description:
Construction of a steel framed structure to support enclosures to form a new vertical farm tower and associated mezzanine floor. The vertical farming complex consists of a single tower, with associated airlock, staging corridors at ground and mezzanine floor levels.
 Full details are provided in the attached tender documents.
 As a minimum, the main contractor must:
 Be listed in an appropriate, relevant trade register;
 Hold independent third party certification under BS EN ISO 45001 (or equivalent);
 Hold independent third party certification under BS EN ISO 14001 (or equivalent) or a valid EMAS (or equivalent certificate);
 The Main Contractor must disclose:
 their (“general”) yearly turnover for the previous three financial years. The minimum acceptable turnover is GBP 2 million per annum;
 that their insurance cover meets the following levels:
 The minimum amount of cover for insurance against death and of or bodily injury to employees of the Contractor arising out of and in the course of their employment in connection with the contract for any one event is GBP 10 million;
 The insurance against loss of or damage to the works, Plant and Materials is to include cover for Plant and Materials provided by the Client for an amount of GBP 5 million;
 The minimum amount of cover for insurance against loss of or damage to property (except the works, Plant and Materials and Equipment) and liability for bodily injury to or death of a person (not an employee of the Contractor) arising from or in connection with the Contractor Providing the Works for any one event is GBP 10 million.

description: SRUC, West Mains Road, Edinburgh, EH9 3JG

title: Construction of a Vertical Farm Facility

description:
Construction of a steel framed structure to support enclosures to form a new vertical farm tower and associated mezzanine floor.
 The vertical farming complex consists of a single tower, with associated airlock, staging corridors at ground and mezzanine floor levels.
 The structure will be constructed within an existing industrial building at the SRUC Peter Wilson building, Kings Buildings Edinburgh EH9 3JG and shall utilise the existing ground bearing slab.

title: Section 1

title: Section 2 & 3

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 4

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 5

title: Section 6

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: Section 7

title: File 1 of 5

title: File 2 of 5

title: File 3 of 5

title: File 4 of 5

title: File 5 of 5

description: Please see attached tender documents.

SRUC

streetAddress: Peter Wilson Building , Kings Buildings West Mains Road

id: Higher Education, Research, and Consultancy

description: (SC Ref:741600)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

title: Local Bus Services and Minimum Subsidy Combined Local Bus/School Transport Services

title: Additional Support Needs School Transport Services

description: A mini competition was carried out under Lot 2 of the Aberdeenshire Council Dynamic Purchasing System (DPS) 2023- 2028 for Minimum subsidy Combined Local Bus/School Transport Services for contract NL7

description: There is no Limit

title: Demand Responsive Transport Services

description: Registered local bus services operated on a demand responsive basis with no fixed route or timetable but instead operating within a pre-defined operating area and between fixed start and end times. Services are usually specified to be operated by taxi or minibus and each service will either operate door-to-door or between bus stops. Passenger journeys are all pre-booked through the Council.

description: There is no Limit

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council's Dynamic Purchasing System 2023-2028 for the Passenger Transport Unit. These contracts were tendered to replace short term contracts that were tendered between October - December 2024. Full details of this award can be found under the council's contract register under contact reference number CRN00038231 and CRN00038445.

title: Adult Social Care Transport Services

description: A mini competition was carried out under Lot 5 of the Aberdeenshire Council's DPS for the PTU for the provision of Adult Social Care transport services to replace 12 short term transport contracts.

title: Dedicated School Transport, Minimum Cost Combined Local Bus/School Transport and Other Scheduled Education Transport Services

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council DPS 2023-2028 and 1 contract was awarded for Banchory Academy.

description: There is no Limit to candidates invited

title: Dynamic Purchasing System For Passenger Transport Services 2023

description: Aberdeenshire Council have created a Dynamic Purchasing System (DPS) for the procurement of Passenger Transport Services which shall is expire in May 2028

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028, for the provision of ASN home to school transport services

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028, for the provision of Mainstream home to school transport services.

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023 - 2028 for the provision of Dedicated School Transport services.

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council Dynamic Purchasing System 2023 - 2028, for the provision of ASN home to school transport services.

description: A mini competition was a carried out under Lot 4 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision of ASN school transport services

description: A mini compettition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System (DPS) 2023-2028, for the provision of mainstream home to school transport services

description: A mini competition was carried out for Lot 2 of the Aberdeenshire Council Dynamic Purchasing System (DPS) 2023-2028 for various local Bus services & minimum subsidy combined Local Bus/School Transport Services.

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Councils DPS for the PTU for the provision of ASN school transport

description: A mini competition was carried out under Lot 4 of the Aberdeenshire council DPS for the provision of home to school transport for ASN pupils.

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision of ASN school transport.

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council's Dynamic Purchasing System for the provision of ASN School Transport Services.

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision or mainstream home to school transport services. (209 Contracts South Aberdeenshire)

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision of mainstream home to school transport services. (7 North Aberdeenshire Contracts and 26 South Aberdeenshire Contracts)

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision of mainstream school transport services (5 South Aberdeenshire contracts).

description: A mini competition was carried out under Lot 4 of the Aberdeenshire Council DPS 23-28 for the provision of ASN home to school transport.

description: A mini competition was carried out under Lot 4 of the current Aberdeenshire Council DPS for the provision of ASN home to school transport services.

description: A tender was issued for the provision of ASN School transport for contract SA606B25 at Alford Primary

description: A mini competition was carried out under Lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 for the provision of Mainstream school transport services

description: A mini competition was carried out under lot 1 of the Aberdeenshire Council Dynamic Purchasing System 2023-2028 , for the provision of Mainstream home to school transport services.

description: A mini competition was carried out under Lot 2 of the Aberdeenshire Council Dynamic Purchasing System (DPS) 2023- 2028 for Minimum subsidy Combined Local Bus/Scholl Transport Services

performanceTerms: Aberdeenshire Council will measure and review performance for each Contract awarded under the DPS through their Contract Performance Management System (CPMS). This system takes account of Liquidated and Ascertained Damages relating to the operation of Services. Please refer to the Contract documents for more information.

description:
Confirmation that drivers will hold an appropriate valid driver’s licence when undertaking any contracts awarded under the DPS.
 Confirmation that vehicles will be insured and taxed as legally required when undertaking any contracts awarded under the DPS.

minimum:
Employers Liability as required by law for each and every claim
 Confirmation that Public Liability Insurance of not less than GDP5m for each and every claim shall be held when undertaking any Contracts awarded under the DPS.
 Result of Credit Report: If the Credit Report of any tenderer contains a risk rating between Very High Risk – Moderate Risk, tenderers will be given an opportunity to provide additional information which will be taken into account during the Council’s assessment. Where it is considered that the additional supporting information does not provide evidence to the satisfaction of the Council that risk is mitigated, the supplier may be awarded a mark of fail and subsequently disqualified.

description:
Employers Liability as required by law for each and every claim
 Confirmation that Public Liability Insurance of not less than GDP5m for each and every claim shall be held when undertaking any Contracts awarded under the DPS.
 The Council may use an independent credit scoring organisation such as CreditSafe, to conduct appropriate financial probity checks.

description: Confirmation that suppliers have experience of operating passenger transport services.

Aberdeenshire Council

description: General public services

description: General public services

A&I Coaches Ltd

streetAddress: Unit 19 Spurryhillock Industrial Estate, Broomhill Road

Classy Taxis Ltd

streetAddress: Unit 3 Fairneyhill Business Park, Anderson Road, Fraserburgh

A&I Coaches Ltd

streetAddress: Unit 19/20 Spurryhillock Industrial Estate, Broomhill Road

DAb plus CIC

streetAddress: Units 7 & 8 Community Services Centre, Market Street

Aberdeen Sheriff Court

streetAddress: Derek Smith House,, Hareness Road,Altens,

Aberdeenshire Council

description: General public services

description: General public services

cadgers taxis

streetAddress: 3 scott terrace belhelvie, aberdeenshire

Aberdeenshire Council

description: General public services

description: General public services

CoSLA

description: General public services

Aberdeenshire Council

description: General public services

description: General public services

description: General public services

description: General public services

description: General public services

description: General public services

description: General public services

description: General public services

description:
Award notice for mini competition carried out under Lot 2 for Minimum Subsidy Combined Local Bus/School Transport Services of the Aberdeenshire Council Dynamic Purchasing System (DPS) 2023 - 2028 via PCS-T. Full details of the award, including contract numbers and values can be found on the Aberdeenshire Council's contract register under the following reference numbers:
 Aberdeenshire DPS- Lot 2 Full tender CRN00040535
 (SC Ref:804029)


rel: canonical

status: complete

description:
CPI's ambition is that MMIC acts as a Digital Lighthouse for the pharmaceutical industry, demonstrating a compliant connected ‘Factory of the Future’ through integration of data. Digital innovation sits at the core of our operation and will inform our operational strategy and deployment as we create and de-risk novel technologies for our partners.
 This will be achieved through:
 - The creation of a compliant digital factory of the future for manufacturing and supply operations.
 - The development and implementation of novel digital solutions for advanced manufacturing.
 This procurement will aid as part of the strategy to meet these ambitions. specifically, by delivering a compliant Digital Laboratory which will integrate the analytical demands of the building’s portfolio with quality systems and digital release tools, creating means of seamless data transfer.
 This tender has been split into 4 different scopes of work:
 Scope 1 - The Supply of High-end Analytical Equipment
 Scope 2 - Laboratory Information Management System (LIMS)
 Scope 3 - Integration of Analytical Equipment with LIMS
 Scope 4 - Integration of Laboratory to Facility
 The full, initial envisaged scope of work can be found in the User Requirement Brief (URB) included in the tender pack. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx to access this information.

