions Direction 2019 (NSW);

2. be a registered entity with an Australian Business Number (ABN);

3. hold and maintain all specified insurances from the project commencement date and for 12 months past the project completion date; and

4. comply with the Suppliers Code of Conduct (available on the BuyNSW online portal.


description: Mammography x ray equipment

title: Expression of Interest - SWSLHD BreastScreens

title: EOI Response Schedule - Outsource of BreastScreens.docx

description:
South Western Sydney Local Health District seeks to expand its scanning capacity per annum in order to met the requirements of the SWSLHD BreastScreen Participation Recovery Plan under a 3yr contract with two, 12mth extensions.

Tenderers will conduct a minimum of 3000 mammography screens per year, per site on women jointly recruited by the tenderer and SWSLHD BreastScreen as per the BreastScreen Australia National Accrediation Standards (NAS).

The Tenderer will adhere to weekly screening targets and nominate one or more Radiologists to oversee the activities of the screening unit for SWSLHD clients.

conditionsForParticipation: Must operate a Breast screening clinic in the South Western Sydney area.


description: Healthcare Services

title: Manufacturing, Storing and Distributing of Musculoskeletal Tissue

title: SESLHD_2210691- Request for Information.pdf

title: SESLHD_2210691 - Addendum 1.pdf

rationale: This Addendum 1 contains information and attachments relating to the above Request for Information (RFI). It is the responsibility of the tenderers to be aware of this Addendum and its contents, taking these factors into consideration for inclusion when developing an offer for this tender.

tenderType: Invitation To Respond

description: The NSW Organ and Tissue Donation Service’s (OTDS) wishes to gauge the market for local Therapeutic Goods Administration (TGA) licenced manufacturing services to manufacture, store and distribute allografts for transplantation.

addressForLodgement: Submissions to be made electronically.

eTenderProcurementMethod: Invitation To Respond


title: Expressions of Interest for a Site for a Primary School in Lennox Head

title: Confidentiality Deed Poll - Lennox Head EOI 2022DPE0019.pdf

title: Annex A - Due Diligence and Project Material - NSW eTender Protocol.pdf

title: Signing Instructions - Confidentiality Deed Poll 2022DPE0019.pdf

title: Internal Conflict of Interest and Confidentiality Undertaking - Lennox Head EOI 2022DPE0019.pdf

title: 2022DPE0019 - Addendum 1.pdf

rationale: Please see Addendum 1

rationale: Amended title to include the word "Site"

description:
In order to meet SINSW forecasted student enrolment demand and to facilitate the construction of a primary school, SINSW is seeking to acquire a suitable site within the Lennox Head Target Area to deliver a primary school.

An invitation is being made to property and landowners in the Lennox Head area to express their interest by submitting their site for consideration by SINSW to undertake due diligence investigations to determine site suitability for the new school.

An electronic data room (Data Room) has been established to facilitate the provision of information for the EOI process.

Access to the Data Room will be granted by PDNSW (at PDNSW’s absolute discretion) on acceptance of a Confidentiality and Process Deed Poll and Authorised User Form submitted in accordance with the conditions outlined in the ROI Conditions. The Data Room is subject to the Data Room Protocol. Instructions and conditions are set out in the ROI Conditions.

Please submit the completed Confidentiality and Process Deed Poll and Authorised User Form to hap_pdnsw_advisory&trans@property.nsw.gov.au requesting access to the Data Room.

Please ensure the Confidentiality and Process Deed Poll  is completed as per the signing instructions.

Identifiers:
Far North Coast
Mid North Coast
New England

timeframeDelivery: Unknown. This will be informed by the proposals.

conditionsForParticipation: Please refer to the Expression of Interest Conditions.


description: Engineering and Research and Technology Based Services

title: 2022 Catchment Audit

title: Workday Strategic Sourcing - ScoutRFP- Supplier Invitation and Guide.pdf

description: The Catchment Audit is required to assess the state of the catchment (see Figure 1) having regard to the catchment health indicators approved under section 41 of the Water NSW Act and in force at the time of assessment.

submissionMethodDetails:
The RFP documents can be accessed by using the link given below.

Link: https://go.scoutrfp.com/rfps/public/325105

For more information, please refer to attached invitation and guide document attached.

