description: direct Award from Scotland Excel Engineering and Technical Consultancy Framework 08-20 for the provision of Structural Assessment of Bridges in the Moray Area. Exercise was carried out as a direct award from SXL engineering and technical consultancy framework ref 0820

description: Moraywide

title: 180413 DA26 Structural Assessment of Bridges

description: Call off from Scotland Excel Engineering and Technical Consultancy Framework for the provision of Structural Assessment of Bridges for Moray

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

description: General public services

legalName: Moray Council

Mott MacDonald

postalCode: EH3 8EG

streetAddress: Caledonian House, 19A Canning Street

legalName: Mott MacDonald

Elgin Sherriff Court

postalCode: IV30 1BU

streetAddress: Sheriff Courthouse, High Street

legalName: Elgin Sherriff Court

description:
Award against framework: Engineering and Technical Consultancy
 (SC Ref:753886)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

rel: canonical

status: complete

description:
Provision of a Homecare Delivery Service to deliver Clotting Factors to patients in NHS Scotland. This includes the dispensing and delivery of the prescribed medicines along with ancillary products, as required, to patients in their homes or other agreed designated delivery points, and to provide removal of sharps containers as detailed within the specification contained within the tender documentation.
 The framework agreement was awarded as a unranked multi-supplier framework two (2) suppliers.

description: All entities constituted pursuant to the National Health Service (Scotland) Act 1978, and any Integrated Joint Boards established pursuant to the new Public Bodies (Joint Working) Scotland Act 2014.

region: UKM

scheme: CPV

title: Homecare Delivery Service for Clotting Factors

format: text/html

description: The provision of a Homecare Delivery Service within NHS Scotland to hospitals and patients' homes or other designated address.

documentType: awardNotice

scheme: CELEX

reviewDetails:
Economic operators should approach the contracting authority in the first instance. However, the only formal remedy is to apply to the courts:
 An economic operator that suffers, or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session.
 The bringing of court proceedings against the Authority after the Framework Agreement has been entered into will not affect the Framework Agreement unless grounds for the imposition of special penalties under the Public Contracts (Scotland) Regulations 2015 can be established. Otherwise the remedies that may be awarded by the courts where the Framework Agreement has been entered into are limited to the award of damages

procurementMethod: limited

mainProcurementCategory: goods

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: This VEAT notice is to advise the need for modification to meet the additional demands of the Scottish Health and Social Care sector during the current Covid-19 pandemic and to maintain necessary supply due to circumstances unforeseen by the Authority in line with Regulation 72(1)(c) of the Public Contracts (Scotland) Regulations 2015.

description: The procurement falls outside the scope of application of the directive

locality: Edinburgh

postalCode: EH12 9EB

streetAddress: Gyle Square (NSS Head Office), 1 South Gyle Crescent

scheme: COFOG

description: Health

Healthcare at Home

region: UK

locality: Burton-upon-Trent

postalCode: DE14 1SZ

streetAddress: 107 Station Street

scale: large

legalName: Healthcare at Home

LloydsPharmacy Clinical Homecare

locality: Harlow

postalCode: CM19 5GU

streetAddress: Scimitar Park, Roydon Road,

legalName: LloydsPharmacy Clinical Homecare

Sheriff Court House

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court House

currency: GBP

status: active

description:
The estimated value(s) of the Framework Agreement referred to in Section V.2.4 cover(s) the twelve (12) month duration of the proposed modification period of the Framework Agreement.
 (SC Ref:753853)

initiationType: tender

scheme: EU-OJ


name: King Communications and Security Limited

description: NAC/5050 CCTV Migration, Annual Maintenance, Repairs, Works and Minor Installations Service.

mainProcurementCategory: services

North Ayrshire Council

locality: Irvine

postalCode: KA12 8EE

streetAddress: Cunninghame House, Friars Croft

legalName: North Ayrshire Council

locality: Coatbridge

postalCode: ML5 4EG

streetAddress: Arca Business Centre, 8 South Caldeen Road

scale: sme

Kilmarnock Sheriff Court

locality: Kilmarnock

postalCode: KA1 1ED

streetAddress: Sheriff Court House, St Marnock Street

legalName: Kilmarnock Sheriff Court

rationale: Need for additional works, services or supplies by the original contractor/concessionaire: North Ayrshire Council use this contractor for all normal maintenance works and no other contractor can work on the system that is installed due to the training requirements.

description: The total contract value of this contract has increased as North Ayrshire Council require additional works from the same supplier.

description: (SC Ref:753882)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

description: Purchase of up to two further vehicles

description: Tactical Rope Rescue Vehicles

description: Throughout Scotland

title: Tactical Rope Rescue Vehicles

title: Tactical Rope Rescue Vehicles

description: Tactical Rope Rescue Vehicles

description: Tactical Rope Rescue Vehicles

reviewDetails:
Scottish Fire and Rescue Service (SFRS) must, by notice in writing as soon as possible after the decision has been made, inform all
 tenderers and candidates of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing
 system. The SFRS is obliged to comply with the regulations and any eligible economic operator can bring an action in the Sheriff Court or the Court of Session where as a consequence of a breach by the SFRS, they suffer or risk suffering loss or damage. The bringing of court proceedings and the remedies that are available to the courts are detailed in the regulations

procurementMethod: open

procurementMethodDetails: Open procedure

Scottish Fire and Rescue Service

locality: Cambuslang

postalCode: G72 7NA

streetAddress: Headquarters, Westburn Driv

description: Public order and safety

legalName: Scottish Fire and Rescue Service

Angloco Limited

locality: Batley

postalCode: WF17 5TA

streetAddress: Station Road

legalName: Angloco Limited

name: Glasgow Sheriff Court and Justice of the Peace Court

locality: Glasgow

postalCode: G5 9DA

streetAddress: Sheriff Clerk's Office, PO Box 23, 1 Carlton Place

description: (SC Ref:753902)


description: An optional phase 2 is available.

description: Specialist services

description: Scotland

title: NP504223b Gartner Negotiation support

title: NP504223b Gartner Negotiation support

description: Specialist services

description: Specialist services

roles: buyer centralPurchasingBody

description: Health

legalName: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

Gartner

locality: Egham

postalCode: TW20 9AH

streetAddress: Tamesis

legalName: Gartner

name: Edinburgh Sheriff Court, Sheriff Court House

postalCode: EH1 1DL

description:
Award against framework: GCloud
 (SC Ref:753915)


description: Extension of purchases form 24 up to 36 appliances

description: Light Pumping Appliances

description: Throughout Scotland

title: Light Pumping Appliances

title: Light Pumping Appliances

description: Light Pumping Appliances

description: Light Pumping Appliances

reviewDetails:
The Scottish Fire and Rescue Service (SFRS) must, by notice in writing as soon as possible after the decision has been made, inform all tenderers and candidates of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing system. The Service is obliged to comply with the regulations and any eligible economic operator can bring an action in the Sheriff Court
 or the Court of Session where as a consequence of a breach by the SFRS, they suffer or risk suffering loss or damage. The bringing of court
 proceedings during the standstill period means that the SFRS must not enter into the contract, conclude the framework agreement or
 establish the dynamic purchasing system unless the proceedings are determined, discontinued or disposed of: or the court, by interim order,
 brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and the remedies that are available
 to the courts are detailed in the regulations

Scottish Fire and Rescue Service

description: Public order and safety

Emergency One (UK) Limited

locality: Cumnock

postalCode: KA18 1SH

streetAddress: Block 4, Unit 1, Caponacre Industrial Estate

legalName: Emergency One (UK) Limited

legalName: Glasgow Sheriff Court and Justice of the Peace Court

description: (SC Ref:753894)


description: Purchase of Prisma Cloud through the Scottish Government Software Value Added Re-seller framework

title: RoS - SG SVAR - Prisma Cloud

title: RoS - SG SVAR - Prisma Cloud

description: strategic toolset for protecting cloud applications and workloads

procurementMethodRationale: Purchased through the Scottish Government Software Value Added Re-seller Framework

description: No tenders or no suitable tenders/requests to participate in response to open procedure

Registers of Scotland

postalCode: EH8 7AU

streetAddress: Meadowbank House, 153 London Road

description: General public services

legalName: Registers of Scotland

Computacenter (UK) Limited

locality: Hatfield

postalCode: SG18 0FL

streetAddress: Hatfield Business Park, Hatfield Avenue

legalName: Computacenter (UK) Limited

Scottish Procurement

streetAddress: Scottish Government

legalName: Scottish Procurement

description: (SC Ref:753921)


name: Funeral Services Limited T/A Co-op Funeralcare

description: Procurement of a supplier to provide public health funerals where there is no family or no funds available

title: PKC12589 National Assistance Funeral Service

description: Provision of public health funerals where there is no family or no funds available

procurementMethodRationale: Short term contract to cover period until new tendering exercise can be undertaken.

description: Additional deliveries by the original supplier ordered under the strict conditions stated in the directive