name: Ability to deliver a technical package of work that delivers a Digital Laboratory Solution for CPI’s MMIC

type: quality

type: price

variantPolicy: allowed

region: UK

scheme: CPV

title: 2876 - MMIC Digital Laboratory

currency: GBP

title: 2876 - MMIC Digital Laboratory

format: text/html

documentType: contractNotice

title: 2876 - Tender Pack

format: application/x-zip-compressed

title: A full list of equipment requiring integration along with their priorities

title: 2876 - MMIC Digital Laboratory

documentType: awardNotice

scheme: CELEX

procurementMethod: selective

mainProcurementCategory: goods

procurementMethodDetails: Competitive procedure with negotiation

Centre for Process Innovation Limited

roles: buyer centralPurchasingBody

locality: Redcar

postalCode: TS10 4RF

streetAddress: Wilton Centre

scheme: COFOG

legalName: Centre for Process Innovation Limited

name: Glasgow Sheriff & Justice of the Peace Court

locality: Glasgow

postalCode: G5 9DA

streetAddress: Sheriff Clerk's Office, 1 Carlton Place

Thermo Fisher Scientific

locality: Loughborough

postalCode: LE11 5RG

streetAddress: Bishop Meadow Road

scale: large

legalName: Thermo Fisher Scientific

status: active

description: (SC Ref:743542)

initiationType: tender

scheme: EU-OJ


description:
1.2	The University of Edinburgh is going out to tender for Coach Hire Services. While the University of Edinburgh will lead this tender process Participating Institutions include the Scotland’s Rural College (SRUC), Edinburgh College, Queen Margaret University, Edinburgh Napier University, and Heriot Watt University. The purpose of this competitive tender is to engage suitably qualified and experienced Contractor’s to provide Coach Hire Services using best practice, overall value for money, and Social Responsibility and Sustainability principles. The successful Contractor’s must be willing to play an active and effective role as a partner in understanding the needs and requirements of a large and complex organisation and will be expected to support the University through the delivery of a comprehensive and thorough range of services.
 The Contractor must provide a prompt and reliable Coach Hire Service that maintains the highest level of quality 52 weeks per year. The service must be responsive to the needs of all University of Edinburgh users and offer flexibility to adapt to emerging needs. The service provision must consistently meet the required collection, departure and arrival at destination times agreed by the customer when placing an order. Sufficient staff capability should be made available to allow a booking to be made at any time during office hours. Any alteration in the agreed booking schedule is to be advised to the University and Participating Institutions immediately it becomes known by the appropriate member of the contractor’s staff.
 More information can be found in Schedule 3 of the ITT.

variantPolicy: notAllowed

title: University of Edinburgh - Coach Hire Services

documentType: technicalSelectionCriteria

title: ITT - Coach Hire

title: Pricing schedule

title: UoE Terms and Conditions

format: application/pdf

title: Schedule 5 Ts & Cs

title: Schedule 6 Form of Tender

title: Schedule 7 FOI

title: Schedule 8 SCCoC

title: Supplier Response Template

title: Open day Coach Timetable Example

title: Quarterly MI Report

title: Carbon Reporting MI

description: Tendering will take place in 2027.

electronicInvoicingPolicy: allowed

procurementMethod: open

type: economic

minimum:
4B.4 Bidders will be required to state the value(s) for the following financial ratio(s): Current Ratio. The acceptable range for each financial ratio is: 1:1 The ratio will be calculated as follows: Current Ratio = Current Assets / Current Liabilities.
 4B.5.1a - 4B.5.3 It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below: Employer’s (Compulsory) Liability Insurance = 5m GBP - Public Liability Insurance = 2m GBP. Please attach proof of Insurance such as a ‘To whom it may concern’ letter.

description:
4B.3 In case the information concerning turnover (general or specific) is not available for the entire period required, please state the date on which the bidder was set up or started trading: Where turnover information is not available for the time period requested, the bidder will be required to state the date which they were set up or started trading.
 Bidders must submit their 2 most recent sets of audited accounts including (i) balance sheets and (ii) profit and loss information - or equivalent according to circumstances.
 The University of Edinburgh will use Dun and Bradstreet’s DBAi financial reporting system to assess the financial stability of tenderers along with financial accounts. The University will then conduct an analysis of the accounts to ensure that there is no significant financial risk.

mainProcurementCategory: services

procurementMethodDetails: Open procedure

University of Edinburgh

locality: Edinburgh

description: Education

legalName: University of Edinburgh

Edinburgh Sheriff Court

postalCode: EH1 1LB

streetAddress: Sheriff Court House, 27 Chambers Street

legalName: Edinburgh Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730584.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:730584)
 Download the copy of the online SPD document here (to be completed online through postbox submission): https://www.publiccontractsscotland.gov.uk/ESPD/ESPD_Download.aspx?id=730584


description: There is an option, subject to satisfactory performance on Harlsdale, Whalsay to undertake the refurbishment of 11 No. properties at Kalliness, Weisdale as a secondary, separate contract.

description: The procurement is a regulated procurement governed by the Public Contracts (Scotland) Regulations 2015, Procurement (Scotland) Regulations 2016 (“the Regulations”) and the Procurement Reform (Scotland) Act 2014. The procedure being followed is a Restricted Procedure.

description: Harlsdale, Whalsay and Kalliness, Weisdale, Shetland and as required by the Contracting Authority.

title: Refurbishment of Properties - Harlsdale, Whalsay and Kalliness, Weisdale, Shetland

description:
The Harlsdale, Whalsay works comprise the full internal and external refurbishment of 12 properties set in a combination of terraces and semi-detached properties contained within a Council estate at Harlsdale, Whalsay. There are several owner-occupied properties within the scheme which although do not form part of the works, have to be kept in occupation at all times.
 The works include the full spectrum of services required in order to refurbish the properties to a new, modern and energy efficient standard together with associated site works and services.
 This procurement is being let as a serial contract with the potential, subject to satisfactory performance of Harlsdale, to add a secondary contract for similar works, that being the refurbishment of 11 properties at Kalliness, Weisdale, Shetland. The Kalliness contract may be negotiated and awarded at any time during the main Harlsdale contract or upon satisfactory completion.

title: Single Procurement Document (SPD)

title: Single Procurement Document Briefing Document

title: Bank Reference Mandate

title: Checklist

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

title: THESE ARE FOR INFORMATION ONLY

minimum:
Three years accounts and business reports;
 A current bank reference report at a minimum value of 1,600,000 GBP;
 Evidence of current Employers and Public Liability Insurances to the minimum extent of 10,000,000 GBP and 5,000,000 GBP respectively;
 The Contracting Authority will carry out an Equifax check where a Bank Reference cannot be obtained and this will form part of the economic and financial evaluation of economic operators.

description: Economic operators must include up to date financial information that confirms the tenderer's financial capacity to fulfil the terms of the contract. Audited accounts and bank references are the preferred evidence but other relevant financial documents and data can be supplied by tenderers that do not hold company status.

type: technical

minimum:
Bidder(s) must complete the Single Procurement Document (SPD). Technical and Professional capability to undertake the commission shall be assessed on the information inserted by the Contractor in Part IV of the SPD. Failure to complete Part IV may result in your expression of interest being refused.
 The information contained in Part IV will be assessed to reduce the number of tenderers to a maximum of five.
 Part III and Sections B and D of Part IV of the SPD (Scotland) will be evaluated on a PASS/FAIL basis.

description: 4C.1 of the Single Procurement Document (SPD) (Scotland): economic operators will be required to provide examples that demonstrate that they have the relevant experience to deliver the works as described in Section 5 of the SPD Briefing Document.

mainProcurementCategory: works

procurementMethodDetails: Restricted procedure

Shetland Islands Council

locality: Shetland

postalCode: ZE1 0LZ

streetAddress: 8 North Ness, Lerwick

description: General public services

legalName: Shetland Islands Council

Lerwick Sheriff Court

locality: Lerwick

postalCode: ZE1 0DH

streetAddress: King Erik Street

legalName: Lerwick Sheriff Court

description:
Please note that it is an essential requirement of the procurement process that Tenderers fully complete and submit a satisfactory Single Procurement Document (SPD) (Scotland) and satisfy all requirements specified or referred to in the Contract Notice and Procurement Documents.
 111.1.2 - Economic operators who do not obtain a satisfactory financial evaluation may not be considered for contract award.
 The UK has left the EU and the transition period after EU came to an end on 31 December 2020. From 1 January 2021, relevant references to the EU and EU procurement legislation will either be updated or removed from the Public Contracts Scotland site where appropriate. This will be an ongoing process.
 Despite the reference to the EU Directives embedded in the header of the Contract Notice, the EU Directives do not apply to this procurement.
 The Contract shall be subject to Scots Law and the jurisdiction of the Scottish Courts.
 GBP means Great British Pounds.
 111.1.2 - A Bank Reference Mandate Form is included for completion by economic operators where a Bank Reference is not submitted direct by the economic operator.
 The Council will carry out an Equifax check where a Bank Reference cannot be obtained and this will form part of the economic and financial evaluation of economic operators.
 For the avoidance of doubt, Tenders are not required for the selection stage. The draft Invitation to Tender documents (Harlsdale only) are for information only. Final form tender documents will be distributed to those economic operators who are to be invited to tender.
 II.2.7 - The duration 24 refers to 24 months for Harlsdale, Whalsay with the option to add Kalliness, Weisdale at a further 24 months.
 V1.4.1 - Review body. The review body noted is Lerwick Sheriff Court but economic operators should contact the Contracting Authority in the first instance if any issue needs to be addressed. The court may be contacted where legal proceedings are contemplated.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at http://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730572.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at http://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 The Contracting Authority does not intend to include a sub-contract clause as part of community benefits (as per Section 25 of the Procurement Reform (Scotland) Act 2014) in this contract for the following reason:
 Whilst the overall estimated value is 6,000,000 GBP, the individual values for both contracts is 3,200,000 GBP and 2,800,000 GBP respectively. Due to this relatively low value and the difficulties and constraints of carrying out the works in a remote location, it is not considered appropriate for a sub-contract clause to be inserted.
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 The overall contract duration of 48 months (Harlsdale plus Kalliness) provides the potential for the successful contractor to undertake the appointment and training of apprentices.
 (SC Ref:730572)


description: Period of three years with the option to extend for one period of twelve (12) months.

