description: East Lothian Council is seeking to appoint a contractor under the Procurement for Housing EEESH 2 Framework for Annual heating & hot water servicing and all-inclusive 24 hour, 365/366 day repairs & maintenance of gas installations & appliances; air source heat pumps; electric storage heaters; solid fuel appliances; solar panel systems; and unvented hot water storage systems in approximately 9400 domestic Council & Mid-Market homes within the boundaries of East Lothian.

description:
Community Benefits are a requirement of this contract.
A summary of the expected community benefits has been provided as follows:
The Service Provider shall engage with the Council with regard to delivering proportionate Community Benefits in relation to the Contract in terms of social, economic, and environmental benefits, in order to achieve sustainability and best value from public spending to benefit the community.

title: Award of ELC-25-0514 Annual Heating Servicing and all inclusive Repairs & Maintenance Contract fo...

description: Heating-plant repair and maintenance work

description: Repair and maintenance services of central heating

Falkirk Council

locality: Larbert

postalCode: FK5 4RU

streetAddress: The Foundry

Akhter Computers Limited

locality: Harlow

postalCode: CM19 5QP

streetAddress: 1-3 Marshgate Business Centre

Barnett Waddingham LLP

locality: London

postalCode: EC2Y 5AU

streetAddress: 2 London Wall Place

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

Hearts & Minds

locality: Edinubrgh

postalCode: EH1 2DP

streetAddress: Lower Ground

Scottish Government

locality: Aberdeen

postalCode: AB11 9DB

streetAddress: Marine Laboratory

APEM Ltd

locality: Stockport

postalCode: SK4 3GN

streetAddress: Riverview, A17 Embankment Business Park,

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

HAGS-SMP Limited.

locality: Egham

postalCode: TW20 8PG

streetAddress: Clockhouse Nurseries

Historic Environment Scotland

postalCode: EH9 1SH

streetAddress: Longmore House

DataVita Limited

locality: Chapelhall

postalCode: ML6 8HW

streetAddress: Fortis Datacentre,

East Dunbartonshire Council

postalCode: G66 1TJ

streetAddress: Civic & Corporate Headquarters

Scot J C B Limited

postalCode: G31 3AR

streetAddress: 400 Townmill Road

Ipsos MORI

postalCode: E1W 1YW

streetAddress: 3 Thomas More Square

The Lines Between Ltd.

postalCode: EH8 7EH

streetAddress: 3 Piershill Place

Deciding Matters

postalCode: EH11 2LX

streetAddress: 22/6 Murieston Lane

Elevator

locality: Inverurie

postalCode: AB51 5TB

streetAddress: Thainstone Business Centre, Thainstone

Forestry and Land Scotland

locality: Inverness

postalCode: IV3 8NW

streetAddress: Great Glen House

GTR Contracts Ltd

locality: Dumfries

postalCode: DG2 8PT

streetAddress: Terraughtie Farm

MAM Contracting

locality: Crieff

postalCode: PH7 4HL

streetAddress: The Office

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road

Venesky-Brown Recruitment Limited

locality: Broxburn

postalCode: EH52 5AU

streetAddress: Axwel House

Tony weir contractor LTD

postalCode: IV30 6ND

streetAddress: 9 Chanonry Spur

Craigforth Consultancy and Research

postalCode: FK9 4TU

streetAddress: 1st Floor

GCU

locality: GLASGOW

postalCode: G4 0BA

streetAddress: Glasgow Caledonian University

EKOS Ltd

postalCode: G3 6JA

streetAddress: St Georges Studios, 93-97 St Georges Road

National Galleries of Scotland

postalCode: EH4 3DS

streetAddress: National Galleries of Scotland

Thomas & Adamson International Limited

postalCode: EH3 9GL

streetAddress: 13 Lister Square

postalCode: EH6 6LX

streetAddress: 86/2 Commercial Quay

Jump Research

postalCode: EH6 7AD

streetAddress: 137/5 Constitution Street

Ace Taxis Perth Ltd

postalCode: PH1 5QN

streetAddress: 271 High Street

Smith and Sons Coaches

locality: Coupar Angus

postalCode: PH13 9LW

streetAddress: The Coach Depot


rel: canonical

status: active

description: 24 months

description: Void Property Energy Supplier

variantPolicy: notAllowed

electronicCataloguePolicy: required

region: UKM

scheme: CPV

title: Void Property Energy Supplier

currency: GBP

title: Void Property Energy Supplier

format: text/html

description: Void Property Energy Supplier

documentType: contractNotice

documentType: economicSelectionCriteria

documentType: technicalSelectionCriteria

title: Tender Pack

format: application/x-zip-compressed

title: Contract and Spec

description: T&Cs document currently issued is being reviewed. We will update in due course.

label: Time limit

label: Conditions for opening of tenders

scheme: CELEX

description: Void Property Energy Supplier

procurementMethod: open

mainProcurementCategory: services

procurementMethodDetails: Open procedure

The Wheatley Housing Group Limited

locality: Glasgow

postalCode: G1 1HL

streetAddress: 25 Cochrane Street

scheme: COFOG

description: Housing and community amenities

legalName: The Wheatley Housing Group Limited

Glasgow Sherriff Court

legalName: Glasgow Sherriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801151.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 The community benefit is a credit on new Wheatley customers energy accounts.
 (SC Ref:801151)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=801151

initiationType: tender


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

status: complete

description: "Cloud Hosting for Clinical Systems using SP–22–023

description: Ayrshire and Arran

title: AA-260-25-DA Cloud Hosting for Clinical Systems using SP–22–023

documentType: awardNotice

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: This is a direct award from SP-22-023

description: The procurement falls outside the scope of application of the directive

NHS Ayrshire & Arran

locality: Ayr

postalCode: KA6 6AB

streetAddress: Eglinton House, Ailsa Hospital, Dalmellington Road

description: Health

legalName: NHS Ayrshire & Arran

DataVita Limited

region: UK

postalCode: ML6 8HW

streetAddress: Fortis Datacentre,, York Road

scale: sme

legalName: DataVita Limited

name: Kilmarnock Sheriff Court, St Marnock Street, Kilmarnock KA1 1ED.

locality: KILMARNOCK

postalCode: KA1 1ED

description: (SC Ref:801175)


description: Traffic Management services are an ongoing requirement, this contract will be re-tendered in advance of the expiry in September 2019.

description:
Key Requirements to be Delivered (Statement of Requirements)
 The key requirements include, but are not limited to:
 The design of Traffic Management Plans, site specific RAMS and where applicable Diversion Plan in conjunction with EDC officers;
 Installation, Maintenance, Relocation & Removal of all Traffic Management equipment and systems as detailed in the Schedule of Rates including but not limited to;
 Traffic Management Supervisor & Operatives to maintain integrity of Traffic Management system and support nearby residents or businesses
 Stop/Go Board Traffic Management
 Temporary and Portable 2,3 & 4 way traffic signals and pedestrian crossing signals.
 Road Closure with up to 30 or 60 standard diversion route signs on roads with a speed limit of 40mph or less, 50mph to 60mph or national speed limit.
 Install, Maintain & Remove pedestrian barriers interlinked and including any couplings and footings, compliant with BS EN 8442 & BS EN 12899-4 reflectivity requirement and supports Chapter 8 protocols.
 Install, Maintain & Remove Pedestrian Barriers heavy duty fixed leg, Metal crowd Control. 1100mm high and Heras Fencing approx 2000mm high, Galvanised to BS EN 10244-2
 Install, Maintain & Remove No waiting cones 500mm
 Install, Maintain & Remove Traffic Cones 500mm, 750mm & 1000mm
 Install, Maintain & Remove Standard Road Signs in accordance with Chapter 8 and TSRGD guidelines
 Install, Maintain & Remove Site Specific bespoke Signage.
 Install, Maintain & Remove Specialist Diversion Signs or Advance Warning Signs In Class RA1 Reflective Material. In accordance with Chapter 8 and TSRGD guideline
 Install, Maintain & Remove Specialist Diversion Signs or Advance Warning Signs In Class RA2 Reflective Material. In accordance with Chapter 8 and TSRGD guidelines
 Install, Maintain & Remove Portable Variable message signs – specification in Appendix 2:
 EDC20254212 TM ITT APPENDIX 2 Specification Portable Variable Message Signs
 Maintenance of temporary access to property
 Convoy System, 1,2 or 3 vehicles
 Impact Protection Vehicle
 Dual Carriageway Closure on roads with a speed limit of 40mpg or less, 50mpg to 6-mph or national speed limit.
 Contraflow on roads with a speed limit of 40mpg or less, 50mpg to 6-mph or national speed limit
 Welfare Facilities
 Project Management of all Traffic Management Services from installation to removal, ensuring minimal disruption and inconvenience to EDC residents;
 Rectification of TM equipment failure in within 2 hours;
 Commitment to maintain a named foreman at each site for duration of works, except in exceptional circumstances.
 Compliance with EDC Health & Safety requirements