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

description: General public services

legalName: Perth & Kinross Council

locality: Manchester

postalCode: M60 0AG

streetAddress: 12th Floor, 1 Angel Square

Perth Sheriff Court

streetAddress: Tay Street

legalName: Perth Sheriff Court

description:
The value in this contract award notice is an estimate only and is not to be construed as a commitment of spend to the supplier.
 (SC Ref:753926)


description: Procurement of a supplier to carry out scour assessments in the Perth & Kinross Council area.

title: PKC12004 Scour Assessments Pack S2

title: PKC12004 Scour Assessments Pack S2

description: Provision of Scour Assessments for priority structures to inform future maintenance priorities.

procurementMethod: selective

procurementMethodDetails: Restricted procedure

Perth & Kinross Council

description: General public services

Jacobs (UK) ltd

postalCode: G2 7HX

streetAddress: 95 Bothwell Street

legalName: Jacobs (UK) ltd

description:
Award against framework: Engineering and Technical Consultancy
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Tenderers were asked what Community Benefits they would offer as part of their tender submission.
 (SC Ref:753934)


description: expenditure also includes emergency breakdown, parts and onsite labour, however cannot be quantified at this time. Expenditure advised is estimated at this time

description: School of Life Sciences, University of Dundee

title: Termed Agreement for the Provision of Service & Maintenance of N2 Generators installed within the School of Life Sciences

description: Termed Agreement for the Provision of Service & Maintenance of Nitrogen Generators installed within the School of Life Sciences Laboratories

procurementMethodRationale: Specific product/service is required for technical reasons to meet existing infrastructure/system or for reasons of continuity

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

University of Dundee

locality: Dundee

postalCode: DD1 4HN

streetAddress: Procurement, 3rd Floor, Tower Building, Nethergate

description: Education

legalName: University of Dundee

mb air systems ltd

locality: Wishaw

streetAddress: 149 glasgow road

legalName: mb air systems ltd

Dundee Sheriff Court

streetAddress: Sheriff Court House, 6 West Bell Street

legalName: Dundee Sheriff Court

description: (SC Ref:753935)


description: PRINCE 2 Foundation Training for Place Services staff at Social Security Scotland.

description: Virtual Training Course, delivered on Teams.

title: PRINCE 2 Foundation Training

title: PRINCE 2 Foundation Training

description: PRINCE 2 Foundation training for Place Services staff.

procurementMethodRationale: Training was purchased as a call off from the PROJECT DELIVERY TRAINING FRAMEWORK

Social Security Scotland

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House, 17 South Union Street

id: Ministry or any other national or federal authority, including their regional or local subdivisions

description: General public services

legalName: Social Security Scotland

Elite Training & Consultancy

postalCode: G2 2RQ

streetAddress: 144 West Regent Street

legalName: Elite Training & Consultancy

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

description: (SC Ref:753944)


name: Stirling District Citizens Advice Bureau Limited

description: This procurement is concerned with the purchase of a service led by Citizens Advice Bureau (CAB) to provide unpaid carers with support and financial health checks. This in turn informs, enables and empowers unpaid carers to know their rights, to be healthier, happier, and financially better off so they can continue in their caring role. All of which are encompassed by the HSCP’s key priorities and principles as laid out within the HSCP’s Strategic Commissioning Plan.

description: Stirling

title: Continuation of Unpaid Carers Specialist Welfare Rights

procurementMethodRationale:
This contract award is in line with Section 12 of the Procurement Reform (Scotland) Act and follows the Guidance on the Procurement of Care and Support Services (Best Practice) 2016 - section 8.12.
 The award is made on the basis of:
 1.	This requirement will provide advice and support, which constitutes as early intervention and preventative support. Evidence suggests that investing in such projects where support is provided early enough, this in turn unlocks savings from long term care and support packages by reducing the need for such packages;
 There are no pre-existing contracts or framework agreements which can meet the requirement;
 The provider is well established and have/are supporting a significant number of unpaid carers for whom this advice is essential to enable them to fulfil their caring roles more effectively to improve their wellbeing and quality of life.

description: The procurement falls outside the scope of application of the directive

Stirling Council

roles: buyer centralPurchasingBody mediationBody reviewContactPoint

locality: Stirling

postalCode: FK8 2ET

streetAddress: Room 41, Old Viewforth

description: General public services

legalName: Stirling Council

postalCode: FK8 2DX

streetAddress: Norman macEwan Centre for Voluntary Organisations, 3 Cameronian Street

Stirling Sheriff Court

legalName: Stirling Sheriff Court

description: (SC Ref:753947)


description: Consultancy to provide an end-to-end student recruitment service from early engagement all the way through to enrolment via IDP’s experts and experienced counsellors.

title: Student Recruitment Consultancy

title: Student Recruitment Consultancy

procurementMethodRationale: The IDP Core offers a range of services and support that can only be purchased through IDP Connect and are unavailable through any other third-party provider. These services dovetail with wider institutional recruitment activity. Unique services include regular stats, data, analysis and review in addition to IDP briefings and market intelligence reports, access to the IDP IQ Demand tool, multimedia content across IDP Connect platforms, enhanced content in the IDP app and access to the Ask IDP engagement tool.

University of Aberdeen

locality: Aberdeen

postalCode: AB24 3FX

streetAddress: University Office, King's College

description: Education

legalName: University of Aberdeen

IDP Connect

locality: London

postalCode: SW6 3JW

streetAddress: Bedford House, 69-79 Fulham High St

legalName: IDP Connect

Aberdeen Sheriff Court

legalName: Aberdeen Sheriff Court

description: (SC Ref:753948)


description: Direct Award off Scotland Excel Reference 1821 for Electrical Testing and Maintenance of 350 properties.

description: Moray

title: 180627 DA02 Electrical Testing and Maintenance x350

description: Call off from Scotland Excel Engineering and Technical Consultancy Framework for the provision of Property Maintenance and Refurbishment.

mainProcurementCategory: works

procurementMethodRationale: The Procurement was carried out as a Direct Award from Scotland Excel Framework Schedule 1821 for Property Maintenance and Refurbishment.

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

description: General public services

legalName: Moray Council

Summit Facilities Services Ltd

postalCode: DD5 3RX

streetAddress: Unit N, Scottway, Pearce Avenue, West Pitkerro Industrial Estate, Broughty Ferry

legalName: Summit Facilities Services Ltd

Elgin Sheriff Court

postalCode: IV30 IBU

streetAddress: Sheriff Courthouse, High Street

legalName: Elgin Sheriff Court

description: (SC Ref:753961)


description:
River Clyde Homes (RCH) are seeking to employ a suitably experienced and competent company to carry out comprehensive Health and Safety / Evacuation Audits to properties and spaces across our portfolio. The work and output reports will include the following requirements:
 Carry out a comprehensive on-site survey and produce a report on all buildings externals and sites listed in the pricing schedule (Appendix D) including all the open spaces areas relating to H&S risks / evacuation routes to a nominated place of safety [as defined in the Technical Standards]. OS survey type plans of the individual spaces will be provided.
 Such reporting will also comment on positions and escape routes and likely fire fighting set down areas and fire hydrant locations from and to the final exits/entrances of the building of which includes from; multi-storey blocks, sheltered housing complexes, commercial premises, low rise flatted dwelling blocks, low rise terraced type properties with shared estate pathways and carparks to a known or suggested safe nominated assembly point.
 Such will include any RCH factored pathways, lanes, etc. Including but not limited to ramps, stair landings etc., any street furniture to the common open spaces, whether or not within the escape route. Reference open spaces, bidders shall include for sketching up on a block location
 .
 Consideration of the condition and suggested repair strategy for any action required in terms of H&S of any surveyed evacuation route including common or individual escape route to a place of safety should also be highlighted, the reporter will prepare a format of reporting category.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.

Methodology & Approach

type: quality

type: price

variantPolicy: notAllowed

description: Inverclyde

title: Health and Safety / Evacuation Audits

title: Health and Safety / Evacuation Audits

documentType: contractNotice

documentType: technicalSelectionCriteria

title: RCH577 - Health & Safety Evacuation Audits Tender Document

title: SPD Guidance Document

title: RCH577 - Appendix A - SPD

title: RCH577 - Appendix B - Tender Response Document

title: RCH577- Appendix C - Pricing Schedule

title: RCH577 - Appendix D - Contract Ts & Cs

title: RCH577 - Appendix E - Certification

title: RCH577 - Appendix F - Data Protection Checklist

electronicInvoicingPolicy: allowed

type: suitability

description: It is a requirement that companies must hold a current accreditation to either BAFE SP205 or Warrington FRACS accredited schemes and be able to evidence such UKAS certification to that effect.

type: economic

description:
SPD question 4B.5.1
 It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers Liability Insurance = 5m GBP
 Bidders should indicate whether they hold the required cover in the table provided within the SPD
 SPD question 4B.5.2
 It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Professional Indemnity Insurance = 5m GBP
 Bidders should indicate whether they hold the required cover in the table provided within the SPD.
 SPD Question 4B.6
 The bidder’s company name and registration number will be used to obtain a financial risk assessment report from Dun & Bradstreet. Only companies, that are deemed to be financially stable by RCH’s Finance Department, on the strength of their financial report will be eligible to be a party to the contract. It is the tenderers responsibility to ensure that the information held by Dun & Bradstreet is up to date at the time of submission. If you prefer to have this assessment carried out in respect of a guarantor, such as an ultimate parent body, then you may elect for this option and details of the guarantor should be provided. Bidders should provide their company registration number in the space provided in the SPD.