description: AWARD OF PURCH2240 PROVISION OF A FRAMEWORK FOR THE PROVISION OF DOSIMETRY AND RECORD KEEPING SERVICES

description: Glasgow

description:
PURCH2240 PROVISION OF A FRAMEWORK FOR THE PROVISION OF DOSIMETRY AND RECORD KEEPING SERVICES
 Tender documents available from Public Contracts Scotland.
 Tender returns should be submitted via Public Contracts Scotland, no paper copies will be accepted. Should paper tenders be submitted, they will be rejected. Further to this any questions or communications regarding individual tender exercises must be sent via the Public Contracts Scotland Portal. Tender queries received through any other channel will not be answered. Should users of Public Contracts Scotland have any problems with the web site they should contact website Support Desk, contact details can be found by following the ‘Contact Us’ option on the left hand menu at http://www.publiccontractsscotland.gov.uk/default.aspx

title: PURCH2240 - ITT

format: application/msword

title: PURCH2240 - Schedule 1B - C&SRM KPI Template

title: PURCH2240 - Schedule 1B - C&SRM Stakeholder Feedback Form

title: PURCH2240 - Schedule 1B - CODE OF CONDUCT

title: PURCH2240 - Schedule 1C - Framework Agreement for Purchase of Services

title: PURCH2240 - Schedule 1C - Non-Compliance Template

title: PURCH2240 - Schedule 1D - SPD

minimum:
-Public liability insurance with a limit of indemnity of not less than five million pounds sterling (5,000,000 GBP) in relation to any one claim or series of claims;
 -Employer's liability insurance with a limit of indemnity of not less than five million pounds sterling (5,000,000 GBP);
 -Professional indemnity insurance with a limit of indemnity of not less than one million pounds sterling (1,000,000 GBP) in relation to any one claim or series of claims
 - Financial Turnover 2 years

University of Glasgow

postalCode: G12 8QQ

streetAddress: Procurement Office, Tay House

description: Education

legalName: University of Glasgow

name: Glasgow Sheriff Court & Justice of the Peace Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

id: European institution/agency or international organisation

description: Education

LANDAUER

locality: Oxford

postalCode: OX5 1JE

streetAddress: OX26 2GH, 18 Blythe Place

scale: sme

legalName: LANDAUER

description: (SC Ref:780790)


description: Single stage price / quality

description: Leith, Edinburgh

title: 2,3,4 Hopefield Terrace, Edinburgh - Roofing and Rendering and associated works

description: The works comprise the stripping and re-roofing of existing roof coverings, with new Cupa Heavy 3 slates. New Leadwork, Replacement rainwater goods, fascia and associated works. Provide overcoat dry dash finish, including smooth banding to windows. Provision of all scaffold access and associated works

title: Tender Documents

streetAddress: Leith, Edinburgh

type: suitability

description:
If required, bidders are required to be enrolled in the relevant professional or
 trade registers within the country in which they are established. Provide details of
 SSIP (e.g. CHAS, Safe Contractor), ISO 1800 / ISO45001 or other way you can
 demonstrate compliance with health and safety for example having a health and
 safety organisation that advises your organisation on health and safety matters.
 This question is NOT asking for your company registration number

minimum:
Bidders will be required to have a minimum “general” yearly turnover of
 200,000.00 GBP for the last 2 years.
 Insurances: Public liability insurance of minimum 2,000,00.00 GBP and Employers
 Liability of 5,00,000.00 GBP is required.

description:
SPD question 4B.1.1: Financial, turnover.
 SPD questions 4B.5.1b and 4B.5.2: Insurances

minimum:
4C.1 Examples of previous work.
 4C.2.1 Management and workforce team.
 4C.9 Tools, plant and equipment.

description:
Bidders will be required to provide examples of works carried out in the past five
 years that demonstrate that they have the relevant experience to deliver the work
 as described in part II.2.4 of the Find a Tender Service Contract Notice or the
 relevant section of the Site Notice.
 Bidders will be required to confirm details of the technicians or technical bodies
 who they can call upon, especially those responsible for quality control.
 Bidders will be required to demonstrate that they have (or have access to) the
 relevant tools, plant or technical equipment to deliver the types of requirements
 detailed in II.2.4 in the Find a Tender Service Contract Notice or the relevant
 section of the Site Notice.

Harbour Homes Scotland Limited

postalCode: EH6 6AZ

streetAddress: 108 Constitution Street, Leith

description: Housing and community amenities

legalName: Harbour Homes Scotland Limited

F3 Building Surveyors

roles: processContactPoint mediationBody

postalCode: eh6 6bz

streetAddress: 99 Giles Street

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at
 https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=715140.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at
 https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the
 closing time to avoid any last minute problems.
 NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730571.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:730571)


description:
THE WORKS
 - Repairs to the external precast concrete panels where spalling is now evident as a result of corrosion of the reinforcement bar.
 - Pinning the existing concrete base plinths back to the structure due to structural movement of the plinths.
 - Replace/repair all concrete plugs from the original shuttering.
 - Coring through the roof and floor slabs to allow 2no. new large capacity downpipes to be installed to accelerate the rainwater discharge from the 2no. flat roofs to the link building. These will discharge into the drainage channel to the north-east of the
 structure.
 - Install cut to falls insulation to ensure rainwater is discharged effectively from the roof.
 - Re-roof the 2no. flat roofs in high performance BMI Icopal mineral finished felt roof coverings.
 - Replace the existing uPVC gutter to the south elevation, in a larger 150mm diameter downpipe.
 - Replace the aluminium framed double glazed casement
 window units.

title: Andrew Melville Hall - External Fabric Repairs

University of St Andrews

locality: Guardbridge

postalCode: KY16 0US

streetAddress: Walter Bower House, Eden Campus

description: Education

legalName: University of St Andrews

Dundee Sheriff Court

locality: Dundee

postalCode: DD1 9AD

streetAddress: 6 W Bell St,

legalName: Dundee Sheriff Court

University of St Andrews

description: Education

Cosmos Projects

postalCode: G74 5BU

streetAddress: 36 Milton Road, East Kilbride

legalName: Cosmos Projects

Dundee Sheriff Court

streetAddress: West Bell Street

description:
Further guidance and support on how to register with InTend can be found at:
 https://www.st-andrews.ac.uk/media/procurement/supplier-registration-portal.pdf
 (SC Ref:738247)


description: The works comprise removal of the existing perimeter anti-intruder fence and gates and their replacement with new materials. The security of the perimeter is to be maintained during the works including overnights

title: Denmore Depot - Security Fence & Gates (7785)

documentType: economicSelectionCriteria

title: 7785 - Appendix 1&2 - BoQ & FoT.pdf

title: 7785 - Appendix 3 - TQA Questionnaire.pdf

title: 7785 Denmore Depot Security fence-7785 AL(00)003 Contractor Site Plan.pdf

title: 7785 Denmore Depot Security fence-7785 AC(90)002 NORTH GATE.pdf

title: 7785 Denmore Depot Security fence-7785 AC(90)003 Fence & blocks details.pdf

title: 7785 Denmore Depot Security fence-7785 AL(00)001 Location Plan.pdf

title: 7785 Denmore Depot Security fence-7785 AL(00)002 Existing Site Plan.pdf

title: 7785 Denmore Depot Security fence-7785 AL(00)005 Proposed Site Plan.pdf

title: 7785 Denmore Depot Security fence-7785 AC(90)001 WEST GATE.pdf

title: 7785 Denmore Depot Security fence-7785 AL(90)004 Fencing & gates elevs_A1.pdf

title: DD 01-02-18 - Denmore Depot - Asbestos Demolition Rpt.pdf

title: N3022-24578 - Denmore Depot - Interpretative GI Report.pdf

title: 7785 Denmore Depot - Security Fencing - Pre Construction Information - 23-06-02.pdf

title: 7785 - Appendix 4 - Selection Criteria.pdf

performanceTerms: As per Tender Documents

description: As per Tender Documents

Aberdeen City Council

locality: Aberdeen

postalCode: AB16 5GB

streetAddress: Woodhill House, Westburn Road

description: General public services

legalName: Aberdeen City Council

name: Sherriff Court of Grampian Highlands and Islands Aberdeen

description: General public services

valley

locality: grantown on spey

postalCode: ph26 3qf

streetAddress: 5 auchroisk place, cromdale

legalName: valley

description: (SC Ref:738424)


description: Demolition works to agricultural buildings

electronicCataloguePolicy: required

description: Glenconglass Farm, Glenlivet Estate

title: Glenconglass East Farm - demolition works

description: Demolition Works at Glenconglass East Farm

title: Glenconglass ITT

title: Glenconglass East Asbestos Survey

title: Glenconglass Site Plan

title: Floor and Roof Plan

title: Elevations

title: Glenconglass - Prelims, Description of Works, Form of Tender

title: Glenconglass Site Plan - please note shared wall denoted by blue line to be retained

performanceTerms: Refer to ITT and tender documents

description: Refer to ITT and tender documents

Strutt & Parker

locality: Inverness

postalCode: IV2 6AA

streetAddress: Perth Suite, Castle House

legalName: Strutt & Parker

locality: Perth

postalCode: PH1 5SP

streetAddress: 5 St John Street

description: General public services

GCM Services Scotland Ltd

region: UKM

locality: Bonnybridge

postalCode: FK4 1HY

streetAddress: 128 Kilsyth Road, Banknock

legalName: GCM Services Scotland Ltd

Edinburgh Sheriff Court

roles: reviewBody mediationBody

streetAddress: 27 Chambers Street

description: (SC Ref:735495)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) ("NSS")

description: Albasoft Ltd are a Scottish IT Supplier who has provided key GP data extraction services to NHS Scotland’s Primary Care sector and he Vaccination Programme. The contract is for NSS to buy the Intellectual Property from Albasoft Ltd and ongoing services.. There will be two optional one year extensions to this contract. The contract value attached to this notice includes the potential value of these extensions.

description: Scotland

title: Albasoft IP and Services

title: Albasoft IP and Services

description: Albasoft Ltd are a Scottish IT Supplier who has provided key GP data extraction services to NHS Scotland’s Primary Care sector and the Vaccination Programme. The contract is for NSS to buy the Intellectual Property from Albasoft Ltd and ongoing services.

