description:
The Works comprise of structural works in order to subdivide units 3,5,6,9 into separate units.
 General builders work and structural works in connection with forming new office blocks. The provision of new accessible/female toilet and male w.c including new sanitary ware, laminate cubicles, vanity units and decoration, plumbing, electrical and mechanical works.

description: Wishaw

title: Refurbishment of Industrial Units at 3,5,7 & 9 Netherbank Road, Wishaw

description: The Works comprise of structural works in order to sub-divide units 3,5,7 and 9 into separate units.

title: ITT Documents (Netherbank Units)

title: TOR Coating Specification

title: Front and rear elevation drawings existing and proposed

title: Updated Drawing register to include elevation drawings uploaded today 20/10/21

streetAddress: MOTHERWELL

North Lanarkshire Council

locality: Motherwell

postalCode: ML1 1AB

streetAddress: Civic Centre, Windmillhill Street

description: General public services

legalName: North Lanarkshire Council

Airdrie Sheriff Court

postalCode: ML6 6EE

streetAddress: Sheriff Court House, Graham Street,

legalName: Airdrie Sheriff Court

North Lanarkshire Council

description: General public services

Procast Building Contractors Ltd

locality: Strathaven

postalCode: ML10 6LT

streetAddress: 31 Green Street

legalName: Procast Building Contractors Ltd

description:
Tenderers must meet the Council's minimum requirements as stated within the contract documentation, else their proposal will be rejected.
 -
 Only electronic returns will be accepted therefore Tenders must be returned using the PCS submission postbox by the date and time specified in the Contract notice and/or documentation.
 -
 Please adhere to the INSTRUCTIONS TO TENDERERS. Please ensure all the relevant documents are returned with your tender submission ie First Stage Documentation completed and signed, Second Stage Documentation Part 1 and Part 2 completed and signed.
 -
 Tenderers MUST ensure that any questions relating to this Tender are submitted via the ONLINE Questions and Answer Facility on the Public Contracts Scotland portal prior to the deadline for raising questions as stated in the Contract Notice. After this time NO QUESTIONS will be answered.
 -
 Tenderers should please note that the Q&A facility should be utilised and therefore NO offer should contain QUALIFICATIONS/ALTERATIONS. If the Offer does include any Qualifications/Alterations, the Offer may be deemed non-compliant and therefore not suitable for consideration for acceptance.
 -
 Tender offers deemed Non-Compliant will be at the discretion of the Issuing Officer.
 -
 The Council reserves the right not to award any contract as a result of the procurement process initiated by this Contract Notice and in such event will not be liable for any costs incurred by any party.
 -
 Tenderers must provide relevant evidence with their submission, please therefore ensure this is uploaded and clearly labeled to the portal and all relevant documentation is authorised.
 -
 For a site visit/survey of the properties, please contact Kenneth McDonald on 07984 070348 or mcdonaldk@northlan.gov.uk who will make suitable arrangements.
 -
 Please note the asbestos report will be uploaded to the portal in due course.
 (SC Ref:679970)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

rel: canonical

status: complete

description:
To provide transport to children with additional support needs to and from their place of residence and school, taking in to account the need of continuity of transport provider/driver and escort.
 This procurement has been conducted under Regulation 6 of the Procurement (Scotland) Regulations 2016.

scheme: CPV

title: Interim Contract for Transport for Renfrewshire Council

format: text/html

documentType: awardNotice

reviewDetails: An economic operator that suffers or risks suffering, loss or damage attributable to breach of duty under the Public Contracts (Scotland) Regulations 2015 (SSI 2015/446, as amended) may bring proceedings in the Sheriff Court or the Court of Session in accordance with Regulation 88 of the 2015 Regulations.

procurementMethod: selective

mainProcurementCategory: services

procurementMethodDetails: Restricted procedure

Renfrewshire Council

locality: Paisley

postalCode: PA1 1JB

streetAddress: Renfrewshire House, Cotton Street

scheme: COFOG

description: General public services

legalName: Renfrewshire Council

Boyds Coach Hire Limited

region: UK

postalCode: PA1 1YB

streetAddress: 26 New Street

scale: sme

legalName: Boyds Coach Hire Limited

Sheriff Court or the Court of Session

locality: See VI.4.3 below

legalName: Sheriff Court or the Court of Session

Court of Session

roles: mediationBody reviewContactPoint

locality: Edinburgh

postalCode: EH1 1RQ

streetAddress: Parliament House Parliament Square

legalName: Court of Session

currency: GBP

status: active

description: (SC Ref:668918)

initiationType: tender


title: CE-133-21-MC - Oracle Fusion ERP Cloud Implementation Support and Change Management Partner

procurementMethod: open

procurementMethodDetails: Open procedure

South Ayrshire Council

locality: Ayr

postalCode: KA7 1DR

streetAddress: County Buildings, Wellington Square

description: General public services

legalName: South Ayrshire Council

Socitm Advisory Ltd

locality: Northampton

postalCode: NN4 5EZ

streetAddress: 8a Bassett Court, Grange Park

legalName: Socitm Advisory Ltd

Ayr Sheriff Court

streetAddress: Sheriff Court House, Wellington Square

legalName: Ayr Sheriff Court

description:
Award against framework: Scottish procurement DPS for Digital Technology Services, Lot 1 - Digital Technology Projects
 (SC Ref:668919)


description: Provision of Tyres

title: CE-17-21-DA - Provision of Tyres

title: CE-17-21-DA - Provision of Tyres

description: Provision of Tyres

description: Provision of Tyres

mainProcurementCategory: goods

South Ayrshire Council

description: General public services

McConechy's Tyre Service Ltd

streetAddress: 13 Miller Road, Ayrshire

legalName: McConechy's Tyre Service Ltd

description:
Award against framework: Scotland Excel 04/17 Tyres for Vehicles and Plant
 (SC Ref:668941)


description:
The aim of this project is to successfully clear the 100ha RSPB reserve at Glenborrodale of the invasive Rhododendron ponticum. Please see accompanying PDF for more details and maps of the site.
 A site visit is essential to determine the extent and difficulty level of the project. Some rope access work will be required, including in a river gully. There is no access through the site by quad/argo other than specified on our maps.
 We would request that the work would be carried out between August and March, outside of the breeding bird season.

variantPolicy: notAllowed

description: RSPB Glenborrodale, Ardnamurchan peninsula

title: Rhododendron Control at RSPB Glenborrodale Reserve

documentType: contractNotice

title: Invitation to quote

title: Maps

format: application/pdf

RSPB Scotland

roles: buyer centralPurchasingBody

region: UKM

postalCode: EH12 9DH

streetAddress: 2 Lochside View, Edinburgh Park

description: Environmental protection

legalName: RSPB Scotland

Edinburgh Sheriff Court

streetAddress: 27 Chambers Street  Edinburgh  EH1 1LB  UK

legalName: Edinburgh Sheriff Court

RSPB Scotland

description: Environmental protection

ICD Contracting Limited

locality: Kilberry road

postalCode: PA29 6XX

streetAddress: Glenakil cottage , Tarbert Argyll

legalName: ICD Contracting Limited

Edinburgh Sheriff Court

roles: reviewBody reviewContactPoint

locality: EDINBURGH

postalCode: EH1 1LB

streetAddress: Sheriff Court House, 27 Chambers Street

description: (SC Ref:718757)


description: To provide transport to children with additional support needs to and from their place of residence and school, taking in to account the need of continuity of transport provider/driver and escort.

Renfrewshire Council

description: General public services

GMT Travel Ltd ta Westway Coaches

postalCode: PA1 1UT

streetAddress: 21 Forbes Place

legalName: GMT Travel Ltd ta Westway Coaches

description: (SC Ref:668958)


Renfrewshire Council

description: General public services

Ian MacMillan t/a Marleigh Hire

postalCode: PA3 2HU

streetAddress: 5-7 Glen Lane

legalName: Ian MacMillan t/a Marleigh Hire

description: (SC Ref:668960)


description: Purchase of 4Nr. New RCVs

title: CE-145-21-DA - Purchase of 4Nr. New RCVs

description: Purchase of 4Nr. New RCVs

description: Purchase of 4Nr. New RCVs

South Ayrshire Council

description: General public services

Dennis Eagle Ltd

locality: Warwick

postalCode: CV34 6TE

streetAddress: Heathcote Way, Heathcote Ind. Est.

scale: large

legalName: Dennis Eagle Ltd

description:
Award against framework: Scotland Excel 03/17 Heavy Vehicles - Lot 1 Chassis, Lot 8 RCV Bodies, Lot 11 Bin Lifts
 (SC Ref:668968)


Renfrewshire Council

description: General public services

Toa Cabs Ltd

locality: Johnstone

postalCode: PA5 8AX

streetAddress: Johnstone Railway Station, Thornbrae

legalName: Toa Cabs Ltd

description: (SC Ref:668975)


description:
During the Licence Period, Procurement Leaders grants the "Member" a licence to access Procurement Leaders'
 Membership Services

title: Procurement Leaders Corporate Membership Agreement

Scottish Government

roles: buyer mediationBody reviewContactPoint reviewBody

locality: Glasgow

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

id: Ministry or any other national or federal authority, including their regional or local subdivisions

description: General public services

legalName: Scottish Government

Procurement Leaders Limited

locality: London

postalCode: SE1 1GA

streetAddress: Third Floor Prospero House, 241 Borough High Street

legalName: Procurement Leaders Limited

Edinburgh Sheriff Court

locality: 27 Chamber Street

description: (SC Ref:668989)


description: The data from a number of disparate legacy systems, several of which are no longer under vendor support and have limited support resources, to be intelligently transformed into a standard UNIFI format and migrated to the new Core System as compliant, quality data while maintaining the links and attributes that underpin data-driven policing.

title: Data Migration Services for National UNIFI Rollout

description: Requirement for the data from a number of disparate legacy systems, several of which are no longer under vendor support and have limited support resources, to be intelligently transformed into a standard UNIFI format and migrated to the new Core System as compliant, quality data while maintaining the links and attributes that underpin data-driven policing.

Scottish Police Authority

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

Capita Business Services Ltd

streetAddress: 65 Gresham Street

legalName: Capita Business Services Ltd

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description:
Award against framework: Crown Commercial Services’ Technology Services 2 (RM3804)
 (SC Ref:669015)


description: This procurement exercise has been conducted in accordance with Section 12 of the Procurement Reform (Scotland) Act 2014 (as amended) and Regulation 6 of the Procurement (Scotland) Regulations 2016 for a Regulated Contract for Health and Social Care Services.

title: Provision of a Carers Centre

title: Provision of a Carers Centre

description: The service will provide a range of support for carers with an aim to support them in their caring role and provide opportunities to have a life outside of their caring responsibilities.