River Clyde Homes

locality: Greenock

postalCode: PA15 2UZ

streetAddress: Clyde View, 22 Pottery Street

description: Housing and community amenities

legalName: River Clyde Homes

Greenock Sheriff Court House,

postalCode: PA15 1TP

streetAddress: 1 Nelson St, Greenock

legalName: Greenock Sheriff Court House,

description:
Tenders must be submitted electronically via the Public Contracts Scotland (PCS) Electronic Tender Post Box. Any response not submitted via the post box will not be considered. Any questions in relation to the tender must be raised via the 'Question & Answer' function of the PCS website.
 Tenderers should ensure they read and understand the SPD guidance document attached to the contract notice prior to submitting a bid.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=753946.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:753946)


description: The contract will be for an initial period of 24 months, with the option to extend for up to further three periods of 12 months each at the sole discretion of Bòrd na Gàidhlig.

description:
KEY TASKS
 The key tasks within this support will be divided into three sections; Data Protection, Information and Records Management, Freedom of Information.
 Data Protection
 This service will provide the role of a Data Protection Officer (DPO) who must be expert, autonomous and free from conflict of interest.
 The DPO will:
 - inform and advise BnG and our employees about our obligations to comply with the UK GDPR and other data protection laws;
 - monitor compliance with the UK GDPR and other data protection laws, and with our data protection polices, including managing internal data protection activities; raising awareness of data protection issues, training staff and conducting internal audits;
 - advise on, and to monitor, data protection impact assessments;
 - cooperate with the supervisory authority;
 - and to be the first point of contact for supervisory authorities and for individuals whose data is processed (employees, customers etc). One key task for the DPO will be assisting officers in ensuring data protection compliance within published data and research documents.
 Information & Records Management
 Bòrd na Gàidhlig recognises that efficient and effective management of its records is necessary to support its core functions and activities, to comply with its legal and regulatory obligations and to contribute to the effective overall management of the organisation. Bòrd na Gàidhlig now seeks a service to ensure the organisation is managing its information and records efficiently whilst meeting the requirements of Public Records (Scotland) Act 2011 (PRSA) and other relevant legislation. Working with the Office Manager, the service provider will identify areas for improvement in information management and produce guidelines as necessary. They will also give practical support in raising awareness of retention schedules; document naming and versioning guidance; and other records management policies and procedures required for Public Records (Scotland) Act 2011 compliance within the Microsoft 365 suite of applications including SharePoint. The tender should include the cost for a training session to ensure all staff have an understanding of the operational requirements.
 Freedom of Information
 As a publicly funded organisation, Bòrd na Gàidhlig is committed to complying fully with the Freedom of Information (Scotland) Act 2002. In 2022/23 we received ten Freedom of Information requests, compared with seven in the previous financial year. The successful service provider will advise BnG staff with specific challenging requests, and on any policy and procedure development.. The anticipated time allocation is expected to be circa 1.5 days per month.
 The working language of the organisation is Gaelic. All policies and key employment documentation are available bilingually and a translation service is provided.

title: Information Governance Support

title: Tender Specification Document

format: application/pdf

title: Information Governance Support

description: Bòrd na Gàidhlig (BnG) is seeking a service provider to assist the Corporate Services function of the organisation to comply with the requirements of information governance legislation including UK data protection legislation, the Freedom of Information (Scotland) Act 2002 and the Public Records (Scotland) Act 2011.

title: Tender Specification Document

languages: en gd

Bord na Gaidhlig

locality: Inverness

postalCode: IV3 8NW

streetAddress: Great Glen House

legalName: Bord na Gaidhlig

Inverness Sheriff Court

postalCode: IV1 1AH

streetAddress: Longman Road

legalName: Inverness Sheriff Court

title: Information Governance Support

documentType: plannedProcurementNotice

description:
Bòrd na Gàidhlig (the Bòrd) is an executive Non-Departmental Public Body established under the Gaelic Language (Scotland) Act 2005. It is the principal body in Scotland responsible for promoting Gaelic development and providing advice to the Scottish Ministers on Gaelic matters, including education.
 The Bòrd’s vision is that Gaelic is seen and heard daily across Scotland, such that it is widely recognised as an integral part of Scottish life and as a national cultural and economic asset.
 Much of the Bòrd’s work focuses on developing and overseeing the National Gaelic Language Plan, together with assisting the development and monitoring of Gaelic Language Plans by public authorities.
 Bòrd na Gàidhlig works to promote Gaelic in partnership with the Scottish Government, Local Authorities, Public Bodies, delivery partners, and communities. The National Gaelic Language Plan 2018-23 positions learning as one of the three priorities, with the opportunities and challenges for developing Gaelic education and learning clearly set out.
 Bòrd na Gàidhlig has statutory educational responsibilities under the 2005 Gaelic Language (Scotland) Act and the 2016 Education (Scotland) Act.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=754091.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:754091)


name: Stantec UK (formerly Peter Brett Associates)

description: Appraisal and modelling works related to bus priority

title: CT2675/SOC562 BPF Accelerated Schemes

title: CT2675/SOC562 BPF Accelerated Schemes

The City of Edinburgh Council

locality: EDINBURGH

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

locality: Edinburgh

postalCode: EH2 4QZ

streetAddress: 3rd Floor, Randolph House, 4 Charlotte Lane

Sheriff Court

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court

description:
Award against framework: Professional Services Framework
 (SC Ref:753998)


description: Procurement of mini buses under the TPPL framework Bus framework, Lot 1.

title: Award of Mini Buses- East Lothian Council

description: Procurement of mini buses under the TPPL/BNES framework Bus framework, Lot 1.

East Lothian Council

locality: Haddington, East Lothian

postalCode: EH41 3HA

streetAddress: John Muir House

description: General public services

legalName: East Lothian Council

Trust Ford

locality: Dagenham

postalCode: RM9 6FF

streetAddress: Messina Way

legalName: Trust Ford

description:
Award against framework: TPPL/BNES Bus Framework
 (SC Ref:754032)


description: Hardware Support & Maintenance along with relevant Flex Software licensing.

title: Netbackup Support Renewal

title: Netbackup Support Renewal

Scottish Police Authority

locality: Glasgow

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

Softcat Plc

locality: Marlow

postalCode: SL7 1LW

streetAddress: Thames Industrial Estate, Fieldhouse Lane

legalName: Softcat Plc

Glasgow Sheriff Court

postalCode: G5 9DA

streetAddress: 1 Carlton Place

legalName: Glasgow Sheriff Court

description:
Award against framework: Technology Products & Associated Services
 (SC Ref:753965)


description: The duration of the Framework Agreement will be for two (2) years with the option to extend the Contract for a further one (1) periods of up to twelve (12) months at the sole discretion of the Authority.

title: Secure Storage Container Furniture

title: Secure Storage Container Furniture

description:
The Scottish Police Authority (known as the “the Authority”) has set up a Framework Agreement to procure Secure Storage Container Furniture.
 Authority is

Scottish Police Authority

description: Public order and safety

Axis Storage Solutions Limited

locality: Hamilton

postalCode: ML3 6JT

streetAddress: 12 Auchingramont Road

legalName: Axis Storage Solutions Limited

description: (SC Ref:754031)


description: the contract will run for 12 months plus and additional 2x 12 months

description: SCTS need an e-signature software in order to formalise contracts. the software must provide an automated workflow, tracking and storage of contract

title: Provision Of e-Signature Software

title: Provision Of e-Signature Software

description: SCTS require an e-signature software to formalise all contracts. the software must have the capability to automate workflow, track signature and store letters

Scottish Courts and Tribunals Service

postalCode: EH11 3XD

streetAddress: Saughton House, Broomhouse Drive, Edinburgh

description: General public services

description: Public order and safety

legalName: Scottish Courts and Tribunals Service

Computacenter

postalCode: EH12 9DQ

streetAddress: Haston House, Redheughs Rigg

legalName: Computacenter

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

description:
Award against framework: Software Value Added Reseller Services
 (SC Ref:754090)


description: This contract allows access to Pitchbook for a period of two years.

title: Access to Pitchbook

title: Access to Pitchbook

description: Computacenter have engaged Pitchbook to allow us access to the system