This RFP is closing at 3.00pm 02.03.2022.


description: Air conditioning installation or maintenance or repair service

title: Cooler Classrooms Program-Coonabarabran High School, Coonabarabran Public School, Baradine Central School - Level 1

title: 10045971 Tender Documents.zip

title: package 36 Level 1-Add-1.zip

rationale:
Addendum 1 consists of:

Further information pertaining to tender


description: High pressure water blasting

title: High Pressure Water Blasting in the Western Region

title: Tender documents.zip

streetAddress: Unit A 39 John Street, Camden

legalName: RETEX PAVEMENT SERVICES (NSW) PTY LTD

description:
Scope of works include to carry out high pressure water blasting at various locations in West Region to improve the surface texture of sprayed bituminous seals by removing the excess binder and residues.

All tenderers must comply with the NSW Government Procurement Policy Framework (NSW Framework), NSW Government Supplier Code of Conduct (NSW Code) and New South Wales Industrial Relations Guidelines: Building and Construction Procurement (NSW Guidelines).

Copies of the NSW Framework and NSW Code are available at www.buy.nsw.gov.au. The NSW Guidelines are available at www.industrialrelations.nsw.gov.au.

Identifiers:
Central West
Orana/Far West
Riverina/Murray


description: Mining and Well Drilling Machinery and Accessories

title: Stage 2 NSW CO2 Storage Assessment Program - Workover rig and camp

title: P22-4373 Provision of workover rig and camp - Tender Documents.zip

description: The Geological Survey of NSW is issuing this Request for Tender for the wet hire of a workover rig for exploration activities in Stage 2 of its NSW CO2 Storage Assessment Program. The completions program is then expected to be undertaken in the first half of 2023 with a preferred earliest anticipated start in March 2023, subject to availability of a suitable workover unit and the requisite long lead materials being available. The completions program involves running completions to depths of 1,700 to 2,000m and is estimated to take approximately 28 days for the campaign, with 7 days per well plus two inter-well moves plus the initial campaign mobilisation and end of campaign demobilisation. Target depths for completions and completion design will be confirmed on completion of the current exploration program (December 2022).

Identifiers:
Central West
Orana/Far West


title: SINSW02320-21 Lawson Public School - Provision of OSHC Services RFT Document Set.zip

title: SINSW02320-21 - Addendum 01.pdf

rationale: SINSW02320-21 - Addendum 01

description: SINSW02320/21 Lawson Public School - Provision of OSHC Services

submissionMethodDetails: No site visit is offered for this tender. Please refer to Building Survey Report and photos for details of premises to be used by the OSHC service.


description: Management and Business Professionals and Administrative Services

title: Biomedical Equipment Asset Survey – Data Transformation

title: HI22053 RFT Docs.zip

streetAddress: 86 Mulholland Avenue, Campbelltown

legalName: AR DATA

ECRI Institute

region: Jaya

countryName: MALAYSIA

streetAddress: ECRI Berhad, E-03-10, Sunway Geo Avenue, Subang

legalName: Emergency Care Research Institute

streetAddress: Level 15, 133 Castlereagh Street, Sydney, Sydney

legalName: GHD PTY LTD

title: HI22053 Addenda 2.zip

rationale: Addenda 2

title: HI22053 Addenda 1.pdf

rationale: Addenda 1 - Change in Pre-Tender Briefing date and Tender Closing Date

description: Biomedical Equipment Asset Survey – Biomedical data transformation and identification to comply with the medical asset nomenclature standard (document included) for a maximum of 10,000 biomedical assets. Photographs of assets will be provided. Also require the dentification of OEM minimum maintenance requirements for identified assets. It is a requirement that the consultant has expertise in biomedical equipment identification and data transformation.

submissionMethodDetails:
An optional pre-tender briefing has been scheduled as follows:

Time and Date: 11 am on Tuesday 29 March 2022 via MS Teams

Tenderers should notify the contact officer by email no later than close of business on 28 March 2022 of their intention to attend so an invitation can be extended.

conditionsForParticipation:
HI draws to your attention the obligations in relation to the Implementation Guidelines to the New South Wales Code of Practice for Procurement: Building and Construction Industry (the Guidelines), applicable to projects of $10 million and above.