Renfrewshire Council

streetAddress: Renfrewshire House, Cotton Street

description: General public services

legalName: Renfrewshire Council

Renfrewshire Carers Centre

locality: Paisley, Renfrewshire, Scotland

postalCode: PA1 1TJ

streetAddress: Unit 55 Embroidery Mill, Abbey Mill Business Centre

legalName: Renfrewshire Carers Centre

Sheriff Court or the Court of Session

legalName: Sheriff Court or the Court of Session

Court of Session

streetAddress: Parliament House Parliament Square

legalName: Court of Session

description:
Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 2 jobs to unemployed people and participation in an Industry Awareness Event.
 (SC Ref:669024)


measure: lowestValidBidValue

measure: highestValidBidValue

description: Clear felling (felling to waste/recycle) two hectares of 50 year old Larch plantation with some Sitka Spruce. Brash management. Ground preparation/manual screefing and restocking of an alternative area with two hectares of native broadleaves at a density of 1600 stems/ha to create an upland oak wood. Trees (plugs) to be provided by supplier. Planted trees (notch planting) to be protected by vole guards. Erection of 2000m of deer fencing with two gates.

description: Loch Ardinning Wildlife Reserve Strathblane

title: Loch Ardinning Felling Restocking and Deer Fencing

description: Clearfell two hectares of 50 year old Larch with Sitka Spruce (fell to waste/recycle). Restock two hectares of native broadleaves at 1600/ha. Erect 2000m of deer fencing.

documentType: economicSelectionCriteria

documentType: technicalSelectionCriteria

title: Loch Ardinning Wildlife Reserve

format: image/jpeg

title: Larch Plantation

title: Restocking area

title: Proposed route for erection of 2000m of deer fencing and areas of additional tree planting.

title: Tender Brief

streetAddress: Cumbernauld

description: Reserves Manager West Central and Head of Reserves

electronicInvoicingPolicy: allowed

type: suitability

description: Service providers must have relevant competency awards (eg: NPTC Chainsaw),

Scottish Wildlife Trust

postalCode: EH6 6NF

streetAddress: Harbourside House 110 Commercial street Edinburgh

description: Environmental protection

legalName: Scottish Wildlife Trust

description: Environmental protection

Scottish Woodlands Ltd

locality: Perth

postalCode: PH1 3EE

streetAddress: Sandpiper House, Ruthvenfield Road

legalName: Scottish Woodlands Ltd

description:
Interested suppliers should contact the Reserves Manager West Central if a site visit is required prior to submission of tender (wgray@scottishwildlifetrust.org.uk)
 (SC Ref:678534)


name: idverde Ltd (Formally The Landscape Group Ltd)

description: Option to extend the contract for any variable period up to a maximum of 24 months.

description:
The Work will comprise routine upkeep, and regular maintenance of open space and garden areas of the various sites listed in the Invitation to Tender documents, to keep them in a neat and tidy condition to promote and control growth.
 The works will include: -
 Grass cutting, Culvert Cleaning, Stream Cleaning, Litter Collection, Weed Control, Shrub Maintenance, Tree Maintenance, Whip Maintenance, Hedge Maintenance, Woodland Maintenance, Garden Care Maintenance, Play Area Maintenance, Bin Store Maintenance, Bin Store Powerwashing, Bin Store Refuse Removal and Rubbish and Bonfire Removal. The above will include the disposal of all arisings resulting from the works. Litter collection will be deemed to include collection and disposal of fallen leaves and other seasonal arisings.
 Reactive repair works will be priced separately for instruction by the Employer on an ad-hoc basis and will typically include items such as uplift and removal of items not included in general litter collection, staking and tying trees, hedging works, pruning trees, crown reduction,
 removing mature shrubs, tree felling, tree replacement, shrub replacement, mulching, soiling, grass area repairs, turfing and work to existing gullies.

Quality Assessment

type: quality

type: price

description: Ayrshire

title: Ayrshire H.A. - Landscape Maintenance Contract 2022 - 2025

description:
The works comprise the routine upkeep and regular maintenance of open space and
 garden areas of the various sites listed in the Bill of Quantities, list of addresses and tender drawings to
 keep them in a neat and tidy condition to promote and control growth. Reactive repair works will also
 require to be priced separately for instruction by the Client on an ad-hoc basis.

title: Supporting Information Document

title: List of Addresses Part 1

title: List of Addresses Part 2

scheme: CELEX

description: Between 2025 and 2027

description: Contracting organisations wishing to participate in the competition should be a member of the British Association of landscape Industries (BALI) or an equivalent organisation recognised within the industry. Certification or proof of membership to be supplied.

Ayrshire Housing

postalCode: KA8 8BX

streetAddress: 119 Main Street

description: Housing and community amenities

legalName: Ayrshire Housing

name: Ewing Somerville Partnership (Scotland) Ltd.

postalCode: G4 9TH

streetAddress: 40C Speirs Wharf

Ayr Sheriff Court

streetAddress: Sheriff Court House

legalName: Ayr Sheriff Court

Ayrshire Housing

description: Housing and community amenities

locality: Coventry

postalCode: CV4 8JP

streetAddress: Octavia House, Westwood Business Park, Westwood Way

Ayr Sheriff Court

postalCode: KA7 1EE

streetAddress: Sheriff Court House, Wellington Square

description: (SC Ref:689363)

scheme: EU-OJ


description:
Direct award via the SPA Framework to meet programme constraints for the 1,140
 hours Early Years and Childcare provision.

title: Avoch Primary School - ELC Expansion

title: Avoch Primary School - ELC Expansion

description:
Extension to existing building with free flow access to outdoor space and
 refurbishment of vacated nursery rooms in the main building.

mainProcurementCategory: works

The Highland Council

locality: Inverness

postalCode: IV3 5NX

streetAddress: Council Headquarters, Glenurquhart Road

description: General public services

legalName: The Highland Council

Morgan Sindall

locality: Motherwell

postalCode: ML1 4YT

streetAddress: 11 Woodhall

legalName: Morgan Sindall

The Sheriff Officer

streetAddress: The Longman

legalName: The Sheriff Officer

description: (SC Ref:669112)


title: GlowMax Plate Reader Instrument

title: GlowMax Instrument Consumables

title: Provision of Service of the GlowMax Instrument

title: GlowMax Plate Reader Instrument

description: Platereader for use in targeted protein degradation research.

title: GlowMax Instrument Consumables

description: Consumables for use with Glowmax instrument

description: provision of service of the Glowmax instrument

description: School of Life Science, University of Dundee

title: Termed Agreement for the Supply of a GlowMax System & related consumables & service

description: Plate Reader for use in targeted protein degradation research

Parent

locality: Dundee

postalCode: DD1 4HN

streetAddress: Procurement, 3rd Floor, Tower Building, Nethergate

description: Education

legalName: Parent

Promega UK Ltd

locality: Southampton

postalCode: SO16 7NS

streetAddress: Delta House, Southampton Science Park

legalName: Promega UK Ltd

Finance and Procurement

streetAddress: Perth Road

legalName: Finance and Procurement

Procurement, Finance and Procurement

roles: reviewBody mediationBody

legalName: Procurement, Finance and Procurement

University of Dundee

roles: buyer reviewContactPoint

description: Education

legalName: University of Dundee

title: GlowMax Plate Reader Instrument

title: GlowMax Instrument Consumables

description: (SC Ref:669150)


description:
The council plans to procure an integrated Social Care Case Management System which meets the emerging and future needs and aspirations of the council.
 The Scotland Excel Social Care Case Management System Framework (1420) was identified as a compliant route to market.
 A mini competition was undertaken in accordance with the call off procedures as outlined within the framework terms and conditions.

description: West Lothian

title: Social Care Case Management System

title: Social Care Case Management System

description: Provision of a Social Care Case Management System.

West Lothian Council

locality: Livingston

postalCode: EH54 6FF

streetAddress: West Lothian Civic Centre, Howden South Road

description: General public services

legalName: West Lothian Council

Servelec Social Care Ltd

locality: Sheffield

postalCode: S2 5SY

streetAddress: The Straddle, Victoria Quays

legalName: Servelec Social Care Ltd

name: Livingston Sheriff Court and Justice of the Peace Court

description:
Award against framework: Social Care Case Management
 (SC Ref:669159)


description:
Supplier: Verint
 Engagement Management Professional LG Platform - SaaS
 Engagement Management Professional LG Named Employees - SaaS
 Engagement Management Professional LG Data Model and Reports for Power BI - SaaS
 Engagement Management Professional LG Process Management - SaaS
 Engagement Management Professional LG Employee Desktop Named Employee (Case Handler Only) - SaaS

description:
The development of Robotic Process Automation for West Lothian Council is a key part of the delivery of the Digital Transformation Strategy 2018-2023.
 The objective is to source and work with the optimum supplier of robotic process automation within the CSC, and develop this functionality with a partner to help deliver the required smooth transition to embed process automation that works seamlessly with current telephony and operating systems.. The Scottish Procurement Software Value Added Reseller Framework (MP5016/17) was identified as a compliant route to market.
 A Direct Award was issued in accordance with the Framework terms and conditions

description: West Lothian

title: Customer Service Centre Automation

title: Customer Service Centre Automation

description: Robotic Process Automation for Customer Service Centre

West Lothian Council

description: General public services

Softcat

locality: BUCKS

postalCode: SL7 1LW

streetAddress: Thames Valley Ind Est, Marlow

legalName: Softcat

legalName: Livingston Sheriff Court and Justice of the Peace Court

description:
Award against framework: Software Value Added Reseller (SVAR)
 (SC Ref:669171)


name: Western Power Distribution(South West)plc

description: Western Power Distribution is the owner of the electricity meters in Causewayside and George IV Bridge sites electricity meters. That will be a 60 month contract till October 2026 for 5 years. 126 GBP x 2 sites X 5 years

title: Building Electricity Meter Charges - 2021 -2026

description: Western Power Distribution is the owner of the electricity meters in Causewayside and George IV Bridge sites electricity meters .

National Library of Scotland

locality: Edinburgh

postalCode: EH1 1EW

streetAddress: George IV Bridge

description: Recreation, culture and religion

id: European institution/agency or international organisation

legalName: National Library of Scotland

locality: Exeter

postalCode: EX2 7WP

streetAddress: Osprey Road, Sow ton Industrial Estate

name: Edinburgh Sheriff Court - Sheriff Clerks Office

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

description:
Non competitive action
 (SC Ref:669183)


description:
To implement a comprehensive integrated care home management solution across four council operated care homes.
 The Crown Commercial Services G-Cloud 12 Framework (RM1557.12) was identified as a compliant route to market.
 A Direct Award was issued in accordance with the Framework terms and conditions.

description: West Lothian

title: Digital Care Planning including Electronic Medication Administration Record

description: Provision of a Digital Care Planning and EMAR solution.

