description: The procurement of a private sector partner to adopt the Ayrshire Authorities’ Existing EVCI and expand the EV public charging network within Ayrshire through a mix of public and private funding, as well as the supply and installation of fleet/depot charging infrastructure funded the Partner Councils will be procured through a partnership between North Ayrshire, South Ayrshire, and East Ayrshire, led by East Ayrshire Council. Please see the Ayrshires Project Information Pack for further details.. This Procurement is following the Restricted Procedure. Its envisaged there shall be up to 5 bidders short-listed to be invited to the Stage 2 Invitation to Tender.

description: East Ayrshire Council, North Ayrshire Council and South Ayrshire Council. East Ayrshire Council are the lead authority.

description: Provision of public electric vehicle charging services and supply and installation of associated electricity vehicle charging services for local authority (including fleet charging) for East Ayrshire Council, North Ayrshire Council and South Ayrshire Council

performanceTerms: The KPIs will be available at Stage 2 Invitation to Tender to the short-listed bidders.

description: Please refer to the SPD documentation.

minimum:
The bidder confirms they already have or can commit to obtain, prior to the commencement of the contract, the levels of insurance cover indicated below:
 Professional Risk Indemnity: GBP 2million (in respect of each and every claim without limit to the number of claims, for 6 years from the date of completion)
 Employer's (Compulsory) Liability: GBP 10million (in respect of each and every claim, without limit to the number of claims)
 Public Liability: GBP 5million (in respect of each and every claim, without limit to the number of claims)
 Product Liability: GBP 5million (in the aggregate)
 Other Insurance:
 Type: Goods in Transit
 Minimum Amount: To be determined by the Concessionaire
 Type: Contract Works (Loss or Damage to Works)
 Minimum Amount: Works Contract value plus 50 percent
 Type: Loss or Damage to Plant, Equipment and Materials
 Minimum Amount: To be determined by the Concessionaire
 Type: Motor Vehicle Insurance
 Minimum Amount: To be determined by the Concessionaire
 Please refer to the attached Insurance Questionnaire in PCS-T for further information, this must be completed successfully.

description:
Bidders are required to provide their General yearly turnover for the previous THREE years. The minimum turnover required per year is GBP 2.5million.In addition, The Council shall commission an independent third party business credit report from Creditsafe Business Solutions Ltd using the Company Registration number supplied by the Tenderer. Any Tenderer who does not meet the minimum threshold of a Credit Score of 30 out of 100 will have their submission regarded as a “Fail” and will not be considered further. Where a Tenderer receives a Credit Score of between 30-50 out of 100, the Council reserves the right to request further financial information to determine the risk to the Council. In the event that such additional measures are requested, the Council shall, in its sole discretion, determine the terms of those measures that it deems as acceptable. If Tenderers cannot provide measures to the satisfaction of the Council then their submission may be rejected.
 Risk or Credit reports from other agencies will not be considered.
 It is the Tenderers responsibility to ensure that all information held by Creditsafe Business Solutions Ltd is current and accurate when submitting their Tender. The Council will not enter into discussions with Tenderers who fail to ensure that their Creditsafe Business Solutions Ltd scores are accurate by the due submission date.

minimum:
4C Qualifications - Bidders are required to confirm that they and/or the service provider have the following relevant educational and professional qualifications and provide:
 -Qualifications for all personnel involved delivering works, including but not limited to electrical, environmental, and project management certifications.
 -New Roads and Street Works Act 1991 Street Works Operative and Supervisor Qualifications
 -Ability to demonstrate that your workforce includes individuals with EV-specific installation training (e.g., City & Guilds 2919-01 or equivalent).
 -Professional memberships and certifications (e.g., NICEIC, CSCS, SMSTS).
 Bidders are required to meet the criteria set out in PCS-T relating to Health and Safety, Quality Management and Environmental Management.

description:
In order to ensure that newer or start-up companies have a chance to demonstrate any experience relevant to the current requirement, examples may be provided from:
 -Within their organisation (bidders may rely on the experience of personnel that they intend to use to carry out the current requirement, even if that experience was gained whilst working for a different organisation)
 -Other consortium members (where a consortium bid is being proposed)
 -Named entities upon whose capacity and capability the bidder is relying in order to meet the selection criteria
 Bidders should be aware that they may be asked to confirm at the Invitation to Tender stage that there has been no material change to the skills, experience and resources available to them since submitting their SPD response.
 The bidder should only provide information where the selection criteria have been specified by the public body in the relevant Contract Notice.
 Question 4C.1 and 4C.1.2 Experience Examples for Works and Services are SCORED questions and are weighted as follows:
 4C.1. Works Experience (30%)
 4C.1.2 Services Experience (70%)
 Bidders will be required to provide 2 example of Works carried out in the past five years that demonstrate that they have the relevant experience to deliver the Works as described in part II.2.4 of this Contract Notice. The Works should be of a similar value, size and scope.
 Bidders will be required to provide 2 example of Services carried out in the past five years that demonstrate that they have the relevant experience to deliver the Works as described in part II.2.4 of this Contract Notice. The Works should be of a similar value, size and scope.
 Bidders must provide contact details of referees for the experience example. Referees may be contacted to discuss the contract and the performance of the Contractor. Any Contractor which fails to have performed satisfactorily in the experience example may be excluded from the tender process.
 4C.10 Sub-Contracting Percentage - for information only.

East Ayrshire Council

locality: Kilmarnock

postalCode: KA3 7BU

streetAddress: Corporate Procurement Team, London Road HQ

description: General public services

legalName: East Ayrshire Council

Kilmarnock Sheriff Court

postalCode: KA1 1ED

streetAddress: Sheriff Court House, St Marnock Street

legalName: Kilmarnock Sheriff Court

description:
The Restricted Procedure indicative timescales are detailed in the Ayrshire Project Information Pack - March 2025.
 The buyer is using PCS-Tender to conduct this PQQ exercise. The Project code is 28613. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Community Benefits information will be available at Stage 2 Invitation to Tender to the short-listed bidders. Community Benefits are a mandatory requirement.
 (SC Ref:791963)


rel: canonical

status: active

description:
The current Integrated Platform Management System (IPMS) is based on a computerised system last upgraded in 2013 on MPV Minna, 2014 on MPV Jura and 2015 on MPV Hirta.
 The system employed uses MOXA Marine PC’s.
 MPV Jura and MPV Hirta have two PCs hard-wired together forming dual-redundant work stations in the machinery control room (MCR), linked by a fibre-optic ring main to nine Input / Output (I/O) plates, and a third PC in the engine room workshop as a remote workstation.
 MPV Minna has two PCs hard-wired to each other forming dual-redundant work stations in the machinery control room (MCR), linked by a fibre-optic ring main to six Input / Output (I/O) plates
 Due to the increasing age of the systems electronic components, there have been several failures on the input/output plates and slices, along with other sensitive electronic components.
 The requirement is to visit each vessel (MPV Jura, Minna & Hirta) at an agreed timing to performance maintenance on the IPMS of each vessel annually.

variantPolicy: allowed

description: At docking site of vessels, Aberdeen and Glasgow.

region: UKM

scheme: CPV

title: Maintenance of Integrated Platform Management System (IPMS) on MPV Jura, Minna & Hirta

currency: GBP

format: text/html

description:
The Scottish Ministers, Marine Directorate invites tenders for the maintenance of the Integrated Platform Management Systems (IPMS) on MPV’s Jura, Minna and Hirta on an annual basis.
 The requirement is to visit each vessel (MPV Jura, Minna & Hirta) at an agreed timing to performance maintenance on the IPMS of each vessel annually.

documentType: contractNotice

title: Invitation to Tender

format: application/msword

title: Schedule 14 - Terms and Conditions for Provision of Services

streetAddress: Aberdeen

procurementMethod: open

type: economic

minimum:
4B2a: Bidders will be required to have a minimum "specific" yearly turnover of 150,000 GBP for the last two years.
 In the event that the Bidder does not comply with this requirement, they will not be considered any further in this tendering exercise.
 As evidence for the SPD (Scotland) question 4B1a, the Procurement Officer may ask for annual accounts from the bidder.
 4B5: It is a requirement of this contract that bidders hold or can commit to obtain prior to the commencement of any subsequently awarded contract, the types of insurance indicated below:
 Employers (Compulsory) Liability Insurance = In accordance with the legal obligation for the time being enforced.
 Public Liability Insurance = 1 Million GBP
 4B6: Bidders must demonstrate a Current Ratio of greater than 0.8.
 Current Ratio will be calculated as follows: net current assets divided by net current liabilities.
 Bidders must demonstrate a Net Profit greater than zero within two year cycle.
 Please state whether you have applied IFRS15 to your accounts.
 There must be no qualification or contra-indication from any evidence provided in support of the bidders economic and financial standing.

description:
a)	A review of the minimum specific yearly turnover over last two years.
 b)	Appropriate insurance levels as stipulated in 4B.5.
 c)	Demonstration of a Current Ratio of greater than 0.8.
 d)	A Net Profit greater than zero within the two year cycle.

type: technical

minimum:
4C1.2: Bidders will be required to provide three examples over the last five years that demonstrate that they have the relevant experience to deliver the services/supplies as described in the Contract Notice or the relevant section of the site notice.
 4C2: Bidders will be required to provide details of the technicians, staff resources or technical bodies the bidder can call upon in relation to this procurement exercise.
 4C3b: Bidders will be required to provide details of the technical facilities.
 4C7: Bidders will be required to confirm what environmental management measures they will employ.
 4C9: Bidders should provide details of relevant tools, plant or technical equipment available to you in relation to this procurement exercise. For desk based activities, this may also relate to IT capability.
 4C10: Bidders will be required to confirm that whether they intend to subcontract and if so, for what proportion of the contract.
 Quality Management Procedures
 1. The bidder must hold a UKAS (or equivalent) accredited independent third party certificate of compliance in accordance with BS EN ISO 9001 (or equivalent).
 OR
 2. The bidder must have the following:
 A documented policy regarding quality management. The policy must set out the responsibilities for quality management demonstrating that the bidder has and continues to implement a quality management policy that is authorised by their Chief Executive, or equivalent, and is periodically reviewed at a senior management level. The policy must be relevant to the nature and scale of the work to be undertaken and set out responsibilities for quality management throughout the organisation.