The Guidelines can be downloaded from www.industrialrelations.nsw.gov.au (follow the links to Construction).


description: Urban design and engineering service

title: Invitation to EOI for Lead Designer for Treeline Lurline Project.docx

rationale: Closing date for this EOI is now 13 January 2023

description: Expressions of Interest for Lead Designer for Treeline Lurline Stage 1 Works.

submissionMethodDetails:
EOI documents must be accessed and submissions are lodged online at

https://360providers.apetsoftware.com.au/request/open/BMCCPro3(“Electronic Tender Box)

eTenderProcurementMethod: Expression of Interest For Pre-Qualification

conditionsForParticipation:
The Conditions for Participation are mandatory requirements, which describe minimum standards that Proponents must meet for their submissions to be considered. If Proponents do not meet the Conditions of Participation, they will be excluded from the evaluation process.

The Conditions for Participation are:

Proponents must be an acceptable legal entity. It is Council’s policy not to trade with any organisation that does not hold a registered ABN;

Proponents must not be bankrupt or insolvent;

Proponents must declare and provide details of any occurrence, within 5 years, where they have been found guilty of breaching any Act or Regulation; and

All Proponents must comply with the New South Wales Government Code of Procurement, which can be found at the following link.

https://www.procurepoint.nsw.gov.au/system/files/documents/code_of_practice_for_procurement_2013_ir_guidelines_0.pdf


description: Application programming services

title: Provision of resources to perform Application Development and Application/Infrastructure Support

title: Part A - RFP DT20220802 - App Dev and Support Services - Terms of Participation.pdf

title: Part B - RFP DT20220802 - App Dev and Support Services - Specifications .pdf

title: Part C - RFP DT20220802 - App Dev and Support Services - ICT Agreement.pdf

title: Part D - RFP DT20220802 - App Dev and Support Services  - Returnable Schedules.docx

title: Part D - RFP DT20220802 - Attachment B - RFP Commercial Proposal.xlsx

title: Part C - RFP DT20220802 - icare Policy and Standards.zip

title: RFP DT20220802 - App Dev and App Infra Support - Addendum 3.pdf

rationale: Addendum 3

title: RFP DT20220802 - Addendum 4.pdf

rationale: Addendum 4

title: RFP DT20220802 - App Dev and App Infra Support - Addendum 2.pdf

rationale: Addendum 2

title: RFP DT20220802 - App Dev and App Infra Support - Addendum 1.pdf

title: Vendor Briefing App Dev and Support - dT20220802.pptx

rationale: Addendum 1

title: RFP DT20220802 - Addendum 5.pdf

rationale: Addendum 5

description:
This RFP relates to the engagement of a Contractor or Contractors to provide the following services:

1. Resources to perform a number of application development and support roles within delivery teams, and

2. End to end delivery teams across multiple technology platforms to deliver required outcomes.

3. Level 2 and 3 Application Support services, including Infrastructure support


description: Information Technology Service Delivery

title: ICT Assurance Services

title: DICT_8962 - Parts A-C - ICT Assurance Services.zip

title: Addendum 1.pdf

rationale: Addendum 1 - Response to questions.

description: GovConnect governance requirements stipulate that GovConnect service providers be subject to an annual ASAE 3402 Assurance Reports on Controls at a Service Organisation assurance review. The review results in a Type 2 assurance report with respect to the design and operating effectiveness of control environments that service providers (internal and external) are responsible for. The results reported in the Type 2 reports are relied upon by the Client Agency auditors from the Audit Office of NSW to support financial statement audits performed in accordance with the Public Finance and Audit Act 1983.

submissionMethodDetails:
Tender is limited to advanced qualification suppliers who are only on the ICT Service Scheme SCM0020, categories H04 Process & Technology Audits, M01 Business Analysis, Q01 Professional Services.

Addendums will be published on Monday, Wednesday and Friday each week.


description: Lease and rental of property or building

title: Googong Public School - Provision for OSHC Services

title: SINSW03365-22 - RFT Googong PS - Prov OSHC.zip

title: SINSW03365-22 - Addendum 01.pdf

rationale: Addenda 01

submissionMethodDetails: No site visit is offered for this tender. Please refer to details of premises to be used by the OSHC Services


description: Medical diagnostic imaging and nuclear medicine products

title: District Wide Radiologist Services

title: MLHD_218833 - District Wide Radiologist Services.zip

title: Addendum - 02.pdf

rationale: Tender closing date is 23rd December 2021

title: Addendum - 03.pdf

rationale: This RFT will close on Friday, 14 January 2022 at 2:00pm (Australian Eastern Standard Time or Australian daylight saving time, as applicable)

title: Addendum - 04.pdf

title: Addendum -04 MLHD SLA Volumes All- 2021 Annual Activity by MBS Item Number.xlsx