West Lothian Council

description: General public services

Access UK Ltd

locality: Essex,

postalCode: CO7 6LZ

streetAddress: The Old School, School Lane, , Stratford St Mary, Colchester,

legalName: Access UK Ltd

description:
Award against framework: G-Cloud 12
 (SC Ref:669198)


description: Free School Meal Provision Extension – Food Vouchers to cover 11th October to 15th October 2021.

description: North Ayrshire Region

title: Free School Meal Provision – Food Vouchers for the period 11th October to 15th October 2021

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: Additional deliveries

description: Additional deliveries by the original supplier ordered under the strict conditions stated in the directive

North Ayrshire Council

locality: Irvine

postalCode: KA12 8EE

streetAddress: Cunninghame House, Friars Croft

description: General public services

legalName: North Ayrshire Council

Sodexo

locality: Stepps   Glasgow

postalCode: G33 6FB

streetAddress: 2 Buchanan Gate, Cumbernauld Road

legalName: Sodexo

Kilmarnock Sheriff Court

locality: Kilmarnock

postalCode: KA1 1ED

streetAddress: St Marnock Street

legalName: Kilmarnock Sheriff Court

description: (SC Ref:669202)


description: Purchase and subsequent maintenance of replacement Pedestrian and Compact Sweepers/Gritters up to 12.5t

title: CT0705 - Contract for Precinct & Midi Sweepers

description: Purchase and servicing of pedestrian and compact sweeper/gritter vehicles

The City of Edinburgh Council

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

Hako Machines Ltd

locality: Crick

postalCode: NN6 7UD

streetAddress: Eldon Close

legalName: Hako Machines Ltd

Edinburgh Sheriff Court

locality: 27 Chamber Street

legalName: Edinburgh Sheriff Court

description:
Award against framework: Halton Housing Fleet Procurement Framework ‘Pedestrian and Compact Sweepers up to 12.5t – Lot 4’
 (SC Ref:669226)


description: Mini Competition via PCS. Mini Competition via PCS

description:
Police Scotland
 2 French Street
 Dalmarnock
 Glasgow
 G40 4EH

title: Supply of bottled water

title: Supply of bottled water

description: The Scottish Police Authority and Police Scotland ( hereafter referred to as the “the Authority”) intends to appoint suitably qualified and experienced contractors to supply and deliver bottled water.

Scottish Police Authority

locality: Glasgow

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

Highland Spring Group

locality: Blackford

postalCode: PH4 1QA

streetAddress: Stirling Street

legalName: Highland Spring Group

name: Glasgow Sheriff Court and Justice of the Peace Court

postalCode: G5 9DA

streetAddress: Sheriff Clerk’s Office, PO Box 23, 1 Carlton Place,

description:
Mini competition via PCS
 (SC Ref:669256)


description: This procurement is for an interim Project Manager for the Scottish Canals regeneration and development team.

title: Scottish Canals-Project Manager (SP-18-015

description: This Procurement is for an interim project manager for a period of 6 months.

Scottish Canals

streetAddress: Canal House, 1 Applecross Street

description: General public services

legalName: Scottish Canals

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

legalName: Venesky Brown Ltd

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description: (SC Ref:669264)


title: Education Prosecutions

title: Lot 2 Employment

title: Corporate

title: General Litigation

title: Children & Families - Advice and Representation

title: General Conveyancing

title: Construction

title: Education Prosecutions

description: To provide advice and representation in relation to Education Prosecutions raised by the Council under the Education (Scotland) Act 1980.

title: Lot 2 Employment

description: To provide advice and representation on all aspects of employment law including, but not limited to, the matters listed in the scope of requirements below. Advice and representation on equal pay and related discrimination claims arising from the Council’s pay and grading structure are excluded from this lot

title: Corporate

description:
To advise and assist the Council in relation to any requirement it may have regarding
 corporate / commercial legal services
 planning, roads and environment law
 local government and public law
 complex, high value or novel property law and conveyancing (excluded from the scope of the General Conveyancing Lot (Lot 6))

title: General Litigation

description: To provide advice and assistance to the Council on all aspects of civil litigation, including representation at courts and tribunals as required. Work falling under the lots 2 (employment), 1 (education prosecutions) and 5 (social work children and families) is excluded from this lot.

description: To advise and assist the Council on its statutory rights and responsibilities in relation to children and young persons, and to provide advice and representation as required. Working with the Council’s in-house legal team or directly on the instruction of Social Work Services

title: General Conveyancing

description: General Conveyancing

title: Construction

description: Construction advice

title: Provison of Legal Services

title: Provison of Legal Services

description: Provision of legal services

description: Provision of legal services

Glasgow City Council

postalCode: G2 1DU

streetAddress: City Chambers

description: General public services

legalName: Glasgow City Council

North Lanarkshire Council

postalCode: ML1 1AB

streetAddress: Civic Centre, Windmillhill Street

description: General public services

legalName: North Lanarkshire Council

North Ayrshire Council

description: General public services

The Wheatley Housing Group Limited

postalCode: G1 1HL

streetAddress: 25 Cochrane Street

legalName: The Wheatley Housing Group Limited

Clyde Gateway URC

postalCode: G40 2QH

streetAddress: Olympia, 2-16 Orr Street

description: General public services

legalName: Clyde Gateway URC

City Property (Glasgow) LLP

postalCode: G1 1QU

streetAddress: 229 George Street

Jobs & Business Glasgow

streetAddress: Ladywell Business Centre, 94 Duke Street

Shoosmiths LLP

streetAddress: 2nd Floor North, Saltire Court, 20 Castle Terrace

name: Glasgow Sherrif Court & Justice of the Peace Court

title: Education Prosecutions

title: Lot 2 Employment

title: Corporate

title: General Litigation

title: General Conveyancing

title: Construction

description: (SC Ref:669290)


description: The contract will run for an initial two-year duration. RCH may wish, at its sole discretion, to extend any resultant agreement for up to an additional two, 12-month periods, subject to the agreement of the successful bidder.

description:
River Clyde Homes are looking to procure a competent and experienced company to undertake the servicing, maintenance and replacement of MVHRs and low rise and high rise fans.
 Each MVHR unit requires to be serviced twice per year. Low and high rise fans require to be serviced once per year. The servicing requirement is detailed within the attached Pricing Schedule.
 The successful bidder must be BPEC accredited and adhere to 18th edition IEE wiring regulations.. Due to the reactive nature of elements of this contract the value is an anticipated cost.

title: Fan Repair, Service & Replacement

title: Fan Repair, Service & Replacement

description: River Clyde Homes are looking to procure an experienced and competent company to repair, service and replace MVHR units and fans.

title: RCH541 - Repair, Servicing & Replacement of Fans Tender

title: RCH541 - Appendix A - SPD

title: RCH541 - Appendix B - Tender Response Document

title: RCH541 - Appendix C - Pricing Schedule

title: RCH541 - Appendix D - Contract Ts and Cs

format: application/msword

title: RCH541 - Appendix E - Certification

title: RCH541 - Appendix F - MVHR and Fan Addresses & Types

title: Fan Repair, Service & Replacement

description: October 2025

performanceTerms: Any resultant agreement will be subject to Key Performance Indicators (KPIs). These KPIs are detailed within the invitation to tender document.

description: It is a requirement of this contract that Bidders are BPEC accredited. Please confirm if you are accredited

type: economic

minimum:
SPD Question 4B.6
 The bidder’s company name and registration number will be used to obtain a financial risk assessment report from Dun & Bradstreet. Only companies that are deemed to be financially stable, on the strength of their financial report, will be eligible to be a party to the contract. It is the tenderers responsibility to ensure that the information held by Dun & Bradstreet is up to date at the time of submission. If you prefer to have this assessment carried out in respect of a guarantor, such as an ultimate parent body, then you may elect for this option and details of the guarantor should be provided. Bidders should provide their company registration number in the space provided.

description:
SPD Question 4B.5.1b
 The Bidder confirms they already have or can commit to obtain, prior to the commencement of the contract, the levels of insurance cover indicated below:
 Employer’s Liability Insurance = 5m GBP
 SPD Question 4B.5.2
 Bidders must also confirm they already have or can commit to obtain, prior to the commencement of the contract, the following levels of Insurance:
 Public Liability Insurance = 10m GBP

type: technical

minimum:
SPD Question 4D.1
 Will the bidder be able to produce certificates drawn up by independent bodies attesting that the bidder holds a UKAS (or equivalent), accredited independent third party certificate of compliance in accordance with BS OHSAS 45001 / 18001 (or equivalent) or have, within the last 12 months, successfully met the assessment requirements of a construction-related scheme in registered membership of the Safety Schemes in Procurement (SSIP) forum.
 Where the preferred bidder does not hold the above accreditation, they will require to satisfy River Clyde Homes' Internal Health & Safety Team of their competence through other means prior to any contract award.
 And
 Will the bidder be able to produce certificates drawn up by independent bodies attesting that the bidder holds a UKAS (or equivalent) accredited independent third party certificate of compliance in accordance with BS EN ISO 9001 (or equivalent), or a documented policy regarding quality management. The policy must be relevant to the nature and scale of the work to be undertaken and set out responsibilities for quality management throughout the organisation.

description:
SPD Question 4C.1.2
 Bidder's will be required to provide three examples of the successful delivery of contracts that are close in nature and scope to RCH’s requirement. Bidders require to describe the scope of the contracts, what their responsibilities are / were, what the scale of the contract was, and how they have performed within the contract.
 Bidders will also be required to provide written references from two of the three clients listed. The references should provide a summary of the works undertaken and indicate the clients own satisfaction levels with the quality of service they received. (Pass/Fail)
 SPD Question 4C.2
 Bidders are required to provide details of the on-site staff that will service the contract in the event of a successful bid. The staff member’s core skills, qualifications, accreditations, experience and competency should be provided. (Pass/Fail)
 SPD Question 4C.6.1
 Bidders are required to provide details of the relevant experience; and the educational and professional qualifications held by their managerial staff.(Pass/Fail)
 SPD Question 4C.10
 Bidders are required to provide details of the proportion of the contract that they intend to subcontract, and provide details of the sub-contractors they intend to sub-contract these works to. If the bidder has decided to subcontract core elements of the contract and relies on the subcontractor’s capacities and capabilities to perform that part, then a separate ESPD for such subcontractors must be completed.(Pass / Fail)