description:
a)	Recent examples demonstrating relevant experience to deliver goods or services.
 b)	Details of staffing resources and facilities available.
 c)	Details of technical facilities.
 d)	Environmental Management
 e)	Technical equipment, tools and plant
 f)	Subcontracting.

mainProcurementCategory: services

procurementMethodDetails: Open procedure

Scottish Government

roles: buyer centralPurchasingBody reviewBody mediationBody reviewContactPoint

locality: Glasgow

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay, 150 Broomielaw

id: Ministry or any other national or federal authority, including their regional or local subdivisions

scheme: COFOG

description: General public services

legalName: Scottish Government

Sheriff Court House

locality: Edinburgh

postalCode: EH1 ILB

streetAddress: 27 Chambers Street

legalName: Sheriff Court House

description:
SPD will be scored on a pass/fail basis.
 Question scoring methodology for Award Criteria outlined in Invitation to Tender.
 0 - Unacceptable. Nil or inadequate response. Fails to demonstrate an ability to meet the requirement.
 1 - Poor. Response is partially relevant but generally poor. The response addresses some elements of the requirement but contains insufficient/limited detail or explanation to demonstrate how the requirement will be fulfilled.
 2 - Acceptable. Response is relevant and acceptable. The response addresses a broad understanding of the requirement but may lack details on how the requirement will be fulfilled in certain areas.
 3 - Good. Response is relevant and good. The response is sufficiently detailed to demonstrate a good understanding and provides details on how the requirements will be fulfilled.
 4 - Excellent. Response is completely relevant and excellent overall. The response is comprehensive, unambiguous and demonstrates a thorough understanding of the requirement and provides details of how the requirement will be met in full.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=538689.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=791983.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:791983)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=791983

initiationType: tender


description:
The contract will originally for 36 months plus extensions of 1 year + 1 year.
 This means the contract may be 48 months or 60 months depending on length of extensions.
 As such there will be a renewal of this contract under a new procurement either in 2028, 2029 or 2030 depending on what renewal options are chosen.

description:
City Building requires on behalf of its clients to manage and maintain a range of swimming pools and hydrotherapy pools across the client estate. Within all the swimming pools and hydrotherapy pools City Building is looking to contract with a company who can provide a reactive and planned maintenance regime in-line with the associated filtration systems that are outlined in the tender documents. These facilities are important in the cultural landscape of the city and help to provide:
 Improve health and well-being.
 Learn important skills.
 Family friendly places.
 Social interaction.
 To this end it is essential that City Building contracts with a provider that can fully demonstrate expertise and excellence in the scope required. The successful bidder must understand the requirement for business agility and cost control across the service.
 The term of the contract will be three years with options to extend by 24 months (1 year + 1 Year).
 The venues are listed below (please note these may be subject to change and venues added or deleted)
 Easterhouse (The Bridge) Swimming Pools
 Castlemilk Leisure Centre swimming Pools
 Tollcross aquatics Centre Swimming Pools
 Emirates Arena Vitality Pool
 Whitehill Swimming Pool
 Gorbals Leisure Centre Swimming Pools
 Springburn Leisure Centre Swimming Pools
 North Woodside Leisure Centre Swimming Pool
 Pollok Leisure Centre Swimming Pool
 Bellahouston Leisure Centre Swimming Pools
 Scotstoun Leisure Centre Swimming Pools
 Drumchapel Swimming Pools
 Maryhill Leisure centre Swimming Pools
 Croftcoin School (Hydrotherapy Pool)
 Kelbourne School (Hydrotherapy Pool)
 Keppoch Campus (Hydrotherapy Pool) Currently drained due to major leak.
 Hazelwood School (Hydrotherapy Pool)
 Langlands School (Hydrotherapy Pool)
 Abercorn School (Swimming Pool)
 Ashcraig / Ashton (Swimming Pool)
 City Building is also looking to contract with providers who undertake best practice and guidance to adhere to Pool Water Treatment Advisory Group (PWTAG) within the pool plant industry.

variantPolicy: notAllowed

electronicCataloguePolicy: required

description: Glasgow

title: CBG253 - Glasgow Swimming Pools - Plant Maintenance

description:
City Building requires on behalf of its clients to manage and maintain a range of swimming pools and hydrotherapy pools across the client estate. Within all the swimming pools and hydrotherapy pools City Building is looking to contract with a company who can provide a reactive and planned maintenance regime in-line with the associated filtration systems that are outlined in the tender documents. These facilities are important in the cultural landscape of the city and help to provide:-
 Improve health and well-being.
 Learn important skills.
 Family friendly places.
 Social interaction.
 To this end it is essential that City Building contracts with a provider that can fully demonstrate expertise and excellence in the scope required. The successful bidder must understand the requirement for business agility and cost control across the service.
 The term of the contract will be three years with options to extend by 24 months (1 year plus 1 year)

description: Contract is for 3 years with options to extend by 1 year + 1 year so new procurement exercise would be in 2028, 2029 or 2030 depending on what extension options are chosen.

reviewDetails:
City Building (Glasgow) LLP must, by notice in writing as soon as possible, after the decision has been made,inform all bidders and candidates concerned of its decision to award the contract. City Building (Glasgow) LLP must allow a period of at leastthe relevant standstill period (where the notice is sent by facsimile or electronic means the period is 10 days ending at midnight at the end of the 10th day after that on which the notice is sent, when sent by other means the period is 15 days) to elapse between the date of dispatch of the notice referred to in Regulation 86 of the Public Contract (Scotland) Regulations 2015 “the Regulations”). CityBuilding(Glasgow) LLP is obliged to comply with the Regulations and any eligible economic operator can bring an action in the Sheriff Court or the Court of Sessionwhere as a consequence of a breach by City Building (Glasgow)LLP, suffers or risks suffering loss or damage. The bringing of court proceedings during the standstill period means that City Building (Glasgow) LLP must not enter into the contract unless the proceedings are determined,discontinued or disposed of; or the court,by interim order, brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and the remedies that are available to the courts are detailed in the Regulations. Economic Operators can write to City Building (Glasgow) LLP seeking further clarification on the notice, to which City Building (Glasgow) LLP must respond within 15 days. Economic Operators
 should be mindful to seek their own independent legal advice when they consider appropriate to do so.

type: suitability

description:
All works shall be carried out in accordance with best practices and shall include all proposed amendments to standard practices prior to the requirement for legal conformity, at the time of formal proposal, principally with regard to the following:
 The Factories Act.
 The Health and Safety at Work Act.
 BS 7671:2008 Requirements for Electrical Installations (IEE Wiring Regulations 17th Edition) and all subsequent amendments.
 All other statutory acts applicable to the works and local amendments or by-laws.
 British Standards and EC Directives.
 The Control of Substances Hazardous to Health (COSHH) Regulations.
 Construction (Design and Management) Regulations.
 Health and Safety documents L21, L22, L23, L24, L25.
 Water Supply Regulations.
 Control of Pollution Act 1974 Section 60.
 HSE Approved Code of Practice for Control of Legionella Bacteria in Water Systems ACoP L08.
 HSE Reporting of Injuries, Disease, and Dangerous Occurrences Regulations (RIDDOR).
 Waste Electrical and Electronic Equipment (WEEE) directives.
 Energy Performance of Buildings Directive (EPBD).
 Control of Asbestos Regulations 2012.
 Swimming Pool Water Treatment and Quality Standards for Swimming Pools and Spas(PWTAG) 2017 [including all recent updates]
 HSG 179 Health and Safety in Swimming Pools

description:
Bidders must comply with the undernoted financial requirements in order
 to participate in the tendering process:-
 There is a minimum financial requirement that affects trading performance and balance sheet strength
 Financial requirements for trading performance and balance sheet strength should be calculated on latest filed accounts
 accounts with Companies House
 Trading Performance
 An overall positive outcome on pre tax profits over a 3 year period
 Exceptional items can be excluded from the calculation.
 The above would be expressed in the ratio Pre-Tax Profit/Turnover
 Balance Sheet strength
 Net worth of the organisation must be positive at the time of evaluation
 and organisation must not be subject to an insolvency process.
 Intangibles can be included for purposes of the Total Assets figure.
 The above would be expressed in the ratio Total Assets/Total Liabilities
 Companies that are only required to file abbreviated accounts, must submit full sets of accounts
 for the last two individual years filed, in order for the three year profitability requirement to be verified
 An applicant should have no outstanding issues, with regard to statutory filing
 requirements with Companies House.
 Applicants who have been trading for less than the 3 years noted above must provide
 evidence that they are complying with the above minimum financial requirements
 for the period in which they have been trading.
 Applicants who do not comply with the above financial requirements but are part
 of a Group, can provide a Parent Guarantee if the Parent company satisfies the financial
 requirements stipulated above.
 City Building (Glasgow) LLP reserves the right, at its own discretion, to seek such other information from the Bidder
 in accordance with Regulations 61(7) or Regulation 61 (8) of the Public Contracts (Scotland) Regulations 2015
 to prove the Bidder's economic and financial standing.
 The insurance requirements for this contract are as follows –
 Employer’s Liability
 The organisation/consultant shall take out and maintain throughout the period of their services Employer’s Liability insurance to the value of at least TEN MILLION (GBP10,000,000) POUNDS STERLING in respect of any one claim and unlimited in the period.
 Public Liability
 The organisation/consultant shall take out and maintain throughout the period of their services Public Liability insurance to the value of at least TEN MILLION ("GBP" 10,000,000) POUNDS STERLING in respect of any one claim and unlimited in the period.
 Products Insurance
 The organisation/consultant shall take out and maintain throughout the period of their services Products Liability insurance to the value of at least TEN MILLION ("GBP"10,000,000) POUNDS STERLING in respect of any one claim and in the aggregate.
 Professional Indemnity
 The organisation/consultant shall take out and maintain throughout the period of their services and for a further 6 years on completion of their service, Professional Indemnity insurance to the value of a minimum TWO MILLION ("GBP"2,000,000) POUNDS STERLING in respect of any one claim and in the aggregate.