Scottish National Investment Bank

postalCode: EH1 3EG

streetAddress: 1-North, Waverley Gate, 2-4 Waterloo Place

legalName: Scottish National Investment Bank

description:
Award against framework: Scottish Government SVAR framework
 (SC Ref:754107)


description: In-app documents provides unique capabilities in using SharePoint online as the data source, as most matter management solutions are standalone platforms. This allows us to leverage our investment in SharePoint and minimise the additional costs to licence a matter management platform. Intapp Documents manages and protects case and email information within Microsoft 365 / SharePoint by extending the capabilities to help easily manage cases

title: Document management on sharepoint

title: Document management on sharepoint

Oyster IMS

postalCode: E1 8PY

streetAddress: The Loom, 14 Gower's Walk

legalName: Oyster IMS

description:
Award against framework: g cloud 13
 (SC Ref:754111)


description: Software required to enable creative processes in SCTS

title: Provision of Adobe License

title: Provision of Adobe License

description: Software required to enable creative Processes within SCTS

Scottish Court Service

description: General public services

legalName: Scottish Court Service

description:
Award against framework: Software Value Added Reseller Services
 (SC Ref:754082)


description: The Contracting Authority reserved the right to purchase additional products under this call-off contract and has exercised its right to do so. This notice is issued on a transparency basis for the additional purchase.

description: The University has awarded a contract for Dell 2-in-1 Laptops (UOS-26813-2023). This was conducted through a simplified mini-competition (price-only) on the Framework for Technology Products & Associated Services - Reference RM6068, Lot 2: Hardware and Associated Services as awarded by the Crown Commercial Service (CCS).. The call-off contract was procured using a simplified competition (price only) as set out in the Technology Products & Associated Services (RM6068) framework Buyer Guide.

description: University of Strathclyde

title: Call Off from Crown Commercial Service's (CCS) Technology Products and Associated Services Framework (RM6068)

procurementMethodRationale: Please note that this is a transparency contract award notice in relation to this Call-Off Contract. This procurement followed the call off procedure for a simplified competition (price only) in relation to the framework for Technology Products & Associated Services, Ref. RM6068 as awarded by CCS.

description: The procurement falls outside the scope of application of the directive

University of Strathclyde

postalCode: G1 1QE

streetAddress: McCance Building, 16 Richmond Street

description: Education

legalName: University of Strathclyde

Dell Corporation Limited

postalCode: EC3A 5AF

streetAddress: 1st & 2nd Floor One , Creechurch Place

legalName: Dell Corporation Limited

description:
Award against the CCS's Framework: Technology Products & Associated Services, RM6068, Lot 2: Hardware and Associated Services. As stated in the procurement documents and the award notice published 14 July 2023, the contracting authority reserved the right to make additional purchases. This contract notice is published on a transparency basis for this additional purchase.
 (SC Ref:754125)


description: Education Scotland is seeking to appoint a suitably qualified specialist as a Glow Blogs Product Owner.. The initial contract period is three months. The contract may be extended by up to a further 20 months.

title: Interim IT Staff Services - Glow Blogs Product Owner

procurementMethodRationale: The contract was awarded under the call-off conditions of the Scottish Government framework for Interim IT Staff Services (Ref SP-22-002) as a direct award to the first ranked supplier.

Education Scotland

locality: Livingston

postalCode: EH54 6GA

streetAddress: Denholm House, Almondvale Business Park

description: Education

legalName: Education Scotland

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

legalName: Venesky Brown Ltd

Livingston Sheriff Court

postalCode: EH54 6FF

streetAddress: Civic Centre, Howden Road South

legalName: Livingston Sheriff Court

description: (SC Ref:754116)


description: Provision of IT Service Management Software. This contract was awarded under the call-off conditions of Crown Commercial Service G-Cloud 13.

title: IT Service Management Software

title: IT Service Management Software

description: IT Service Management Software

description: IT Service Management Software

Education Scotland

description: Education

House on the Hill Software Ltd

locality: Stockport

postalCode: SK6 6AF

streetAddress: 127 Stockport Road, Marple

legalName: House on the Hill Software Ltd

description: (SC Ref:754127)


description: SCTS requires a docking station to for colleagues working from home to connect all devices through one piece of hardware.

title: Provision of Docking stations

title: Provision of Docking stations

description: SCTS is looking for the Docking stations to allow colleagues who work from home to connect all devices through one system.

Scottish Courts and Tribunals Service

description: General public services

description: Public order and safety

Insight Direct (UK) Ltd

postalCode: EH10 5AL

streetAddress: 9 Merchiston Crescent

legalName: Insight Direct (UK) Ltd

description:
Award against framework: Technology Peripherals and Infrastructure Framework Agreement
 (SC Ref:754104)


description: The University has awarded a contract for Software and Related Services for IPAM,including Support & Maintenance (UOS-30796-2023). This was conducted through a call-off on the Framework for Software Value Added Reseller Services (SVARS) - Reference SP-21-034, as awarded by the Scottish Government.

description: University of Strathclyde

title: Call-off from Scottish Government Software Value Added Reseller Services Framework (SVARS)

description: The University has awarded a contract for Software and Related Services for IPAM, including Support & Maintenance (UOS-30796-2023). This was conducted through a call-off on the Framework for Software Value Added Reseller Services (SVARS) - Reference SP-21-034, as awarded by the Scottish Government.

reviewDetails: An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 (SSI2015/446) (as amended) may bring proceedings to the Sheriff Court or the Court of Session.

procurementMethodRationale: Please note that this is a transparency contract award notice in relation to this call-off contract. This procurement followed the call-off procedure for a direct award in relation to the Framework for Software Value Added Reseller Services (SVARS), Ref. SP-21-034 as awarded by the Scottish Government.

University of Strathclyde

description: Education

Computacenter (UK) Limited

locality: Hatfield

postalCode: SG18 0FL

streetAddress: Hatfield Business Park, Hatfield Avenue

legalName: Computacenter (UK) Limited

description:
Award against Framework: Software Value Added Reseller Services (SVARS), SP-21-034
 (SC Ref:754134)


description:
Social Security Scotland required Test Management Software which incorporates the significant Testing collateral developed & being utilised for functional manual and automated test execution.
 The software requirements meets all Scottish Government data storage requirements. It is also accommodates a growing number of projects, users, integrations, and test collateral. It also includes provision for on-going support and training that will include but not be limited to users guides, knowledge bases, reliable customer support and clear escalation process for issues.

title: Provision of Test Software

title: Provision of Test Software

Social Security Scotland

locality: Dundee

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House, 17 South Union Street

description: General public services

legalName: Social Security Scotland

Computacenter (UK) Ltd

postalCode: AL10 9TW

streetAddress: Hatfield Avenue

legalName: Computacenter (UK) Ltd

description:
Award against framework: Software Value Added Re-seller Framework (SP-21-034)
 This contract is for 1 year with 2 x 12 months extension options (1+1+1)
 The contract was awarded through Direct Award call-off from the Scottish Government sole supplier Framework 'Software Value Added Reseller Framework (SP-21-034)'
 (SC Ref:754138)


description:
The Scottish Police Authority had a requirement for the Cellebrite Software Licences Subscription Renewal
 A Mini-Competition exercise was carried out under the Northants Police, Dynamic Purchasing System, Digital Tools Equipment Development (DiTED), Lot 3a, Evidence examination/analysis – Products for use by a Digital Unit,
 2019/S 019-040362

description: Police Scotland, 2 French Street, Glasgow, G

title: PROC-23-2389 - Cellebrite Software Licences Subscription Renewal

description: A Mini-Competition was carried out under the Northants Police, Dynamic Purchasing System, Digital Tools Equipment Development (DiTED), Lot 3a, Evidence examination/analysis – Products for use by a Digital Unit, 2019/S 019-040362

Scottish Police Authority

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

Cellebrite UK Ltd

postalCode: London

streetAddress: Cellebrite Limited  |  Metro Building, 1 Butterwick, London W6 8DL, United Kingdom

legalName: Cellebrite UK Ltd

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description:
Award against framework: Northants Police ICT VAR
 (SC Ref:754139)


description:
The Council has a legislative requirement to provide and deliver advocacy services for people living in West Dunbartonshire who require it, many of whom have complex needs. This can relate to people with significant or enduring health needs and disabilities. Services can be provided using various models of support; one of which is independent advocacy services.
 The main focus of the service will be to support individuals with independent professional advocacy which adheres to the standards and principles for Independent Professional Advocacy as outlined by Scottish Independent Advocacy Alliance (SIAA). This role is to inform, empower and represent the interests of individual service users to improve access to health and social care services and to improve health and social care outcomes.
 The provider must be independent of other third and statutory service providers. Independent advocates must be able to work with people living in West Dunbartonshire and must be experienced in acting independently and without conflict of interest. Further to the terms and conditions stated within the Contract, the Provider is required to comply with the requirements detailed in the Service Specification.

description: West Dunbartonshire

title: Independent Advocacy Services for Adults (aged 16 and over – including over 65)

West Dunbartonshire Council

locality: Dumbarton

postalCode: G82 1QL

streetAddress: 16 Church Street

description: General public services

legalName: West Dunbartonshire Council

Lomond & Argyll Advocacy Service

postalCode: G82 1RH

streetAddress: 155 Glasgow Road, Dumbarton

legalName: Lomond & Argyll Advocacy Service

name: Dumbarton Sheriff Court and Justice of the Peace Court

postalCode: G82 1QR

description: (SC Ref:754278)


description: Up to 12 weeks contract extension.

description: Direct award via the 1st ranked framework supplier to appoint one temporary worker as described above. The contract will be for 6 months from 3rd January - 28th June 2024, with the option to extend the contract for up to an additional 12 weeks.

title: Temporary Evidence Co-ordination Manager

description: One temporary worker to work closely with the Evidence and Review Manager and Records Manager to plan and execute tasks to ensure delivery of information to the Scottish Child Abuse Inquiry.