River Clyde Homes

locality: Greenock

postalCode: PA15 4JT

streetAddress: Roxburgh House, 102-112 Roxburgh Street

description: Housing and community amenities

legalName: River Clyde Homes

Greenock Sheriff Court

streetAddress: 1 Nelson Street

legalName: Greenock Sheriff Court

River Clyde Homes

postalCode: PA15 2UZ

streetAddress: Clyde View, 22 Pottery Street

description: Housing and community amenities

MS All Trades Ltd

locality: Beith

postalCode: KA15 1AB

streetAddress: 45 Eglinton Street

legalName: MS All Trades Ltd

description:
Tenders must be submitted via the Public Contracts Scotland (PCS) Electronic tender Post Box. Any response not submitted via the Post Box will not be considered. Any queries in relation to the tender must be raised via the 'Question & Answer' function of the PCS website.
 (SC Ref:678756)


description:
Name: Morton Hall, Newmilns – External Fabric Restoration – Phase 3
 Nature: External fabric restoration works including stonework, roofing, plumbing and painting works
 Locations: 123 Main Street, Newmilns, KA16 9HB
 Length of contract: 16 weeks

title: PS-21-112 - Morton Hall, Newmilns - External Fabric Restoration - Phase 3 (PRJ0013114)

description:
For the purpose of this Contract, all Electrical Subcontractors (including the Main Contractor if appropriate) proposed to be used on this Project must have Registration with either ‘NICEIC (Approved Contractor Scheme)’ or ‘SELECT (Approved Certifier of Construction Scheme)’ throughout the entire Contract period, and all Employees (including Employees of Electrical Subcontractors) must have appropriate trade certification.
 For the purpose of this Contract, all Mechanical Subcontractors (including the Main Contractor if appropriate) proposed to be used on this Project must have Registration with either ‘B&ES Association (Member status)’ or ‘CIPHE (Member status)’ throughout the entire
 Contract period, and all Employees of Mechanical Subcontractors must have appropriate trade certification.
 For the purpose of this Contract, all Gas Sub-Contractors (including the Main Contractor if appropriate) must be on the current Capita Gas Safe Register of Gas Installers at a commercial level throughout the entire Contract period. It is also required by the authorities that any operative employed to do gas work will have to be reported to Capita, and their fees paid as stipulated.
 For the purpose of this Contract, the Asbestos removal Contractor proposed to be used on this Project must hold an Asbestos Removal Licence (issued by the HSE) throughout the entire Contract period, and all employees must have appropriate certification.

description:
Financial Standing
 The Council shall commission an independent third party business credit report from Creditsafe Business Solutions Ltd using the Company Registration number supplied by the Tenderer. Any Tenderer who does not meet the minimum threshold of a Credit Score of 30 out of 100 will have their submission regarded as a “Fail” and will not be considered further. Where a Tenderer receives a Credit Score of between 30-50 out of 100, the Council reserves the right to request further financial information to determine the risk to the Council. In the event that such additional measures are requested, the Council shall, in its sole discretion, determine the terms of those measures that it deems as acceptable. If Tenderers cannot provide measures to the satisfaction of the Council then their submission may be rejected.
 Risk or Credit reports from other agencies will not be considered.
 It is the Tenderers responsibility to ensure that all information held by Creditsafe is current and accurate when submitting their Tender. The Council will not enter into discussions with Tenderers who fail to ensure that their Creditsafe scores are accurate by the due submission date.
 Insurances
 It is a requirement of this Contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded Contract, the insurances indicated below.
 Public & Products Liability Insurance = 5 million GBP in respect of each claim without limit to the number of claims.
 Employers (Compulsory) Liability Insurance = 10 million GBP in respect of each claim without limit to the number of claims.
 Professional Indemnity Insurance = 2 million GBP in respect of each claim without limit to the number of claims, for 6 years from the date of practical completion of the Works.

East Ayrshire Council

postalCode: KA3 7BU

streetAddress: Corporate Procurement Team, London Road HQ

description: General public services

legalName: East Ayrshire Council

Kilmarnock Sheriff Court

streetAddress: Sheriff Court House, St Marnock Street

East Ayrshire Council

description: General public services

MCW Scotland Ltd

locality: Ayr

postalCode: KA8 8AN

streetAddress: 108 Green Street

legalName: MCW Scotland Ltd

description: (SC Ref:796404)


description: To replace the parapets of Victoria Bridge, Kilmarnock and the adjacent retaining walls. As well as, the maintenance painting of the bridge beams, waterproofing of the bridge deck and associated roadworks.

description: Kilmarnock

title: PS/21/20 - Refurbishment of Victoria Bridge, Kilmarnock (A735 20)

East Ayrshire Council

roles: buyer mediationBody reviewContactPoint

postalCode: KA18 1TF

description: General public services

Diack & Macaulay Ltd

postalCode: G69 0LY

streetAddress: 7 Gartferry Road, Moodiesburn, Chryston,

legalName: Diack & Macaulay Ltd

Kilmarnock Sheriff Court

postalCode: KA1 1ED

legalName: Kilmarnock Sheriff Court

description: (SC Ref:669426)


description: Award of PURCH2008 Provision Of A Portable X-Ray System

description: Glasgow

description:
PURCH2008 Provision Of A Portable X-Ray System
 Tender documents available from Public Contracts Scotland.
 Tender returns should be submitted via Public Contracts Scotland, no paper copies will be accepted. Should paper tenders be submitted, they will be rejected. Further to this any questions or communications regarding individual tender exercises must be sent via the Public Contracts Scotland Portal. Tender queries received through any other channel will not be answered. Should users of Public Contracts Scotland have any problems with the web site they should contact website Support Desk, contact details can be found by following the ‘Contact Us’ option on the left hand menu at http://www.publiccontractsscotland.gov.uk/default.aspx

title: PURCH2008 ITT FINAL

title: PURCH2008 - CODE OF CONDUCT - FINAL

title: PURCH2008 Agreement for the Purchase of Goods and Services

title: PURCH2008 Appendix 1 C&SRM KPI Template

title: PURCH2008 Appendix 2 C&SRM Stakeholder Feedback Form Brief 0-5

title: PURCH2008 Non-compliance template

title: PURCH2008 SPD Qualification

title: PURCH2008 Whole Life Cost Model

minimum:
- Product liability insurance with a limit of indemnity of not less than ten million pounds sterling (10,000,000 GBP) in relation to any one claim or series of claims.
 -Public liability insurance with a limit of indemnity of not less than five million pounds sterling (5,000,000 GBP) in relation to any one claim or series of claims;
 -Employer's liability insurance with a limit of indemnity of not less than five million pounds sterling (5,000,000 GBP);
 -Professional indemnity insurance with a limit of indemnity of not less than one million pounds sterling (1,000,000 GBP) in relation to any one claim or series of claims
 - Financial Turnover 2 years

University of Glasgow

postalCode: G12 8QQ

streetAddress: Procurement Office, Tay House

description: Education

legalName: University of Glasgow

name: Glasgow Sheriff Court & Justice of the Peace Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

description: Education

description: Economic affairs

Celtic SMR Ltd

locality: Haverfordwest

postalCode: SA62 3AQ

streetAddress: Frederick House, Hayston View, Johnston

legalName: Celtic SMR Ltd

description: (SC Ref:679803)


description: The works are various fender repairs at Loth (Sanday) and Rapness (Westray) Ferry Terminals. The works comprise repairs to existing fendering including replacement of chains and shackles, existing bolts and the replacement of HIDAC rubber elements.

title: North Isles Fender Repairs (Sanday & Westray)

title: ITT Document

title: WI Appendix 1 - WI Drawings

title: WI Appendix 1 - WI Drawings

title: WI Appendix 1 - WI Drawings

title: SI Appendix 1 - SI Drawings

format: image/tiff

title: SI Appendix 1 - SI Drawings

title: SI Appendix 1 - SI Drawings

title: SI Appendix 1 - SI Drawings

description: The relevant selection criteria will be included in the SPD Scotland module.

Orkney Islands Council

locality: Kirkwall

postalCode: KW15 1NY

description: General public services

description: Recreation, culture and religion

legalName: Orkney Islands Council

Kirkwall Sheriff Court

postalCode: KW15 1PD

streetAddress: Watergate

legalName: Kirkwall Sheriff Court

Orkney Islands Council

streetAddress: Council Offices, School Place

description: General public services

description: Recreation, culture and religion

Leask Marine Ltd

postalCode: KW15 1RG

streetAddress: 6 Crowness Road, Hatston Industrial Estate

legalName: Leask Marine Ltd

description: (SC Ref:678648)


description: NEC3 Engineering and Construction Short Contract follows a single procurement exercise which was conducted as a Quick Quote procurement procedure.

title: Workshop Garage Equipment Improvements

title: Workshop Garage Equipment Improvements

description: The requirement is for a Contractor to supply and installs 4 new vehicle workshop lifts, 1 inspection pit and ancillary equipment at Renfrewshire Council’s Operational Depot

Renfrewshire Council

locality: Paisley

postalCode: PA1 1JB

streetAddress: Renfrewshire House, Cotton Street

description: General public services

legalName: Renfrewshire Council

Tecalemit Garage Equipment Co Ltd

locality: Plymouth

postalCode: PL7 5JY

streetAddress: Unit R2 Eagle Rd, Plympton

legalName: Tecalemit Garage Equipment Co Ltd

See VI.4.3 below

locality: See VI.4.3 below

legalName: See VI.4.3 below

Court of Session

postalCode: EH1 1RQ

streetAddress: Parliament House Parliament Square

legalName: Court of Session

description: (SC Ref:669462)


description: PPE Ref 7855 Direct Award for the Provision of a Payment Solution for retail and catering outlets to integrate with our current EPOS system.

description: Glasgow

description: PPE Ref 7855 Direct Award for the Provision of a Payment Solution for retail and catering outlets to integrate with our existing EPOS system.

procurementMethodRationale: Competition is absent for technical reasons under Regulation 33(1)(b)(ii) of the Public Contracts (Scotland) Regulations 2015 (“PC(S)R 2015”). Our EPOS Provider has confirmed this is the only solution that can meet our needs and also integrate with our EPOS System.

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

University of Glasgow

description: Education

Paymentsense ltd

locality: Pitmedden

postalCode: AB41 7GQ

streetAddress: 1, Breckview

legalName: Paymentsense ltd

legalName: Glasgow Sheriff Court & Justice of the Peace Court

awardID: PPE Ref 7855

description: (SC Ref:669470)


description:
Direct Award via Framework Agreement:
 ESPO Framework Agreement (2664) – Property Advice and 	Management Services – Lot 1B: Rest of the UK Property & Buildings. Direct Award via Framework Agreement:
 ESPO Framework Agreement (2664) – Property Advice and 	Management Services – Lot 1B: Rest of the UK Property & Buildings

description:
Police Scotland
 2 French Street
 Dalmarnock
 Glasgow
 G40 4EH

title: PROC 21 1261 – Estates Professional, Technical and Design Services to Support NEDIP Project ( New Requirements at Bucksburn and Nelson Street).

description:
The Scottish Police Authority and Police Scotland (hereinafter referred to as “the Authority”) requires to appoint a Contractor to deliver the following services to support additional works 	required under the North East Division Integration Project (NEDIP):
 Professional design services associated to additional works in adjacent rooms at Bucksburn and Nelson Street to provide same standard of finish to that in NEDIP areas due to existing condition.
 Move management support resource for remainder of phase 2 project buildings and also addition of the productions new build at Kittybrewster.