description:
List and brief description of selection criteria:
 SPD 4C.1.2 Statement [GOODS AND SERVICES ONLY]
 CBG’s guidance for this question is detailed below-
 Provide two relevant examples from within the last five years that demonstrate
 your organisation has the relevant and necessary skills, expertise, and experience to
 deliver the service required by CBG.
 For each relevant example the following information should be provided but is not
 limited to –
 1.	an overview of the contract including customer name, contract start and completion date and contract value.
 2.	a thorough and detailed description for each example of the scope of the requirement and service provided by you demonstrating experience in dealing with a contract the same or similar in scope and complexity to the CBG’s requirements.
 Your response to this question should not exceed, for each example, 2 x A4 sides, this page count includes all text (Arial font 11), photographs, figures and diagrams.
 Where a submission exceeds the maximum number of pages indicated per example, no account will be taken of the content of the pages beyond the maximum.
 Weighting
 The weighting will be out of 100 with 50% attributed to each example. A minimum
 pass mark of 60 out of 100 is required overall for this question. Any bidder who fails
 to achieve the minimum score for this question will be excluded from the process at
 this stage.
 Minimum level(s) of standards required:
 Bidders must score a minimum of 60% in total for question 4C.1.2 question. Any Bidder who fails to achieve the minimum points score will be disqualified.
 Selection Criteria (Quality 30%)
 Total Technical Weighting
 Service Delivery 	40%
 Staff Resource	30%
 Contract Management 	25%
 Fair Work First 	5%
 Full details will be in the tender documents.

City Building (Glasgow) LLP

roles: buyer centralPurchasingBody

postalCode: G21 4BA

streetAddress: 350 Darnick Street

id: Maintenance, Construction and Manufacturing

legalName: City Building (Glasgow) LLP

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description:
Health and Safety will be assessed on a PASS/FAIL basis - Bidders must hold
 ISO18001/ISO450001, or lot specific SSIP or comply with all questions in the Health and
 Safety Questionnaire.
 Environmental will be assessed on a PASS/FAIL basis - Bidders must hold ISO14001 or
 comply with all questions in the Environmental Questionnaire.
 Quality will be assessed on a PASS/FAIL basis - Bidders must hold ISO 9001 or comply
 with all questions in the Quality Questionnaire.
 Freedom of Information Act - Information on the FOI act is contained in the tender
 documents
 Insurance Mandate - Bidders will be asked to sign and return an Insurance Mandate that
 authorises CBG to request copies of insurance documents from the bidders insurance
 provider, should the bidder be successful
 Non Collusion - Bidders will be required to complete the Non Collusion Certificate
 contained within the tender documents.
 Additional information relevant to this contract opportunity can be found in the tender documents and SPD guidance documents
 The buyer is using PCS-Tender to conduct this tender exercise. The Project code is 28763.
 Fair Work First - This will be scored as 5% in the evaluation. Full details are in the ITT.
 The Contract is to be placed under, standard form SBCC Measured-Term Contract 2019 edition.
 The term of the contract will be three years with options to extend by 24 months.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 28763. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 CBG is requesting community benefits on a Mandatory basis for this the tender.
 CBG has a strong reputation for social values. At CBG where we are “Building a Sustainable Future”, we are providing skills to the
 workforce of tomorrow and generating true economic and sustainable benefits in our local communities and beyond.
 We are committed to:
 Delivering lasting employment opportunities to local people, including those with a disability and/or from minority groups.
 Engaging directly with local community groups, organisations and other agencies to ensure we maximise opportunities to improve local
 areas and overall well-being.
 - Combining commercial success with socially and environmentally responsible practices by giving life changing opportunities to those far
 removed from the labour market.
 Our strong commitment to sustainable development will ensure that we continue to leave positive and lasting legacies for future
 generations and inspire transformations in local communities.
 Community Benefits will be mandatory on a Pass/Fail basis and will therefore not be evaluated as part of the tender evaluation. Community
 benefits will therefore be a contractual requirement and form part of the awarded contact.
 Bidders must commit to paying 0.5% of the annual income derived from this contract with CBG to Community Benefits the detail of which
 to be determined by CBG, acting reasonably.
 (SC Ref:791998)


status: planned

description: To obtain expressions of interest from Tier 1 construction contractors wishing to join the hub North Scotland supply chain. Must have experience of successfully delivering community infrastructure projects with a value of GBP10 million and above.. Firms expressing an interest will have the opportunity to meet the hub North Scotland team in Aberdeen on 11 March 2025.

description: North of Scotland territory

title: Tier 1 Construction Contractor Refresh

scheme: CELEX

description: Expressions of interest for refreshing our Tier 1 construction contractors supply chain

mainProcurementCategory: works

hub North Scotland Limited

locality: Aberdeen

postalCode: AB25 1XQ

streetAddress: 18 Albert Street

legalName: hub North Scotland Limited

title: Tier 1 Construction Contractor Refresh

documentType: plannedProcurementNotice

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792009.
 (SC Ref:792009)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

status: complete

description: Vehicle Purchase

title: Vehicle Purchase

title: Vehicle Purchase

description: Vehicle purchase

documentType: awardNotice

description: Vehicle purchase

mainProcurementCategory: goods

Scottish Police Authority

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

description: General public services

legalName: Scottish Police Authority

Ford Motor Company Limited

locality: Brentwood Essex

postalCode: CM13 3BW

streetAddress: Central Office Eagle Way, Warley

scale: large

legalName: Ford Motor Company Limited

description:
Award against framework: Purchase of Standard and Specialist Vehicles
 (SC Ref:792023)


title: HH185-24-TW08 EDIS Support

title: HH185-24-TW08 EDIS Support

description:
1 year support contract covering period 24 / 25 covering EDIS (Emergency Department System) Support
 hours 24*7*365 The expectation is that NHS Highland will have migrated to a new system within 2 years.

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale:
A tendering process is not being undertaken as this is support that can only be provided by the supplier.
 Support has been in place for a number of years and the original implementation was supported by a national procurement and programme.

description: New works/services, constituting a repetition of existing works/services and ordered in accordance with the strict conditions stated in the directive

NHS Highland

locality: Inverness

postalCode: IV2 3BW

streetAddress: Assynt House, Beechwood Park

description: Health

legalName: NHS Highland

DH OpCo UK Ltd (Dedalus)

region: UK

locality: Leeds

postalCode: LS1 4BA

streetAddress: Suite 2, Riverside Studio, The Embankment

legalName: DH OpCo UK Ltd (Dedalus)

Inverness Justice Centre

legalName: Inverness Justice Centre

description: (SC Ref:792029)


description:
The University of St Andrews, through the Estates Unit, wishes to procure a Campus Accessibility Audit (CAA) of all buildings and publicly accessible campus areas to determine the level of compliance with The Equality Act (2010), and to identify key issues to prioritise mitigation measures where best practise relative to the RIBA Inclusive Design Overlay is not achieved.
 The CAA will be the basis for the phased implementation of improvements to our built estate in order to meet compliance as a priority, and best practise standards where appropriate to meet the University’s Equality, Diversity and Inclusion Policy https://www.st-andrews.ac.uk/policy/staff-equality-diversity-and-inclusion-review/equality-policy.pdf.

title: Campus Accessibility Audit

title: Campus Accessibility Audit

University of St Andrews

locality: Guardbridge

postalCode: KY16 0US

streetAddress: Walter Bower House, Eden Campus

description: Education

legalName: University of St Andrews

Dundee Sheriff Court

locality: DUNDEE

postalCode: DD1 9AD

streetAddress: 6 West Bell Street

legalName: Dundee Sheriff Court

description:
Further guidance and support on how to register with InTend can be found at:
 https://www.st-andrews.ac.uk/media/procurement/supplier-registration-portal.pdf
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792028.
 (SC Ref:792028)


description: Vehicle Purchase

title: Vehicle Purchase

title: Vehicle Purchase

description: Vehicle purchase

description: Vehicle purchase

Scottish Police Authority

description: Public order and safety

description: General public services

Toyota (GB) PLC

locality: Epsom

postalCode: KT18 5UX

streetAddress: Great Burgh, Burgh Heath

legalName: Toyota (GB) PLC

description:
Award against framework: Purchase of Standard and Specialist Vehicles
 (SC Ref:792042)


description: Vehicle Purchase

title: Vehicle Purchase

title: Vehicle Purchase

description: Vehicle purchase

description: Vehicle purchase

Scottish Police Authority

description: Public order and safety

description: General public services

Peugeot Motor Company

locality: Coventry

postalCode: CV3 1ND

streetAddress: Pinley House, 2 Sunbeam Way

legalName: Peugeot Motor Company

description:
Award against framework: Purchase of Standard and Specialist Vehicles
 (SC Ref:792040)


description: The supplier is a reseller of Monday.com licences.

title: SPPD-Monday.com Licences

title: SPPD-Monday.com Licences

description:
Monday.com is a cloud-based work management platform that allows Scottish Procurement and Property Directorate (SPPD) to automate workflows and manage projects, tasks and resources in one pace.
 The Monday.com operating system offers a modern, intuitive and user-friendly experience. It is completely customisable to meet the needs of each division within SPPD.
 Crown Commercial Services G-Cloud 14 Framework is an online catalogue where public sector customers can buy cloud-based computing services such as hosting, software and cloud support. Includes many off-the-shelf, pay-as-you-go cloud solutions.
 G-Cloud 14 has defined a 6-step buying process you should follow when using the agreement. After following these steps, the search demonstrated that only one supplier can deliver the service. This means that there is no need to run a mini-competition to use the framework.
 This call-off is for 80 Monday.com licences for a 12-month period.