rationale: The tender will now close on Friday, 28 January 2022 at 2:00pm

title: Addendum - 01.pdf

rationale: Addendum  # 01

description: Provide In-House Radiologists and reporting services District-Wide across Murrumbidgee Local Health District (MLHD)

addressForLodgement: Tenders (including all supporting information, if any) must be fully received by the Closing Date and Closing Time through NSW Government eTendering website at www.tenders.nsw.gov.au

submissionMethodDetails: Please note; End of period for question or requests 26/11/2021


description: Electrical Systems and Lighting and Components and Accessories and Supplies

title: Bungendore WS Upgrade - Power Supply

title: RFT-10048821 Tender Document.pdf

title: RFT-10048821 - Tender Schedules.docx

description: Replacement of existing 200kVA substation with new 500kVA substation at as described in the Technical Specification and Drawings

timeframeDelivery: 10 weeks

submissionMethodDetails:
Please note that this is not an open tender. It is an invited tender and tender responses from the listed companies ONLY will be accepted

Tenders invited are from the companies listed under:

Complete Power Pty Ltd

Ecowise Services (Australia) Pty Ltd t/as Ecowise Services

Gasnier's Electrical Pty Ltd t/as Gasnier's Electrical

Inland Power Solutions Pty Ltd Att: Shaun Bennett

Enacon Group Pty Ltd t/as Enacon Group

Ramsben Pty Ltd t/as Country Powerline Constructions

Specialized Electrical Pty Ltd

Documentation available for this RFT.

A softcopy only of the whole specification including a separate softcopy of the returnable schedules is available for downloading by following the instructions below.

Obtaining RFT Documentation

First time visitors to this web site who wish to download, or order documents will need to self-register on this web site to gain access to the documents.

Softcopy Document

An electronic version of the specification and returnable schedules can be downloaded from this web site free of charge.

To obtain the provided specification and schedules from this web site download all the provided files by clicking on the "DOWNLOAD A SOFT COPY" link at the bottom of this page and following the on screen instructions.

Hardcopy Copy is not available for this Document

Submitting your response - Electronic Lodgement

When you have completed your response you can lodge it electronically via this Web Site.

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC Software requirements:

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe ® Acrobat Reader ® 8.0 (or more recent)

WinZip ® 10.0 (or more recent) or equivalent

Additional software may also be required, including the following, depending on the file types provided:

Microsoft Word 2010 (or more recent) or equivalent

Microsoft Excel 2010 (or more recent) or equivalent

Other requirements

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows – IE version 8 or later with Cipher Strength = 128bit.

Cookies.

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software

Still having problems?

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ” section under the On-line HELP button.


description: Cloud storage as a service

title: Live.NSW - AWS Migration

title: SS13960 - RFQ - Part-A - AWS Migration.pdf

title: Contract Departure Schedule - ICT Agreement ICTA.xlsx

title: TAB A - SS13960 - Scope of Work - AWS Migration.pdf

title: Appendix A - Bathurst Data Centre Infrastructure Analysis - Cloud Migration Assessment BTS.pdf

title: Appendix B - Working with Spatial Services.pdf

title: SS13960- RFQ - Price Schedule - AWS Migration.xlsx

title: Addendum 5.pdf

rationale:
Addendum #5 - Extension of Closing Date

Please refer to the attachment for details.

title: Addendum 3.pdf

rationale: Addendum 3 - Ammendment to close time and date.

title: Addendum 1.pdf

rationale: Addendum 1 - New procurement Contact Officer and response to clarification.

title: Addendum 4.zip

rationale: Addendum 4 - Response to questions.

title: Addendum 2.zip

rationale: Addendum 2 - Response to questions including new SS13960 - RFQ - Part-B - AWS Migration_V2.doc to replace SS13960 - RFQ - Part-B - AWS Migration.pdf

description: Live.NSW - AWS Migrationis seeking quotations from a suitably qualified vendor to assist with the preparation and migration of key Spatial Services (SS) workloads to the AWS cloud. This aligns with the NSW Government strategy of “cloud by default”. The existing SS data centre in Bathurst will be demolished as part of building renovations and it is imperative that the relevant infrastructure and workloads are properly migrated to ensure operational consistency for SS.

submissionMethodDetails: IMPORTANT NOTE: ONLY supplier submitting a response to this RFQ is listed as an advanced supplier on prequalification ICT Services Scheme (SCM00020) Category C01 – Data Centre Services


description: Environmental management

title: P22-4185 Tender Documents.zip

title: P22-4185 Additional Documents.zip

title: P22-4185 - Addendum 1 - Extension of close date.pdf

title: P22-4185 - Addendum 2 - Q and A.pdf

rationale: P22-4185 - Addendum 2 - Q and A

rationale: Changed location to Statewide

description:
P22-4185 - Captains Flat - WHS Occupational Hygienist On-Site Services

Occupational Hygienist develop an Occupational Health Management plan and Training staff for the red zone decontamination.