Quality

type: quality

type: price

title: EDC/2025/4212 Traffic Management

title: EDC/2025/4212 Traffic Management

description:
The Authority wishes to establish a contract for Traffic Management Services (TMS) across the EDC authority area, the contract will be utilised primarily to support Capital Investment and Maintenance Programmes of work however will be accessible to all authority departments.
 The contractor is required to provide the design of Traffic Management Plans, provision of all signage and associated TMS equipment & operatives, installation, maintenance, relocation, removal of equipment, project management of Traffic Management Plan and emergency response.

title: Invitation to Tender Document

title: Appendix 1 -EXAMPLE 12 Month Road and Carriageway Replacement Program

title: Appendix 2 -Specification Portable Variable Message Signs

format: application/pdf

title: Appendix 3 -Work Order Quotation Template

title: Appendix 4 -HSP05 Management of Contractors

title: Appendix 5 -Contract Variation Form

title: Appendix 6 -Variation to SOR Template

title: Schedule of Rates

title: SBCC Measured Term Contract Data

description: Q2 2029

performanceTerms: Key Performance Indicators are included with the ITT document.

electronicInvoicingPolicy: allowed

type: suitability

type: economic

minimum:
Detailed within the SPD module:
 General Turnover per annum - GBP 744,000 per annum
 Insurances:
 Employee Liability minimum of GBP 10,000,000, each and every claim
 Public Liability minimum of GBP 10,000,000, each and every claim
 Motor Vehicle minimum of GBP 5,000,000, each and every claim

description:
Detailed within the SPD module:
 General Turnover per annum
 Insurances

type: technical

minimum:
Traffic Management Design Layouts – Lantra National Highway Sector Scheme Approved Chapter 8 Qualified Designers T7 or equivalent.
 Traffic Management Supervisor/Foreman – Lantra National Highway Sector Scheme 12A or equivalent
 Traffic Management Operatives – Lantra National Highways Sector Scheme Approved Chapter 8 Qualified Operatives 12 B T1/T2 or equivalent

description:
As detailed within the SPD
 All Traffic Management Operatives, Supervisors, Designers and Sub-contractors must hold National Highways Sector Scheme Certification of equivalent.

East Dunbartonshire Council

locality: Kirkintilloch

postalCode: G66 1TJ

streetAddress: Civic & Corporate Headquarters, Southbank Marina,12 Strathkelvin Place

description: General public services

legalName: East Dunbartonshire Council

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801200.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Bidders are invited to detail below any appropriate Community Benefits offered in accordance with this contract.
 A Community Benefit is a contractual requirement imposed by the Authority relating to training, recruitment or availability of sub-contracting opportunities, which is intended to improve the economic, social or environmental wellbeing of the Authority’s area in a way that is additional to the main purpose of the contract in which the requirement is included.
 Potential Providers are encouraged to offer a contribution towards Community Benefits, which will be provided as part of the contract. Therefore, please describe the Community Benefits that your organisation commits to deliver.
 Opportunities for community benefits may include:
 i)	Generating employment and training opportunities for priority groups;
 ii)	Vocational training, work experience and modern apprenticeships;
 iii)	Up-skilling existing workforce;
 iv)	Equality and diversity initiatives;
 v)	Sub-contracting opportunities available to SME’s, the third sector and supported businesses and/or in the local area;
 vi)	Supply-chain developmental activity;
 vii)	Building capacity in community organisations;
 viii)	Education support initiatives;
 ix)	Working with schools, colleges, universities to offer work experience or educational/professional advice;
 x)	Community engagement events or providing value to the local community;
 xi)	Minimising negative environmental impacts, for example impacts associated with vehicle movements and/or associated emissions and impacts on protected species, areas, buildings or sites.
 This question is designed to ascertain which Community Benefits the Potential Provider is committed to provide if awarded the contract. Please note that responses to this question shall be monitored under the Potential Providers performance indicators.
 (SC Ref:801200)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=801200


description: The requirement is for Marketing Services Framework 2022 for the "Parental Audience - Communications related Research" contract. Full details are supplied in the documents attached.

title: Award of MSF 2022 - Parental Audience - Research Services - ITT - 2025

description: Business services: law, marketing, consulting, recruitment, printing and security

Falkirk Council

locality: Larbert

postalCode: FK5 4RU

streetAddress: The Foundry

Akhter Computers Limited

locality: Harlow

postalCode: CM19 5QP

streetAddress: 1-3 Marshgate Business Centre

Barnett Waddingham LLP

locality: London

postalCode: EC2Y 5AU

streetAddress: 2 London Wall Place

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

Hearts & Minds

locality: Edinubrgh

postalCode: EH1 2DP

streetAddress: Lower Ground

Scottish Government

postalCode: AB11 9DB

streetAddress: Marine Laboratory

APEM Ltd

postalCode: SK4 3GN

streetAddress: Riverview, A17 Embankment Business Park,

Moray Council

postalCode: IV30 1BX

streetAddress: High Street

HAGS-SMP Limited.

postalCode: TW20 8PG

streetAddress: Clockhouse Nurseries

Historic Environment Scotland

locality: Edinburgh

postalCode: EH9 1SH

streetAddress: Longmore House

DataVita Limited

streetAddress: Fortis Datacentre,

East Dunbartonshire Council

streetAddress: Civic & Corporate Headquarters

Scot J C B Limited

postalCode: G31 3AR

streetAddress: 400 Townmill Road

Ipsos MORI

postalCode: E1W 1YW

streetAddress: 3 Thomas More Square

The Lines Between Ltd.

postalCode: EH8 7EH

streetAddress: 3 Piershill Place

Deciding Matters

postalCode: EH11 2LX

streetAddress: 22/6 Murieston Lane

Elevator

postalCode: AB51 5TB

streetAddress: Thainstone Business Centre, Thainstone

Forestry and Land Scotland

postalCode: IV3 8NW

streetAddress: Great Glen House

GTR Contracts Ltd

postalCode: DG2 8PT

streetAddress: Terraughtie Farm

MAM Contracting

postalCode: PH7 4HL

streetAddress: The Office

Scottish Government- SASA

postalCode: EH12 9FJ

Craigforth Consultancy and Research

locality: Stirling

name: Leith Creative Agency Ltd (T/A Leith Agency)


description: Renewal will be 5-7 years after contract award.

description: Argyll & Bute Council are looking to contract with a transport operator who will provide safe and secure school and local transport on Tiree. See attached tender documents for full details.

description: Isle of Tiree

title: Provision of School and Local Transport Services - Tiree

description: Argyll and Bute Council are looking to Contract with a transport operator who will provide safe and secure school and local transport on Tiree.

title: Invitation to Tender

title: Route Spec - 1129N SS1

title: Route Spec - 1129N TS1A

title: Route Spec - 1130N 1 of 2 SSI

title: Route Spec - 1130N 2 of 2 SSI

title: Route Spec - 1130N TS1A

title: 1129N Pricing and Capacity

title: 1130N Pricing and Capacity

title: ABC Community Benefits Clauses, Guidance for Tenderers

streetAddress: On-line via PCS Post-box.

description: 5 or 7 years from award.

Argyll and Bute Council

locality: Lochgilphead

postalCode: PA31 8RT

streetAddress: Kilmory

description: General public services

legalName: Argyll and Bute Council

Oban Sheriff Court

locality: Oban

legalName: Oban Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801231.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Please see attached tender documents.
 (SC Ref:801231)


description: Argyll & Bute Council are looking to contract with a transport operator who will provide safe and secure school transport on Bute. See attached tender documents for full details.

description: Isle of Bute

title: Provision of School and Local Transport Services - Bute

description: Argyll and Bute Council are looking to Contract with a transport operator who will provide safe and secure school on Bute.

title: ITT for the Provision of School Transport Services, Bute

title: Route Specification, 1213N SS1

title: Pricing and Capacity

description: 5 or 7 years from award.

Argyll and Bute Council

description: General public services

description: General public services

J & J Zan-Kreyser Taxis Ltd

locality: Rothesay

postalCode: Pa20 9eh

streetAddress: Cabrera, Serpentine road

scale: large

legalName: J & J Zan-Kreyser Taxis Ltd

description: (SC Ref:807053)

scheme: EU-OJ


description: Provision of Casualty Insurance

title: Provision of Casualty Insurance

title: Provision of Casualty Insurance

description: Provision of Casualty Insurance

description: Provision of Casualty Insurance

procurementMethodRationale: The Council ran a mini-competition which received no bids for this requirement. There are no alternatives and this award would fit into the exemption clauses as highlighted above. Due to the deadline of 30th April 2025, it is not possible to re-run this competition or go out to open tender as the Council has a statutory obligation to provide insurance cover beyond this date. No other provider has presented a quote to the Councils Insurance Broker. This provider is the only company who have quoted for the services the Council needs.