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: Albasoft are the only suppliers that can extract all GP data from both GP System Suppliers clinical servers, query it using a library of clinical, pharmacological, workforce and patient encounter cluster definitions and present it in a non-proprietary format.

description: The works, supplies or services can be provided only by a particular economic operator due to protection of exclusive rights, including intellectual property rights

postalCode: EH12 9EB

streetAddress: Gyle Square, 1 South Gyle Crescent

description: Health

ALBASOFT LTD

postalCode: IV2 3JH

streetAddress: The Centre for Health Science, Raigmore

legalName: ALBASOFT LTD

Sheriff Court House

legalName: Sheriff Court House

description: (SC Ref:730676)


description: The contract may be extended by a further two, twelve month periods following the initial two years at the sole discretion of the Council

description:
The City of Edinburgh Council is seeking a supplier who can provide rental of rated hostile vehicle mitigation equipment, deployment of the equipment and provide associated services to support the security of events and public spaces. The equipment must be suitable for deployment in high-traffic areas, including pedestrian permeable solutions. The supplier must also provide storage and deployment options.
 The rental period for the equipment will vary depending on the individual event needs, and suppliers must be able to provide flexible rental terms to accommodate these varying requirements.
 Interested suppliers should upload their submissions via the Public Contract Scotland Tender Website/ portal. Further tender information can be found via Public Contract Scotland Tender.

title: Hostile Vehicle Mitigation

title: Hostile Vehicle Mitigation

description: The City of Edinburgh Council is seeking a supplier who can provide rental of rated hostile vehicle mitigation equipment and associated works to support the security of events and public spaces. Acceptable ratings are IWA-14 or PAS68

title: Hostile Vehicle Mitigation

reviewDetails: An economic operator that suffers or risks suffering loss or damage attributable to a breach of duty under Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or Court of Session. . A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the Find a Tender Service /OJEU or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.

minimum:
Minimum “general” annual turnover of 120000GBP for the last two financial years.
 Current ratio for Current Year: 1.15
 Current ratio for Prior Year: 1:15
 Employer’s Liability Insurance (minimum of 5 Million GBP)
 Public Liability Insurance (minimum of 10 Million GBP)
 Where a Tenderer does not hold or commit to obtaining the types and levels of insurance indicated, the Council will exclude the Tenderer from the competition.

description:
Tenderers are required to have a minimum “general” annual turnover of 50000GBP for the last two financial years. Where a Tenderer does not have an annual turnover of this value, the Council may exclude the Tenderer from the competition or may apply discretion seeking supporting evidence to determine the Tenderer’s suitability to proceed in the competition.
 Tenderers will be required provide the following information:
 Current ratio for Current Year: 1.15
 Current ratio for Prior Year: 1:15
 The formula for calculating a Tenderer’s current ratio is current assets divided by current liabilities. The acceptable range for each financial ratio is greater than 1.15. Where a Tenderer’s current ratio is less than the acceptable value, the Council may exclude the Tenderer from the competition or may apply discretion seeking supporting evidence to determine the Tenderer’s suitability to proceed in the competition.

description:
It is a mandatory requirement of this Framework that a prompt payment clause is present in all Contracts used in the delivery of the requirements. This ensures payment of sub-contractors at all stages of the supply chain within 30 days and includes an obligation to provide a point of contact for sub-contractors to refer to in the case of payment difficulties. This will require active monitoring of payment
 performance as well as the provision of evidence and reports to the Council on request or as contractually scheduled. Tenderers will be required to provide evidence that their organisation has taken steps to build their awareness of the climate change emergency and how they will respond. Accepted evidence includes but is not limited to: A completed copy of “Climate Change Plan” including planned projects and actions to reduce the bidder’s carbon emissions. This does not need to contain calculated carbon emissions. Where a Tenderer’s response is of a less than the acceptable standard, the Council may exclude the Tenderer from the competition or may
 apply discretion seeking supporting evidence to determine the Tenderer’s suitability to proceed in the competition. It is a mandatory requirement that Tendering Organisations with more than 5 employees have in place a Health & Safety Policy which is approved at a senior level within the Organisation and is reviewed regularly. Bidders should confirm that this condition has been met within the response to this question. Where a Bidder does not have a Health & Safety Policy and is required to do so, the Council may exclude the Bidder from the competition.

The City of Edinburgh Council

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

description: General public services

Sheriff Court

postalCode: EH1 1LB

streetAddress: Sheriff Court House, 27 Chambers Street

legalName: Sheriff Court

The City of Edinburgh Council

description: General public services

Crowdguard

locality: Altrincham

postalCode: WA14 1PJ

streetAddress: 16 Kingsway

legalName: Crowdguard

Sheriff Court

streetAddress: Sheriff Court House 27 Chambers Street

title: Hostile Vehicle Mitigation

documentType: plannedProcurementNotice

description:
It is a mandatory requirement of this Framework Agreement that a prompt payment clause is present in all Contracts used in the delivery of the requirements. This ensures payment of sub-contractors at all stages of the supply chain within 30 days and includes an obligation to provide a point of contact for sub-contractors to refer to in the case of payment difficulties. This will require active monitoring of payment performance as well as the provision of evidence and reports to the Council on request or as contractually scheduled.
 (SC Ref:760288)


description: The supplier will be required to provide –-	Server support and maintenance for the leased Linux php servers. – covering system security updates; backup and retrieval processes, review and maintenance of system logs etc.This will be done by remote access on secure login to the server. The supplier will require to have a fixed IP to access the server remotely.-	Support and maintenance for the live i-develop Moodle installation and test Moodle instance covering Moodle system security updates, security updates for Moodle plugins including reimplementation of customisations where necessary.-	Installation of any essential updates for the 2 WordPress installations.-	Advice to the Technical Project Manager in carry out standard on going service tasks – such as using reporting tools, extracting and analysing statistics etc.

title: Award of CLD Standards Council Online Maintenance and Development

description: Education and training services

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road

Muirhouse Housing Association

postalCode: EH4 4RW

streetAddress: 11 Muirhouse, Medway

description: Housing and community amenities

legalName: Muirhouse Housing Association

VWR International Ltd

locality: Lutterworth

postalCode: LE17 4XN

streetAddress: Hunter Boulevard

East Ayrshire Council

locality: Kilmarnock

postalCode: KA3 7BU

streetAddress: Corporate Procurement Team, London Road HQ

description: General public services

legalName: East Ayrshire Council

Sweco UK Limited

locality: Leeds

postalCode: LS7 4DN

streetAddress: Grove House, Mansion Gate Drive

legalName: Sweco UK Limited

Anderson Strathern LLP

postalCode: EH3 8EY

streetAddress: 1 Rutland Court

Scottish Government

roles: buyer centralPurchasingBody reviewBody mediationBody reviewContactPoint

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

description: General public services

id: Ministry or any other national or federal authority, including their regional or local subdivisions

legalName: Scottish Government

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

Social Security Scotland

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House, 17 South Union Street

description: General public services

legalName: Social Security Scotland

Venesky-Brown Recruitment

postalCode: EH1 2AS

streetAddress: 4A Rutland Square

Comhairle nan Eilean Siar

locality: Stornoway

postalCode: HS1 2BW

streetAddress: Council Offices, Sandwick Road

description: General public services

legalName: Comhairle nan Eilean Siar

Econ Engineering Ltd

locality: Ripon

postalCode: HG4 1UE

streetAddress: Boroughbridge Road

The City of Edinburgh Council

description: General public services

Whereverly Limited

postalCode: EH3 7LB

streetAddress: 2 Walker Street

name: Social Care and Social Work Improvement Scotland (Care Inspectorate)

postalCode: DD1 4NY

streetAddress: Compass House

name: Mitie Cleaning & Environmental Services Ltd

postalCode: EH12 9DB

streetAddress: The Granary, Roddinglaw Business Park

Highlands and Islands Enterprise

postalCode: IV2 5NA

streetAddress: An Lòchran

Hall Aitken

postalCode: G2 6AE

streetAddress: 45 Hope Street

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Jack Dryburgh

description: Health

description: General public services

legalName: Fife Council

Capability Scotland

postalCode: EH12 5HG

streetAddress: Osborne House

Venesky Brown Ltd

streetAddress: 4a Rutland Square

legalName: Venesky Brown Ltd

A.C. Nielsen Company Limited

postalCode: OX4 2WB

streetAddress: AC Nielsen House

North East Scotland College

postalCode: AB25 1BN

streetAddress: Aberdeen City Campus, Gallowgate

description: Education

legalName: North East Scotland College

North Offshore Ltd

postalCode: AB12 3PG

streetAddress: Saltire House, Blackness Avenue,

name: Protect International Risk and Safety Services

Dumfries and Galloway Council

description: General public services

Angus Council

description: General public services

East Lothian Council

description: General public services

Education Scotland

description: Education

Langstane Press

streetAddress: 28B Firth Road, Houstoun Industrial Estate

Perth & Kinross Council

description: General public services

Forestry and Land Scotland

description: Environmental protection

Midlothian Council

description: General public services

Moray Council

description: General public services

XMA Limited

streetAddress: Junction 24 Business Park, Pavilion 2, Helen Street, Glasgow

boxxe Limited

streetAddress: The e-centre, Coopergate Way Business Village


title: Provision of SPECT/CT Gamma Camera System at RHC

title: Provision of Associated Enabling Works for SPECT/CT Gamma Camera System at RHC

title: Provision of SPECT/CT Gamma Camera System at Forth Valley Royal Hospital

description: Provision of SPECT/CT Gamma Camera System At Royal Hospital for Children