Scope

The tenderer is to provide a full occupational hygiene service that will allow SCS to focus solely on construction responsibilities. It is the intent of this engagement that all measures relating to design, implementation, monitoring & reporting within the occupational hygiene element of the works will be the sole responsibility of the successful tenderer.

Site Location

The Lake George Mine is located on the Western edge of the town of Captains Flat, approximately 52 km Southeast of Queanbeyan NSW. A site location diagram is provided as an attachment to the tender documentation.

All services must be provided at the site location being Corner Miner Rd. & Old Mines Rd. Captains Flat N.S.W. (GPS: -35.592425, 149.442101)

Delivery & Access

The site compound will be located in the North Western corner of the Northern dumps area. Access to the compound will be via the Northern dumps access gate opposite the intersection of Miners Rd. & Old Mines Rd. Gravel construction access only beyond this gate, suitable for light vehicles & rigid body trucks only.

Site access is via Old Mines Rd. & Captains Flat Rd. from Queanbeyan only. Call traffic control on UHF 17 on approach.

For the purposes of quoting the following is assumed:

Total project workers to be serviced: 20 – 40 project workers

Project duration: 18 months (72 weeks, 360 working days)

The number of workers & the duration of the engagement may increase & consideration needs to be given to service any such increases. Subject to approval, machine operators are to be managed via a dry decontamination process whilst ground crew are to be managed via a wet decontamination process.

The successful tenderer will be required to deliver the following items which are detailed below in the Requirements:

1.Preparation & delivery of the Occupational Hygiene induction package.

2.Provision of the relevant portions of & engagement in site inductions & ‘Take 5’s’ (toolbox talks) where required.

3.Provision of & collection & analysis of data from personal exposure & field air monitoring services to detect the presence of: asbestos, copper, lead, zinc, cadmium, arsenic & Respirable Crystalline Silica (RCS) particulates.

4.Health surveillance of SCS site staff, contractors & accredited visitors including: demographic, medical & occupational history; biological monitoring (where required); maintenance of site personnel exposure records.

5.Provision of mask fit training & testing.

6.Plant & equipment checking & clearance.

7.Occupational Hygienist field work relating to the above items.

The successful tenderer is to provide site staff to undertake various tasks relating to personnel health testing & monitoring, participation in site OH&S tasks (including training), the deployment of monitoring equipment, collection & collation of monitoring & testing data & on-site health monitoring & testing.

The successful tenderer is to be qualified and experienced in hygiene monitoring on contaminated sites.


description: Building maintenance and repair services

title: Minor Building Works

rationale: Update contact details

description:
Sydney Trains is seeking responses from experienced suppliers with demonstrated ability to meet its requirements to carry out minor building works across the network. Minor building works scope includes a variety of reactive, general maintenance services, including, but not limited to, carpentry, concreting, painting and plumbing. A full list of the required services is included within the Statement of Works. These services are critical to maintaining our assets, safety standards and customer satisfaction across the network.

The market approach is a multi-stage sourcing event for two separable portions, Separable Portion 1: Metro and Separable Portion 2: Regional. Stage 1 will be an Expression of Interest (EOI) to identify and subsequently shortlist capable suppliers for delivering the intended scope of services, followed by Stage 2 a Select Request for Tender (RFT). The Stage 2 Select Request for Tender (RFT) will seek further clarification of service methodology and pricing.