Scottish Government

roles: buyer reviewBody mediationBody reviewContactPoint

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

description: General public services

legalName: Scottish Government

Venesky-Brown Recruitment

streetAddress: 4A Rutland Square

legalName: Venesky-Brown Recruitment

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

description:
Award against framework: Admin, Catering & Manual Staff Services - South
 (SC Ref:754287)


measure: lowestValidBidValue

measure: highestValidBidValue

description: Appointment of a Main Contractor for the delivery of the design, construction and fit-out of the Food Hub for Innovation (Food Hub). Food Hub is a 7.7 million GBP construction project to accelerate growth and build on the strengths of the food industry cluster in the North East of Scotland. This will be a 2 stage design and build contract.

description: Technical and professional ability: Three recent projects of a similar size and scope.

description: Sunnybrae, Nr Aberdeen Airport, Aberdeen, Scotland

title: Food Hub - Appointment of Main Contractor

description: Appointment of a main contractor for the design, construction and fit out of the Food Hub for Innovation (Food Hub). The Food Hub is a 7.7 million GBP construction project to accelerate growth and build on the strengths of the food industry cluster in the North East of Scotland. This will be a 2 stage design and build contract.

title: Food Hub (NES) Ltd Main Contractor - Information Notice

performanceTerms: The Contract will include performance conditions relating to fair working practices and community benefits.

description: If required by the member state, the Candidate must be registered or enrolled in the relevant professional or trade register kept in the Member State of its establishment (as described in Schedule 5 of the Public Contracts (Scotland) Regulations 2015).

description:
ESPD 4B.1.2 Turnover - Tenderers will be required to have an average yearly turnover of a minimum of 16 million GBP for the last two complete financial years.
 ESPD 4B.5.1 and 4B.5.2 Insurance - It is a requirement of this contract that Tenderers hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers (Compulsory) Liability - a minimum of 10 million GBP any one event and unlimited in the period.
 Public Liability - a minimum of 5 million GBP any one event and unlimited in the period. Insurance to be maintained from the commencement of services until the completion of services.
 Professional Indemnity - a minimum of 10 million GBP any one event. PI Insurance to be maintained from the commencement of services until the expiry of 12 years from practical completion.

type: technical

description: ESPD 4C.1.2 Tenderers will be required to provide examples that demonstrate that they have the relevant experience to deliver the services/supplies as described in part ll.2.4.

Food Hub (NES) Limited

locality: Aberdeen

postalCode: AB15 4YD

streetAddress: 11 Queens Gardens

legalName: Food Hub (NES) Limited

Food Hub (NES) Ltd

legalName: Food Hub (NES) Ltd

Robertson Construction Eastern Limited

postalCode: AB16 6NB

streetAddress: Whitemyers Avenue, Mastrick

legalName: Robertson Construction Eastern Limited

Aberdeen Sheriff Court

legalName: Aberdeen Sheriff Court

description:
ESPD to be completed in line with the requirements set out in the Information Notice. The latest ESPD can be accessed on the procurementjourney.scot website (route 3) or by going to:
 https://www.procurementjourney.scot/espd/espd-documents
 Suppliers should note that this a voluntary PCS notice. Food Hub (NES) LTD is not a contracting authority for the purposes of the Scottish public procurement rules. This contract is being openly tendered so as to demonstrate value for money for the public sector funding Food Hub (NES) LTD has been granted for the design, construction and fit-out of the new Food Hub for Innovation.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 The Contracting Authority does not intend to include a sub-contract clause as part of community benefits (as per Section 25 of the Procurement Reform (Scotland) Act 2014) in this contract for the following reason:
 The successful bidder shall be required to ensure that all contracts with Subcontractors and Suppliers procured following the Commencement Date, and which the Contractor has not, before the date of this Contract, already planned to award to a particular Subcontractor or Supplier, are awarded following a fair, open, transparent and competitive process proportionate to the nature and value of the contract. Bidders are encouraged to achieve this through advertising on the Public Contracts Scotland procurement portal(www.publiccontractsscotland.gov.uk) or by other agreed routes.
 Community benefits are included in this requirement. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2361
 A summary of the expected community benefits has been provided as follows:
 Food Hub (NES) LTD intends to include Community Benefits clauses in the contract. Information in regards to the particular Community Benefits sought will be contained within the initial ITT released to Candidates selected to tender. Themes may include Fair Working Practices, development of the supply chain / SME's and Employment, Education and Training.
 (SC Ref:620252)
 (SC Ref:731691)


title: Programmable 1 MW 4Q Power Supply

title: Programmable 1 MW 4Q Power Supply

description:
The Contracting Authority reserves the right to request additional deliveries by the Successful Tenderer, either intended as partial replacement of suppliers or installations or as extensions of existing supplies and installations.
 The Contracting Authority may at it's sole discretion exercise this option.

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 1.1.

Cost

type: cost

title: Programmable 1 MW 4Q Power Supply

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 1.2.

title: Programmable 1 MW 4Q Power Supply

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 1.3.

title: 1MW DC Power Supply Unit (PSU)

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 2.

title: Small Environmental Chamber

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 3.1.

title: Small Environmental Chamber (Temperature/Humidity/Pressure)

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 3.2

title: Large Environmental Chamber (Temperature/Humidity/Vibration)

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 3.3.

title: High Speed Dynamometer with 4Q converter and Low Speed Dynamometer with 4Q converter

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 4.1.

title: High Speed & Low Speed Dynamometers with integrated 4Q converter

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 4.2.

title: High Speed Dynamometer with 4Q converter and Low Speed Eddy Current Dynamometer

description: Contract scope includes; supply, delivery, commissioning and ongoing support and warranty of the above equipment. Tenderers should note that the proposed site is yet to be confirmed, however it is highly probable that it will be a new site, meaning the awarded supplier will be required to cooperate with the main building contractor during the commissioning process.. Potential Tenderers should note that the lot referencing is a locked function on the notice and cannot be amended. Within the tender documentation, this is categorised as lot 4.3.

title: PNDC Propulsion & Power Train Accelerator

description:
Founded by the University of Strathclyde, Scottish Power Energy Networks and SSE Power Distribution, with support from Scottish Enterprise and the Scottish Funding Council, the Power Networks Demonstration Centre (PNDC), recently secured funding from the ISCF DER challenge fund to be spent on equipment which enhances PNDC’s capability in the aerospace, marine and transport sectors.
 The equipment will be additional to the current infrastructure at PNDC, and must be connected to/utilise the current infrastructure to provide the enhanced capability.
 The requirement for equipment has been split into lots as detailed in the procurement documents.
 Tenders should note that the Contract is divided into four parent lots:
 Lot 1 - Programmable 1 MW 4Q Power Supply
 Lot 2 - DC Power Supply Unit
 Lot 3 - Environmental Chamber
 Lot 4 - High Speed & Low Speed Dynos
 Lots 1, 3 and 4 have three possible configurations, the ITT is divided in ten (10) sublots.
 Tenderers should note that, at a maximum, four contracts may be awarded under this Contract.

description:
The Contract award relates to a contact to procure equipment for the Power Networks Demonstration Centre (PNDC). funding was secured from the ISCF DER challenge fund to be spent on equipment which enhances PNDC’s capability in the aerospace, marine and transport sectors.
 The equipment will be additional to the current infrastructure at PNDC, and must be connected to/utilise the current infrastructure to provide the enhanced capability.
 The requirement for equipment was split into lots as detailed in the procurement documents.

reviewDetails: An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland)Regulations 2015 (SSI2015/446) (as amended) may bring proceedings in the Sheriff Court or the Court of Session.

description:
4B.5.1A - the Tenderer must maintain Professional Risk Indemnity insurance in the sum of not less than GBP2,000,000 in respect of any one incident and unlimited as to numbers of claims.
 4B.5.1b - the Tenderer must maintain Employer's (Compulsory) Liability insurance in the sum of not less than GBP10,000,000 in respect of any one incident and unlimited as to numbers of claims.
 4B.5.2 - the Tenderer must maintain Public Liability insurance in the sum of not less than GBP10,000,000 in respect of any one incident and unlimited as to numbers of claims.
 4B.5.2 - the Tenderer must maintain Product Liability insurance in the sum of not less than GBP10,000,000 in respect of any one incident and unlimited as to numbers of claims.

description: 4C.1.2 Bidders will be required to provide five (5) examples that demonstrate that they have the relevant experience to deliver the services/supplies as described in part II.2.4 of the Contract Notice or the relevant section of the Site Notice.