Scottish Police Authority

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

Pick Everard

postalCode: G2 5SG

streetAddress: 176 St Vincent Street

legalName: Pick Everard

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

description:
Award against framework: ESPO 2664 Property Advice and Management Services Lot 1B: Rest of the UK Property & Buildings
 (SC Ref:669471)


description: additional rotors

description: Supply of Floor Standing Centrifuge and Rotors

title: Supply of a Floor Standing Centrifuge & Rotors

University of Dundee

locality: Dundee

postalCode: DD1 4HN

streetAddress: Procurement, 3rd Floor, Tower Building, Nethergate

description: Education

legalName: University of Dundee

Beckman Coulter

locality: High Wycombe

postalCode: HP11 1JU

streetAddress: Oakley Court, Kingsmead Business Park

legalName: Beckman Coulter

Procurement, Finance and Procurement

legalName: Procurement, Finance and Procurement

description: (SC Ref:669475)


name: Colin John Lindley, Object & Artefact Display

description:
Orkney Islands Council (“the Authority”) has a requirement for a suitably experienced and qualified mount maker to supply object mounts for the new Scapa Flow Museum (“the Museum”) exhibition. Orkney Islands Council’s Cultural Services team (“the Client”) is currently part way through the major restoration and redevelopment of the Scapa Flow Museum at Lyness, on the Orkney Island of Hoy.
 The Lead Consultants on the project are LDN Architects. Exhibition design has been carried out by Studio MB, who have worked with the Client to develop a detailed exhibition design, including graphic interpretation panels, digital and audio-visual media, showcases, plinths, and object mounts. Object installation will be carried out by the Client, in collaboration with the mount makers. Travel to Hoy involves two ferry crossings ferry capacity can be limited and ferries need to be booked in advance.
 The Museum explores the history of Scapa Flow, focusing on the role of that great naval anchorage during both world wars. This story is made all the more resonant and powerful, by being sited at the former Lyness Royal Naval Base, HMS Proserpine, which played a crucial part in that history. The current phase of the project will restore the Category ‘A’ listed former Oil Fuel Pumphouse and add a new extension to house fragile artefacts as well as improved visitor facilities. These buildings are due for final handover to the Client team in October 2021 and are expected to be ready for the installation fit-out from November 2021.

description: Lyness on the Island of Hoy

title: Provision of Scapa Flow Museum Exhibition Mount Making

title: Case Dressing

format: application/x-zip-compressed

title: Designer Risk Assessments

title: Open Display

title: Plans and Elevations

title: Schedules

title: Invitation to Quote Documentation

title: Structure and Format of Proposal

title: Pricing Schedule

title: General Specification Schedule (for information)

title: Excel Version of SFM Open Display and Cased Objects Mounts Schedule.

title: Designers Drawing for object no 2002.13 Hindeburg Flag for Zone 7 C18

title: Conservation Treatment Report Hindenberg Flag

streetAddress: TEAMS Meeting

description: 3 Officers present and authorised to open and record tenders received

Orkney Islands Council

description: General public services

description: Recreation, culture and religion

description: General public services

description: Recreation, culture and religion

locality: London

postalCode: NW5 1PP

streetAddress: Flatt 11 Lissenden Mansions, Lissenden Gardens

description:
Orkney Islands Council reserves the right to cancel the procurement at any stage and not award a Contract. The expenditure, work or effort undertaken by bidders prior to the award of any Contract is accordingly a matter solely for the commercial judgement of bidders. Late tenders will not be considered by the Council and all questions are to be submitted via the Questions and Answers section of this contract advertisement on PCS. An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations may bring proceedings in the Sheriff Court or Court of Session.
 (SC Ref:678936)


description:
East Renfrewshire Council is inviting tenders, from suitably qualified and experienced contractor to undertake the installation of replacement heating systems in 3 no. sheltered housing complexes. The requirement will be to remove the existing heating system, provide a full replacement of the gas fired boilers, pipework, heat emitters and associated parts in the boiler room; this includes the whole heating system in the complex; common areas and individual flats.
 .

title: Renewal of Heating Systems to Fordyce Court

description: Replacement of heating systems in Fordyce Court Sheltered housing complex within East Renfrewshire.

description: Bidders must hold a Gas Safe Register inline with Under the Gas Safety (Installation and Use) Regulations 1998

minimum:
1 . Public Liability and Employers Liability 5m GBP
 Professional Indemnity/ Contractors all risk 2m GBP
 2. To establish the financial standing of a potential Tenderer, the Council will firstly take into account a risk report provided independently
 by Credit Safe. Tenders are asked to provide their company number so that the council can run this report.
 Within such reports, the risk of business failure is expressed as a score ranging from 1 -100.
 In the event that a company is determined to have a risk failure rating of below 30 i.e. that the company is considered to have a high risk of
 business failure, the submission will not be considered further.

description:
1. Insurances
 2. Credit Check
 The Council reserves the right at its own discretion to seek such other information from the Applicant in accordance with Regulation
 61(7) or Regulation 61(8) of the Public Contracts (Scotland) Regulations 2015 to determine the Applicant’s economic and financial
 standing.

minimum:
Bidder are required to provide 2 example of previous work in response to the following question “ Provide outline details of similar projects undertaken within the last five years.
 This should show experience with phasing a similar type of project; demonstrate experience where it was necessary to minimise any system/facility downtime and projects where you used a temporary boiler plant for both heating and domestic hot water services (contractor design element).
 The following information should be provided for each example project;
 -Brief description of works
 -Approximate Value
 -Completion date
 -Details of added benefit/value demonstrated
 -Names and contact information for someone able to provide reference
 Examples must be of a similar value and scope to that outlined in the tender documents

description: Previous Experience

East Renfrewshire Council

locality: Giffnock

postalCode: G46 6UG

streetAddress: Eastwood HQ, Eastwood Park,

description: General public services

legalName: East Renfrewshire Council

name: Paisley Sheriff Court and Justice of the Peace Court

postalCode: PA3 2HW

streetAddress: St James Street

description: General public services

City Technical Services (UK) LTD

postalCode: G32 8RF

streetAddress: Unit 1 Block 16 Clydesmill Place, Clydesmill Industrial Estate

legalName: City Technical Services (UK) LTD

description: (SC Ref:679888)


description: Additional 24 Months dependant of contractor performance

description: Collection of segregated waste to include, Bales of Cardboard, General Waste, Dry Mixed Recycling and Food Waste. Date to be provided monthly to include the capture of Carbon Emissions and Weights of material disposed of. Billing to be one month in arrears of service

description: National Museums Scotland, Chambers Street, Edinburgh, EH1 1JF an National Museums Collection Centre, 242 West Granton Road, Edinburgh EH5 1JA

title: Waste Collection

title: Waste Contract Specification

title: Waste Collection

description: Collection of Waste to include General, Dry Mixed recycled material presented in bags, Cardboard in bales, Food Waste from two location within the Edinburgh areas of EH1 and EH5

title: Tender Documents

title: NMS Standard terms and Conditions

title: Waste Collection

streetAddress: National Museums Scotland, 44 Chambers Street, Edinburgh, EH1 1JF

performanceTerms: As per Tender documents

National Museums Scotland

locality: Edinburgh

postalCode: EH1 1JF

streetAddress: Chambers Street

legalName: National Museums Scotland

description: Recreation, culture and religion

Chartered Institute of Surveyors

legalName: Chartered Institute of Surveyors

Hamilton Waste & Recycling Ltd

locality: Musselburgh

postalCode: EH21 8PZ

streetAddress: Smeaton Recycling Centre

legalName: Hamilton Waste & Recycling Ltd

title: Waste Collection

documentType: plannedProcurementNotice

awardID: NMS Waste Collection

description: (SC Ref:725929)


description:
High Life Highland, on behalf of the Highland Council, are seeking to appoint an experienced creative agency to develop and create interactive content inspired by stories of the Highlands and Islands gathered from local communities, to increase engagement with visitors, extend the tourist season and encourage sustainable and off the beaten track travel. These assets may include, but are not limited to, AR models in the landscape, audio recordings, visuals, ebooks, QR codes, travel blogs, games, incentives or animations.
 The audio and visual content created will be used to enhance the Spirit: Journeys interactive story map platform to encourage more geographically dispersed travel around the region and create authentic connections with local communities. This tender includes provision for the Contractor to create bespoke routes or trails using audio and visual content to guide visitors through the Highlands and Islands.

title: Provision of Spirit: Journeys Audio-Visual Assets

title: 1. Invitation to Tender

title: 1a. Tender Specification

title: 2. List of Key Staff

title: 3. Non Disclosure Items FOI

title: 4. Certificate of Bona Fide Tendering

title: 5. Form of Tender

title: 6. Conditions of Contract

title: 7. Schedule of Rates

streetAddress: Ardross Street, Inverness

description: Digital Project Officer; Business Support Officer

High Life Highland

locality: Inverness

postalCode: IV3 5NS

streetAddress: 12-13 Ardross Street

legalName: High Life Highland

Inverness Justice Centre

postalCode: IV1 1AH

streetAddress: Longman Road

legalName: Inverness Justice Centre

Smartify CIC

postalCode: N8 0QS

streetAddress: Frobisher Road 12

legalName: Smartify CIC

description: (SC Ref:680325)


description: NHSD may at its discretion extend the contract for a further 12 month interval

description: See enclosed Scope of Works and SPD for detail on procurement criteria

title: NHSDG Site Security Contractor February 2022 - February 2025

description: Dumfries & Galloway NHS Board (hereinafter for the purposes of this documentation shall be referred to as NHSDG) requires a provider to undertake Site Security services to NHSDG properties in the Nithsdale area of Dumfries

title: SoW- Site Security 2020

title: SPD v1.1 Site Security 2021

title: SPD Scoring guide V1

title: Site Security Qualifications Matrix

title: Appendix 5 Security Pricing Schedule

performanceTerms: The form of Contract will be the NEC3 Term Service Short Contract April 2013 Edition

description: See enclosed Scope of Works and SPD

Dumfries and Galloway Health Board

locality: Dumfries

postalCode: DG1 4AP

streetAddress: Mountainhall Treatment Centre, Bankend Road

description: Health

legalName: Dumfries and Galloway Health Board

Sheriff Court House

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court House

name: Royal Institution of Chartered Surveyors

postalCode: EH2 4AD

streetAddress: 3rd Floor 125, Princess Street

NHS Dumfries & Galloway

streetAddress: Mountainhall Treatment Centre

legalName: NHS Dumfries & Galloway

Dumfries and Galloway Health Board

description: Health

Vigilant Security (Scotland) Ltd

postalCode: DG1 4BZ

streetAddress: Security House, 23 Loganbarns Road

legalName: Vigilant Security (Scotland) Ltd

Sheriff Court House

postalCode: DG1 2AN

streetAddress: Buccleuch Street

description: (SC Ref:680646)


description: May be extended for a period of up to 3 years

description: The scope of this tender is to provide website design, development and maintenance services to the Net Zero Technology Centre, aiming to commence on or around December 2021 / January 2022, renewable on an annual basis subject to satisfactory performance for an anticipated maximum period of 3 years. We are seeking to appoint a website partner that will bring a fresh, forward-thinking approach to how we engage with our audiences on the web.

description: Aberdeen

title: Provision of website design, development and maintenance services for Net Zero Technology Centre

title: ITT Website Services

streetAddress: Aberdeen

Net Zero Technology Centre Limited

locality: Aberdeen

postalCode: AB15 4ZT

streetAddress: 20 Queens Road, Aberdeen

legalName: Net Zero Technology Centre Limited

Net Zero Technology Centre

streetAddress: 20 Queens Road

legalName: Net Zero Technology Centre

Hatched Ltd

locality: LDN

postalCode: EC1R 5AR

streetAddress: 79 Clerkenwell Rd

legalName: Hatched Ltd

description: (SC Ref:679789)


description: An experienced consultant is sought to undertake a study on exploring how to digitally bring heritage home to Orkney. Following the impact of Covid-19 it is critical that tourism and community links are rebuilt in new and sustainable ways which can help strengthen the local economy.

description: Orkney Islands

title: Provision of Consultancy Services for the Exploring Bringing Heritage Home Study

title: 001 - Bringing Heritage Home Study

streetAddress: Via Teams - PCS Postbox opening

description: Three Officers with delegated authority via Teams.