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

South Ayrshire Council

roles: buyer centralPurchasingBody

postalCode: KA7 1DR

streetAddress: County Buildings, Wellington Square

description: General public services

legalName: South Ayrshire Council

Risk Management Partners Ltd

postalCode: FK7 7UF

streetAddress: Enterprise House, Springkerse Business Park

legalName: Risk Management Partners Ltd

Ayr Sheriff Court

legalName: Ayr Sheriff Court

description: (SC Ref:801260)


description: Option to extend 2 x 12 month periods

description: The Trust is seeking to appoint a suitably qualified and experienced team to work closely with our Retail Team to revitalise the design of our retail shops as part of a rolling programme of shop refurbishment.

title: Retail shop design services

title: Retail shop design services

title: Retail shop design services ITT

title: RBBM layout

title: NTS Visual Identity Guidance

National Trust for Scotland

postalCode: EH12 9LD

streetAddress: Broadstone, 50 South Gyle Crescent

legalName: National Trust for Scotland

Sheriff Court

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801261.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:801261)


description:
The contract will originally for 36 months plus extensions of 1 year + 1 year.
 This means the contract may be 48 months or 60 months depending on length of extensions.
 As such there will be a renewal of this contract under a new procurement either in 2028, 2029 or 2030 depending on what renewal options
 are chosen.

description:
City Building requires on behalf of its clients to manage and maintain a range of swimming pools and hydrotherapy pools across the client
 estate. Within all the swimming pools and hydrotherapy pools City Building is looking to contract with a company who can provide a
 reactive and planned maintenance regime in-line with the associated filtration systems that are outlined in the tender documents. These
 facilities are important in the cultural landscape of the city and help to provide:
 Improve health and well-being.
 Learn important skills.
 Family friendly places.
 Social interaction.
 To this end it is essential that City Building contracts with a provider that can fully demonstrate expertise and excellence in the scope
 required. The successful bidder must understand the requirement for business agility and cost control across the service.
 The term of the contract will be three years with options to extend by 24 months (1 year + 1 Year).
 The venues are listed below (please note these may be subject to change and venues added or deleted)
 Easterhouse (The Bridge) Swimming Pools
 Castlemilk Leisure Centre swimming Pools
 Tollcross aquatics Centre Swimming Pools
 Emirates Arena Vitality Pool
 Whitehill Swimming Pool
 Gorbals Leisure Centre Swimming Pools
 Springburn Leisure Centre Swimming Pools
 North Woodside Leisure Centre Swimming Pool
 Pollok Leisure Centre Swimming Pool
 Bellahouston Leisure Centre Swimming Pools
 Scotstoun Leisure Centre Swimming Pools
 Drumchapel Swimming Pools
 Maryhill Leisure centre Swimming Pools
 Croftcoin School (Hydrotherapy Pool)
 Kelbourne School (Hydrotherapy Pool)
 Keppoch Campus (Hydrotherapy Pool) Currently drained due to major leak.
 Hazelwood School (Hydrotherapy Pool)
 Langlands School (Hydrotherapy Pool)
 Abercorn School (Swimming Pool)
 Ashcraig / Ashton (Swimming Pool)
 City Building is also looking to contract with providers who undertake best practice and guidance to adhere to Pool Water Treatment
 Advisory Group (PWTAG) within the pool plant industry.

description: Glasgow

title: Glasgow Pool Plant Maintenance

title: Glasgow Pool Plant Maintenance

description:
City Building requires on behalf of its clients to manage and maintain a range of swimming pools and hydrotherapy pools across the client estate. Within all the swimming pools and hydrotherapy pools City Building is looking to contract with a company who can provide a
 reactive and planned maintenance regime in-line with the associated filtration systems that are outlined in the tender documents. These
 facilities are important in the cultural landscape of the city and help to provide:-
 Improve health and well-being.
 Learn important skills.
 Family friendly places.
 Social interaction.
 To this end it is essential that City Building contracts with a provider that can fully demonstrate expertise and excellence in the scope
 required. The successful bidder must understand the requirement for business agility and cost control across the service.
 The term of the contract will be three years with options to extend by 24 months (1 year plus 1 year)

description:
Contract is for 3 years with options to extend by 1 year + 1 year so new procurement exercise would be in 2028, 2029 or 2030 depending
 on what extension options are chosen

reviewDetails:
City Building (Glasgow) LLP must, by notice in writing as soon as possible, after the decision has been made,inform all bidders and
 candidates concerned of its decision to award the contract. City Building (Glasgow) LLP must allow a period of at leastthe relevant
 standstill period (where the notice is sent by facsimile or electronic means the period is 10 days ending at midnight at the end of the 10th
 day after that on which the notice is sent, when sent by other means the period is 15 days) to elapse between the date of dispatch of the
 notice referred to in Regulation 86 of the Public Contract (Scotland) Regulations 2015 “the Regulations”). CityBuilding(Glasgow) LLP is
 obliged to comply with the Regulations and any eligible economic operator can bring an action in the Sheriff Court or the Court of
 Sessionwhere as a consequence of a breach by City Building (Glasgow)LLP, suffers or risks suffering loss or damage. The bringing of
 court proceedings during the standstill period means that City Building (Glasgow) LLP must not enter into the contract unless the
 proceedings are determined,discontinued or disposed of; or the court,by interim order, brings to an end the prohibition. The bringing of
 court proceedings after the standstill period has elapsed and the remedies that are available to the courts are detailed in the Regulations.
 Economic Operators can write to City Building (Glasgow) LLP seeking further clarification on the notice, to which City Building
 (Glasgow) LLP must respond within 15 days. Economic Operators
 should be mindful to seek their own independent legal advice when they consider appropriate to do so.

submissionMethod: electronicSubmission written

description:
List and brief description of conditions:
 All works shall be carried out in accordance with best practices and shall include all proposed amendments to standard practices prior to the
 requirement for legal conformity, at the time of formal proposal, principally with regard to the following:
 The Factories Act.
 The Health and Safety at Work Act.
 BS 7671:2008 Requirements for Electrical Installations (IEE Wiring Regulations 17th Edition) and all subsequent amendments.
 All other statutory acts applicable to the works and local amendments or by-laws.
 British Standards and EC Directives.
 The Control of Substances Hazardous to Health (COSHH) Regulations.
 Construction (Design and Management) Regulations.
 Health and Safety documents L21, L22, L23, L24, L25.
 Water Supply Regulations.
 Control of Pollution Act 1974 Section 60.
 HSE Approved Code of Practice for Control of Legionella Bacteria in Water Systems ACoP L08.
 HSE Reporting of Injuries, Disease, and Dangerous Occurrences Regulations (RIDDOR).
 Waste Electrical and Electronic Equipment (WEEE) directives.
 Energy Performance of Buildings Directive (EPBD).
 Control of Asbestos Regulations 2012.
 Swimming Pool Water Treatment and Quality Standards for Swimming Pools and Spas(PWTAG) 2017 [including all recent updates]
 HSG 179 Health and Safety in Swimming Pools

description:
Bidders must comply with the undernoted financial requirements in order
 to participate in the tendering process:-
 There is a minimum financial requirement that affects trading performance and balance sheet strength
 Financial requirements for trading performance and balance sheet strength should be calculated on latest filed accounts
 accounts with Companies House
 Trading Performance
 An overall positive outcome on pre tax profits over a 3 year period
 Exceptional items can be excluded from the calculation.
 The above would be expressed in the ratio Pre-Tax Profit/Turnover
 Balance Sheet strength
 Net worth of the organisation must be positive at the time of evaluation
 and organisation must not be subject to an insolvency process.
 Intangibles can be included for purposes of the Total Assets figure.
 The above would be expressed in the ratio Total Assets/Total Liabilities
 Companies that are only required to file abbreviated accounts, must submit full sets of accounts
 for the last two individual years filed, in order for the three year profitability requirement to be verified
 An applicant should have no outstanding issues, with regard to statutory filing
 requirements with Companies House.
 Applicants who have been trading for less than the 3 years noted above must provide
 evidence that they are complying with the above minimum financial requirements
 for the period in which they have been trading.
 Applicants who do not comply with the above financial requirements but are part
 of a Group, can provide a Parent Guarantee if the Parent company satisfies the financial
 requirements stipulated above.
 City Building (Glasgow) LLP reserves the right, at its own discretion, to seek such other information from the Bidder
 in accordance with Regulations 61(7) or Regulation 61 (8) of the Public Contracts (Scotland) Regulations 2015
 to prove the Bidder's economic and financial standing.
 The insurance requirements for this contract are as follows –
 Employer’s Liability
 The organisation/consultant shall take out and maintain throughout the period of their services Employer’s Liability insurance to the value
 of at least TEN MILLION (GBP10,000,000) POUNDS STERLING in respect of any one claim and unlimited in the period.
 Public Liability
 The organisation/consultant shall take out and maintain throughout the period of their services Public Liability insurance to the value of at
 least TEN MILLION ("GBP" 10,000,000) POUNDS STERLING in respect of any one claim and unlimited in the period.
 Products Insurance
 The organisation/consultant shall take out and maintain throughout the period of their services Products Liability insurance to the value of
 at least TEN MILLION ("GBP"10,000,000) POUNDS STERLING in respect of any one claim and in the aggregate.
 Professional Indemnity
 The organisation/consultant shall take out and maintain throughout the period of their services and for a further 6 years on completion of
 their service, Professional Indemnity insurance to the value of a minimum TWO MILLION ("GBP"2,000,000) POUNDS STERLING in
 respect of any one claim and in the aggregate