Scottish Government

description: General public services

description: Economic affairs

Softcat Plc

locality: Marlow

postalCode: SL7 1LW

streetAddress: Thames Industrial Estate, Fieldhouse Lane

legalName: Softcat Plc

name: Edinburgh Sheriff Court and Justice of the Peace Court

postalCode: EH1 1LB

description:
Award against framework: Crown Commercial Service G-Cloud 14
 (SC Ref:792038)


description: Out of hours doctors for Tongue & Armadale practice area.

description: Tongue and Armadale

title: HH220-24-TW09 Out of Hours Medical Services to Tongue & Armadale

procurementMethodRationale: The procurement is for Health / Social Care & falls below the regulated threshold.

description: The procurement falls outside the scope of application of the directive

NHS Highland

description: Health

Ash Healthcare Ltd

postalCode: G46 7QF

streetAddress: 35 Dalmeny Avenue,, Giffnock

scale: sme

legalName: Ash Healthcare Ltd

description: (SC Ref:792039)


description: Vehicle Purchase

title: Vehicle Purchase

title: Vehicle Purchase

description: Vehicle purchase

description: Vehicle purchase

Scottish Police Authority

description: Public order and safety

description: General public services

Volkswagen Group UK Limited

locality: Milton Keynes

postalCode: MK14 5AN

streetAddress: Yeomans Drive

legalName: Volkswagen Group UK Limited

description:
Award against framework: Purchase of Standard and Specialist Vehicles
 (SC Ref:792046)


description: 3-year fully comprehensive service contract to cover 3x Proveo 8 microscopes and 1x Envisu optical coherence tomography. All based at the National Treatment Centre.

title: HH208-24-TW13 Microscope Servicing

title: HH208-24-TW13 Microscope Servicing

procurementMethodRationale: The equipment can only be serviced/maintained by the original equipment manufacturer (OEM).

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

NHS Highland

description: Health

Leica Microsystems (UK) Ltd

postalCode: MK14 6FG

streetAddress: Larch House, Woodlands Business Park, Breckland, Linford Wood West

legalName: Leica Microsystems (UK) Ltd

description: (SC Ref:792063)


title: Accommodation with Support for Women & Children experiencing Domestic Abuse and/or Coercive Control - East

title: Accommodation with Support Services for Women and Children experiencing Domestic Abuseand/or coercive control - West

description: Optional 2 year extension period to the contract terms at the sole discretion of Dumfries and Galloway Council.

description: This Contract is for the provision of accommodation with support services for women and children who are experiencing or have experienced domestic abuse and/or coercive control to assist them in sustaining temporary accommodation and moving to settled permanent accommodation.

description: Nithsdale, Stewartry, Annandale & Eskdale area(s) of Dumfries and Galloway region

description: Wigtownshire

title: Accommodation with Support for Women and Children experiencing Domestic Abuse and/or Coercive Control

description:
This contract is for the provision of accommodation with support services for women and children who are experiencing or have experienced domestic abuse and/or coercive control to assist them in sustaining temporary accommodation and moving to settled permanent accommodation.
 The purpose is to provide women and their children:
 - safe accommodation with support
 - Housing support services
 - Counselling
 - Advocacy;
 - Access to an out of hours emergency contact and advice service.
 This service does not include outreach housing support.

procurementMethodRationale: The contract is for established accommodation in Dumfries and Galloway where there has been no competition identified through the publishing of notices. This requirement would fall under the Light Touch Regime.

Dumfries and Galloway Council

locality: Dumfries

postalCode: DG1 2HP

streetAddress: Procurement Team, Carruthers House

description: General public services

legalName: Dumfries and Galloway Council

Dumfriesshire & Stewartry Women's aid

postalCode: DG2 OBX

streetAddress: NWRC College Drive Dumfries

legalName: Dumfriesshire & Stewartry Women's aid

Wigtownshire Women's Aid

locality: Stranraer

postalCode: DG9 8ED

streetAddress: 22 Bellevilla Road

legalName: Wigtownshire Women's Aid

Dumfries Sheriff Court

legalName: Dumfries Sheriff Court

description: (SC Ref:792055)


description: Possible 1 year extension

description: Design, create and install livery for new vehicles as required. 	Design, create, install, remove and replace signage such as building fascia signs, car park signs, fire safety, no smoking and new-build development signage.

title: HM/R037 – Signage and Vehicle Livery

title: HM/R037 – Signage and Vehicle Livery

description: Signage and Vehicle Livery

documentType: economicSelectionCriteria

documentType: technicalSelectionCriteria

title: Invitation to Tender

title: Quality Questions

title: Scoring Matrix

title: Community Benefits Statement

title: T&Cs

title: Pricing Schedule

title: Vehicle Livery Pictures

format: application/x-zip-compressed

streetAddress: Hillcrest HQ, 1 Explorer Road, Dundee

description: As per Hillcrest's internal process

description: Signage and Vehicle Livery

electronicInvoicingPolicy: allowed

Hillcrest

locality: Dundee

postalCode: DD2 1EG

streetAddress: 1 Explorer Road

description: Housing and community amenities

legalName: Hillcrest

Dundee Sherriff Court

legalName: Dundee Sherriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792048.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Please see clause within Invitation to Tender document and attached Community Benefits Statement
 (SC Ref:792048)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=792048


description: Integrated Housing Management and Finance System

description: Hawick

title: Integrated Housing Management & Finance systems

description: integrated housing management and finance system.

title: ITT

title: Schedule_Tender_Submissions

title: Response_To_Spec

title: Pricing_schedule

title: SPD_Document

title: Term & Conditions

format: application/pdf

title: ITT

streetAddress: Hawick

description: As per internal procurement strategy.

performanceTerms: Stated within additional documents.

Waverley Housing

locality: Hawick

postalCode: TD9 9PX

streetAddress: 51 North Bridge Street

description: Housing and community amenities

legalName: Waverley Housing

Jedburgh Sheriff Court

locality: Jedburgh

legalName: Jedburgh Sheriff Court

description:
All information is contained within the additional documents.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792053.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792053)


description: HOP2 Phase 3 Scope 2 – Electrolyser Marinisation, Technology Qualification

Net Zero Technology Centre Limited

postalCode: AB15 4ZT

streetAddress: 20 Queens Road, Aberdeen

legalName: Net Zero Technology Centre Limited

Net Zero Technology Centre

roles: reviewBody mediationBody

streetAddress: 20 Queens Road

legalName: Net Zero Technology Centre

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792070.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792070)


title: Lot 1 - Project and Asset Management Support to Estates Team

title: Lot 2 - Change and Improvement Services

description: The duration of the call-off contract will be for 6 months plus option to extend for a further period up to 6 months. The extension will be at the Authorities sole discretion.

title: Lot 2 - Change and Improvement Services

description: Lot 2 - Change and Improvement Services

title: PROC 25 2875 Estates Professional Services

description: Estates Professional Services

description: Estates Professional Services

Scottish Police Authority

locality: Glasgow

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

description: General public services

legalName: Scottish Police Authority

Knight Frank LLP

postalCode: AB25 1XQ

streetAddress: 4 Albert Street

legalName: Knight Frank LLP

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

title: Lot 2 - Change and Improvement Services

description:
Award against framework: Crown Commercial Services (CCS) RM6168 - Estates Management Services
 (SC Ref:792064)


description:
Dumfries and Galloway Council (‘the Council’) are seeking to procure support with Stage 1 - Early Contractor Involvement (ECI) and Stage 2 - Main Works Construction for the Whitesands Project (Flood Protection Scheme and Public Realm Improvements).
 The Council is issuing this Prior Information Notice (PIN) to inform potential suppliers about an upcoming procurement opportunity for Early Contractor Involvement (ECI) support (Stage 1) for the detailed design development of the Whitesands Project (Flood Protection Scheme and Public Realm Improvements), followed by the Main Works Construction (Stage 2) subject to commercial agreement and Council budget approval. This notice aims to provide early information to the market and encourage interested parties to prepare for the forthcoming tender process.
 It is the Council’s intention to appoint a single supplier to deliver the ECI and the subsequent Main Works Construction through a two-stage process:
 - Stage 1 – ECI
 - Stage 2 – Main Works Construction
 Stage 1 - Early Contractor Involvement (ECI)
 The Council now requires the services of a qualified Contractor to input to and support the detailed design development of the Whitesands Project through Early Contractor Involvement (ECI), including the production of a Report to detail the methodology, findings and considerations relating to the delivery of the Whitesands Project.
 The supplier will be expected to deliver, including but not limited to:
 - Detailed Design Support – To Progress the 60-100% Design
 - Constructability Review and Construction Methodology
 - Cost and Programme Certainty
 - Programme Development (Work Breakdown Structure, Critical Path, Construction and Phasing)
 - Supply Chain Analysis and Strategy
 - Community Benefits and Social Value Strategy
 Additional details will be provided in due course.
 A “Meet the Buyer” event is to be held.
 Stage 2 - Main Works Construction
 The Council would expect the chosen supplier to lead on delivery of the Main Works Construction, with elements including, but not limited to:
 - Health and Safety Management (CDM 2015)
 - Site Planning and Management
 - Waste Management
 - Traffic Management
 - Planning and License Condition Discharge
 This Scope of Work will be further developed and detailed for the subsequent procurement stage and should not be considered fixed within this Prior Information Notice.
 Estimated Value: The estimated value of the works is GBP 37.5m (Outline Design Scheme Construction Cost). Final project costs for the Flood Protection Schemes are subject to ongoing design work.
 Timeline:
 PIN Publication Date: 04/03/2025
 Expected Tender Release Date: 31/03/2025
 Contract Start Date (ECI): 14/07/2025
 Contract Completion Date (ECI): 31/12/2025
 Contract Start Date (Main Works): TBC. For additional information please email: Procurement.CIRW@dumgal.gov.uk
 For Meet the Buyer Event to be held on Friday 21 March 2025 in person in Dumfries, please send confirmation of intention to attend by Wednesday 12 March 2025 to email: Procurement.CIRW@dumgal.gov.uk

description: Whitesands, Dumfries

title: Whitesands Project (Flood Protection Scheme & Public Realm Improvements) – Early Contractor Involvement & Main Works Construction

title: Slides shared during the Meet the Buyer Event on 21st March.