University of Strathclyde

postalCode: G1 1QE

streetAddress: 40 George Street, Procurement Department

description: Education

legalName: University of Strathclyde

Glasgow Sheriff Court

postalCode: G5 9DA

streetAddress: PO Box 23, 1 Carlton Place

University of Strathclyde

description: Education

EGSTON Power Electronics GmbH

locality: Eggenburg

streetAddress: Grafenbergerstraße 37

legalName: EGSTON Power Electronics GmbH

title: Programmable 1 MW 4Q Power Supply

description:
Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 (SC Ref:754129)


status: unsuccessful

statusDetails: discontinued

status: cancelled

description: This contract may be extended by an additional up to 2 years.

description: The SPS has commenced this procurement process in good faith and with the intention of awarding a contract. Following publication of the Contract Notice, an Invitation to Tender (ITT) including the Single Procurement Document (SPD (Scotland)) will be published by SPS and will be made available to bidders on Public Contract Scotland - Tender. Tender responses will then be evaluated by the SPS in accordance with the ITT.

description: All SPS Sites

title: Provision of a Self Service System for all SPS Sites

description:
SPS recognises that the ability of those in custody to develop their digital skills is limited to that of a classroom setting. As a result, the SPS has undertaken an active role in promoting the use of digital technology within its establishments, through the use of virtual visits and mobile phone technology. More recently, the SPS has undertaken a Proof of Concept (Test of Change) for a KIOSK service in one of its operational Establishments. Following the success of the PoC, the SPS is now looking to roll this out to all SPS operational Establishments.
 One of the Digital Strategy’s objectives is to enhance the digital skills of the Purchaser’s staff group and move away from various transaction activities that take up a considerable amount of their time. The Purchaser’s staff still rely extensively on paper based systems for managing basic day-to-day activities (including menu choice, staff requests, canteen purchases and other regular tasks). Research has identified that adoption of new technology requires active engagement and perceived positive outcomes from the user group(s) in order to accept new ways of working.
 As a result of the above, the purpose of this tender activity is to appoint a supplier to install and manage a Self Service System to all operational Establishments. The system will include a standalone managed portal with a range of modules (including menu selectrion, PPC balance, staff messaging and notice board). The Contract Term shall be for a period of 5 years, plus up to an additional 2 year extension option.

performanceTerms: As stated in the procurement documents

description:
Financial information will be evaluated as Pass or Fail using turnover as a percentage of SPS business, the ratio between assets and liabilities, interest cover, gross margin and operating margin.
 - Assessment will reflect SPS’s consideration that there are no adverse financial factors noted and the bidder assessed as a low or acceptable level of commercial risk for SPS – (Pass).
 - Where, in the view of the SPS the bidder has insufficient financial or economic resources to undertake a contract of this scale and/or the bidder’s financial position is likely to put the contract at risk should they be awarded the contract, the SPS reserves the right to exclude (Fail) an organisation from the tender stage.
 - Failure to provide the requested financial information will result in a Fail.

Scottish Prison Service

postalCode: EH12 9HW

streetAddress: Calton House, 5 Redheughs Rigg

description: Public order and safety

legalName: Scottish Prison Service

description: Public order and safety

Edinburgh Sherriff Court

postalCode: EH1 1LB

streetAddress: 27 Chambers St

legalName: Edinburgh Sherriff Court

Scottish Prison Service

description: Public order and safety

description:
SPS recognises that the ability of those in custody to develop their digital skills is limited to that of a classroom setting. As a result, the SPS has undertaken an active role in promoting the use of digital technology within its establishments, through the use of virtual visits and mobile phone technology. More recently, the SPS has undertaken a Proof of Concept (Test of Change) for a KIOSK service in one of its operational Establishments. Following the success of the PoC, the SPS is now looking to roll this out to all SPS operational Establishments.
 One of the Digital Strategy’s objectives is to enhance the digital skills of the Purchaser’s staff group and move away from various transaction activities that take up a considerable amount of their time. The Purchaser’s staff still rely extensively on paper based systems for managing basic day-to-day activities (including menu choice, staff requests, canteen purchases and other regular tasks). Research has identified that adoption of new technology requires active engagement and perceived positive outcomes from the user group(s) in order to accept new ways of working.
 As a result of the above, the SPS is intending to issue a tender activity for a supplier to install and manage a Self Service System to all operational Establishments. The system will include a standalone managed portal with a range of modules (including menu selectrion, PPC balance, staff messaging and notice board). The system must be easily accessible to SPS staff through the existing SPIN network via a web browser or dedicated terminals. The self service portal should be able to be accessible through a Kiosk system or alternative platforms such as tablet or smart TV as determined by the Purchaser. The system will be able to fully integrate with the existing Prisoner Records System and future Case Management Platform systems.

description: (SC Ref:753194)


description:
PURCH1997 Appointment of Strategic Commercial JV Partner for Mixed-Use University Campus Development
 The University is seeking an investment and development Partner with the financial means and relevant experience to assist the University in realising their vision for the Mixed-Use Quarter and Innovation Zone.
 Please refer to the Project Information Document for further details.

description: Glasgow

description:
PURCH1997 Appointment of Strategic Commercial JV Partner for Mixed-Use University Campus Development
 Tender documents available from Public Contracts Scotland.
 Tender returns should be submitted via Public Contracts Scotland, no paper copies will be accepted. Should paper tenders be submitted, they will be rejected. Further to this any questions or communications regarding individual tender exercises must be sent via the Public Contracts Scotland Portal. Tender queries received through any other channel will not be answered. Should users of Public Contracts Scotland have any problems with the web site they should contact website Support Desk, contact details can be found by following the ‘Contact Us’ option on the left hand menu at http://www.publiccontractsscotland.gov.uk/default.aspx

documentType: economicSelectionCriteria

title: PURCH1997 - Project Information Document

title: PURCH1997 - SPD Qualification

title: PURCH1997 -  Stage 1 Selection Questions

title: PURCH1997 - Financial Ecomonic Standing Guidance

title: 2017_Sec42_17-01420-PPP Decision Notice corrected version 30 July 2018

title: 2019_Sec42_19-00363-PPP Decision Notice_May 2019

title: Architectural Design Guidance Report_Rev_03

title: Campus Wide Masterplan

title: University of Glasgow Marketing

title: UOG Innovation Strategy Final Draft Sept 2021

title: UOG Research Strategy

title: UOG Strategy 2020-25

title: UOG Sustainabilty Strategy

title: UOG-DOC-11-1 Design & Access Statement

title: UOG-DWG-01 - Parameter Plan - Plot Boundaries_Rev_07

title: UOG-DWG-02 - Parameter Plan - Development Parameters_Rev_09

title: UOG-DWG-03 - Parameter Plan - Height Parameters_Rev_09

title: UOG-DWG-04 - Parameter Plans - Active Frontages_Rev_08

title: UOG-DWG-05 - Parameter Plan - Route Hierarchy_Rev_07

description:
Case Study 1 - the vision: weighting 25%
 Case Study 2 - the delivery: weighting: 20%
 Case Study 3 - partnership: weighting: 20%
 Case Study 4 - funding: weighting: 20%
 Case Study 5 - innovation zone: weighting: 15%
 Stage 1 - SPD total: weighting: 100%

procurementMethodDetails: Competitive procedure with negotiation

University of Glasgow

postalCode: G12 8QQ

streetAddress: Procurement Office, Tay House

description: Education

legalName: University of Glasgow

name: Glasgow Sheriff Court & Justice of the Peace Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

description: Education

description:
Once the deadline has passed submissions can neither be created nor submitted. It is not advisable for Suppliers to wait until the last moment before creating and dispatching a response in case of any last minute problems. Please note large files should be uploaded as early as possible to ensure transfer before deadline. If a Supplier is having problems uploading to the PCS site, then the University must be informed well in advance and depending upon the merit of the case, the University may arrange for the tender to remain open on the PCS system for a short period after the deadline time stated. System problems do not fall under the University’s remit and should be referred to PCS.
 Postbox Security: Postbox submissions cannot be accessed by anyone, including Millstream, (the provider of the Public Contracts Scotland system) until the deadline.
 Freedom of Information
 The Freedom of Information (Scotland) Act 2002, which came into force on 1 January 2005, designates University of Glasgow as a Scottish public authority and therefore subject to the provisions and obligations in that Act. This means that any person who makes a valid request for information held by University of Glasgow will be entitled to receive it, unless all or part of that information can be withheld by virtue of the exemptions in that Act.
 As part of our responsibility under the Act, University of Glasgow may be required to disclose any information held relating to your response to anyone who makes a request under that Act. Such information may only be withheld if it meets one or more of the exemptions or conditions in that Act. Even if an exemption is available University of Glasgow may nevertheless disclose requested information. Information held cannot simply be classified as “confidential" or "commercial in confidence" to enable it to be protected from disclosure.
 University of Glasgow may publish the names and contact details of companies who have been issued with a Questionnaire on its website.
 Information may also be requested under Data Protection legislation and the Environmental Information (Scotland) Regulations 2004.
 (SC Ref:752347)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) ("NSS")

description: There are a number of additional services which will be included in a contract catalogue which may be utilised throughout the contract term. These will be described in the procurement documentation at the Initial Bid stage.

description: Two optional three year extensions.