Maintenance and Support (Commercial)

type: cost

description:
Provision of enabling (turnkey) works associated with SPECT/CT Gamma Camera System at Royal Hospital for Children.
 The existing equipment shall be disconnected, removed from site and disposed of unless otherwise instructed by the Board.
 The design shall take account of the current room layout and departmental operations modifying the space to meet current design standards and existing patient flow arrangements. Pre-installation works shall be through a turnkey arrangement which will be required to prepare the installation to a clinical operational standard, this is expected to include, but not be limited to re-wiring, plumbing, ventilating, chilling, lead lining, decoration etc. Provision for data and telecommunication shall be made in liaison with Board representatives. Dedicated central server rooms are distributed across the building for the purpose of networked resiliency and bidders should confirm any requirements for networking and data integration with these facilities.
 Pre-installation work may include the following:
 -	Any required radiation protection works as necessary
 -	Re-wiring and provision of appropriate power supplies and distribution systems to comply with electrical legislation
 -	UPS/IPS systems and re-wiring
 -	Earth bonding system and re-wiring
 -	Levelling of floors if required
 -	Finishing of floors, walls and ceilings
 -	Dry lining, room decoration and fitments
 -	Cleaning of room prior to handover
 -	Provision of new or extended plumbing, ventilation, heating and cooling, where necessary
 -	Upgrading or the addition of IT and telecommunication infrastructure where necessary

description:
Royal Hospital for Children
 1345 Govan Road, Govan
 G51 4TF

description:
Forth Valley Royal Hospital
 Stirling Road, Larbert
 FK5 4WR

description: Provision of SPECT/CT Gamma Camera System and Associated Enabling Works For NHS Greater Glasgow & Clyde, Provision of SPECT/CT Gamma Camera System for NHS Forth Valley

title: Invitation to Tender

title: NHS GGC Terms and Conditions Goods & Services

title: Prompt Payment Question

title: Proposed Award Criteria - SPECT-CT Gamma Camera System Lot 1 RHC

title: Proposed Award Criteria - SPECT-CT Gamma Camera System Lot 2 - Turnkey RHC

title: SPD Additional Information SPECT-CT

title: SPD PCS SPECT-CT Gamma Camera System Lot 1

title: SPD PCS SPECT-CT Gamma Camera System Lot 2 - turnkey RHC

title: Specification - SPECT-CT Gamma Camera System Lot 1 - equipment RHC

title: Specification - SPECT-CT Gamma Camera System Lot 2 - Turnkey RHC

title: SPECT-CT Pre-acquisition Questionnaire

title: SPECT-CT Tender Evaluation Matrix (Lot 1 and Lot 2)

title: SPPQ - SPECT-CT Tender

title: Supplementary GDPR Provisions (addendum to T&Cs)

title: 1.5.22 Picture Archiving and Communication System v4 25-04-21

title: 1.5.23 Dicom statement intergration performa

title: 1.5.25 Equipment Standards

title: 1.5.27 IRMER17+IRR17 equipment compliance proforma v0.4

title: 2.1.3 FINAL - FORTH VALLEY SPECT CT Gamma Camera Specification 28.04.23

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_a_2016

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_b_2016

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_c_2016

title: 2.1.7 Scoring FVRH Spect CT v3 28.04

title: 2.1.12 Lot 3 KEP-R(77)L-0-RAD092-01_Iss8

title: 2.1.14 Turnkey Survey Sheet

title: 3.2.3 FV Trade In

title: Lot 3 NHS FV ITT Response Form

title: SPD Additional Information SPECT-CT Lot 3 NHS FV

title: SPD SPECT-CT Gamma Camera System Lot 3 NHS FV

title: National Services Scotland Framework Terms and Conditions

streetAddress: Glasgow Royal Infirmary

description:
Gareth Miller (Commodity Manager - Capital Equipping)
 Sophie Connelly (Commodity Officer - Capital Equipping)
 Gerry Mather (Project Manager - Property and Capital Planning)

awardCriteriaDetails: Tenderers can bid on all three (3) Lots for both equipment and turnkey. We reserve the right to award the Lot for equipment only and turnkey only, should it be deemed acceptable by the co-operating Health Boards. In the event where Lot 1, Lot 2 and Lot 3 are awarded to different suppliers, the successful bidders of Lot 1, Lot 2 and Lot 3 are expected to work together in a collaborative, constructive manner that benefits both parties and to the benefit of NHS stakeholders.

performanceTerms:
3 year manufacturer's warranty on Lot 1.
 10 year maintenance on Lot 1.
 Description of Added Value Features (FOC) for Lot 1.

NHS Greater Glasgow and Clyde

locality: Glasgow

postalCode: G4 0SF

streetAddress: Procurement Department, Glasgow Royal Infirmary, 84 Castle Street

description: Health

legalName: NHS Greater Glasgow and Clyde

NHS Forth Valley

locality: Stirling

postalCode: FK9 4SW

streetAddress: Trust Headquarters, Carseview Castle Business Park

legalName: NHS Forth Valley

name: Glasgow Sheriff Court and Justice of the Peace Court

postalCode: G5 9DA

streetAddress: 1 Carlton Place

NHS Greater Glasgow and Clyde

description: Health

Siemens Healthcare Limited

locality: Camberley

postalCode: GU15 3YL

streetAddress: Park View, , Watchmoor Park,

legalName: Siemens Healthcare Limited

streetAddress: Sheiff Clerk's Office, PO Box 23, 1 Carlton Place

description:
This tender is a joint venture between NHS Greater Glasgow and Clyde (GG&C) and Forth Valley.
 Scoring for Lot 1 and Lot 2 will be conducted by NHS GG&C.
 Scoring for Lot 3 will be conducted by National Services Scotland (NSS) and NHS Forth Valley.
 (SC Ref:742658)


id: Software for Housing Management & Finance

description: Option to extend by up to 36 months

description: Single Stage open tender, evaluation based on 30% price / 70% quality. Top three evaluation scorers invited to interview.

description: 17 Bridge St, Linwood, Paisley PA3 3DB

description: Software for areas including tenancy, income management, reactive repairs, planned investment, tenant safety/compliance, complaints handling, factoring, finance, GDPR compliance

title: Tender Information

reviewDetails: Interviews held on 3rd and 9th August. Scoring complete and winning tenderer notified 25/08/2023.

Linstone Housing

locality: Linwood

postalCode: PA3 3DB

streetAddress: Bridge Street

description: Housing and community amenities

legalName: Linstone Housing

Leadership Team

locality: Paisley

streetAddress: 17 Bridge Street

legalName: Leadership Team

Linstone Housing

description: Housing and community amenities

Designer Software Ltd

locality: Milton Keynes

postalCode: MK5 8FT

streetAddress: 11 Whittle Court, Davy Avenue

legalName: Designer Software Ltd

Linstone Housing Association

legalName: Linstone Housing Association

description:
Attached document gives detailed requirements
 (SC Ref:747679)


description:
The successful contractor will be required to carry out internal alterations and refurbishment of existing Cultural & Leisure Council offices and storage to provide new nursery facilities. The works include creating new nursery classrooms, toilets, staff areas, teachers’ offices and kitchen. Works also include reconfiguration of asphalt car parking into a secure nursery play space to include a canopy and a new flat roof system. The external works also include the extension of the existing car parking as well as the requirement for a retaining wall.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 8 and 9 of the Procurement (Scotland) Regulations 2016.
 The works budget for this project is 1,240,000GBP however the Council reserves the right to spend up to 1,480,000GBP.

title: Reconfiguration Works at St John's Primary School for new Early Years Accommodation

description:
The successful contractor will be required to carry out internal alterations and refurbishment of existing Cultural & Leisure Council offices and storage to provide new nursery facilities. The works include creating new nursery classrooms, toilets, staff areas, teachers’ offices and kitchen. Works also include reconfiguration of asphalt car parking into a secure nursery play space to include a canopy and a new flat roof system. The external works also include the extension of the existing car parking as well as the requirement for a retaining wall.
 This procurement will be conducted via the Public Contracts Scotland - Tender portal (PCS-T). We will apply a one stage Open procedure.
 Bidders must self-certify their adherence to the conditions of participation via the SPD (Scotland) in PSC-T, and may be required to submit Means of Proof before contract award. Bidders must refer to the specific requirements listed in Section III in this Contract Notice when completing the SPD in PCS-T.