description:
SPD 4C.1.2 Statement [GOODS AND SERVICES ONLY]
 CBG’s guidance for this question is detailed below-
 Provide two relevant examples from within the last five years that demonstrate
 your organisation has the relevant and necessary skills, expertise, and experience to
 deliver the service required by CBG.
 For each relevant example the following information should be provided but is not
 limited to –
 1. an overview of the contract including customer name, contract start and completion date and contract value.
 2. a thorough and detailed description for each example of the scope of the requirement and service provided by you demonstrating
 experience in dealing with a contract the same or similar in scope and complexity to the CBG’s requirements.
 Your response to this question should not exceed, for each example, 2 x A4 sides, this page count includes all text (Arial font 11),
 photographs, figures and diagrams.
 Where a submission exceeds the maximum number of pages indicated per example, no account will be taken of the content of the pages
 beyond the maximum.
 Weighting
 The weighting will be out of 100 with 50% attributed to each example. A minimum
 pass mark of 50 out of 100 is required overall for this question. Any bidder who fails
 to achieve the minimum score for this question will be excluded from the process at
 this stage.
 Minimum level(s) of standards required:
 Bidders must score a minimum of 60% in total for question 4C.1.2 question. Any Bidder who fails to achieve the minimum points score
 will be disqualified.
 Selection Criteria (Quality 30%)
 Total Technical Weighting
 Service Delivery 40%
 Staff Resource 30%
 Contract Management 25%
 Fair Work First 5%
 Full details will be in the tender documents.

City Building (Glasgow) LLP

postalCode: G21 4BA

streetAddress: 350 Darnick Street

id: Maintenance, Construction and Manufacturing

id: Maintenance, Construction & Manufacturing

legalName: City Building (Glasgow) LLP

description:
Health and Safety will be assessed on a PASS/FAIL basis - Bidders must hold
 ISO18001/ISO450001, or lot specific SSIP or comply with all questions in the Health and
 Safety Questionnaire.
 Environmental will be assessed on a PASS/FAIL basis - Bidders must hold ISO14001 or
 comply with all questions in the Environmental Questionnaire.
 Quality will be assessed on a PASS/FAIL basis - Bidders must hold ISO 9001 or comply
 with all questions in the Quality Questionnaire.
 Freedom of Information Act - Information on the FOI act is contained in the tender
 documents
 Insurance Mandate - Bidders will be asked to sign and return an Insurance Mandate that
 authorises CBG to request copies of insurance documents from the bidders insurance
 provider, should the bidder be successful
 Non Collusion - Bidders will be required to complete the Non Collusion Certificate
 contained within the tender documents.
 Additional information relevant to this contract opportunity can be found in the tender documents and SPD guidance documents
 The buyer is using PCS-Tender to conduct this tender exercise. The Project code is 28763.
 Fair Work First - This will be scored as 5% in the evaluation. Full details are in the ITT.
 The Contract is to be placed under, standard form SBCC Measured-Term Contract 2019 edition.
 The term of the contract will be three years with options to extend by 24 months.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 28763. For more information see:
 http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see:
 https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 CBG is requesting community benefits on a Mandatory basis for this the tender.
 CBG has a strong reputation for social values. At CBG where we are “Building a Sustainable Future”, we are providing skills to the
 workforce of tomorrow and generating true economic and sustainable benefits in our local communities and beyond.
 We are committed to:
 Delivering lasting employment opportunities to local people, including those with a disability and/or from minority groups.
 Engaging directly with local community groups, organisations and other agencies to ensure we maximise opportunities to improve local
 areas and overall well-being.
 - Combining commercial success with socially and environmentally responsible practices by giving life changing opportunities to those far
 removed from the labour market.
 Our strong commitment to sustainable development will ensure that we continue to leave positive and lasting legacies for future
 generations and inspire transformations in local communities.
 Community Benefits will be mandatory on a Pass/Fail basis and will therefore not be evaluated as part of the tender evaluation. Community
 benefits will therefore be a contractual requirement and form part of the awarded contact.
 Bidders must commit to paying 0.5% of the annual income derived from this contract with CBG to Community Benefits the detail of which
 to be determined by CBG, acting reasonably.
 (SC Ref 791998)
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 29453. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 0.5% of contracted spend
 (SC Ref:801267)


status: unsuccessful

statusDetails: unsuccessful

description: Dumfries & Galloway Health Board (more commonly known as NHS Dumfries & Galloway) (“NHS Dumfries & Galloway”) placed an advertisement in the Public Contracts Scotland portal on 10th June 2025, seeking expressions of interest from any parties interested in providing primary medical services to patients in Port William, Whithorn and the surrounding area.

description: Dumfries and Galloway

title: PROVISION OF PRIMARY MEDICAL SERVICES AT SOUTHERN MACHARS PRACTICE (Port William and Whithorn Practice Premises)

title: Specification

format: application/msword

title: Advert

title: Update

Dumfries and Galloway Health Board

locality: Dumfries

postalCode: DG1 4AP

streetAddress: Mountainhall Treatment Centre, Bankend Road

description: Health

legalName: Dumfries and Galloway Health Board

Dumfries Sheriff Court

postalCode: DG1 2AN

streetAddress: 40 Buccleuch Street

legalName: Dumfries Sheriff Court

Dumfries and Galloway Health Board

description: Health

Dumfries Sheriff Court

streetAddress: Buccleuch Street

description: (SC Ref:805079)


description: where specialist contractors are required

description: The framework may be extended for a further period of 1x 12 months

description: Moray Council is seeking a single supplier framework to engage with a contractor to deliver a number of civil engineering projects over a 2-3 year period, funding has been received through the levelling up funding from UK Government.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.

variantPolicy: allowed

description: Elgin, Moray

title: Levelling Up Funding LUF Civil Engineering and Construction Framework 2025

description: This procurement involves the establishment of a single supplier framework to deliver a number of civil engineering work packages associated with the Levelling up Funding for Moray.

description: Tender deadline extended to allow bidders time to consider and submit

periodRationale: Not applicable

minimum:
Bidders will be required to have a minimum “general” yearly turnover of 16 Million GBP for the last 3 years
 The bidder is required to confirm that (to the best of their knowledge) there are no material post balance sheet events or other business issues arising since the date of the last audited financial statements that materially impact the economic and financial standing of the economic operator.
 Where the operator is not able to make such a conformation, full details of the relevant events shall be provided along with an explanation of the expected impact on the bidders economic and financial standing.
 The bidder is required to provide a copy of the last 2 or 3 audited financial statements as evidence of their compliance to meet their statutory obligations.
 Employer's (Compulsory) Liability: 10000000 GBP (Ten million pounds)
 Public Liability: 10000000 GBP (Ten million pounds)
 Contractors all risks: 5000000 GBP (Five million pounds)

description:
Bidders will be required to confirm the financial criteria stated below:
 The bidder confirms they already have or can commit to obtain, prior to the commencement of the contract, the levels of insurance cover indicated below:

minimum: Provide 3 examples of projects in the last 5 years that have included civil engineering works on multiple sites with a total contract value over 1,000,000 GBP.

description: Bidders will be required to confirm that they have the relevant experience to deliver the works within this framework

mainProcurementCategory: works

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

description: General public services

legalName: Moray Council

Elgin Sherriff Court

roles: reviewBody mediationBody

postalCode: IV30 1BU

streetAddress: Sheriff Courthouse, High Street

legalName: Elgin Sherriff Court

Moray Council

description: General public services

Pat Munro Construction Ltd

locality: Alness

postalCode: IV17 0XU

streetAddress: Caplich Quarry

legalName: Pat Munro Construction Ltd

description:
Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 (SC Ref:806940)


title: Electrical Contractors

description: The Framework will be for a period of 2 years with the Council having the option to extend the Framework for an additional 12-month period on 2 separate occasions. Given a potential Framework duration of 4 years.