description:
The existing NHS Scotland Picture Archiving and Communication System (PACS) contract is coming to an end and National Services Scotland (NSS) is managing a procurement exercise on behalf of NHS Scotland to procure a new PACS solution.
 The objective of this programme is to undertake a PACS Re-procurement exercise to establish a replacement national contractual arrangement that is sustainable and can evolve over time at a pace that is acceptable to the NHS in Scotland. To achieve a more effective and joined up imaging environment that supports changes to the clinical workflows required to implement the new Scotland Radiology Model.
 As a minimum, the new contract for the PACS service aims to:
 - Provide a modern, secure PACS system which will support the evolving models of care;
 - Support the Scottish Government’s Digital Health and Care Strategy 2021;
 - Enable evolving Scottish Government strategies related to integration, cyber security, digital imaging, Radiology transformation, Artificial Intelligence (AI) and person-centred care.
 The current PACS IT Solution for Acute services comprises a fully replicated central national PACS, which captures radiological images and reports from 22 (by Summer 2022) local PACS instances across 15 NHS Boards. A separate PACS solution for the Scottish Breast Screening Programme (SBSP) consists of six local PACS instances and a separate central archive.
 The contract will deliver services to entities constituted pursuant to the National Health Service (Scotland) Act
 1978 as amended.. Contract Value Assumptions are included in the Additional Information document as attached to this contract notice.

description: PACS RP SPD Instruction to Bidders document attached to this notice outlines the SPD evaluation criteria.

description: Scotland

title: PACS Reprovisioning

title: PACS Reprovisioning

title: PACS SPD

title: PACS RP SPD Instruction to Bidders

title: PACS RP Additional Information for SPD

title: PACS RP SPD Instruction to Bidders

title: PACS Reprovisioning

reviewDetails:
The authority will notify economic operators who submitted a tender or (where no deselection notification has previously been made) applied to be selected to tender, of its decision to award the contract which notification will contain among other information, a summary of the reasons why the economic operator was unsuccessful. The notification will incorporate a ‘standstill period’ of a minimum of 10 clear calendar days (or a minimum of 15 if the communication method used is not electronic) between the date on which the authority despatches the notice(s) and the date on which the authority proposes to conclude the relevant contract. The bringing of court proceedings against the authority during the standstill period will automatically continue the prohibition on entering into the contract until the court proceedings are determined, discontinued or disposed of, or the court, by interim order, brings to an end the prohibition. The remedies that may be awarded by the courts before the contract has been entered into include the setting aside of the decision to award the contract to the winning tenderer(s). The bringing of court proceedings against the authority after the contract has been entered into will not affect the contract unless grounds for the imposition of special penalties under the Public Contracts (Scotland) Regulations 2015 can be established. Otherwise the remedies that may be awarded by the courts where the contract has been entered into are limited to the award of damages. Economic operators are entitled to write to the authority after receipt of the notification should they require further clarification. The authority will respond within 15 days of such a written request, but it should be noted that receipt by the authority of such request during the standstill period may not prevent the authority from awarding the contract following the expiry of the standstill period. Economic operators should approach the contracting authority in the first instance. However, the only formal remedy is to apply to the courts:
 An economic operator that suffers or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts(Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session.

postalCode: EH12 9EB

streetAddress: Gyle Square (NSS Head Office), 1 South Gyle Crescent

description: Health

Edinburgh Sheriff Court

streetAddress: 27 Chambers Street

Court of Session

roles: reviewBody reviewContactPoint

postalCode: EH1 1RQ

legalName: Court of Session

description: Health

Sectra Ltd

locality: London Stansted

postalCode: CM22 6DR

streetAddress: First Floor, Water Circle, City Meadows

legalName: Sectra Ltd

Court of Session

streetAddress: Parliament House, Parliament Square

description:
Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 The Public Sector in Scotland is committed to the delivery of high quality public services, and recognises that this is critically dependent on a workforce that is well-rewarded, well-motivated, well-led, has access to appropriate opportunities for training and skills development, diverse and engaged in decision making. These factors are also important for workforce recruitment and retention, and thus continuity of service.
 Public Bodies in Scotland are adopting fair work practices, which include:
 — a fair and equal pay policy that includes a commitment to supporting the living wage, including, for example being a living wage
 accredited employer;
 — clear managerial responsibility to nurture talent and help individuals fulfil their potential, including for example, a strong commitment
 to modern apprenticeships and the development of Scotland's young workforce;
 — promoting equality of opportunity and developing a workforce which reflects the population of Scotland in terms of characteristics such
 as age, gender, religion or belief, race, sexual orientation and disability;
 — support for learning and development;
 — stability of employment and hours of work, and avoiding exploitative employment practices, including for example no inappropriate use of zero-hours contracts;
 — flexible working (including for example practices such as flexi-time and career breaks) and support for family friendly working and
 wider work life balance;
 — support progressive workforce engagement, for example Trade Union recognition and representation where possible, otherwise
 alternative arrangements to give staff an effective voice.
 In order to ensure the highest standards of service quality in this contract we expect contractors to take a similarly positive approach to fair work practices as part of a fair and equitable employment and reward package.
 Bidders who are invited to submit an initial bid will need to describe how they will commit to fair work practices for workers (including any agency or subcontractor workers) engaged in the delivery of this contract.
 A sub-contract clause has been included in this contract. For more information see:
 http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see:
 https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 (SC Ref:753914)


description: The contract will last for three years from 1 June 2022 to 31st May 2025; with the possibility of a further two single year extensions through to 31st May 2027. The extension of the contract will be at the discretion of VHA Executive Management Team and subject to meeting the performance requirements within the key performance indicators. Please refer to Appendix F for more detail.

description:
VHA is inviting applications from suitably experienced and skilled organisations to provide our tenants with a quality telecare alarm monitoring and response service and Out of Hours emergency repair and response service across our housing types.
 The telecare service will include the monitoring of core alarms and linked peripheral devices such as pull cord activation, smoke and fire detection, door entry systems and movement sensors across our housing types of Enhanced Sheltered, Sheltered, Alarmed, Amenity and Retirement Housing as well as an appropriate and timely response to all alarms raised.
 The Out of Hours emergency repair and response service will handle emergency repair calls outwith office hours across all of our housing types, logging repairs and co-ordinating with contractors to ensure repairs are responded to within VHA repair compliance timeframes.

description: As detailed in Appendix E - Address List of all Properties - Final

title: Telecare Monitoring/Response and OOH

title: Telecare Monitoring/Response and OOH

description: The provision of Telecare Monitoring/Response and Out of Hours Repairs Service

title: VHA ITT- Telecare  & OOH Service Tender Pack

format: application/x-zip-compressed

title:
VHA ITT- Telecare  OOH Service 2022-2027 - Final (002)
New start date confirmed as 1 July 2022

title: All calls Dec 2021

title: Housing type breakdown

title: Telecare Monitoring/Response and OOH

description: Bidders requests for more time to cost.

label: Time limit

label: Conditions for opening of tenders

streetAddress: VHA Head Office

description: VHA Senior Officer

description: 36 or 48 or 60 months

performanceTerms: As outlined in the attached Appendix F - Key Performance Indicators - Final

description: As outlined in the attached VHA ITT- Telecare OOH Service 2022-2027 - Final

description: Execution of the service is reserved to a particular profession

Viewpoint Housing Association

postalCode: EH9 2HG

streetAddress: 4 South Oswald Road

description: Housing and community amenities

legalName: Viewpoint Housing Association

description:
Please ensure that you comprehensively read and understand the attached "VHA ITT- Telecare OOH Service 2022-2027 - Final" document and all other associated documents, in particular in connection with the Global Questions Pass or Fail requirements and you complete and return all the required evidence in the required format the price schedule as requested in Excel.
 The SPD process is attached via Section E. Global Question for All Selection Criteria. The criteria on the SPD are PASS or FAIL. You will pass the SPD Global Questions by completing and meeting all the criteria a set out in the attached. If you fail to provide all the required and requested information as below you will FAIL the SPD and in turn the Tender Requirements and you will be disqualified from the tender process.
 (SC Ref:754289)


title: EC0958 - Lift Maintenance Central Area

title: EC0958 - Lift Maintenance Peripheral Area

title: EC0958 - Lift Maintenance Central Area

description: This Contract is for a period of 2 years, with the option to extend for up to two years (2+1+1).

description: The University of Edinburgh appointed a Lift Maintenance Contractor for Lot 1 Central Area.

description: The University of Edinburgh appointed a Lift Maintenance Contractor for Lot 2 Peripheral Area.

description: Edinburgh

description: Edinburgh

title: EC0968 Comprehensive planned and reactive lift maintenance services.

description: The University of Edinburgh wishes to appoint two Lift Maintenance Contractors (one per geographical Lot) for comprehensive planned and reactive lift maintenance services, including regular planned preventative maintenance, 24 hour breakdown response and all repairs to the lifts to keep them operating in a safe and reliable condition. Please refer to the ITT tender documents for full details of the scope.