description: Whitesands Project (Flood Protection Scheme and Public Realm Improvements) – Early Contractor Involvement (ECI) and Main Works Construction

Dumfries and Galloway Council

description: General public services

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792098.
 (SC Ref:792098)


description: The key objective of this contract is to refresh the existing assessment undertaken during the pilot phase of the program and bring into line with the current specification set out in the published Single Building Assessment specification, June 2024.. Single Building Assessment(s) for Fire Safety in Scotland DPS Mini Comp

title: Single Building Assessment Refresh – Set 1 - Mini Competition - Single Building Assessment(s) for Fire Safety in Scotland DPS

description: The key objective of this contract is to refresh the existing assessment undertaken during the pilot phase of the program and bring into line with the current specification.

Scottish Government

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay, 150 Broomielaw

description: General public services

description: Economic affairs

legalName: Scottish Government

PartB

locality: Melton Mowbray

postalCode: LE13 0PB

streetAddress: Pera Business Park, Nottingham Road

legalName: PartB

Sheriff Court House,

locality: Edinburgh

streetAddress: 27 Chambers Street,

legalName: Sheriff Court House,

description:
Award against framework: Single Building Assessment(s) for Fire Safety in Scotland - Dynamic Purchasing System (DPS)
 (SC Ref:792095)


description: 24 months with the option to extend a further 24-months exercised at 12-month intervals

description: Inspection & Repair Fall Protection Roof Systems

Quality

type: quality

type: price

minimum:
Insurance Requirements
 Employer’s (Compulsory) Liability Insurance - 10mGBP
 Public Liability Insurance - 5mGBP
 Product Liability Insurance - 5mGBP
 Professional Indemnity Insurance - 1mGBP

description:
Bidders must comply with the undernoted financial requirements in order
 to participate in the tendering process:-
 There is a minimum financial requirement that affects trading performance, and balance sheet strength.
 Financial requirements for trading performance and balance sheet strength should be calculated on latest filed accounts
 accounts with Companies House
 Trading Performance
 An overall positive outcome on pre tax profits over a 3 year period
 Exceptional items can be excluded from the calculation.
 The above would be expressed in the ratio Pre-Tax Profit/Turnover
 Balance Sheet strength
 Net worth of the organisation must be positive at the time of evaluation
 and organisation must not be subject to an insolvency process.
 Intangibles can be included for purposes of the Total Assets figure.
 The above would be expressed in the ratio Total Assets/Total Liabilities
 Companies that are only required to file abbreviated accounts, must submit full sets of accounts
 for the last two individual years filed, in order for the three year profitability requirement to be verified
 An applicant should have no outstanding issues, with regard to statutory filing
 requirements with Companies House.
 Applicants who have been trading for less than the 3 years noted above must provide
 evidence that they are complying with the above minimum financial requirements
 for the period in which they have been trading.
 Applicants who do not comply with the above financial requirements but are part
 of a Group, can provide a Parent Guarantee if the Parent company satisfies the financial
 requirements stipulated above.
 Glasgow Life reserves the right, at its own discretion, to seek such other information from the Bidder
 in accordance with Regulations 61(7) or Regulation 61 (8) of the Public Contracts (Scotland) Regulations 2015
 to prove the Bidder's economic and financial standing

Glasgow Life (Culture & Sport Glasgow)

postalCode: G1 1LH

streetAddress: 38 Albion Street

description: General public services

legalName: Glasgow Life (Culture & Sport Glasgow)

name: Glasgow Sheriff Court and Justice of the Peace

postalCode: G6 9TW

streetAddress: 1 Carlton Place

description:
Bidder Guidance.
 There is a capped budget figure of 264,000 GBP over the full contract duration excluding VAT. Any submissions over the capped budget figure of 264,000 GBP will not be accepted.
 The bidder with the commercial bid furthest away from this figure will receive the highest commercial mark and any other bids will be pro rata’d accordingly in line with the evaluation process.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 28618. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Within Technical Award Questions
 (SC Ref:792079)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

description:
Tissues, Cells and Advanced Therapeutics (TCAT) utilise the Miltenyi Biotec CliniMACS Prodigy device at both the Jack Copland Centre (JCC) and Institute for Regeneration and Repair North (IRRN) for the manufacture of Advance Medicinal Therapeutic Products (ATMPs). The CliniMACS Prodigy is an automated, enclosed, cell therapy medical device that conforms to ATMP standards. It is an essential piece of equipment utilised in a range of ATMP manufacturing processes.
 The commercial Contract will cover purchase of the CliniMACS Prodigy. As stated within the commercial contract, this equipment is required for the manufacturing process.

description: Scottish National Blood Transfusion Service, at the Jack Copland Centre

description: Purchase of CliniMACS Prodigy Cell Processor for Tissues, Cells & Advanced Therapeutics (TCAT).

procurementMethodRationale: This will be a direct award under Regulation 33 b (ii).

description: The works, supplies or services can be provided only by a particular economic operator due to protection of exclusive rights, including intellectual property rights

postalCode: EH12 9EB

streetAddress: 1 South Gyle Crescent

description: Health

Miltenyi Biotec Ltd

locality: Bisley

postalCode: GU24 9DR

streetAddress: 2 Almac House , Church Lane

legalName: Miltenyi Biotec Ltd

Edinburgh Sheriff Court House

streetAddress: 27 Chambers Street

legalName: Edinburgh Sheriff Court House

description: (SC Ref:792082)


description:
The project involves the restoration of ~202ha of upland peatland. The site is found at grid reference NC 515 396, and sits between around 160 m and 246 m above sea level to the east of Loch Meadie, along the Altnaharra to Loch Hope road.
 The area has previously been cut with artificial drains. The total extent of artificial drains is 21.86km. There is a further 595m of gullies and 1.19km of haggs to be restored.

description: Altnaharra, Sutherland, Scotland

title: Proposed Peatland Restoration - Althanarra Phase 1

description: Proposed peatland restoration works on Althanarra Phase 1

title: Statement of Requirements - Altnaharra P1

title: Altnaharra Phase 1 Map

description: All details are contained in the Statement of Requirements (SoR) relating to this tender.

Strutt & Parker

locality: Inverness

postalCode: IV2 6AA

streetAddress: Fairways Business Park

description: General public services

legalName: Strutt & Parker

NatureScot

postalCode: IV3 8NW

streetAddress: Great Glen House, Leachkin Road

legalName: NatureScot

description:
Contract award will be subject to funding approval from Peatland Action. Peatland Action are expected to inform applicants of the outcome of their applications by 31st July 2025.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792044.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792044)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=792044


title: Single Building Assessment Refresh – Set 2 - Mini Competition - Single Building Assessment(s) for Fire Safety in Scotland DPS

Scottish Government

description: General public services

description: Economic affairs

AFEC International

locality: Dublin

streetAddress: Unit 1, Airport Logistics Park

legalName: AFEC International

Sheriff Court House,

postalCode: EH1 1LB

description:
Award against framework: Single Building Assessment(s) for Fire Safety in Scotland - Dynamic Purchasing System (DPS)
 (SC Ref:792100)


title: Clean and Clear

description: Optional 1 x 24 months

description: The purpose of the clear and clean Framework Agreement is to bring Fife Council housing stock, hostels and Gypsy traveller sites back to their original standard with regard to cleanliness and general maintenance after a Council tenant or homeless person moves on to alternative accommodation, to allow the property to be re-let. This includes general clearance of large items and rubbish, deep cleaning, and trauma cleaning. As well as clear and clean services, the requirement may also extend to minor repairs, a garden tidy, emptying of bins, stair cleaning, pest control, and sharps removal.