description:
The employment of electrical contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned electrical works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Joinery Contractors

description:
The employment of joinery contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned joiner works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Plumbing Contractors

description:
The employment of plumbing contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned plumber works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Plastering and Ceramic Tiling Contractors

description: 6.	The Framework will be for a period of 2 years with the Council having the option to extend the Framework for an additional up to 12-month period on 2 separate occasions. Given a potential Framework duration of 4 years

description:
The employment of plastering and ceramic tiling contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned plastering and ceramic tiling works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Painting and Decorating Contractors

description:
The employment of painting and decorating contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned painting and decorating works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Glazing Contractors

description:
The employment of glazing contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned glazing works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Tile and Slate Roofing Contractors

description:
The employment of roof tiling and slating contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned roof tiling and slating works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Flat Roofing Contractors

description:
The employment of flat roofing contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned flat roofing works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Blacksmiths and Metal Fencing Contractors

description:
The employment of Blacksmith and Metal Fencing contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned Blacksmith and Metal Fencing works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Suspended Ceiling Contractors

description:
The employment of Suspended Ceiling contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned Suspended Ceiling works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Heating Engineers

description:
The employment of Heating contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned Heating Engineer works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: General Builders

description:
The employment of General Building contractors to provide a reactive repair and maintenance service to domestic properties, public buildings and leisure centres. There will also be an option to procure planned General Builders works under this Lot.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Multi Trades Contractors

description:
The employment of Multi Trades Contractors to provide a reactive repair and maintenance service to the Contracting Authorities. There will also be an option to procure planned Multi Trades works under this Lot.
 Contractors awarded onto this Lot would require to be able to provide all the trades from Lots 1 to 12 to be deployed on a single Work Package as required. Contractors may also be required to provide trades not specifically included within Lots 1 to 12.
 Where a multi trades Work Package is awarded the Contractor will be required to supervise and coordinate all the trades under their control to ensure the efficient completion of the Work Package.
 Contractors should note that this framework will be used to supplement and support in-house resources at times of peak demand therefore the actual volume and value of works to be issued through this Lot is not known.

title: Framework Agreement for the Provision of Trades Contractors

description:
The purpose of this Framework Agreement is to give the Contracting Authorities (Renfrewshire Council, East Renfrewshire Council and ONEREN) a route to employ specialist contractors to carry out reactive repair, maintenance and lower value one-off projects.
 The trades required would be;
 ~ Electricians
 ~ Joiners
 ~ Plumbers
 ~ Plasterers and Ceramic Tilers
 ~ Painters and Decorators
 ~ Glaziers
 ~ Tile and Slate Roofers
 ~ Flat Roofers
 ~ Blacksmiths and Metal Fence Erectors
 ~ Suspended Ceiling Installers
 ~ Heating Engineers
 ~ General Builders
 There are Lots for individual trades groups (as mentioned above) and also a Lot for Multi-Trades should an individual work package require the coordinated use of various trades to enable its completion.

performanceTerms: As contained within the Invitation to Tender

reviewDetails: An economic operator that suffers or risks suffering, loss or damage attributable to breach of duty under the Public Contracts (Scotland) Regulations 2015 (SSI 2015/446, as amended) may bring proceedings in the Sheriff Court or the Court of Session in accordance with Regulation 88 of the 2015 Regulations.

description: Selection criteria as stated in the procurement documents

Renfrewshire Council

locality: Paisley

postalCode: PA1 1JB

streetAddress: Renfrewshire House, Cotton Street

description: General public services

legalName: Renfrewshire Council

See VI.4.3

locality: See VI.4.3

legalName: See VI.4.3

Court of Sessions

postalCode: EH1 1RQ

streetAddress: Parliament Square

legalName: Court of Sessions

description:
The bidder must complete and submit, WITH THEIR TENDER RESPONSE the following documents;
 ~ Completed Contract Data Part 2
 ~ Completed Offer Worksheet(s) relevant to the Lot or Lots that you are bidding for.
 ~ Tender Declaration Page(s) relevant to the Lot or Lots that you are bidding for.
 ~ Completed Tender Compliance Certificate.
 The Offer Worksheets and Tender Declaration Pages can be found within the attachment area of each individual Lot ITT. Please ensure that you complete the Offer Worksheet and Declaration Page for each Lot you are bidding for and reattach your completed documents in the attachment area of the relevant Lot.
 The Contract Data Part 2 and the Tender Compliance Certificate can be found within a folder entitled “Contract Documents” uploaded into the Attachment Area of the Master ITT.
 The bidder may also be required to complete and submit, at “REQUEST FOR DOCUMENTATION STAGE” the following Supplementary documents (S Docs);
 ~ S1 - Equalities Questionnaire
 ~ S2 - Equalities Declaration
 ~ S3 - No Collusion Certificate
 ~ S4 - Prompt Payment Certificate (if subcontractors are to be used)
 ~ S5 – Registered Waste Carrier Form
 ~ S7 - Health and Safety Questionnaire
 The above mentioned documents are provided with the tender documents and can be located within a folder entitled “Supplementary Documents” uploaded into the Attachment Area of the Master ITT.
 Within the Technical Envelope of the Master ITT, tenderers are requested to provide information in relation to their organisation and workforce. It should be noted that the detail requested in this section is for information only and will not form part of the award criteria and therefore has a “0” weighting.
 Tenderers are also required to provide responses to the Quality criteria as stated within the Invitation to Tender.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 29443. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Bidders are requested to refer to the document entitled Community Benefit Outcome Menu and state, in their tender response, how many Community Benefits Points (CBPs) they would commit to offering per GBP100K of spend per Lot through this Framework Agreement.
 (SC Ref:801284)


description:
The Highland Council has identified the former Torvean Quarry (Inverness) for development of a Battery Energy Storage System (BESS), which would support distribution network operations via connection to an existing (collocated) overhead 33kV line.
 The Highland Council has accepted a grid connection offer provided by the Distribution Network Operator (Scottish Hydro Electric Power Distribution PLC), for a 9,900 kVA import / 9,900 kW export connection, with an estimated connection date of 31 October 2027 (note that this date is subject to change).
 The Highland Council intends to tender (via open competition) for a developer to design, build and operate a BESS at the former Torvean Quarry. It is envisaged that the Highland Council would assign the accepted grid connection offer to the contracted party, and that the contracted party would undertake all required contestable distribution network works, in addition to the BESS build. The Highland Council would receive a standing lease payment for occupation of the site, plus an agreed revenue share, throughout the term of the lease (20 years). An Option to Lease fee would also be payable, from contract award, until the lease period begins.

description: Inverness, Highlands

title: Battery Energy Storage System (BESS) – Torvean Quarry, Inverness

description: The Highland Council has identified a site for the development of a Battery Energy Storage System (BESS). The Highland Council has accepted a grid connection offer and intends to tender for a developer to design, build and operate the facility.

title: 2012 Highland Wide Local Development Plan

title: 2019 Torvean and Ness-side Development

title: 2022 NFCC Planning Guidance

title: 2022-27 Administration Prog

title: 2024 Biodiversity Enhancement Planning Guidance

title: 2024-27 Delivery Plan

title: 2025 Topographical Survey 2

title: 2025 Topographical Survey

title: 2310 FBH005 Grid Connection Offer

title: 080130 SSSI 1557 Citation

title: 080130 SSSI 1557 Map

title: 080130 SSSI 1557 Operations Requiring Consent

title: 230528 Registered Land Title

title: 231102 Grid App Map

title: 231102 Total Installed Capacity Drawing

title: 250207 Drone footage of site

title: 250221 Preliminary Ecological Appraisal

title: Social Value Charter for Renewables Investment

title: Torvean Former Quarry - Plan

title: Torvean Former Quarry - Proposed Location Plan

title: 1 ITT Rev I

title: Appendix 1 Statement of Req Rev I

title: Appendix 2 Fair Work Rev C

title: Appendix 3 Bidder Climate Change Plan Rev D

title: Appendix 4 Specification Rev H

title: Appendix 5 Award Questionnaire Rev E

title: Appendix 6 Pricing Schedule Rev D

title: Appendix 7 Declaration Rev C

title: Heads of Terms Option Lease Torvean Quarry

The Highland Council

locality: Inverness

postalCode: IV3 5NX

streetAddress: Glenurquhart Road

description: General public services

legalName: The Highland Council

Inverness Sherriff Court

legalName: Inverness Sherriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801350.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 See procurement documents
 (SC Ref:801350)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=801350


description: extensions permitted with valid reasoning

description: Construction of new steel portal framed shed

description: Leitcheston Farm, Fochabers

title: Leitcheston - New GP Shed

title: Leitcheston - New GP Shed

description: Construction of new shed at Leitcheston Farm, Fochabers

title: Structural Engineer 1 of 2

title: Structural Engineer 2 of 2

title: Description of Works

title: Invitation to Tender

title: Site and Location plan

title: Floor Plan

title: Elevations

title: Structural Engineer 2 of 2

title: Updated floor plan - Robinsons drawing removed

title: Leitcheston - New GP Shed

performanceTerms: Refer to ITT and tender documents

description: Refer to ITT and tender documents

Strutt & Parker

postalCode: IV2 6AA

streetAddress: Perth Suite, Castle House, Fairways Business Park

id: Ministry or any other national or federal authority, including their regional or local subdivisions

description: General public services

legalName: Strutt & Parker

Crown Estate Scotland

roles: buyer reviewBody

postalCode: EH3 9GL

streetAddress: Quartermile Two, 2nd Floor, 2 Lister Square

legalName: Crown Estate Scotland

Strutt & Parker

description: General public services

S&L HENDRY  LTD

locality: Huntly

postalCode: AB54 7JX

streetAddress: Duncairn, Tarryblake

legalName: S&L HENDRY  LTD

Crown Estate Scotland

roles: buyer centralPurchasingBody reviewBody

description: General public services

description: (SC Ref:806555)


description: Two optional 12-month extensions will be available, at the College's discretion

description: Award of Contract for the provision of gritting and snow clearing services to North East Scotland College.