performanceTerms: SBCC Standard Building Contract With Quantities for use in Scotland (SBC/Q/Scot), 2016 Edition, incorporating Amendment 1, February 2018

description:
Due to the nature of the works it is mandatory that all of the successful contractor’s staff or staffs of a sub-contractor(s) are accredited under the Construction Skills Competence Scheme (CSCS) or the Scottish Construction Operative Registration Executive (SCORE).
 Bidders must confirm if they hold the particular authorisation or memberships.
 Bidders will be required to evidence their current membership / accreditation or the membership / accreditation of their sub-contractor(s) with the following trade associations in order to be considered for this contract.
 SELECT / NICEIC
 Gas Safe
 SNIPEF
 A request for documentation will be issued to all contractors who submit a bid upon receipt of their tender response.
 Failure to be able to evidence accreditation with these institutes will result in the bidder being automatically disqualified from the evaluation process. The Council’s decision on this is final.

description:
Bidders will be required to have a minimum yearly “specific” turnover of 1,500,000 GBP for the last 12 months in the business area covered by the contract.
 The Council reserves the right at its own discretion to seek information from the applicant in accordance with Regulation 61(7) or Regulation 61(8) of the Public Contracts (Scotland) Regulations 2015 to determine the Applicant’s economic and financial standing. East Renfrewshire Council requires to ensure that the economic operator has the necessary economic and financial capacity to perform and complete the contract. In the current difficult economic environment, the Council seeks to ensure that the contractor who undertakes the works has suitable financial strength and capacity to complete these goods, works or services.
 Where an economic operator wishes to be considered for selection under this contract but cannot meet the turnover and/or Credit Safe score of 30 that economic operator must provide financial information which will satisfy the Council that they have an equivalent level of economic and financial standing; and must provide related guarantees or formal assurances to support their right to participate and be considered for any contract award (Regulation 61(8)). Please note that any financial information disclosed should evidence the financial strength of the economic operator tendering, therefore additional supporting information will need to be provided where joint or group accounts are provided in support of a bid to explain to the Council the relevance of that information.
 Where the economic bidder relies upon or intends to reply upon any Key Subcontractors in performance of the contract, then the Council reserves the right to assess the financial strength and suitability the Key subcontractor as part of the qualification process; Where the economic operator relies upon a parent company to provide financial assurance in support of their bid, the Council will also reserve the right to seek financial information on the strength and suitability of the parent company; and
 Where the economic operator relies upon the capacity of other parties in respect of selection and/or performance of the contract, then dependent on the nature of the arrangement the Council may require full disclosure of financial information in support of the bid. For example, where the bidder identifies as a consortium the Council will require that the consortium, as a group, can meet the financial selection requirements contained in the procurement documents. Where a bidder is part of a Consortium, it shall procure the execution and delivery to the Employer of a Consortium Guarantee (in the form provided by the council) executed by each member of the Consortium (acting as Consortium guarantor) in Self Proving Form.
 The Council reserves the right to monitor that the economic operator continues to meet the financial selection requirements upon receipt of the invitation to tender or after evaluation has been completed and prior to any award being made. Economic operators must inform the Council of any changes to any submission made by them in respect of their financial and or economic situation. The Council will further reserve the right to remove any economic operator from the tendering process where they are no longer able to fulfil any of the selection requirements as directed within the procurement documents.
 Further detail is contained within the procurement documents.
 Bidders who cannot meet the required level of turnover will be excluded from this tender.
 It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers Liability Insurance - 5 million GBP
 Public Liability Insurance - 5 million GBP
 Professional Indemnity Insurance - 2 million GBP
 Third Party Motor Vehicle Insurance

minimum:
Bidders will be required to provide three examples of similar projects / works. Examples provided MUST have been undertaken within a LIVE education school setting in the past five years.
 Your response must demonstrate that you have the relevant experience to deliver the work as per the scope of works described within the tender documentation including the Tender Information, Contract Notice, Prelims and BOQ, within a main school building.
 The examples provided must be of a similar value (between 1,00,000GBP - 1,500,000GBP), size and scope and include reference to the works undertaken in relation to internal alterations, refurbishment works, new flat roof system and external works, as per the scope of work provided.
 Bidders must also provide the dates these projects were undertaken including start and end dates in the format MM/YY i.e. 06/19 to 03/20 and the name of the customer / client.
 Responses must be returned in the attachment provided at 1.71.3, no other format will be accepted. Coloured brochures are not acceptable and zip files with additional information should not be submitted as they wont be considered.
 Failure to provide responses relevant to this project will result in your bid being removed without further consultation.
 The Council's decision on this is final.

description:
Bidders who intend to use a supply chain to deliver the requirements detailed in the Contract Notice, must confirm they have (or have access to) the relevant supply chain management and tracking systems to ensure a resilient and sustainable supply chain. Bidders must provide a response at SPD Q4.C.4 and this will include confirmation that they have the systems in place to pay subcontractors through the supply chain promptly and effectively, and provide evidence when requested of:
 a) their standard payment terms.
 b) ≥95% of all supply chain invoices being paid on time (in accordance with the terms of contract) in the last financial year.
 Bidders unable to confirm (b) must provide an improvement plan, signed by their Director, which improves payment performance. It should be noted that where a bidder is unable to confirm or provide a satisfactory improvement plan the Council reserves the right to remove you from the process.
 Bidders are required to confirm whether they intend to subcontract and, if so, for what proportion of the contract.
 Bidders who intend to subcontract more than 25% to any individual organisation must ensure the SPD (Scotland) - Subcontractors Supplier Response is completed and uploaded at question 2C.1 of the qualification envelope.

East Renfrewshire Council

locality: Giffnock

postalCode: G46 6UG

streetAddress: Eastwood HQ, Eastwood Park,

description: General public services

legalName: East Renfrewshire Council

name: Paisley Sheriff Court and Justice of the Peace

postalCode: PA3 2HW

description: General public services

Fleming Buildings Ltd

postalCode: G66 5ET

streetAddress: 23 Auchinloch Road, LENZIE

legalName: Fleming Buildings Ltd

description:
Prompt Payment-The successful tenderer shall, as a condition of being awarded the contract, be required to demonstrate to the council's satisfaction that all funds due to the tenderer's permitted sub-contractors in respect of these services are paid timeously and that as a minimum invoices rendered by subcontractors shall(unless formally disputed by the tenderer)be paid within 30 days
 of receipt. The successful tenderer shall also impose this condition on its subcontractors in respect of payments due to any sub-sub-contractors, if any.
 The Council reserves the right to request copies of insurance certificates from bidders at any point during the contract period. Failure to supply the information within timeframe requested may result in your bid being rejected & the Council proceeding with the procurement exercise to the next appropriate bidder. Additional information pertaining to this contract notice is contained within the Tender documents. Applicants must ensure they read in line with this contract notice.
 (SC Ref:748802)


description:
CPI is delivering SONNET (Smart Connected Technology Innovation Programme), a GBP 3.8M project funded by the European Regional Development Fund to support SMEs in the Northeast of England. The project runs until June 2023.
 The project aim is to bring regional SMEs up to date with the latest in Digital and Internet of Things (IoT) technologies, to support the development of products and services, with a particular focus on the health sector. The key audience comprises innovative SMEs active in technology development applicable to the health sector; innovation leads with the health sector; and other stakeholders in government and funding bodies.

region: UKC

title: 5G Playbook

title: 5G Playbook

description: CPI is a leading independent technology innovation centre and a founding member of the UK Government’s High Value Manufacturing Catapult, which supports businesses and academia to help them overcome innovation challenges in the development of next generation products and processes by providing the facilities, in depth technical expertise and innovation support to enable ideas, research and knowledge to be translated into commercial business propositions.

title: 2881 - Tender Pack

title: 5G Playbook

Centre for Process Innovation Limited

locality: Redcar

postalCode: TS10 4RF

streetAddress: Wilton Centre

legalName: Centre for Process Innovation Limited

streetAddress: Sheriff Clerk's Office, 1 Carlton Place

legalName: Glasgow Sheriff & Justice of the Peace Court

Wander Films Limited

locality: Middlesbrough

postalCode: TS1 1PQ

streetAddress: 23-25 Albert Road

legalName: Wander Films Limited

name: Glasgow Sheriff & Justice Of The Peace Court

description: (SC Ref:736008)


description: The purpose of this ITT is to appoint a single supplier to conduct an equity market gap analysis. The findings will inform Scottish Government and Scottish Enterprise strategy development and future market interventions to support Scotland’s risk capital equity market.

title: Equity Investment Gap Analysis

title: Equity Investment Gap Analysis

title: P24-0012 - Invitation to Tender (ITT)

title: P24-0012 - ITT - Appendix 1 - Off Payroll Working Rules Outcome

title: P24-0012 - ITT - Appendix 2 - Tender Response Document

title: P24-0012 - ITT - Appendix 3 - Monitoring Information

title: P24-0012 - ITT - Appendix 4 - Information Security Questionnaire

title: P24-0012 - SPD - Bidder 'Relevant Contract' Climate Change Plan Template

title: Equity Investment Gap Analysis

reviewDetails:
In the first instance, contact the Head of Facilities Management and Procurement at Scottish Enterprise, with any concerns or enquiries. Email: https://www.scottish-enterprise.com/help/contact-us.
 An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015, may bring proceedings that will be started in the High Court.