description: The University of Edinburgh appointed two Lift Maintenance Contractors (one per geographical Lot) for comprehensive planned and reactive lift maintenance services, including regular planned preventative maintenance, 24 hour breakdown response and all repairs to the lifts to keep them operating in a safe and reliable condition.

description: Spring 2027

description:
SPD Part IV: Selection Criteria - A: Suitability - Question 4A.2
 Bidders must confirm they hold membership of LEIA (Lift Escalator Industries Association) or equivalent.

minimum:
Question 4B1.1
 Tenderers are required to have the following minimum “general” annual turnover for the last three financial years:
 - Lot 1: 450,000 GBP
 - Lot 2: 300,000 GBP
 Where turnover information is not available for the time period requested, the bidder will be required to state the date which they were set up/started trading in question 4B3
 Question 4B5.1 and 4B5.2
 Tenderers are required to hold, or commit to obtaining prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 - Employer’s Liability Insurance: 5,000,000 GBP
 - Public Liability Insurance: 10,000,000 GBP
 - Professional Indemnity Insurance: 5,000,000 GBP
 Question 4B6
 SPD 4B.6 Statement 1 (PCG):
 Where the bidder is providing a submission on behalf of a subsidiary company, upon request, the bidder must obtain a Parent Company Guarantee prior to commencement of any subsequently awarded contract.
 SPD 4B.6 Statement 2 (Financial Strength):
 Bidders will be required to provide adequate assurance of financial strength to successfully complete their contractual obligations.
 Bidders must be able to provide upon request, their 3 most recent sets of annual audited accounts, including profit and loss information, and the following ratios:
 - Current Ratio
 - Quick Ratio
 - Debtors Turnover Ratio
 - Return on Assets
 - Working Capital
 - Debt to Equity Ratio
 - Gross Profit Ratio
 A review of your ratios and audited accounts may be undertaken. In some cases this review may lead to an additional request for further financial information to help clarify any potential issues raised.
 This information may be used to assess financial sustainability.

description: Part IV: Selection criteria - B: Economic and financial standing – Question 4B1.1 (turnover requirement), 4B5.1 and 4B5.2 (insurance requirements), and 4B6 (other requirements).

minimum:
Question 4C1.2
 Bidders will be required to provide three relevant examples of services carried out during the past three years that demonstrate that you have relevant experience to deliver the services described in the Contract Notice. Please refer to the ITT tender documents for full details.
 Question 4C10
 Bidders will be required to confirm whether they intend to subcontract and, if so, for what proportion of the contract.
 Please refer to the ITT tender documents for full details.

description: Part IV: Selection criteria - C: Technical and Professional Ability – Question 4C1.2 and 4C10

University of Edinburgh

description: Education

legalName: University of Edinburgh

description: Education

Edinburgh Sheriff Court

streetAddress: Sheriff Court House, 27 Chambers Street

University of Edinburgh

description: Education

Scotec Lifts Ltd

postalCode: G69 6UL

streetAddress: Unit 32, 28 Nurseries Road, Baillieston Distribution Centre

legalName: Scotec Lifts Ltd

Orona Limited

postalCode: G71 5PW

streetAddress: Suite 6, Ellismuir House, Ellismuir Way, Tannochside Park

legalName: Orona Limited

description:
The University of Edinburgh is seeking to gather market information with regards to a potential future tender opportunity - contract for comprehensive planned and reactive lift maintenance services.
 The contract will require suppliers to provide a fully comprehensive lift service to the University. This will include the regular planned preventative maintenance, 24 hour breakdown response and all repairs to the lifts to keep them operating in a safe and reliable condition. The repairs will include any defects that are reported within the LOLER Thorough Examinations and those identified during Maintenance Evaluation Audits by our Lift Consultants.
 There are approximately 250-300 lifts in operation across all University sites, using electric, hydraulic and disabled platform lift systems.
 Interested parties will be required to demonstrate they have the relevant proven experience to deliver the services which are similar in value and complexity of estate.
 Due to the size of the estate it is anticipated this contract will be divided into geographical lots and therefore reduce any risk associated with delivery of services by one supplier.
 The procurement strategy and tender documents are currently work in progress and the information provided above may change prior to tender publication.
 Please record your interest in this notice if you would like to be kept informed and invited to tender if this opportunity were to go ahead.
 Please note, the University may also contact you prior to any tender publication for the purpose of gathering market information specific to services detailed above.

title: EC0958 - Lift Maintenance Central Area

description:
The anticipated contract values are based on tendered maintenance costs and estimates for reactive requirements and inflation.
 (SC Ref:741894)


title: Bathing

title: Manual & Handling Equipment

title: CYP Seating

title: CHILDRENS YOUNG PEOPLE (CYP) - EDUCATION ACCESSORIES Lot 5

title: CHILDRENS YOUNG PEOPLE (CYP) - STANDERS, WALKERS AND POSITIONING Lot 6

title: Wheelchairs

title: Stair Climbers

statusDetails: unsuccessful

title: CHAIRS & CHAIR ACCESSORIES ADULT

title: CYP Seating

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Refurbishment, Servicing and Repair CYP Seating equipment.

title: Beds Delivery and fit

description: 12 months extension optional

description: Fife Council is looking for suppliers who can deliver and fit beds to client homes.

title: Bathing

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Repair bathing equipment.

title: CHAIRS & CHAIR ACCESSORIES ADULT

description: 12 months extension optional

description: Fife Council is looking for suppliers who can repair chairs & accessories adult equipment.

title: Manual & Handling Equipment

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Service and Repair Manual & Handling equipment.

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Repair CYP Accessories equipment.

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Service and Repair CYP Standers Walker & Positioning.

title: Stair Climbers

description: 12 months extension optional

title: Wheelchairs

description: 12 months extension optional

description: Fife Council is looking for suppliers who can Service and Repair Wheelchairs.

description: Fife

description: Fife

description: Fife

description: Fife

description: Fife

description: Fife

description: Fife

description: Fife

description: Fife

title: Refurbishment, Servicing and Repairing of Medical Aids

description: Fife Council is looking for suppliers who can Refurbishment, Servicing and Repairing Medical Aids Equipment.

description:
Yahia Reggab
 Jade Scott

performanceTerms: The successful Contractor shall be required to attend quarterly meetings to discuss performance to date and future requirements of the Contract. If there are any issues with the Contract the Council may opt to amend the frequency of the meetings.

reviewDetails:
Economic operators should approach the contracting authority in the first instance. However, the only formal remedy is to apply to the courts:
 An economic operator that suffers, or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session

minimum:
4B1.1 - Tenderers will be required to have a minimum “general” yearly turnover of GBP GBP 144,000.00 for the last 2 years.
 Tenderers shall be advised that where they do not currently meet the above requirements they shall require to confirm why and the Council may undertake additional financial checks using a tool such as Creditsafe and a qualitative judgement shall be made as to the financial capacity of the tenderer. Fife Council may require a parent company guarantee, a performance guarantee bond, a bank guarantee, and/or an advance payment bond.
 4B.4 - Tenderers are expected to achieve a ratio of 1 or more. Where a Tenderer does not meet this requirement further details should be provided to confirm why and the Council may undertake additional financial checks using a tool such as Creditsafe and a qualitative judgement shall be made as to the financial capacity of the tenderer. Fife Council may require a parent company guarantee, a performance guarantee bond, a bank guarantee, and/or an advance payment bond.
 4B.5.1b - Where a Bidder does not confirm that they already have or can commit to obtaining, prior to the commencement of the contract, GBP 10,000,000 of Employer’s (Compulsory) Liability Insurance, the Council may exclude the Bidder from the competition.
 4B.5.2 - Where a Bidder does not confirm that they already have or can commit to obtaining, prior to the commencement of the contract
 Employer’s Liability - 10 million GBP
 Public Liability – 5 million GBP
 Professional Negligence - 250,000 GBP

description:
4B1.1 - Tenderers are required to provide their annual turnover for their last two financial set of accounts.
 4B.4 - The Current Ratio will be applied. Tenderers are required to provide their current assets and current liabilities in relation to their audited published accounts for the last two years and to divide the current assets by the current liabilities figure. If a company does not have 2 years of audited published accounts an explanation should be given.
 4B.5.1b - Insurance - Employer’s (Compulsory) Liability: Bidders are required to hold or commit to obtaining GBP 10,000,000 of Employer’s (Compulsory) Liability Insurance.
 4B.5.2-Insurance-All other types listed: Bidders are required to hold or commit to obtaining, prior to the commencement of the contract, the levels of all other types of insurance cover indicated.The values of the policies must be as follows:
 Employer’s Liability - 10 million GBP
 Public Liability – 5 million GBP
 Professional Negligence - 250,000 GBP

minimum: Tenderers must have a minimum of 5 years of experience in delivering the same service and have to provide relevant examples of service carried out in the past 3 years.

Fife Council

description: General public services

name: Kirkcaldy Sheriff Court & Justice of Peace Court

description: General public services

title: Bathing

title: Manual & Handling Equipment

title: CYP Seating

title: Wheelchairs

title: CHAIRS & CHAIR ACCESSORIES ADULT

description: (SC Ref:752444)