Identifiers:
Far North Coast
Mid North Coast
New England
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

submissionMethodDetails:
In order to gain access to the Expression of Interest documents, Tenderers are required to register their interest by sending an email to tss.bidder@transport.nsw.gov.au and include the following information:

1) Event Title, 2)EOI ID , 3) Organisation Name, 4) ACN/ ABN, 5) Contact Name, 6) Organisation/Contact Postal Address, 7) Contact Email Address (preferably an email address with the contact person's name), 8) Contact Phone number

To gain access to the EOI documents in Ariba over the internet once access is provided, please ensure that you are using PC with web browser:

• Google Chrome 54+ (64 –bit)

• Microsoft Internet Explorer 7-11(32-bit)

• Mozilla Firefox 24 or 27(ESR)

• Safari 9+ (64-bit)

 • Microsoft Edge (32-bit)


description: Highway and road construction services

title: RFT MSC Installations CRC.pdf

title: Schedule of Prices Package 1MSC Installations CRC.pdf

title: Tender Form CRC.pdf

title: Tender Commercial Docs CRC.zip

title: ANNEXURES G1 - D - SCOPE OF WORKS - EASTERN HARBOUR CITY - SOUTH.zip

title: ANNEXURES G1 - D - SCOPE OF WORKS - EASTERN HARBOUR CITY - NORTH.zip

title: RFT Preview Document

streetAddress: Suite 1a, Level 2, 802 Pacific Highway, Gordon

DM Roads

legalName: Downer EDI Works Pty Ltd

title: Addendum 1 22.0000139283.0130 CRC 1.pdf

title: R143  Signposting  MSC Installations.pdf

rationale: Addendum 1

title: Addendum 2 22.0000139283.0130 CRC.pdf

title: Scope of Works Centeral River City.zip

rationale: Addendum 2

description:
Transport for NSW is inviting suitably experienced, qualified and accredited Contractor to participate in the tender process for the Supply and Installation of Mobile Speed Camera (MSC) Fixed Signs – Central River City

This advertisement invites the submission of a tender from any organisation that meets the minimum participation requirements.

Supply and Installation of Mobile Speed Camera (MSC) Fixed Signs - Greater Sydney to fast-track priority installation to increase community awareness about the use of mobile speed cameras in NSW and remind motorists that they should not speed and could be detected anywhere at anytime.

In November 2020 the Government announced enhancements to the NSW MSC Program towards best practice and national consistency, proven to reduce road trauma.

The works to be carried out under this contract involve the site investigation, supply and installation of three different sizes of Mobile Speed Camera (MSC) Fixed Signs at various locations (Approximately 315 Signs across 3 packages) within Greater Sydney area including State and Local Roads as detailed in the Request for Tender. The works are to be installed near live traffic, pedestrians and businesses. The works are to be undertaken with appropriate traffic management, suitable for the adjacent traffic speeds, to ensure the safety of both workers and road users. The works under the contract is to be carried out with the least possible disruption to traffic, road users and communities.

Separate ROL (Road Occupancy Licences) applications need to be submitted for each site by contractors undertaking sign installation works.

All site investigation and potholing required ahead of work commences and during to identify any clashes with existing services.

The signage installations under overhead power lines is to be in accordance with Safe work NSW ‘Work near overhead power lines: Code of practice.

All sign installations, including supply of materials, plant, supervision, coordinating and sequencing required in the performance of the Works;

establishment and maintenance of all work sites including all mobilisation, demobilisation, clean-up and required amenities and on-site services;

Undertake all other activities and works necessary to complete the Works.

The Contractor general obligations include but are not limited to:

Providing a skilled team, which will work collaboratively with TFNSW, councils, utility companies and key stakeholders to deliver contract works in line with agreed documentations and programme requirements.

To successful participate in the tender process for the Project, organisations:

Must execute (to the satisfaction of TfNSW) the Confidentiality Deed Poll to receive the tender documents and must return to TfNSW via Tejas.Mistry@transport.nsw.gov.au by 5:00pm (AEST) Friday 11 February 2022

Must provide evidence of National Pre-qualification System for Civil (Road and Bridge) compliance with R1 level or greater.

Without any obligation to do so, where the integrity of the tender process is not compromised, TFNSW may determine (in its absolute discretion) that it is appropriate to consider a late tender submission.

All tenderers must comply with the NSW Government Procurement Policy Framework (NSW Framework), NSW Government Supplier Code of Conduct (NSW Code) and New South Wales Industrial Relations Guidelines: Building and Construction Procurement (NSW Guidelines).

Copies of the NSW Framework and NSW Code are available at www.buy.nsw.gov.au.  The NSW Guidelines are available at www.industrialrelations.nsw.gov.au.

Identifiers:
Cumberland/Prospect
Inner West
South East Sydney

addressForLodgement: "Electronic Lodgement Only"