Orkney Islands Council

postalCode: KW15 1NY

description: General public services

description: Recreation, culture and religion

legalName: Orkney Islands Council

Sherrifs Court

postalCode: KW15 1PD

streetAddress: Watergate

legalName: Sherrifs Court

Orkney Islands Council

streetAddress: Council Offices, School Place

description: General public services

description: Recreation, culture and religion

Cameron Taylor Consulting

locality: South Ronaldsay

postalCode: KW17 2RH

streetAddress: Craigflower Cottage, Herston

legalName: Cameron Taylor Consulting

description:
Orkney Islands Council reserves the right to cancel the procurement at any stage and not award a Contract. The expenditure, work or effort undertaken by bidders prior to the award of any Contract is accordingly a matter solely for the commercial judgement of bidders.
 Late quotations will not be considered by the Council and all questions are to be submitted via the Questions and Answers section of this contract advertisement on PCS.
 An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or Court of Session.
 (SC Ref:680512)


description: Call off contract from Interim IT Staff Services ref SP-18-015 for the provision of a Business Analyst.

description: Scottish Parliament, Holyrood, Edinburgh

title: Award of Business Analyst Role

title: Award of Business Analyst Role

description: Award of call off contract from Interim IT Staff Services ref SP-18-015

Scottish Parliamentary Corporate Body

postalCode: EH99 1SP

streetAddress: The Scottish Parliament, Procurement Services

legalName: Scottish Parliamentary Corporate Body

Harvey Nash

postalCode: EH1 3EG

streetAddress: 2-4 Waterloo Place, Waverly Gate (LG2)

legalName: Harvey Nash

Edinburgh Sheriff Court

locality: 27 Chamber Street

legalName: Edinburgh Sheriff Court

description:
Award against framework: Interim IT Staff Services ref SP-18-015
 Call off contract from Interim IT Staff Services ref SP-18-015
 (SC Ref:669621)


title: Curtains, Blinds, Bedding, Decorative Accessories to include manufacture, supply, delivery, installation of the goods.

title: Towels, Bedding Accessories, Table Linen, Miscellaneous items (including Shower Curtains) and to include supply and delivery of goods

description:
The supply and delivery of Towels, Bedding Accessories, Table Linen, Miscellaneous items (including Shower Curtains) predominantly to
 council care homes and homelessness units. Some of these items are required to adhere to British Standards Flame Retardancy.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public
 Contracts (Scotland) Regulations 2015

description:
The manufacture, supply, delivery and installation of Curtains, Blinds, Bedding, Decorative Accessories. predominantly for council care
 homes and homelessness units. These items must also adhere to British Standards flame retardancy.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public
 Contracts (Scotland) Regulations 2015

description: Glasgow

description: Glasgow

title: Linens and Fabrics

title: Linens and Fabrics

description:
Glasgow City Council is seeking suppliers which can satisfy the Council’s requirements and would like to invite Tender bids for the
 Supply and Delivery of Linens and Fabrics.

reviewDetails:
Precise information on deadline(s) for review procedures:
 Glasgow City Council (“the Council”) must, by notice in writing as soon as possible after the decision has been made, inform all tenderers
 and candidates concerned of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing
 system. The Council must allow a period of at least the relevant standstill period (where the notice is sent by facsimile or electronic means
 the period is 10 days ending at midnight at the end of the 10th day after that on which the last notice is sent, when sent by other means the
 period is 15 days) to elapse between the date of despatch of the notice referred to in Regulation 85(1) of the Public Contracts (Scotland)
 Regulations 2015 (“the Regulations”). The Council is obliged to comply with the Regulations and any eligible economic operator can bring
 an action in the Sheriff Court or the Court of Session where as a consequence of a breach by the Council, suffers or risks suffering loss or
 damage. The bringing of court proceedings during the standstill period means that the Council must not enter into the contract, conclude
 the framework agreement or establish the dynamic purchasing system unless the proceedings are determined, discontinued or disposed of;
 or the court, by interim order, brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and
 the remedies that are available to the courts are detailed in the Regulations. Economic Operators can write to the Council seeking further
 clarification on the notice, to which the Council must respond within

Glasgow City Council

locality: Glasgow

postalCode: G2 1DU

streetAddress: City Chambers

description: General public services

legalName: Glasgow City Council

Muirgroup Interiors Ltd

postalCode: G78 1QB

streetAddress: 2 Muriel Street, , Barrhead

legalName: Muirgroup Interiors Ltd

GAILARDE LTD

locality: BOREHAMWOOD

postalCode: WD6 1RU

streetAddress: UNIT 2  ELSTREE DISTRIBUTION PARK , ELSTREE WAY

legalName: GAILARDE LTD

streetAddress: PO Box 23 1 Carlton Place

legalName: Glasgow Sheriff Court and Justice of the Peace Court

description:
Re SPD Questions 4D.1, 4D1.1, 4D1.2, 4D2, 4D2.1 and 4D2.2 bidders must hold the certificates for Quality Control, Health and Safety
 and Environmental Management Standards or comply with all the questions noted in SPD Section 4D. Please refer to the ‘SPD Statements’within the Invitation to Tender document.
 Health & Safety – applicants must complete and return the H&S questionnaire found in the Buyers Attachments area of the tender portal. Freedom of Information Act - Information on the FOI Act is contained in Appendix A of the ITT. Applicants must note the implications of this legislation and ensure that any information they wish the council to consider withholding is specifically indicated on the FOI Certificate contained in the Qualification Envelope within the PCS Tender portal (NB the council does not bind itself to withhold this information). Applicants will be required to complete the FOI certificate at ITT stage. Tenderers Amendments - Applicants must enter any clause, condition, amendment to specification or any other qualification they may wish to make conditional to this offer. Applicants will be required to complete the tenderers amendment certificate contained in the Qualification Envelope within the PCS tender portal (at ITT stage). Prompt Payment - The successful tenderer shall, as a condition of being awarded the tender, be required to demonstrate to the council's satisfaction that all funds due to the tenderer's permitted sub-contractors in respect of these works are paid timeously and that as a minimum invoices rendered by subcontractors shall (unless formally disputed by the tenderer) be paid within 30 days of receipt. The successful tenderer shall also impose this condition on its subcontractors in respect of payments due to any sub-sub-contractors, if any. Applicants will be required to complete the prompt payment certificate contained in the Qualification Envelope area within PCS Tender portal. Non – Collusion - Applicants will be required to complete the Non-Collusion certificate contained in the Qualification Envelope area
 within the tender portal. Insurance Mandate - All successful suppliers will be required to sign an Insurance Mandate, which will be issued in conjunction with the award letter authorising the Council to request copies of insurance documents from the supplier’s insurance provider. If the mandate is not signed and returned the Council reserves the right to request copies of insurance certificates from bidders at any point during the contract period. Terms and Conditions are located within the Buyers Attachments area of the tender portal. Request for Documentation: Once the Evaluation of Price and Quality has been completed, the recommended Bidder will be expected to provide all documentation as specified in the SPD. When the Request for Documentation is made, Bidders must supply the relevant
 information within 5 working days. Failure to provide this information within the specified time may result in your bid being rejected and
 the Council proceeding with the procurement exercise to the next appropriate bidder. Additional information pertaining to this contract notice is contained within the Invitation To Participate/Tender documents. Applicants must ensure they read in line with this contract notice. Mandatory-Supplier Proposals Community Benefits are required as non-evaluated and a value of 50 points.
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 18728. For more information see:
 http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 Community benefits are included in this requirement. For more information see:http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2361
 A summary of the expected community benefits has been provided as follows: Lot 1 and Lot 2 are Mandatory non-evaluated. Supplier Proposals apply at 50 points per lot from the community benefits menu.
 (SC Ref:669623)


name: Williamsburgh Housing Association Limited

description: May take up option of a twelve month extension upon conclusion of the four year initial period of the contract at an approximate additional cost of 57453GBP excluding VAT.

description:
Williamsburgh Housing Association intend to enter into a Measured Term Contract with a Single Contractor to undertake Gutter Cleaning, Roof Inspection Surveys and Roof Safety System testing services, as described within the Pricing Matrices incorporated within Tender Document A.
 Subject to satisfactory performance of the Contractor, which will be assessed through measurement of the Key Performance Indicator’s (Refer Tender Document H), it is intended that the Contract may be extended by a further twelve months upon completion of the four year initial period of the Contract.
 The Contract is intended to commence on 10th January 2022.. Economic Operators may be excluded from this competition if they are in any of the situations referred to in Regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 SPD (Scotland) v1.2 Question 2D.1.2- Bidders must provide a separate SPD response (Sections A and B of this Part and Part III) for each subcontractor.

description: Paisley, Renfrewshire, Johnstone, Kilbarchan and Elderslie, Renfrewshire

title: Four Year Contract for Gutter Cleaning, Roof Inspection Surveys and Roof Safety System Testing

description: The Contract will involve gutter cleaning, roof inspection surveys and roof safety system testing maintenance services throughout Paisley, Renfrew, Johnstone, Kilbarchan and Elderslie, Renfrewshire

title: Document A

title: Document B

title: Document C

title: Document D

title: Document E

title: Document F

title: Document G

title: Document H

title: Document I

title: Document J

title: Document K

description: 2025 at the earliest if the optional 12 month extension is not applied

performanceTerms:
The performance of the successful Bidder will be monitored through the Key Performance Indicators described within Tender Document H Key Performance Indicators attached to this Contract Notice.
 Where performance falls below the minimum acceptable level during the Contract, the successful Bidder will be required to produce a Remedial Plan for the approval of Williamsburgh Housing Association.
 Failure to produce a Remedial Plan or implement an approved Remedial Plan will be deemed to be a breach of the Contract, which may lead to the termination of the successful Bidder's Contract.