Scottish Enterprise

postalCode: G2 6HQ

streetAddress: Atrium Court, 50 Waterloo Street

description: Economic affairs

legalName: Scottish Enterprise

streetAddress: Sheriff Clerk’s Office, PO Box 23, 1 Carlton Place,

legalName: Glasgow Sheriff Court and Justice of the Peace Court

Scottish Government

roles: mediationBody reviewContactPoint buyer

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay, 150 Broomielaw

description: General public services

legalName: Scottish Government

Scottish Enterprise

description: Economic affairs

RSM (Quick Quote contact)

locality: London

postalCode: EC4A 4AB

streetAddress: 6th Floor, 25 Farringdon Street

legalName: RSM (Quick Quote contact)

streetAddress: PO Box 23 1 Carlton Place

Scottish Government

locality: Edinburgh

postalCode: EH6 6QQ

streetAddress: Victoria Quay,

description: General public services

description: Environmental protection

description:
This is a relevant climate change contract, bidders are required to complete and return the attached Climate Change Plan template.
 (SC Ref:736315)


description:
The Contracting Authority reserves the right to request additional deliveries by the successful Tenderer, either intended as partial replacement of supplies or installations or as extensions of existing supplies and installations.
 The Contracting Authority may at its sole discretion exercise this option.

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities.
 SIPBS required the supply, delivery and commissioning of a new autoclave which is vital to support all of SIPBS research and teaching activities. The service provided by this equipment is the autoclaving of biological and clinical waste and safe disposal in accordance with the Control of Substances Hazard to Health Regulations 2002 (COSHH), Genetically Modified Organisms Regulations 2014 (GMO) and The Health Technical Memorandum (HTM07-01) Safe Management of Healthcare Waste.
 The supplier will be required to decommission and remove the existing autoclave system, and additionally install and commission the new system within the existing space.
 There is additional requirement that the new system is sustainable and environmentally conscious. In particular, the system should reduce water, energy consumption and carbon consumption.
 It should be noted that this is the award notice of the contract for the provision of these requirements.. The equipment is to be installed w/c 4th December 2023.

title: Supply, Delivery and Commissioning of Autoclave, Removal and Disposal of Existing Autoclave

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities. SIPBS requires the supply, delivery and commissioning of new autoclave which is vital to support all of SIPBS research and teaching activities.
 It is a requirement that the supplier decommissions and removes the existing autoclave to replace it with the new system supplied.

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities. SIPBS required the supply, delivery and commissioning of new autoclave which is vital to support all of SIPBS research and teaching activities.
 It was a requirement that the supplier decommissions and removes the existing autoclave to replace it with the new system supplied.

minimum:
4B.1.2 It is a requirement of this contract that bidders have a general yearly turnover of 140,000.00 GBP for the last three years.
 4B.5.1-4B.5.3 It is a requirement of this contract that bidders can hold or commit to obtain prior to the commencement of any subsequently awarded contract, the types of insurance indicated below:
 The Contractor shall maintain in force with reputable insurers
 Employer’s (Compulsory) Liability Insurance = 10,000,000.00 GBP
 Public and Product Liability Insurance = 10,000,000.00 GBP
 Professional Risk Indemnity Insurance = 2,000,000.00 GBP
 In respect of any one incident and unlimited as to numbers of claims

description:
4B.1.2
 4B.5.1 – 4B.5.3

minimum:
4C1.2 Bidders are required to provide three (3) examples that demonstrate that they have the relevant experience to deliver the services/supplies as described in part II.2.4 of the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 This will be scored in accordance with the scoring matrix as detailed in the ITT.

University of Strathclyde

postalCode: G1 1XQ

streetAddress: McCance Building, 16 Richmond Street

description: Education

legalName: University of Strathclyde

Glasgow Sheriff Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

legalName: Glasgow Sheriff Court

University of Strathclyde

postalCode: G1 1QE

description: Education

BMM WESTON

locality: Faversham / Kent

postalCode: ME13 7EB

streetAddress: Brent Hill, Faversham

legalName: BMM WESTON

description: (SC Ref:747988)


description: Scene Connect is administering this contract on behalf of Dundee Renewable Energy Society, a Dundee charity established to develop community owned renewable energy assets. The contract is to design, build, operate and maintain a 2 MegaWatt (MW) Solar Photovoltaic (PV) ground-mounted array; construction of a new site access from the A90; all ancillary electrical infrastructure to connect the site to the point of connection at the James Hutton Institute's Invergowrie campus, including horizontal directional drilling underneath the A90 using the Client's nominated subcontractor; and associated ancillary work.

description: North Bullionfield (Dundee City) and the James Hutton Institute's Invergowrie Campus (Perth & Kinross)

title: Bullionfield Solar Meadow

title: Bullionfield Solar Meadow

title: DRES Procurement - Volume 1 (Tender Requirements)

title: DRES Procurement - Volume 2 (Technical Specification and Scope of Work)

title: DRES Procurement - Volume 3 (Tender Returns)

title: Volume 2, Appendix 1 - DCC Decision Notice

title: Volume 2 - Appendix 1, PKC Decision Notice

title: Volume 2 - Appendix 2, SSEN Connection Offer

title: This Export Limitation Scheme has been submitted to SSEN and approved by their designer (17.04.2023)

title: Zip file containing plans submitted (and consented) for the project planning consent.

format: application/zip

title: Zip file containing plans submitted to Transport Scotland showing detailed site access.

title: Word version of Tender Returns - Volume 3

title: Word version of Pricing Schedule - Volume 4

title: DRES Procurement - Volume 4 (Pricing Schedule)_v3 (Excel version)

title: Drg. 2104-001 General Arrangement of Solar PV array, as .DWG file

format: application/octet-stream

title: Copy of existing services at JHI from Survey.

title: .DWG file of the new services being installed for the IBH development (under construction on site)

title: Existing SLD and proposed SLD showing upgraded SSEN connection and PV array

title: Drg. 2104-007 CAD Site layout of Solar PV array and elevations, as .DWG file

title: Bullionfield Solar Meadow

Scene Connect Ltd

postalCode: EH6 6BR

streetAddress: 46a Constitution Street

legalName: Scene Connect Ltd

Dundee Sheriff Court

locality: Dundee

postalCode: DD1 9AD

streetAddress: 6 W Bell St,

legalName: Dundee Sheriff Court

Munro Wilson Ltd

locality: Whitsome

postalCode: TD11 3NB

streetAddress: Glamis House, Main Street

legalName: Munro Wilson Ltd

Dundee Sheriff Court

streetAddress: West Bell Street

description:
Please see tender documents for additional information.
 (SC Ref:765934)


description: May take up option of twelve month extensions up to a maximum of two further years (2025-2027) at an estimated value 75000 GBP (excluding VAT) per annum.

description: The procurement is being undertaken in accordance with Regulation 28 'Open Procedure' of the Public Contracts (Scotland) Regulations 2015.

description: Govan, Elderpark, Ibrox, Cessnock and KInning Park, Glasgow

title: Elderpark Housing Association - Landscape Maintenance Contract 2023-2025

description:
The Contract will principally comprise litter picking, grass cutting, leaf collection, tree, shrub bed, planters and hedging landscape maintenance services to existing properties and common landscaped areas throughout Elderpark, Govan, Ibrox, Cessnock and Kinning Park, Glasgow to the areas detailed within the Landscape Architects tender drawings and Elderpark Housing Association’s property address list (refer Tender Document K – Elderpark HA Address List). The Contract may also include an annual tree survey service, tree and stump removal works, and repairs to existing damaged grass areas.
 The Contract may also include Elderpark Housing Association’s ‘helpline’ garden maintenance scheme involving landscape maintenance to gardens of elderly residents. However, this work is provisional and not guaranteed, and Bidder’s rates for the ‘helpline’ garden scheme will not be taken into account in the tender evaluation.The commencement date for the Measured Term Contract is currently estimated to be 1st July 2023 and the completion date is 30th June 2025.
 Subject to satisfactory performance of the Contractor, which will be assessed through measurement of the Key Performance Indicator’s (Refer Tender Document F), it is intended that the Contract will be extended on an annual basis by a maximum of two further years until 2027. Orders for future landscape maintenance services may be placed by Elderpark Housing Association during Year Thee, Year Four or at any point until expiry of the Measured Term Contract (maximum of four years from the date of entering into the Contract).

title: Document A

title: Document B

title: Document C

title: Document D

title: Document E

title: Document F

title: Document G

title: Document H

title: Document I

title: Document J

title: Document K

title: Document L

title: MAP Quantities

title: M01A

title: M02B

title: M03B

title: M04B

title: M05B

title: M06B

title: M07C

title: M08A

description: 2024 at the earliest if the optional 12 month extensions are not applied

performanceTerms:
The performance of the successful Bidder will be monitored through the Key Performance Indicators described within Tender Document F
 Key Performance Indicators attached to this Contract Notice.
 Where performance falls below the minimum acceptable level during the Contract, the successful Bidder will be required to produce a
 Remedial Plan for the approval of Elderpark Housing Association.
 Failure to produce a Remedial Plan or implement an approved Remedial Plan will be deemed to be a breach of the Contract, which may
 lead to the termination of the successful Bidder's Contract.

description:
Please refer to these statements when completing Section 4A of the SPD Scotland.
 4A.1 - If required by the member state, bidders are required to be enrolled in the relevant professional or trade registers within the country
 in which they are established.
 4A.2 - Where it is required, within a bidder’s country of establishment they must confirm which authorisation or memberships of the
 relevant organisation(s) are required in order to perform this service. Bidders must confirm if they hold the particular authorisation or
 memberships

description:
Please refer to these statements when completing Section 4B of the SPD (Scotland) v1.2_0.
 Question 4B.1.1 - Bidders will be required to have a minimum 'general' yearly turnover of 150000 GBP for the last two years.
 Question 4B.1.2 - Bidders will be required to have an average yearly turnover of a minimum of 150000 GBP for the last two years.
 Question 4B.3 - Where turnover information is not available for the time period requested, the bidder will be required to state the date
 which they were set up or started trading.
 4B.5.1 and 4B.5.2 - It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any
 subsequently awarded contract, the types and levels of insurances indicated below:
 Employer's (Compulsory) Liability Insurance - 5,000,000 GBP Public Liability Insurance - 5,000,000 GBP

description:
4C.8.1 - Bidders will be required to confirm their average annual manpower for the last three years.
 4C.8.2 - Bidders will be required to confirm their and the number of managerial staff for the last three years.
 4C.9 - Bidders will be required to demonstrate that they have (or have access to) the relevant tools, plant or technical equipment to deliver
 the types of requirements detailed in II.2.4 in the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 4C.10 - Bidders will be required to confirm whether they intend to subcontract and, if so, for what proportion of the contract. Minimum
 level(s) of standards required:
 SPD Scotland, Part C Technical and Professional Ability - Bidders responses to Part C of the SPD will be limited to a maximum of nine A4
 single sided pages, excluding any certification that a Bidder submits in support of their response, which must be completed in English using
 Arial 11 font