title: Final Clean of Void Properties

description: Optional 1 x 24 months

description: Final clean only of void properties

description: Fife

description: Fife

title: House Clearance and Cleaning & Associated Services

title: CW0274 Clean and Clear SPD Guidance

title: Appendix 3 - Data Processing Schedule

title: TENDERINFODOC CW0274

title: CW0274 TN Part 1 STATEMENT OF REQUIREMENTS

title: LOT 1 CLEAN AND CLEAR TN PART 2

title: LOT 1 CLEAN AND CLEAR PRICING SCHEDULE

title: LOT 2 FINAL CLEAN TN PART 2

title: LOT 2 FINAL CLEAN PRICING SCHEDULE

title: Appendix 1 - Fair Work First

title: Appendix 2 - Modern Slavery

title: Appendix 4 - Data Processing Agreement

title: Appendix 5 - Bidder Relevant Contract Climate Change Plan

title: Question 4 Response - Additional information -Temporary Accommodation information

title: Amended Lot 1 Pricing Schedule Rev 1

title: Information regarding site visit to Homeless Hostels

title: Information regarding Gypsy Travellers Sites site visit

description: To give bidders adequate time after site visits

label: Time limit

label: Conditions for opening of tenders

streetAddress: Fife Council, Bankhead Central, Bankhead Park, Glenrothes

description: QS Manager and Lead QS - tenders unlocked and downloaded from PCS Portal

awardCriteriaDetails: 1 and 2

description:
We can exclude you from this procurement if you are not enrolled in the relevant professional or trade registers kept in the Member State of your establishment (as described in Schedule 5 of the Public Contracts (Scotland) Regulations 2015
 i.e British Pest Control Association or equivalent

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House, North Street

description: General public services

legalName: Fife Council

Sheriff Court

streetAddress: Sheriff Court House, 27 Chambers Street

legalName: Sheriff Court

description:
TUPE – The Transfer of Undertakings (Protection of Employment) Regulations 2006 give effect to the EC Acquired Rights Directive 1977. Tenderers should note that TUPE may or may not apply to some or all of the personnel currently assigned to undertakings that are currently performing part or all of the duties described in the Tender Specification. Tenderers should, prior to submitting their tender, take their own specific legal advice to ascertain whether TUPE could be held to apply to such undertakings and, if so, how that would impact on their tender. The Council is not able to advise tenderers upon the effect of the TUPE Regulations.
 If Tenderers consider TUPE does apply, Tenderers should contact the incumbent contractor/supplier to obtain the required specific and necessary information about the personnel currently employed in providing the services that are the subject of this tendering exercise.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792075.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 The Council recognises the importance of connecting economic and social development to improve the quality of life for residents, workers, and visitors. Our focus is on putting communities first and ensuring Fife uses its resources wisely for future generations. We aim to support business growth while ensuring that local communities benefit, making Fife a fairer place.
 We are dedicated to maximising Community Benefits in its procurement process, emphasising social, economic, and environmental goals. We encourage contractors and their suppliers to align with our objectives.
 Further information on Community Benefits can be found Community Benefits - a guide for suppliers | Fife Council.
 Community Benefits must be as a direct result of being awarded a Council contract and not something the provider is already engaged in delivering, relevant and of economic, social or environmental benefit to the locality the contract is being delivered, Fife, and the regions citizens.
 Tenderers shall provide a Community Benefits delivery plan/methodology as part of their tender submission, fully describing how they intend to deliver community benefits in Fife.
 Lot 1 only - Bidders are to consider what % of spend they are willing to pay back to the Council as a Public Rebate
 (SC Ref:792075)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=792075


name: Galliford Try Construction Limited t/a Morrison Construction

description:
This project is part of an overall masterplan for Wester Hailes High School and Edinburgh Leisure to provide enhanced facilities for both the Educational
 and Sport and Leisure Community within the site of the existing Wester Hailes Education Centre (WHEC)

title: Wester Hailes High School – Phase 1B

title: Wester Hailes High School – Phase 1B

procurementMethod: selective

procurementMethodDetails: Restricted procedure

The City of Edinburgh Council

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

description: Housing and community amenities

legalName: The City of Edinburgh Council

postalCode: G33 1AP

streetAddress: Rowan House, 1 Robroyston Oval

locality: Stirling

postalCode: FK8 1NH

streetAddress: Old Viewforth

description: (SC Ref:792086)


description:
Scotland’s peatlands represent a significant carbon store, but large areas are degraded, often as result of historic patterns of land management. Degraded peatlands can release carbon thus contributing to the enhanced greenhouse effect. Peatland restoration is undertaken to improve the condition of peatlands, which has a net positive effect on the carbon balance of the site (whether slowing losses or promoting gains) and improves the condition of the habitat for our upland species like Curlew and Dunlin.
 The identified restoration area at Black Moss of Evrigert is located within the southern part of the Birsay Moors RSPB Reserve which spans just over 1300ha of predominantly bog, mire and heathland habitats. The site is also part of West Mainland Moorlands SSSI and Orkney Mainland Moors SPA which recognise Birsay Moors’ importance for breeding Hen Harrier, Red-Throated Diver and Short Eared Owl as well as bog plant communities.
 It is anticipated that work will be undertaken on the Black Moss Phase 1 site between September 2025 and March 2026. The Black Moss Phase 1 site has been subjected to extensive peat cutting historically, which comprises a significant proportion of the restoration required on site. Other restoration required involves the reprofiling and damming of gullies/drainage features, and the reprofiling of peat hags.
 Peatland restoration was undertaken on approximately 28 hectares of the Black Moss Phase 1 site in September and October 2024, focused on both eastern and southern corners of the site (Annex 5).
 Restoring these features will improve the resilience and overall condition of the habitat making it better able to support a range of wildlife and be able to cope with changing weather patterns linked to climate change.
 The site boundary for the restoration area is approximately 146 ha in size. The work will be procured on a treatment basis which includes machine days, hand labour days and the supply of materials where needed. The site has been assessed and requires a combination of work using machinery of appropriate size on extra-wide low ground pressure tracks for peat and mineral-based techniques, and manual/machine construction of wooden/composite dams.
 A range of techniques will be employed to treat the features across the sites, these are outlined below. It is anticipated that machine work will be the preference, although there are some areas that may require hand work for the instillation of dams. Required materials will be moved onto site with a suitable ATV.

description: Black Moss of Evrigert is located within the southern part of the Birsay Moors RSPB Reserve, Orkney, KW17 2PL

title: RSPB Scotland: Orkney Peatland Restoration, Black Moss 2025-26

description: Tender For The Supply Of Peatland Restoration Works On Black Moss Of Evrigert, Orkney Mainland, 2025-2026

title: ITT RSPB Scotland Orkney Peatland Restoration 25-26

title: Annex 1

title: Annex 2

title: Annex 3

title: Annex 4

title: Annex 5

title: Annex 6

title: Annex 7

title: Site visit notes from 13-03-25

title: Updated site visit notes from 13-03-25

RSPB Scotland

postalCode: EH12 9DH

description: Environmental protection

legalName: RSPB Scotland

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792077.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792077)


description: The key objective of this contract is to refresh the existing assessment undertaken during the pilot phase of the program and bring into line with the current specification set out in the published Single Building Assessment specification, June 2024.. Single Building Assessment(s) for Fire Safety in Scotland DPS Mini Comp

title: Single Building Assessment Refresh – Set 3 - Mini Competition - Single Building Assessment(s) for Fire Safety in Scotland DPS

description: The key objective of this contract is to refresh the existing assessment undertaken during the pilot phase of the program and bring into line with the current specification.

Scottish Government

streetAddress: 5 Atlantic Quay, 150 Broomielaw

description: General public services

description: Economic affairs

description:
Award against framework: Single Building Assessment(s) for Fire Safety in Scotland - Dynamic Purchasing System (DPS)
 (SC Ref:792102)


description: Direct Award for the provision of property security and land protection services through the Scottish Procurement Alliance – Asset Safety and Compliance Framework Agreement

title: Property and Security Services, Edinburgh

description: This Contract Award Notice follows a Direct Award to SPS Doorguard Ltd and Orbis Protect Ltd utilising the Scottish Procurement Alliance for Asset Safety and Compliance Framework Agreement.

reviewDetails:
Precise information on deadline(s) for review procedures:
 A tenderer that suffers loss as a result of a breach of duty under the Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or the Court of Session. The City of Edinburgh Council (the Council) will have a minimum standstill period of 10 days before awarding the contract. The communication of the award decision notice will be sent by fax or e-mail to all tenderers with the standstill period commencing on the next day. If proceedings are started in the Sheriff Court or the Court of Session against the Council in respect of the decision to award the contract within the standstill period then the Council is prevented from awarding the contract. Post contract award the Sheriff Court or the Court of Session may (1) award damages provided proceedings are brought within 3 months from the date when the grounds for the bringing of the proceedings first arose (2) be entitled to issue an ineffectiveness order or impose a financial penalty on the Council. A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the FTS or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.

City of Edinburgh Council

locality: Edinbugh

streetAddress: 4 East Market Street

description: General public services

legalName: City of Edinburgh Council

SPS Doorguard Limited

postalCode: G4 0EE

streetAddress: The Octagon, 35 Baird Street

legalName: SPS Doorguard Limited

description:
Award against framework: Scottish Procurement Alliance - Asset Safety & Compliance Framework Agreement
 This direct award is based on allocation of a geographical zone within the City of Edinburgh. This contractor will operate in the South East and South West area of the City.
 (SC Ref:792113)


description: The City of Edinburgh Council requires the services of a qualified technical advisor to support initial public consultation and strategic policy context in light of its plans to expand the city's tram network. The appointed contractor will also undertake the initial design development and technical expert advice in relation to the preparation of the outline business case.

title: Trams to Granton, BioQuarter & Beyond – Technical Advisor Support

description: The City of Edinburgh Council requires the services of a qualified technical advisor to support the initial public consultation and the strategic policy context in light of its plans to expand the city's tram network. the appointed contractor will also undertake the initial design development and technical expert advice in relation to the preparation of the outline business case.