description: 4A.2 - Where it is required, within a bidder’s country of establishment they must confirm which authorisation or memberships of the relevant organisation(s) are required in order to perform this service. Bidders must confirm if they hold the particular authorisation or memberships.

description:
Question 4B.1.1 - Bidders will be required to have a minimum 'general' yearly turnover of 114905 GBP for the last two years.
 Question 4B.1.2 - Bidders will be required to have an average yearly turnover of a minimum of 114905 GBP for the last two years.
 Question 4B.3 - Where turnover information is not available for the time period requested, the bidder will be required to state the date which they were set up or started trading.
 Questions 4B.5.1 and 4B.5.2 - It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurances indicated below:
 Employer's (Compulsory) Liability Insurance - 5,000,000 GBP Public Liability Insurance - 5,000,000 GBP

description:
4C.8.1 - Bidders will be required to confirm their average annual manpower for the last three years.
 4C.8.2 - Bidders will be required to confirm their and the number of managerial staff for the last three years.
 4C.9 - Bidders will be required to demonstrate that they have (or have access to) the relevant tools, plant or technical equipment to deliver the types of requirements detailed in II.2.4 in the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 4C.10 - Bidders will be required to confirm whether they intend to subcontract and, if so, for what proportion of the contract.
 SPD (Scotland), Part C Technical and Professional Ability - Bidders responses to Part C of the SPD (Scotland) will be limited to a maximum of fifteen A4 single sided pages, excluding any certification that a Bidder submits in support of their response, which must be completed in English using Arial 11 font

locality: Paisley

postalCode: PA1 1RW

streetAddress: Ralston House, Cyril Street

description: Housing and community amenities

A.D.A Construction Consultants

postalCode: PA3 3BB

streetAddress: Pavilion 3, St James Business Park, Linwood Road

legalName: Paisley Sheriff Court and Justice of the Peace Court

description: Housing and community amenities

Paterson Safety Anchors Ltd

locality: Barrhead

streetAddress: Anchor House, 18 Muriel Street

legalName: Paterson Safety Anchors Ltd

description: (SC Ref:689378)


description: Direct Award via the YPO 799 Vehicle Hire, Lease and Purchase Portal Lot 2.

title: Hire of Electric Utility Vehicles and Trailers

description:
This contract is for the hire of electric utility vehicles and trailers and associated maintenance. The vehicles are required at the following sporting venues throughout the Glasgow Life estate; Knightswood Golf Centre, Scotstoun Stadium, Greenfield Football Centre, Toryglen Football Centre, and Glasgow Green Football Centre.
 The electric utility vehicles are required within the sporting centres for the building of external goals and also the movement of goods within the venue perimeters.

Glasgow Life (Culture & Sport Glasgow)

postalCode: G1 1LH

streetAddress: 38 Albion Street

description: General public services

legalName: Glasgow Life (Culture & Sport Glasgow)

GMP DRIVERCARE LTD

locality: STAFFORD

streetAddress: Jupiter House, Drummond Road, Astonfields

legalName: GMP DRIVERCARE LTD

name: Glasgow Sheriff Court and Justice of Peace Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

description:
Award against framework: YPO Vehicle Hire, Lease and Purchase Portal - 799
 (SC Ref:669675)


description: The works comprise the replacement of the heat emitter units in the 14nr sheltered cottages that are adjacent to the main sheltered block at Margaret Clyne Court. The works also include the replacement of the filtration unit in the boiler house. The dwellings will remain occupied during the works period.

description: Aberdeen City

title: Margaret Clyne Court - Replacement Heat Emitters

description: The works comprise the replacement of the heat emitters in the 14nr sheltered cottages within the grounds of the sheltered housing block at Margaret Clyne Court, and the replacement of the filtration unit in the boiler house.

title: H1373 Invitation to Tender document - ITT

title: ITT - Appendix 1.1 - Bill of Quantities

title: ITT - Appendix 1.2 - Bill No 3 - Measured Works (Heat Emitter Installations)

title: ITT - Appendix 1.3 - Bill No 4 - Measured Works (Filtration Vessel Installation)

title: ITT - Appendix 2  - Form of Tender

title: ITT - Appendix 3 - Award Questionnaire

title: ITT - Appendix 4 - Selection Criteria

title: ITT - Appendix 5 - Pre-construction Information

title: H1373 - Drawings

title: H1373 - Manufacturers Info & Product Sheets

Aberdeen City Council

postalCode: AB16 5GB

streetAddress: Woodhill House, Westburn Road

description: General public services

legalName: Aberdeen City Council

Aberdeen Sherrif Court

postalCode: AB10 1WP

streetAddress: Castle Street

legalName: Aberdeen Sherrif Court

Aberdeen City Council

postalCode: AB10 1AB

streetAddress: Business Hub 10, Second Floor South, Marischal College, Broad Street

description: General public services

Hutcheon Services Ltd

postalCode: AB12 3LW

streetAddress: Bourtree House, Minto Drive

legalName: Hutcheon Services Ltd

description: (SC Ref:679670)


description: Call Off Framework Contractor

description: Ayr

title: Residential Development (31Nr Units) at Carrick Street, Ayr

description: 31 new build home construction and related services.

Ayrshire Housing

locality: Ayr

postalCode: KA8 8BX

streetAddress: 119 Main Street

description: Housing and community amenities

legalName: Ayrshire Housing

JR Construction (Scotland) Ltd

postalCode: PA3 4HP

streetAddress: Cardea House, 5 Sandyford Road

legalName: JR Construction (Scotland) Ltd

name: Ayr Sheriff Court and Justice of the Peace Court

streetAddress: Sheriff Court House, Wellington Square, Ayr

description: (SC Ref:669768)


description: 26.1.1.	The Faculty of Construction have approximately 600 registered apprentices on the SVQ 3 Construction Crafts Qualification. The students on the 1st and 2nd year of their programmes require to begin the process of accumulating Work Based Evidence into a portfolio. Students on their 3rd year and 4th year need to add evidence from Direct Observation in the workplace to that portfolio until such time as the Assessor deems it sufficiently complete. A completed portfolio of work-based evidence has to be completed before any candidate can be put forward for their Skills Test. As the ability of candidates and their site experience vary so too will the number of site visits. Therefore, what is sought is not the number of site visits but a completed portfolio.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015

description: East Kilbride

title: On Site Assessment Services for SVQ Construction Courses

description: South Lanarkshire College is seeking a Contractor(s) for the Provision of On-Site Assessment Services for Construction Courses which are provided under the Faculty of Construction.

streetAddress: East Kilbride

description: 4 years after contract end date

performanceTerms: As per Invitation to Tender

description:
Question 4B.5.1a and 4B.5.2
 The appointed Contractor must have the following in place prior to the commencement of the Contract:
 Employer's (Compulsory) Liability Insurance (legal requirement) = 5m GBP
 Public Liability Insurance = 5m GBP
 Question 4B.6
 Where requested, Tenderers must make available a copy of their audited accounts for the most recent two years, along with details of any significant changes since the previous year end, prior to commencement of the Contract. Where unavailable, the College may make further request for other, suitable documentation.
 Pass: A copy of the accounts or other suitable documentation has been made available prior to commencement of the Contract and the College is satisfied with the financial standing of the Contractor proportionate to the value of Contract.
 Fail: A copy of the accounts or other suitable documentation has not been made available prior to commencement of the Contract or the College is dissatisfied with the financial standing of the Contractor proportionate to the value of Contract.

minimum:
Question 4B.5.1a and 4B.5.2
 The appointed Contractor must have the following in place prior to the commencement of the Contract:
 Employer's (Compulsory) Liability Insurance (legal requirement) = GBP 5m
 Public Liability Insurance = GBP 5m
 Professional Indemnity Insurance = GBP 1m
 Question 4B.6
 Where requested, Tenderers must make available a copy of their audited accounts for the most recent two years, along with details of any significant changes since the previous year end, prior to commencement of the Contract. Where unavailable, the College may make further request for other, suitable documentation.
 Pass: A copy of the accounts or other suitable documentation has been made available prior to commencement of the Contract and the College is satisfied with the financial standing of the Contractor proportionate to the value of Contract.
 Fail: A copy of the accounts or other suitable documentation has not been made available prior to commencement of the Contract or the College is dissatisfied with the financial standing of the Contractor proportionate to the value of Contract.

minimum:
Question 4C6.1
 Technical and Professional Ability
 The following educational and professional qualifications are held by Its managerial staff: The staff conducting the contract must hold or be working towards appropriate Assessor/Verification qualifications as required by the Awarding Body.
 Pass: The bidder has confirmed that staff conducting the Contract must hold or be working towards appropriate Assessor/Verification qualifications as required by the Awarding Body.
 Fail: The bidder has not confirmed that staff conducting the Contract hold or are working towards appropriate Assessor/Verification qualifications as required by the Awarding Body.

South Lanarkshire College

postalCode: G75 0NE

streetAddress: College Way, Scottish Enterprise Technology Park,, East Kilbride

description: Education

legalName: South Lanarkshire College

Hamilton Sheriff Court

locality: Hamilton

postalCode: ML3 0BT

streetAddress: 4 Beckford Street

legalName: Hamilton Sheriff Court

South Lanarkshire College

description: Education

Competence Matters Ltd

locality: Cumbernauld

postalCode: G68 9HN

streetAddress: 56 Deerdykes View, Westfield Park

legalName: Competence Matters Ltd

description: (SC Ref:680648)


description:
The services can be provided only by a particular economic operator for the following reason: No other facility suitable
 Explanation:
 Under Regulation Reg 6(1)(b)(ii) of the Procurement (Scotland) Regulations 2016, a contracting authority may award a contract without competition based on the following justification:
 Competition is absent for technical reasons (only if it is not caused by artificial narrowing down of the parameters of the procurement and no reasonable alternative or substitute exists).
 - i.e. No other venue can meet requirements.

title: Award of Contract for Graduation Venue - University of Aberdeen

University of Aberdeen

postalCode: AB24 3FX

streetAddress: University Office, King's College

description: Education

legalName: University of Aberdeen

P&J Live

postalCode: AB23 8BL

streetAddress: The Event Complex Aberdeen, East Burn Road, Stoneywood

legalName: P&J Live

Aberdeen Sheriff Court

legalName: Aberdeen Sheriff Court

description: (SC Ref:669871)


description: The council reserves the right to source non-core and additional items from the awarded Supplier.

description: Supply, repair and ,maintenance of plumbed in water coolers.

description: Glasgow

title: Water Coolers & Repair & Maintenance : Plumbed In

description: Call off for the supply, repair and maintenance of plumbed in water coolers.

reviewDetails:
Glasgow City council ("the council") must, by notice in writing as soon as possible after the decision has been made, inform all tenderers and candidates concerned of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing system. The Council must allow a period of at least the relevant standstill period (where the notice is sent by facsimile or electronic means the period is 10 days ending at midnight at the end of the 10th day after that on which the last notice is sent. When sent by other means the period is 15 days) to elapse between the date of despatch of the notice referred to in Regulation 85(1) of the Public Contracts (Scotland) Regulations 2015 ("The Regulations"). The Council is obliged to comply with the regulations and any eligible economic operator can bring an action in the Sherriff Court of the Court of Session where a consequence of a breach by the Council, suffers or risks suffering loss or damage.The bringing of court proceedings during the standstill period means that the council must not enter into the contract, conclude the framework agreement or establish the dynamic purchasing system unless the proceedings are determined, discontinued or disposed of: or
 the court, by interim order, brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and the remedies that are available to the courts are detailed in the Regulations. Economic operators can write to the Council seeking further clarification on the notice, to which the Council must respond within 15 days. Economic Operators should be mindful to seek their own independent legal advice when they consider appropriate to do so.