Elderpark Housing Association

postalCode: G51 3AX

streetAddress: 65 Golspie Street

description: Housing and community amenities

legalName: Elderpark Housing Association

A.D.A Construction Consultants

postalCode: PA3 3BB

streetAddress: Pavilion 3, St James Business Park, Linwood Road

Elderpark Housing Association

description: Housing and community amenities

Digby Landscaping

locality: Renfrew

postalCode: PA2 7EP

streetAddress: 8 Wallace Road, Renfrew

legalName: Digby Landscaping

postalCode: G5 9DA

description:
The award value of 70889.62GBP is the anticipated annual value of the contract excluding VAT
 (SC Ref:805806)


name: The Rural Development Trust (Community Action Lanarkshire)

description:
Community Action Lanarkshire (CAL) wishes to commission construction design and survey work for an Active Travel project which links the villages of Coalburn and Douglas in rural South Lanarkshire, to enable local people to choose walking, cycling, and wheeling for everyday functional journeys.
 CAL has successfully secured Construction Design funding for the work from Paths for All with up to GBP43,000 available from the Ian Findlay Path Fund’s 2022/23 pot, for delivery in 2023/24. CAL will be acting as the client for the work to be carried out under this funding.
 The project builds on previous (and current) work undertaken through Smarter Choices Smarter Places and Sustrans projects locally and compliments existing work CAL has developing around Active travel community mapping in the Douglas Valley.

title: Coalburn to Douglas Active Travel Path

title: Coalburn to Douglas Active Travel Path

title: Statement of Requirements: Coalburn to Douglas Active Travel Path

title: Ian Findlay Path Fund Guidance

title: Paths for All Ian Findlay Path Fund Application and Project Reporting Guide

streetAddress: 1 Powell Street, Douglas Water, ML11 9PP

roles: buyer reviewBody

locality: Lanark

postalCode: ML11 9PP

streetAddress: 1 Powell Street, Douglas Water

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730819.
 (SC Ref:730819)


description:
PPE1000029 Direct award for the Provision For Outright Purchase of Springer Materials.
 Outright purchase of SpringerMaterials - Archive online database: Landolt-Börnstein. SpringerMaterials provides curated data and advanced functionalities to support research in materials science, physics, chemistry, engineering, and other related fields.

description: Glasgow

description:
PPE1000029 Direct award for the Provision For Outright Purchase of Springer Materials.
 Internal Procurement Policy Exception (PPE) Form completed.

procurementMethodRationale: Regulations 2015-33 (1) (b) (ii)Technical Reasons

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

University of Glasgow

postalCode: G12 8QQ

streetAddress: Procurement Office, Tay House

description: Education

legalName: University of Glasgow

Springer Nature

postalCode: N1 9XW1

streetAddress: 4 Crinan Street

legalName: Springer Nature

legalName: Glasgow Sheriff Court & Justice of the Peace Court

description: (SC Ref:730833)


description: Forth Valley College is seeking a Contractor for the provision of Insurance Services via mini-competition under the APUC Framework INS1002 AP.

description:
The Contract will commence on 1st August 2023 for a period of 2 years and expire on 31st July 2025.

The Purchaser reserves the right to extend the contract for a further 2 periods of 12 months subject to satisfactory performance and continued Purchaser requirements.

title: Award of Insurance Services for Forth Valley College

description: Insurance services

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road

Muirhouse Housing Association

postalCode: EH4 4RW

streetAddress: 11 Muirhouse, Medway

description: Housing and community amenities

legalName: Muirhouse Housing Association

VWR International Ltd

locality: Lutterworth

postalCode: LE17 4XN

streetAddress: Hunter Boulevard

East Ayrshire Council

locality: Kilmarnock

postalCode: KA3 7BU

streetAddress: Corporate Procurement Team, London Road HQ

description: General public services

legalName: East Ayrshire Council

Sweco UK Limited

locality: Leeds

postalCode: LS7 4DN

streetAddress: Grove House, Mansion Gate Drive

legalName: Sweco UK Limited

Anderson Strathern LLP

postalCode: EH3 8EY

streetAddress: 1 Rutland Court

Scottish Government

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

description: General public services

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

Social Security Scotland

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House, 17 South Union Street

description: General public services

legalName: Social Security Scotland

Venesky-Brown Recruitment

postalCode: EH1 2AS

streetAddress: 4A Rutland Square

Comhairle nan Eilean Siar

locality: Stornoway

postalCode: HS1 2BW

streetAddress: Council Offices, Sandwick Road

description: General public services

legalName: Comhairle nan Eilean Siar

Econ Engineering Ltd

locality: Ripon

postalCode: HG4 1UE

streetAddress: Boroughbridge Road

The City of Edinburgh Council

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

Whereverly Limited

postalCode: EH3 7LB

streetAddress: 2 Walker Street

postalCode: DD1 4NY

streetAddress: Compass House

postalCode: EH12 9DB

streetAddress: The Granary, Roddinglaw Business Park

Highlands and Islands Enterprise

locality: Inverness

postalCode: IV2 5NA

streetAddress: An Lòchran

Hall Aitken

postalCode: G2 6AE

streetAddress: 45 Hope Street

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Jack Dryburgh

description: Health

description: General public services

legalName: Fife Council

Capability Scotland

postalCode: EH12 5HG

streetAddress: Osborne House

Venesky Brown Ltd

streetAddress: 4a Rutland Square

legalName: Venesky Brown Ltd

A.C. Nielsen Company Limited

locality: Oxford

postalCode: OX4 2WB

streetAddress: AC Nielsen House

North East Scotland College

locality: Aberdeen

postalCode: AB25 1BN

streetAddress: Aberdeen City Campus, Gallowgate

description: Education

legalName: North East Scotland College

North Offshore Ltd

postalCode: AB12 3PG

streetAddress: Saltire House, Blackness Avenue,

Dumfries and Galloway Council

description: General public services

Angus Council

description: General public services

East Lothian Council

description: General public services

Education Scotland

description: Education

Langstane Press

streetAddress: 28B Firth Road, Houstoun Industrial Estate

Perth & Kinross Council

description: General public services

Forestry and Land Scotland

description: Environmental protection

Midlothian Council

description: General public services

Moray Council

description: General public services

XMA Limited

streetAddress: Junction 24 Business Park, Pavilion 2, Helen Street, Glasgow

boxxe Limited

streetAddress: The e-centre, Coopergate Way Business Village

Stirling Council

description: General public services

Scottish Enterprise

description: Economic affairs

name: Clyde Valley Housing Association Limited

description: Housing and community amenities

Falkirk Council

description: General public services

Forth Valley College

description: Education


description: Refurbishment of St. Josephs School

title: St Joseph's School Phase 3

title: St Joseph's School Phase 3

description: Toilets, Windows and P1 Classroom Refurbishment Works.

title: 8355 Invitation to Tender

title: 8355 MW Prelims

title: 8355 PCI

title: 8355 Selection Criteria

title: 8355 SPD March 2021

title: 8355 TQA revised

title: 150336 St Joseph's RC SER Certificate 392077

title: 150336 St Joseph's RC School Structural Spec

title: Client Restriction Checklist

title: Drawings

title: Electrical

title: Mechanical

title: NBS Primary 1

title: NBS Toilets

title: NBS Windows

title: P361986 St Josephs School Survey Report Rev 2

title: P371731 St Josephs School Survey Report

title: Refurbishment of traditional windows

title: St. Joseph’s RC School J064513

title: St. Joseph's RC School J061135

title: Window Schedule

title: 8355 St Josephs School Refurbishment Phase 3 Tender Pricing Document

Aberdeen City Council

postalCode: AB16 5GB

streetAddress: Woodhill House, Westburn Road

description: General public services

legalName: Aberdeen City Council

name: Head of Commercial and Procurement Shared Services

Aberdeen Sheriff Court

postalCode: AB10 1WP

streetAddress: Castle Street

legalName: Aberdeen Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730847.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:730847)


description: Tenders will be subject to a quality assessment. The overall score will be ascertained on the basis of a cost:quality assessment in the ratio of 70:30.

description: Borders General Hospital,Melrose,Roxburghshire,TD6 9BS

title: Mobile Unit Enabling Works - Borders General Hospital

description: The project comprises hard and soft landscaping alterations car parks and access roads at Borders General Hospital, Melrose.

title: 23091 - Mobile Unit Enabling Works - BGH - Tender Document

title: Design Information

title: Contractor's Quality Questionnaire.

title: Tender Document - Excel

title: Lamppost Details

title: traffic sign drawing schedule

title: traffic sign drawing schedule 2

streetAddress: TBC

description: TBC

performanceTerms: See Tender Document

description: See Tender Document

Thomson Gray

postalCode: EH2 1DF

streetAddress: Prospect House, 5 Thistle Street

description: Health

legalName: Thomson Gray

Scottish Courts & Tribunal Service

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Scottish Courts & Tribunal Service

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730854.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:730854)