The City of Edinburgh Council

description: General public services

description: Housing and community amenities

Jacobs UK Limited

locality: London

postalCode: SE1 2QG

streetAddress: Cottons Centre, Cottons Lane

legalName: Jacobs UK Limited

description:
Award against framework: Scotland Excel Technical Engineering & Consultancy Framework Agreement
 (SC Ref:792109)


description: Riverside Footbridge detailed design consultancy services encompassing the development of a widened active travel crossing in Haddington.. Direct Award on CEC Professional Services Framework CT2675, Lot 13

description: East Lothian

title: Award of Riverside Footbridge Consultancy Services

East Lothian Council

locality: Haddington, East Lothian

postalCode: EH41 3HA

streetAddress: John Muir House

description: General public services

legalName: East Lothian Council

Stantec

postalCode: G2 1DY

streetAddress: 5th Floor, 9 George Square

legalName: Stantec

description:
Award against framework: Professional Services Framework
 (SC Ref:792117)


City of Edinburgh Council

description: General public services

ORBIS PROTECT

locality: GOVAN

postalCode: G51 3HD

streetAddress: UNIT B, CITY LINK INDUSTRIAL ESTATE

legalName: ORBIS PROTECT

description:
Award against framework: Scottish Procurement Alliance - Asset Safety & Compliance Framework Agreement
 This direct award is based on allocation of a geographical zone within the City of Edinburgh. This contractor will operate in the South East and South West area of the City.
 (SC Ref:792111)


description: Tender process for proposed peatland restoration works on Glendoe Phase 1. Please see SoR for all detail relating to this opportunity. All Questions and Answers pertaining to the SoR, other than site visit, should be submitted via this PCS portal.

description: Glendoe Estate, Highland

title: Proposed Peatland Restoration – Glendoe Phase 1: D and E - Highland

description: Proposed Peatland Restoration works on Glendoe Phase 1: D and E

title: CCP_GlendoeDandE_Statement of Requirements_2025

title: CCP_GlendoeDandE_Tender Response Template_2025

title: CCP_GlendoeDandE_Schedule of Costs_2025

title: CCP_GlendoeDandE_Data

title: CCP_GlendoeDandE_Maps

title: Contractor_Tender_Response_Folder_Structure

title: Details included within attached PDF. To confirm attendance, email tenders@caledonianclimate.com

streetAddress: Digital

description: Caledonian Climate Partners: Tender administrator.

description: All details required within Statement of Requirements (SoR) relating to this Proposed Restoration Project.

Caledonian Climate Partners

locality: Forfar

postalCode: DD8 3TY

streetAddress: East Memus

id: Caledonian Climate Partners on behalf of Achentoul Estate

description: Environmental protection

id: Caledonian Climate Partners on behalf of Duncroisk Estate

id: Caledonian Climate Partners on behalf of Glutt Estate

id: Caledonian Climate Partners on behalf of Innerwick Estate

id: Caledonian Climate Partners on behalf of Clients

id: Caledonian Climate Partners on behalf of Braigh Raithneach Estate

id: Caledonian Climate Partners on behalf of Kildrummy & Glenkindie Estates

id: Caledonian Climate Partners on behalf of Drummond Estate

id: Caledonian Climate Partners on behalf of Glendoe Limited

legalName: Caledonian Climate Partners

name: NatureScot, Great Glen House, Leachkin Road, Inverness, IV3 8NW.

description:
Please see details in Statement of Requirements. Tenderers should be aware that a Contract is dependent on Funding being achieved.
 The successful tender response for this project will be incorporated into a funding application to be submitted to Peatland ACTION no later than the 30th April 2025. Caledonian Climate Partners expect Peatland ACTION to inform applicants of the of the outcome of their application by the end of July 2025 at the latest. The contract will be with the Landowners.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=790872.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792123.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792123)


description: The Scottish Ministers acting through Social Security Scotland have a requirement for the provision of an identity broker as part of the solution to integrate the Identity Provider Proxy (part of ScotAccount).

title: Identity Broker for ScotAccount

title: Identity Broker for ScotAccount

Social Security Scotland

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House, 17 South Union Street

description: General public services

legalName: Social Security Scotland

Red Hat Ltd

locality: Farnborough

postalCode: GU14 7JP

streetAddress: 200 Fowler Avenue

legalName: Red Hat Ltd

Edinburgh Sheriff Court

streetAddress: 27 Chambers Street

currency: USN

description:
This contract is for one (1) year with no option to extend.
 The contract was awarded through a Direct Award via the AWS Marketplace under Social Security Scotland's Cloud Hosting Contract.
 (SC Ref:792124)


description: The work/ services to be undertaken comprises a maintenance contract for timber fencing repairs and replacements in the Employer’s properties.

title: Award of Cassiltoun HA Fence Repairs and Replacements 2025

description: Fences

Dumfries and Galloway Council

locality: Dumfries

postalCode: DG1 2HP

streetAddress: Carruthers House

Groundwork Services Durham Ltd

locality: Durham

postalCode: DH7 8HJ

streetAddress: Thistle Road

Fife Council

streetAddress: Fife House

HAMILTON BROS. (ENGINEERING) LTD

locality: LANARK

postalCode: ML11 7DZ

streetAddress: ST LEONARD STREET

A M Phillip Trucktech Ltd

streetAddress: Muiryfaulds

Scottish Government

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay

Lorien Resourcing Ltd

postalCode: EH2 4QZ

streetAddress: Randolph House

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

Scottish Police Authority

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay

Ignite Consulting Ltd

postalCode: WC1N 3AX

streetAddress: 27 Old Gloucester Street

Hymans Robertson LLP

postalCode: G2 6DB

streetAddress: 20 Waterloo Street

The Open University

locality: MILTON KEYNES

postalCode: MK7 6AA

streetAddress: Business Development Unit, Walton Hall

PricewaterhouseCoopers

postalCode: WC2N 6RH

streetAddress: 1 Embankment Place

PS PARTNERSHIPS & CONSULTANCY LTD

locality: Nesscliffe, Shrewsbury

postalCode: SY4 1DR

streetAddress: 12 Sandhurst Way

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road

Life Technologies Ltd

locality: Inchinnan

postalCode: PA4 9RF

streetAddress: 3 Fountain Drive

The Highland Council

postalCode: IV3 5NX

streetAddress: Glenurquhart Road

name: EJ Parker Technical Services (Scotland North) Ltd

postalCode: IV3 8DU

streetAddress: Units 3 & 4, 9 Carsegate Road North

Food Standards Scotland (FSS)

locality: Aberdeen

postalCode: AB11 5RL

streetAddress: 4th Floor, Pilgrim House

name: Mistev Export Health Certification Limited

postalCode: EH16 6UY

streetAddress: 10, Howden Hall Loan

name: Eville & Jones (Commercial Services) Ltd

locality: Leeds

postalCode: LS15 8ZB

streetAddress: Century House

Midlothian Council

locality: Dalkeith

postalCode: EH22 1DN

streetAddress: Midlothian House

Wirtgen Ltd

locality: Newark

postalCode: NG24 2UA

streetAddress: Wirtgen Group House

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

Forestry and Land Scotland

streetAddress: Great Glen House

Molplant Construction Ltd

locality: Dumnfries

postalCode: DG1 3RS

streetAddress: Downsway Industrial Estate

Leica Microsystems (UK) Ltd

locality: Milton Keynes

postalCode: MK14 6FG

streetAddress: Larch House, Woodlands Business Park

Trabazon Ltd.

locality: Orrell

postalCode: WN5 7XA

streetAddress: Hewitt House

Nith Valley Construction Ltd

locality: Thornhill

postalCode: DG3 5NB

streetAddress: Glendal

Venesky-Brown Recruitment

streetAddress: 4A Rutland Square

Highlands and Islands Enterprise

postalCode: IV2 5NA

streetAddress: An Lòchran

name: Social Care and Social Work Improvement Scotland (Care Inspectorate)

name: Walk In The Gate Ltd (Trading as The Gate Worldwide)

name: Leith Creative Agency Ltd (T/A Leith Agency)


description:
The Scottish Government (SG), on behalf of the Scottish Ministers, is seeking to commission a Contractor to undertake analysis of responses to a public consultation on the Scottish Government consultation on Mitigation of the two-child limit in Universal Credit. The overall aim of the contract is to provide robust and timely analysis and reporting on the responses to the consultation.
 The contract is expected to last two months, starting on the 4th April 2025 and ending on the 6th June 2025.
 The key deliverables for the project will be required in electronic format only and are listed below:
 - An inception report – which should detail the agreed full project plan and include a minute of the inception meeting as an appendix, full project plan (methodological approach, task allocation, corresponding timescales, reporting schedules, risk management, management arrangements and contingencies etc.) and received within one week of the inception meeting.
 - A draft report, leading to a final report, of publishable standard which includes key findings summary report of publishable standard, as described below.
 - Final auditable database in Excel. This should include all the responses with catalogues of the ones that wants to be excluded, the ones included, from publishing, responses have been excluded from analysis and why, etc.

title: Invitation to Tender - Provision of Analysis of Consultation Responses to the Scottish Government Consultation on Mitigation of the Two-child Limit

description: Provision of analysis of responses to the Scottish Government Consultation on Mitigation of the Two-child Limit

title: Invitation to Tender

Scottish Government

locality: Glasgow

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay, 150 Broomielaw

description: General public services

legalName: Scottish Government

Edinburgh Sherriff Court

locality: Edinburgh

legalName: Edinburgh Sherriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792127.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:792127)


description: Supply of Buprenorphine (Buvidal®) to NHS Scotland. The Authority has awarded this framework as a single supplier framework per line to one (1) Framework Participant.

description: All entities constituted pursuant to the National Health Service (Scotland) Act 1978, and any Integrated Joint Boards established pursuant to the new Public Bodies (Joint Working) Scotland Act.