Glasgow City Council

postalCode: G2 1DU

streetAddress: Chief Executives Department, City Chambers

description: General public services

legalName: Glasgow City Council

Waterlogic GB Limited

locality: Wolverhampton

postalCode: WV10 9LE

streetAddress: Shaw House

legalName: Waterlogic GB Limited

postalCode: G5 9DA

streetAddress: Sheriff Clerk’s Office, PO Box 23, 1 Carlton Place,

description:
Award against framework: 13-17 Supply, Delivery, Installation and Maintenance of Water Coolers and Associated Consumables
 (SC Ref:669876)


description: Forres Duckpond Bridges replacement

description: Moray

title: Forres Duckpond Bridges

title: Forres Duckpond Bridges

description: Forres Duckpond Bridges

description: Forres Duckpond Bridges

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

description: General public services

legalName: Moray Council

Geo-Structural Ltd

locality: Caldercruix

postalCode: ML6 7RP

streetAddress: Drumbreck Farm , Eastfield Road

legalName: Geo-Structural Ltd

Elgin Sherriff Court

postalCode: IV30 1BU

streetAddress: Sheriff Courthouse, High Street

legalName: Elgin Sherriff Court

description:
Award against framework: 18/0326 Civil Engineering Small Works Framework
 (SC Ref:669897)


description: Single Stage Open Tender. Contract Conditions: NEC3 Engineering and Construction Short Contract

description: Oak Grove, Livingston

title: Oak Grove, Environmental Improvements

title: Oak Grove, Environmental Improvements

description: Hard and Soft landscaping works to be carried out at Oak Grove, Livingston within a residential housing area.

title: 50325_600

title: 50325_601

title: 50325_602

title: 50325_603

title: 50325_604

title: 50325_701

title: 50325_702

title: 50325_703

title: 50325_704

title: 50325_705

title: 50325 Pre Construction Information (PCI) v1

title: 50325 Price List v1

title: 50325 Tender Document v1

title: 50325 Tenderer's Acceptance v1

title: 50325 Tenderer's Financial Submission v1

title: 50325 Tenderer's Quality Submission v1

title: Community Benefit Outcome Matrix - Oak Grove

title: WI Section 2.0 - Drawing Issue Register

title: WI Section 3.0 - Specification

title: 001 - Topographic Survey

title: 002 - Existing Services

title: Oak Grove, Environmental Improvements

Almond Housing Association

locality: Livingston

postalCode: EH54 5AB

streetAddress: 44 Etive Walk, Craigshill,

description: Housing and community amenities

legalName: Almond Housing Association

Edinburgh Sheriff Court

locality: Edinburgh

streetAddress: 27 Chambers Street  Edinburgh  EH1 1LB  UK

legalName: Edinburgh Sheriff Court

Almond Housing Association

streetAddress: 44 Etive Walk

description: Housing and community amenities

Caley Construction Ltd

postalCode: G31 1NZ

streetAddress: 136 Glenpark Street

legalName: Caley Construction Ltd

description: (SC Ref:679852)


description: This procurement is concerned with the recruitment of two web content officers to support with the implementation of the new corporate website.

description: Stirling

title: Web Content Designers

title: Web Content Designers

Stirling Council

locality: Stirling

postalCode: FK8 2ET

streetAddress: Strategic Commissioning, Old Viewforth

description: General public services

legalName: Stirling Council

Badenoch and Clark

postalCode: G2 4BG

streetAddress: 20 Blythswood Square

legalName: Badenoch and Clark

Stirling Sheriff Court

postalCode: FK8 1NQ

streetAddress: Viewfield Place

legalName: Stirling Sheriff Court

description:
Award against framework: Strategic HR Services 3S18
 (SC Ref:669939)


description: There is a requirement to procure additional laptops for IT and to establish reserves for the instances where devices become unusable due to failure and for those working from home due to the pandemic.

description: Stirling

title: Purchase of 200 Laptops

title: Purchase of 200 Laptops

description: There is a requirement to procure additional laptops for IT and to establish reserves for the instances where devices become unusable due to failure.

Stirling Council

description: General public services

Dell

locality: Bracknell

postalCode: rg12 1lf

streetAddress: DEll House , The Boulevard

legalName: Dell

description:
Award against framework: Digital Workplace: Hardware (Link 3)
 (SC Ref:669954)


name: The Scottish Sports Council trading as sportscotland

title: Frozen Food Ref 1016

title: Groceries and Provisions Ref 1219

title: Frozen Food Ref 1016

description: sportscotland required the provision of frozen food for its National Training Centre Glenmore Lodge

title: Groceries and Provisions Ref 1219

description: sportscotland required provision of groceries and provisions at its National Training Centre Glenmore Lodge

title: Scotland Excel Provision of Frozen Food and Groceries and Provisions sportscotland National Centre Glenmore Lodge

description: sportscotland required provision of frozen food and groceries and provisions at its National Training Centre Glenmore Lodge

postalCode: G40 1DA

streetAddress: Doges, Templeton on the Green, 62 Templeton Street

description: Recreation, culture and religion

Brake Bros Ltd

locality: Ashford

postalCode: TN25 4AG

streetAddress: Enterprise House, Eureka Business Park

legalName: Brake Bros Ltd

Glasgow Sheriff Court

legalName: Glasgow Sheriff Court

title: Frozen Food Ref 1016

title: Groceries and Provisions Ref 1219

description:
Award against framework: Scotland Excel Frozen Food and Groceries and Provisions
 (SC Ref:669962)


description:
South Lanarkshire Council have identified a requirement to appoint a contractor to supply and deliver electrical materials for CEEF 21/22 LED Lighting upgrades at various properties in South Lanarkshire.
 Mini Competition from SXL Electrical Materials Framework

title: CEEF 21/22 LED Lighting upgrades - Mini Comp from SXL Electrical Materials FW

South Lanarkshire Council

postalCode: ML3 0AA

streetAddress: Council Headquarters, Almada Street

description: General public services

description: Housing and community amenities

legalName: South Lanarkshire Council

Holland House Electrical Co Ltd

streetAddress: 120 Scotland Street

legalName: Holland House Electrical Co Ltd

Hamilton Sheriff Court

postalCode: ML3 0BA

streetAddress: Beckford Street

legalName: Hamilton Sheriff Court

description: (SC Ref:670000)


description: The University of Stirling is seeking tenders to supply an eddy covariance flux tower to measure landscape-scale carbon (CO2 and CH4) and water (H2O) fluxes at a peatland restoration site in the Forth Valley, Scotland. The system will form part of Forth-ERA, a multimillion-pound flagship investment in a new digital environment observatory being developed in the Firth of Forth catchment. Forth-ERA will be the first observatory of its type in the UK, providing real-time data from sensors, satellites, and models to transform how we monitor and manage our environment. The University are working in partnership with numerous national and regional stakeholders to co-develop the observatory to maximize opportunities to use the platform to support the operational needs of public, private and charitable organizations while also providing a testbed for technological innovation.

variantPolicy: allowed

description: Forth Valley

title: Eddy Covariance System

title: Eddy Covariance System

title: 8455 main ITT

title: 8455 - App 1

title: 8455 - App 2

title: 8455 - App 3

title: 8455 - App 4

title: 8455 - App 3A

title: 8455 - App 5

title: Eddy Covariance System

University of Stirling

postalCode: FK9 4LA

streetAddress: Procurement Services, Finance Office, Room 3Z6, Cottrell Building

description: Education

legalName: University of Stirling

name: Stirling Sheriff Court and Justice of the Peace Court

postalCode: FK8 1NH

streetAddress: Sheriff Court House, Viewfield Place

description: Education

LI-COR Environmental - UK Ltd

locality: CAMBRIDGE

postalCode: CB4 0WS

streetAddress: St. John's Innovation Centre , Cowley Road

legalName: LI-COR Environmental - UK Ltd

description: (SC Ref:678635)


description:
The award of this contract is under the Negotiated Tendering Procedure under Regulation 33(1) of The Public Contracts (Scotland) Regulations 2015. The recommended Contractor holds exclusive rights to the software and owns the equipment currently embedded within Roads and Transportation Services. A change in provider would result in significant additional cost and/or operational risk to the Council.
 The contract period has been determined and agreed as being	01 October 2021 – 30 September 2026 with the option to extend for a further period of up to 60 months.
 The contract between the Council and the contractor will consist of the Council’s Standard Terms and Conditions of Contract/ the NEC3 Term Service form of contract – Option A.

description:
South Lanarkshire Council has a requirement for a suitably qualified provider for Traffic Signal Equipment Works and Ancillary Support Services. The Contractor will provide the maintenance and repair to all traffic signal equipment and associated equipment within the boundary of South Lanarkshire Council. This will include the maintenance and upgrade of all new traffic signal and integrated traffic systems.
 The contract between the Council and the contractor will consist of the Council’s Standard Terms and Conditions of Contract/ the NEC3 Term Service form of contract – Option A.
 the contract period has been determined and agreed as being	01 October 2021 – 30 September 2026 with the option to extend for a further period of up to 60 months.

reviewDetails:
Precise information on deadline(s) for review procedures:
 Court of Session
 Parliament House
 Parliament Square
 Edinburgh
 EH1 1RQ
 +44 1312252595
 supreme.courts@scotcourts.gov.uk

South Lanarkshire Council

description: General public services

Siemens Mobility

locality: Ashby de la Zouch

postalCode: LE65 1JD

streetAddress: Ashby Park, Ashby de la Zouch

legalName: Siemens Mobility

Hamilton Sheriff Court

postalCode: ML3 0BT

streetAddress: Sheriff Court House, 4 Beckford Court

description: (SC Ref:670019)