description: North East Scotland College Campuses around Aberdeen City and Aberdeenshire

title: Gritting and Snow Clearing Services

title: Gritting and Snow Clearing Services

description: Invitation to tender for the provision of gritting and snow clearing services to North East Scotland College.

title: Invitation to Tender

title: Appendix A

title: Appendix B

title: Appendix C

title: Appendix D

title: Appendix E

title: Appendix F

title: Gritting and Snow Clearing Services

streetAddress: North East Scotland College - Aberdeen City Campus

description: Electronic Download by Mark Davidson

performanceTerms: As stated in the procurement documents

North East Scotland College

locality: Aberdeen

postalCode: AB25 1BN

streetAddress: Aberdeen City Campus, Gallowgate

description: Education

legalName: North East Scotland College

name: Aberdeen Civil Justice Centre & Commercial Courts

postalCode: AB10 1WP

streetAddress: Castle Street

description: Education

idverde Ltd

locality: Coventry

postalCode: CV4 8JP

streetAddress: Octavia House, Westwood Business Park, Westwood Way

legalName: idverde Ltd

description: (SC Ref:809825)


description: The Contracting Authority has received funding to support a Glasgow-wide initiative that will enable users to measure the binding properties of molecules directly on live cells. The equipment will be suitable for a wide range of analyses for eukaryotic cell types and will be underpinned by support from dedicated research technical professionals within the Strathclyde Centre for Molecular Bioscience (University of Strathclyde) and the Integrated Protein Analysis Facility (University of Glasgow). The equipment will be part of the facility enabling the UK userbase integrated access to a breadth of bioanalytical and biophysical facilities to examine cellular binding interactions.

title: Instrument to measure binding kinetics and thermodynamics parameters in individual cells in a high-throughput format.

description: The Contracting Authority received funding to support a Glasgow-wide initiative that will enable users to measure the binding properties of molecules directly on live cells. To support this research, the Contracting Authority requires an instrument to measure binding kinetics and thermodynamics parameters in individual cells in a high-throughput format.

reviewDetails: An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland)Regulations 2015 (SSI2015/446) (as amended) may bring proceedings in the Sheriff Court or the Court of Session.

mainProcurementCategory: goods

procurementMethodRationale:
The Contracting Authority has received funding for an automated biosensor for single-cell Interaction Cytometry. The instrument allows kinetic characterisation of molecules binding to membrane targets in individual cells.
 Equipment to be procured must be capable of enabling real-time kinetic binding analysis at the single-cell level, with unmatched sensitivity, microfluidic control, and fluorescence detection in a single high-throughput format.
 The dynamic chip-based biosensor system identified was used in the application for funding and contains patented technology (WO/2021/239855) relating to the time-resolved dynamics measurement of biosensor probes.
 As such, this contract shall be awarded under Regulation 33 (1) (b) (ii) as the University intends to award this public contract following the negotiated procedure without prior publication of a contract notice as the competition is absent for technical reasons.

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

University of Strathclyde

locality: Glasgow

postalCode: G1 1XQ

streetAddress: 49 Richmond Street ,Procurement, Finance Directorate

description: Education

legalName: University of Strathclyde

Dynamic Biosensors GmbH

region: DE

locality: Martinsried / Planegg

streetAddress: Lochhamer Str. 15

legalName: Dynamic Biosensors GmbH

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

University of Strathclyde

streetAddress: McCance Building, 16 Richmond Street

description: Education

Glasgow Sheriff Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

description:
It should be noted that this VEAT notice is intended to inform the market of the intention to award a contract under Regulation 33 (1) (b) (ii) and whilst the system requires an award date before the notice publication for the avoidance of doubt it should be noted that the contract has not been entered into before the publication of this notice. The University intend to enter into the contract on 14/07/2025.
 (SC Ref:808973)


title: NHS Borders Winter Gritting Lot 1

description: The contract is for 2 years with the option to extend for years 3 & 4 - as set out in the tender document

description:
Winter gritting / snow clearance to footpaths, roads and car parks to properties as listed below:
 Kelso Health Centre
 Kelso Hospital
 Coldstream Health Centre
 Greenlaw Medical Centre
 Knoll Hospital
 Eyemouth Health Centre & Day Hospital
 Earlston Health Centre

title: NHS Borders Winter Gritting Lot 2

description:
Winter gritting / snow clearance to footpaths, roads and car parks to properties as listed below:
 Newcastleton Health Centre
 Jedburgh Health Centre
 Hawick Health Centre
 Hawick Community Hospital & Dental Centre
 Selkirk Health Centre
 Andrew Lang Centre

title: NHS Borders Winter Gritting Lot 3

description:
Winter gritting / snow clearance to footpaths, roads and car parks to properties as listed below:
 Galavale Hospital
 Galashiels Health Centre
 Sime Place Day Unit
 Roxburgh Street Health Centre
 Stow Health Centre
 Melrose Health Centre
 Lauder Health Centre
 St Ronanas Health Centre
 Firholm Day Unit
 Hay Lodge Hospital & Health Centre
 West Linton Health Centre

title: NHS Borders Winter Gritting

title: NHS Borders Winter Gritting

description: Treatment (gritting and snow clearance) to car parks, access roads and footpaths around NHS Borders properties.

title: Lot 1 - Tender Documents

title: Lot 2 - Tender Documents

title: Lot 3 - Tender Documents

title: Lot 1 - Excel Tender Document

title: Lot 2 - Excel Tender Document

title: Lot 3 - Excel Tender Document

title: Winter Gritting Tender Lots Property List - updated for Community Hospital

performanceTerms: Measured Term Contract - as per tender documents

NHS Borders

locality: Melrose

postalCode: TD6 9BS

streetAddress: Borders General Hospital

description: Health

legalName: NHS Borders

Scottish Courts and Tribunals Service

locality: Selkirk

postalCode: TD7 4LE

streetAddress: Sheriff Court House, Ettrick Terrace

legalName: Scottish Courts and Tribunals Service

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=801383.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 There is a Community Benefits question within the quality section to be provided within the tender return
 (SC Ref:801383)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=801383


description: The Contract will have an option to extend of 2 years on 1 occasion at the sole discretion of the Council.

description:
Renfrewshire Council's ICT Services requires the continued delivery of a Software Asset Management as a Service model as currently used by the Council for a period of 3 years with the option to extend for a further 2 at the sole discretion of the Council.
 SAMaaS will provide analysis of the Council’s data ensuring that software compliance issues are highlighted for action. They will offer advice and support in the execution of these actions and defend the Council’s position in any compliance audit scenario. Whilst continuing to achieve full software compliance the next stage will be to optimise the Council’s license usage through knowledge and review of the license models.
 The Tender Procedure shall be conducted in accordance with an above Government Procurement Agreement (GPA)Threshold as an Open procedure.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.

name: Approach to Implementation, Resources, Knowledge and Skills

description: Renfrewsjore Council’s ICT Service requires the renewal of its Software Asset Management as a Service (SAMaaS) Contract. The SAMaaS provides analysis of the Council’s data which ensures that software compliance issues are highlighted for action. The SAMaaS provider offers advice and support in the execution of these actions. It also helps the Council in its aim to reduce the number of contracts the Council has across various departments with the same Service Provider, allowing for more streamlined contract management and a reduction in costs.

description: Tenders will be opened in accordance with the Council's Standing Orders Relating to Contracts.

description: Another notice will be published around 1 year prior to the expiry of this Contract.

performanceTerms: Contract performance conditions are stated within the Invitation to Tender documentation which can be found under project 29403 at https://www.publictendersscotland.publiccontractsscotland.gov.uk/esop/pts-host/public/pts/web/login.html

minimum:
The Council will utilise Dun & Bradstreet (D&B) to calculate a Failure Score. Tenderers (including all participants in a group) are required to have a Failure Score of 20 or above in order to demonstrate its financial strength and stability. For further information regarding evidencing financial stability can be found within the Invitation to Tender attached to the General Attachment area on PCS-T project number 29403.
 Where the Tenderer is under no obligation to publish accounts and/or does not have a D&B Failure Score, they must provide their audited financial accounts for the previous 2 years as part of their ESPD Submission in order that they Council may asses these accounts to determine the suitability of the Tenderer to undertake a Framework of this size and duration.
 It is a requirement of this Contract and Tenderers hold, or can commit to obtain prior to the commencement of the Contract and maintain throughout the Contract, the types and levels of insurance indicated below:
 Employer’s (Compulsory) Liability Insurance = Statutory minimum 5 million GBP each and every claim, where the tenderer is exempt from this requirement, eg as a ‘sole trader’, then this must be confirmed by the Provider in writing;
 Public Liability Insurance = minimum 1 million GBP for each and every claim;
 Professional Indemnity Insurance – minimum 1 million GBP every claim, and will accept cover in the aggregate.

minimum:
Tenderers will be required to provide examples that demonstrate that they have at least 3 years of the relevant experience to deliver the services described in the Tender Documents to be considered for this Contract.
 Tenderers will be asked to provide details of their Environmental Management Plan and Health and Safety Policy.