title: Buprenorphine (Buvidal®)

title: Buprenorphine (Buvidal®)

reviewDetails:
The notification will incorporate a ‘standstill period’ of a minimum of 10 clear calendar days (or a minimum of 15 if the communication method used is not electronic) between the date on which the Authority despatches the VEAT notice and the date on which the Authority proposes to conclude the relevant framework agreement.
 The bringing of court proceedings against the authority during the standstill period will automatically continue the prohibition on entering into the framework agreement until the court proceedings are determined, discontinued or disposed of, or the court, by interim order, brings to an end the prohibition. The remedies that may be awarded by the courts before the framework agreement has been entered into include the setting aside of the decision to award the framework agreement to the winning tenderer.
 The bringing of court proceedings against the authority after the framework agreement has been entered into will not affect the framework agreement unless grounds for the imposition of special penalties under the Public Contracts (Scotland) Regulations 2015 can be established. Otherwise, the remedies that may be awarded by the courts where the framework agreement has been entered into are limited
 to the award of damages

procurementMethodRationale: The medicine to be awarded to the framework agreement is protected by exclusive rights, including intellectual property rights, in line with Regulation 33(1)(b)(iii) of the Public Contracts (Scotland) Regulations 2015.

description: The procurement falls outside the scope of application of the directive

postalCode: EH12 9EB

streetAddress: 1 South Gyle Crescent

description: Health

legalName: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

Camurus AB

region: SE

locality: Lund

streetAddress: Ideon Science Park

legalName: Camurus AB

Sheriff Court House

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court House

description:
The estimated value of the Framework Agreement referred to in Section V.2.4 covers the thirty-six (36) month contract duration and the twelve (12) month extension period of the Framework Agreement.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=792146.
 (SC Ref:792146)


title: Taxi Vehicle up to 8 seats

title: Accessible Vehicles 1- 4 Wheelchairs

title: Bus 17+ Seats

title: Taxi Vehicle up to 8 seats

description: Quarterly notice of contract awards from Lot 1 of the Scottish Borders CPP Sustainable Transport DPS. This award notice covers the period October - December, 2024.

title: Accessible Vehicles 1- 4 Wheelchairs

description: Quarterly notice of contract awards from lot 2 of the Scottish Borders CPP Sustainable Transport DPS. This award notice covers the period October - December, 2024.

title: Bus 17+ Seats

description: Quarterly notice of contract awards from the Lot 4 of the Scottish Borders CPP Sustainable Transport DPS. This award covers the period October - December,2024.

title: Notice of Contracts Awarded from the Scottish Borders CPP Transport DPS - October - December 2024

description: Quarterly notice of contract awards from the Scottish Borders CPP Sustainable Transport DPS. This award notice covers the period October to December, 2024.

Scottish Borders Council

locality: Newtown St Boswells

postalCode: TD6 0SA

streetAddress: Council Headquarters

description: General public services

legalName: Scottish Borders Council

Peter Hogg of Jedburgh

locality: Jedburgh

postalCode: TD8 6ED

streetAddress: Taxi Yard, Bankend Industrial Estate

legalName: Peter Hogg of Jedburgh

E & AJ Robertson

locality: Duns

postalCode: TD11 3QG

streetAddress: Eran Paddock, Sunnyside

legalName: E & AJ Robertson

tweedline taxis

locality: peebles

streetAddress: 3a george street

legalName: tweedline taxis

Greenlyne Private Hire

locality: Peebles

postalCode: EH46 7AT

streetAddress: Robinsland Farm, West Linton

legalName: Greenlyne Private Hire

barc travel

locality: walkerburn

postalCode: eh43 6hg

streetAddress: galashiels road, walkerburn

legalName: barc travel

Five Star Taxis (Scotland) Ltd

locality: Galashiels

postalCode: TD1 1SQ

streetAddress: 98 High Street

legalName: Five Star Taxis (Scotland) Ltd

Go Taxis Ltd

locality: Carluke

postalCode: ML8 4PE

streetAddress: 22 Barmore Avenue

legalName: Go Taxis Ltd

name: Jedburgh Sherriff Court and Justice of the Peace Court

postalCode: TD8 6AR

streetAddress: Castlegate

title: Taxi Vehicle up to 8 seats

title: Accessible Vehicles 1- 4 Wheelchairs

title: Bus 17+ Seats

description:
Award against framework: Scottish Borders Community Planning Partnership Sustainable Transport DPS
 Lot 1 Taxi vehicle up to 8 seats additional information:
 - Langlee Cabs
 The above supplier are awarded within the additional information section of this Award Notice as they are not registered on PCS.
 (SC Ref:792175)


description: Supplier of Orthotics services

title: HH053-24-TW27 Orthotics A&B

title: HH053-24-TW27 Orthotics A&B

description: Supplier of Orthotics services

description: Supplier of Orthotics services

procurementMethodRationale:
The current contract ends in February 2025, due to the detailed work required to develop our own
 specification, cost model and data analysis (this has previously been a national contract) we require
 more time to move to a new contractor and wish to extend for 12 months. This supplier has an exisiting contract with us and has for a number of years, service continuity and
 continued clinic cover is essential to avoid gaps in clinical care and build up of waiting lists.

description: Additional deliveries by the original supplier ordered under the strict conditions stated in the directive

NHS Highland

locality: Inverness

postalCode: IV2 3BW

streetAddress: Assynt House, Beechwood Park

description: Health

legalName: NHS Highland

Buchanan Orthotics Ltd

postalCode: G51 3AR

streetAddress: 603 Helen St

legalName: Buchanan Orthotics Ltd

Inverness Justice Centre

legalName: Inverness Justice Centre

description: (SC Ref:792137)


description: Network Connection and Network Maintenance

description:
The Invitation to Tender to was published as a Quick Quote for Work under 2m GBP under the governance of the Council's Standing Orders on Contracts.
 Prior to issuing the Invitation to Tender a Capacity and Capability email was sent to 56 identified NSI accredited contractors based in and around the Council's boundary to facilitate the involvement of local SMEs. Of the 56 invitations 17 contractors confirmed interest in participating in the Quick Quote for Works.

title: Quick Quote for Works under 2m GBP - South Lanarkshire Council CCTV Infrastructure Upgrade Phase 2 - Installation Works for Cameras and Network Upgrade

description:
The Council are seeking to appoint an appropriately qualified contractor for Phase 2 of South Lanarkshire Council's CCTV infrastructure upgrade.
 For Phase 2 the Council is prioritising an upgrade to the network element of the CCTV Infrastructure, which involves an improvement to the current solution through Wi-Fi and Fibre connectivity to enhance and secure the Council CCTV connections with the CCTV Control Room in Pollock Ave, Hamilton. Bidders are required to propose a upgraded network solution as part of their quotation including recurring costs for maintenance and the network solution e.g. circuit rental etc.
 This will be procured as a Quick Quote for Works under 2m GBP and governed by the JCT 2011 Design and Build Contract for use in Scotland DB/Scot (2011Edition)
 Funding by the UK Shared Prosperity Fund: https://www.gov.uk/government/publications/uk-shared-prosperity-fund-prospectus/uk-shared-prosperity-fund-prospectus

South Lanarkshire Council

locality: Hamilton

postalCode: ML3 0AA

streetAddress: Council Headquarters, Almada Street, Almada Street

description: General public services

legalName: South Lanarkshire Council

RACAM Security and Communications

postalCode: G52 4JW

streetAddress: Wing 5, 15 Edison Street, , Hillington Park

legalName: RACAM Security and Communications

Hamilton Sheriff Court

postalCode: ML3 0BT

streetAddress: Sheriff Court House, 4 Beckford Street

legalName: Hamilton Sheriff Court

description: (SC Ref:792147)


name: Custody and Offender Medical Services (COMS)

description:
NHS Highland have responsibility for the 24/7 delivery of Forensic Medical Services. The Forensic Medical Services
 (Victims of Sexual Offences) (Scotland) Act 2021 (“FMS Act”) was implemented on 1st April 2022. The FMS Act places
 legal, statutory duties on Health Boards.

title: HH037-24-TW17 Forensic and Custodial Medical Service

procurementMethodRationale:
CUSTODY AND OFFENDER MEDICAL SERVICES (COMS) have been engaged by NHSH for many years to deliver custody and forensic services to NHSH. The delivery of this service is a legal requirement. Due to staffing NHSH do not have doctors to cover this service 24/7 and require COMS to provide cover when there is no NHSH Dr available.
 COMS are the only locum agency that have the right training to deliver this specialist service.

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

NHS Highland

description: Health

locality: Troon

streetAddress: PO Box 8616

description: (SC Ref:792128)


description: The objective of this ITT is to appoint a supplier capable of delivering a series of refurbishment and upgrade works to existing customer facilities within the New Port Downie building at The Falkirk Wheel.

title: Scottish Canals 0086 - NPD Customer Facilities

Scottish Canals

postalCode: G4 9SP

streetAddress: Canal House, 1 Applecross Street

description: General public services

legalName: Scottish Canals

EC Specialist Contractors Limited

postalCode: EH12 0BD

streetAddress: Unit 1B West Craigs Industrial Estate,, Turnhouse Road

legalName: EC Specialist Contractors Limited

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description: (SC Ref:792191)


description:
Supply of Anti-Ligature IPS panels, Anti-Ligature Toilets and Anti-Ligature sinks for the Morar High Risk
 Ligature Points Removal Project.

title: HH191-24-TW24 IPS Panels (New Craigs)

title: HH191-24-TW24 IPS Panels (New Craigs)

procurementMethodRationale: This project has been instructed by a HSE improvement notice.

description: Extreme urgency brought about by events unforeseeable for the contracting authority/entity and in accordance with the strict conditions stated in the directive

NHS Highland

description: Health

Trovex Limited

locality: Welham Green, Hatfield

postalCode: AL9 7JL

streetAddress: Axiom House, Units 1-2, Travellers Close

legalName: Trovex Limited

description: (SC Ref:792135)