Renfrewshire Council

description: General public services

Court of Session

roles: reviewContactPoint reviewBody

locality: Edinburgh

legalName: Court of Session

description:
Tenderers are required to comply with the following:
 - Specification;
 - General Conditions of Contract;
 - Special Conditions;
 - Data Processing Agreement document.
 - Cyber Security Requirements as contained in the Specification.
 Tenderers must complete, sign and upload the following documentation (as contained within the Supplier attachment area on PCS_T) with their tender submission:
 - Tender Declaration Certificate;
 - Equalities Questionnaire;
 - Equalities Declaration;
 - Tender Compliance Certificate;
 - Prompt Payment Certificate;
 - No Collusion Certificate;
 - H&S Questionnaire;
 Please note that all documents must be signed by an authorised signatory.
 Request for Information:
 Evidence of your company's insurance certificates detailing the required level of insurance's as per the levels stated within this Contract Notice and as detailed within the Invitation to Tender documentation must be uploaded within the general attachments area in Public Contract Scotland Tender Portal upon request by the Council.
 Any contract awarded as a result of this tender exercise will be subject to Scots Law and the exclusive jurisdiction of the Scottish Courts.
 Tenderers are asked to complete a Community Benefit (CB) Outcome Menu and supporting methodology for a technical value of 5%. Full instructions regarding how to complete the Community Benefit (CB) Outcome Menu will be contained within the Invitation to Tender which can be found on PCS-T project number 29403.
 All additional information relevant to this procurement exercise is detailed within the Invitation to Tender document which can be found on PCS-T project number 29403.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 29403. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Tenderers will be asked to complete Renfrewshire Council's Community Benefit Outcome Menu to a value of 50 Community Benefit Points for a value of 3% of the overall technical score. Tenderers will also be asked to provide supporting methodology regarding how Community Benefits will be delivered for a value of 2% of the overall technical score.
 (SC Ref:801394)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

name: Penumbra Interventional Therapies UK Limited

title: Thrombectomy Kits

title: Accessories and Miscellaneous

title: Innovation

title: Commitment and Collaboration

title: Guidewires

title: Detachable coils (for intracranial use)

title: Endosaccular devices

title: Stent retrievers

description:
The supply of Guiding catheters (including balloon guides and long sheaths) which are used within Interventional Neuro Radiology
 procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Intermediate Catheters (including aspiration, intracranial support and distal access) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Intracranial catheters (including Microcatheters) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Guidewires

description: The supply of Guidewires which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Detachable coils (for intracranial use)

description: The supply of Guiding Detachable coils (for intracranial use) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Endosaccular devices

description: The supply of Endosaccular devices which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Intracranial stents (including flow diverting, braided, lasercut and venous stents) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Extracranial stents including embolic protection devices which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Stent retrievers

description: The supply of Stent retrievers which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Embolic material (including particles and liquids) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

description: The supply of Balloons (for balloon remodelling catheter and intracranial angioplasty balloons) which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Thrombectomy Kits

description: The supply of Thrombectomy Kits which are used within Interventional Neuro Radiology procedures across NHS Scotland. These products will be delivered to multiple sites across Scotland.

title: Accessories and Miscellaneous

description:
Accessories & Miscellaneous - Unscored Lot.
 This Lot is for items which don't fall into Lots 1-12 but are used in association with an item(s) submitted in another Lot. These items must be relevant to any of the items within Lots 1-12 of the framework. The Authority reserves the right to accept or decline any items submitted into this Lot onto the framework. Suppliers are only awarded to this Lot if they have been successfully awarded to one of the scored Lots (1-12).

title: Innovation

description:
Innovation - Unscored Lot.
 For items which are yet to be made available to the market, but will become available over the duration of the framework. These items must be relevant to any of the items within Lots 1-12. The Authority reserves the right to accept or decline any items submitted into this Lot onto the framework. Suppliers are automatically awarded to this Lot if they have been successfully awarded to any of the other Lots (1-12).

title: Commitment and Collaboration

description:
Commitment Lot - Unscored.
 This Lot is for suppliers who have been awarded to one or more of the scored Lots (1-12). The purpose of this Lot is to allow suppliers to propose commitment (value or volume) or collaboration (multi Health Boards) structures, which will result in improved value for end users or Health Boards. Please detail below any improved value offers below.

description:
This framework is a retender for the supply and delivery of Interventional Neuro Radiology and Thrombectomy Consumables, awarded
 across a total of 15 Lots as a multi-supplier unranked award.

reviewDetails: The bringing of court proceedings against the Authority after the Framework Agreement has been entered into will not affect the Framework Agreement unless grounds for the imposition of special penalties under the Public Contracts (Scotland) Regulations 2015 can be established. Otherwise the remedies that may be awarded by the courts where the Framework Agreement has been entered into are limited to the award of damages.

description: Health

Abbott Medical U.K. Ltd

streetAddress: Abbott House, Vanwall Business Park, Vanwall Road

Cordis Medical UK Limited

streetAddress: Suite 402, Chadwick House, Birchwood Park

Microvention UK Ltd

streetAddress: Suite 3, The Barracks Building, 10 Cliffords Fort,

SELAMEDICL UK LTD

streetAddress: BUILDING 4 NORTH LONDON BUSINESS PARK, Oakleigh Road South

title: Thrombectomy Kits

title: Accessories and Miscellaneous

title: Innovation

title: Commitment and Collaboration

title: Guidewires

title: Detachable coils (for intracranial use)

title: Endosaccular devices

title: Stent retrievers

description:
The total value stated in sections II.2.5 and V.2.4 covers the full duration of the framework, including any extension options.
 (SC Ref:801406)


description: Argyll and Bute Council wish to appoint a single supplier to facilitate the Design, Fabrication and Installation of a minimum of 10 artworks for Helensburgh Outdoor Museum, inspired by Community Engagement undertaken on behalf of the council.. There is a maximum budget of 80,000 GBP available for this project, if the fee is above the allocated budget the tender will not progress. To meet external funding requirements, all activity must be completed by 31st March 2027.

description: Helensburgh.

title: Delivery of Artwork for Helensburgh Outdoor Museum.

title: HOM - Delivery of Artwork ITT v3

title: Engaging-Communities-PDF_-002

title: HOM Delivery of Artwork Pricing Schedule

Argyll and Bute Council

locality: Lochgilphead

postalCode: PA31 8RT

streetAddress: Kilmory

description: General public services

legalName: Argyll and Bute Council

description: General public services

Oban Sheriff Court House

postalCode: PA34 4AL

streetAddress: Sheriff Court House

legalName: Oban Sheriff Court House

description: Argyll and Bute Council wish to appoint a single supplier to facilitate the Design, Fabrication and Installation of a minimum of 10 Artworks at the Helensburgh Outdoor Museum. Services to include community engagement activities to support the development of the designs.

documentType: plannedProcurementNotice

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=810036.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:810036)


description: In line with 72 - Modification of Contracts During their Term, of the Public Contracts (Scotland) Regulations 2015, this Contract may be modified without a new procurement procedure in accordance with this Part in some cases.

description: The contract duration is 24-months, with the option to extend for up to an additional two 12-month periods. The Contracting Authority reserves the right to utilise the extension periods at its discretion.

description:
The University of Strathclyde (“the University”) is seeking to establish a Contract to support the delivery of activities outlined below. The Contract will include, however, will not be limited to:
 - Provide routine analysis and interpretation of results for microbiological (TVCs, coliforms, E. coli) & legionella:
 - Provide ad hoc sample collection and analysis for all types of water tests (both microbiological & chemical):
 - Must be able to react to unforeseen circumstances and provide assistance with technical engineering issues related to water services:
 - Supplier sampling staff should be appropriately trained in sampling techniques as per British Standards Institution (BSI) BS 8554:2015 for the sampling and monitoring of hot and cold-water services in buildings, and subject to verification of competence, before being allowed to work unsupervised; and
 - Must be able to provide reactive services and respond to any queries within 1 hour of the initial query.
 This contract will be awarded on a sole supply basis and will be largely related to services.
 Please note, any tank sampling / risk assessment requirements at NMIS & PNDC is covered by Skanska Construction UK Ltd via the contract for the Provision of Facilities Management Services for NMIS & PNDC (2023-33) (UOS-21891-2021). Regarding other sites located out with the John Anderson Campus, there is no current requirement for these Services at these sites, however, they will be able to utilise this Contract also.
 All orders will be raised by Estates Services who will manage the Contract, it is not envisaged that departments will raise any orders for these Services, as any requirement for tank sampling & risk assessment should be done via the EMS (Estates Maintenance Services) system at the University.

description: University of Strathclyde.

description: The University of Strathclyde ("the University") is seeking to establish a Contract for the Provision of Tank Sampling, Legionella Risk Assessments & Associated Services (2025-29) (UOS-36552-2025).

description:
II.2.4) Description of the Procurement
 Please note, Section II.2.4) Description of the Procurement, has been updated as follows:
 The University of Strathclyde (the "University") is seeking to establish a contract to support the delivery of activities outlined below.
 This Contract will include, however, will not be limited to:
 - Routine analysis and interpretation of results for microbiological (TVCs, coliforms, e.coli) & legionella:
 - Ad hoc sample collection and analysis for all types of water tests & both microbiological chemical (usually requested when the University / Estates Services have identified potential water quality issue):
 - Investigative monitoring in cases of staff complaints or whereby analysis highlights issues of non-conformity:
 - Required to operate independently. No remedial water treatment work will be awarded to the appointed Contractor of analytical services, and they must be able to demonstrate impartiality and independence from any water treatment works:
 - Testing laboratory must be accredited to BS EN ISO/IEC 17025. Laboratory must be situated locally, ideally within 1 hour of Glasgow in order to undertake short notice sampling with swift and efficient analytical turnaround:
 - The appointed Contractor must be able to react to unforeseen circumstances and provide assistance with technical engineering issues related to water services:
 - The appointed Contractor must provide competent auditing and technical advice to ensure full WQ legislative compliance:
 - The appointed Contractor's sampling staff must be appropriately trained in sampling techniques as per British Standards 8554:2015 Code of Practice for the sampling and monitoring of hot and cold water services in buildings, and subject to verification of competence, before being allowed to work unsupervised; and
 - The appointed Contractor's sampling staff will also possess an understanding of the basic principles and practices of water services, distribution and quality. In addition to this, sampling staff shall demonstrate a basic knowledge of relevant chemical and microbiological analytical procedures.
 The appointed Contractor must hold the following accreditation (or equivalent):
 - Registered with Legionella Control Association for Legionella Risk Assessment Services and Legionella Monitoring Services: 1.1 -Legionella Risk Assessment Services - Hot and Cold Water Systems, 1.3 - Legionella Risk Assessment Services - Process and Other Systems, 7.1 - Sampling, 7.3 - Laboratory Services, and 7.4 - Interpretation of Analysis:
 - SGS ISO 9001:2015:
 - UKAS (ISO / IEC 17025:2017); and
 - SafeContractor.

description: Yes, it is envisaged that when this contract comes to an end that the Contracting Authority will tender this requirement again - a Contract Notice is expected to be published in c. June 2029.

performanceTerms:
For full details of the conditions relevant to the proposed Contract, please refer to the tender documents (details of how to access these being set out in section 1.3) Communication, of this Contract Notice.
 The University of Strathclyde will require the members of any tendering group of entities (including, but not limited to consortium members, members of a group of economic operators and/or subcontractors) to be jointly and severally liable for the performance of the Contract (no matter the legal form taken by those entities in order to enter into the Contract).

reviewDetails: An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contract (Scotland) Regulations 2015 (SSI2015/446) (as amended) may bring proceedings to the Sheriff Court or the Court of Session.

procurementMethod: selective

minimum:
1. SPD (Scotland) Question 4B.1.2: Average Yearly Turnover
 The Candidate will be required to have a minimum average yearly turnover of GBP 573,570 for the past 3 financial years.
 2. SPD (Scotland) Question 4B.5: Insurance Requirements
 It is a requirement that Candidates hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below;
 SPD (Scotland) Question 4B.5.1a
 Professional Risk Indemnity: maintain a minimum indemnity limit of GBP 2 million any one claim, and in the aggregate.
 SPD (Scotland) Question 4B.5.1b
 Employer's (Compulsory) Liability: maintain a minimum indemnity limit of GBP 10 million in respect of each claim, and without limit to the number of claims.
 SPD (Scotland) Question 4B.5.2
 Public Liability: maintain a minimum indemnity limit of GBP 10 million in respect of each claim, and without limit to the number of claims.
 Motor Vehicle Insurance - maintain a minimum indemnity limit of GBP 5 million for Property Damage, and unlimited in respect of Third Party Injury

description:
1. SPD (Scotland) Question 4B.1.2: Average Yearly Turnover
 2. SPD (Scotland) Question 4B.5: Insurance Requirements

minimum:
1. SPD (Scotland) Question 4C.1.2: Services
 The Candidate will be required to provide examples that demonstrate that they have the relevant experience to deliver the services/supplies as described in part II.2.4 of the OJEU Contract Notice or the relevant section of the Site Notice.
 The Candidate must use the template provided for them (Appendix C) to answer question 4C.1.2 of their SPD (Scotland) response, which can be found in the "Appendices" folder within the "Buyer Attachments" area.
 The Candidate MUST upload the completed document next to question 4C.1.2. DO NOT UPLOAD THIS DOCUMENT INTO THE “GENERAL ATTACHMENTS” AREA.
 The below scoring methodology will be applied to the question.
 Excellent response - 4
 Response is completely relevant and excellent overall. The response is comprehensive, unambiguous and demonstrates thorough experience, knowledge or skills/capacity/capability relevant to providing similar services to similar clients.
 Good response - 3
 Response is relevant and good. The response is sufficiently detailed to demonstrate a good amount of experience, knowledge or skills/capacity/capability relevant to providing similar services to similar clients.
 Acceptable response - 2
 Response is relevant and acceptable. The response demonstrates broad previous experience, knowledge and skills/capacity/capability but may lack in some aspects of similarity e.g., previous experience, knowledge or skills may not be of a similar nature.
 Poor response - 1
 Response is partially relevant but generally poor. The response shows some elements of relevance to the criterion but contains insufficient/limited detail or explanation to demonstrate previous relevant experience/ capacity/capability.
 Unacceptable (Nil or Inadequate response) – 0
 Nil or inadequate response. Fails to demonstrate previous experience/capacity/capability relevant to this criterion.
 These questions will be scored by a technical panel made up of representatives from the Contracting Authority. Once all scores are agreed, an average score will be applied to all questions.
 The Candidate is required to provide one (1) example of services which they have delivered in the past three years that demonstrates they have relevant experience and capacity to deliver the key elements of the services, as described in part II.2.4 of the Contract Notice or the relevant section of the Site Notice and noted individually below.
 Please note, the Candidate is permitted to use the same example for one, several, and / or all of their responses, and is also permitted to provide different examples as required and / or appropriate, taking into consideration the requirements outlined under each question.
 - Question / Example 1 - Transportation Process & Timelines (35%)
 - Question / Example 2 - In-house Laboratory Testing & Accreditations (35%)
 - Question / Example 3 - Water Sampling Analytical Services (30%)
 2. SPD (Scotland) Question 4D.1: Quality Assurance Schemes
 Due to restrictions placed upon the character count by the advertising portal, the Candidate should refer to the full detail provided within the document "Appendix D - Contract Notice Additional Information v1", which can be found in the "Appendices" folder, within the "Buyers Attachments" area within the relevant ITP (Invitation to Participate) on PCS-Tender (PCS-T). The Candidate must meet the relevant minimum level(s) of standards set out.
 3. SPD (Scotland) Question 4D.2: Environmental Management Standards
 Due to restrictions placed upon the character count by the advertising portal, the Candidate should refer to the full detail provided within the document "Appendix D - Contract Notice Additional Information v1", which can be found in the "Appendices" folder, within the "Buyers Attachments" area within the relevant ITP (Invitation to Participate) on PCS-Tender (PCS-T). The Candidate must meet the relevant minimum level(s) of standards set out.

description:
1. SPD (Scotland) Question 4C.1.2: Services
 2. SPD (Scotland) Question 4D.1: Quality Assurance Schemes
 3. SPD (Scotland) Question 4D.2: Environmental Management Standards

procurementMethodDetails: Restricted procedure

University of Strathclyde

postalCode: G1 1XU

streetAddress: Learning & Teaching Building, 49 Richmond Street

description: Education

name: Glasgow Sheriff Court and Justice of the Peace Court

postalCode: G5 9DA

description:
In line with regulation 72 of the Public Contracts (Scotland) Regulations 2015, this Contract may be modified without a new procurement procedure in accordance with this Part in some cases.
 The buyer is using PCS-Tender to conduct this PQQ exercise. The Project code is 29467. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 In accordance with section 25(3) of the Procurement Reform (Scotland) Act 2014 note that, the University of Strathclyde intends to include community benefit requirements. As part of your response within the Technical Envelope of the Invitation to Tender (ITT), the Tenderer will be requested to commit to the delivery of community benefits in accordance with the methodology outlined in the tender documents.
 (SC Ref:801410)