description: Structures and Building and Construction and Manufacturing Components and Supplies

title: Supply of Boardwalk Material - Royal Coast Track

title: Request For Tender Oct 15 Boardwalk Materials.docx

title: LFcontractGoodsServicesRFT Oct15_Boardwalk Materials.docx

title: Final Boardwalk Designs- Royal Coast Track-Environmental Partnership.pdf

Composite Engineering Pty Ltd

streetAddress: 23 Paw Paw Rd, Brooklyn

legalName: Composite Engineering Pty Ltd

Envirowalk Grating

streetAddress: 13 Katrina St, Lake Heights

legalName: Envirowalk Grating Pty Ltd

GZ Engineering

streetAddress: 4 Poley Cow Lane, Jindabyne

legalName: GZ Engineering

IR Composite

streetAddress: 83 - 85 Banbury Road, Reservoir

legalName: Integrated Recycling

Metwest Engineering Pty Ltd

streetAddress: 18 Lee Holm Rd, St Marys

legalName: Metwest Engineering Pty Ltd

Scavenger Supplies Pty Ltd

streetAddress: 15 Waverley Drive, Unanderra

legalName: Scavenger Supplies Pty Ltd

name: Scully Outdoor Desings Australia Pty Ltd

streetAddress: PO Box 2074, Taren Point

legalName: Scully Outdoor Designs Australia Pty Ltd

streetAddress: Unit 6, 7 - 9 Streiff Road, Wingfield

legalName: Sustainable Infrastructure Systems (Aust) Pty Ltd

wagners cft manufacturing pty ltd

streetAddress: 339 Anzac Av, toowoomba

legalName: wagners cft manufacturing

Weldlok Industries

streetAddress: 117-153 Rookwood Road, Yagoona

legalName: Weldlok Industries

title: RFT Addendum 1 OEH-509-2015.pdf

rationale: Addendume Number 1

description: The goods required is for the construction of 1.5 kilometres on the Royal Coast Track, located in Royal National Park.  The goods are to be sourced and transported to National Parks and Wildlife Service workshop in the Royal National Park.

Identifiers:
South East Sydney
Illawarra


scheme: UNSPSC

title: Henry Deane Building Fit-outs

status: complete

RFTAccess: Restricted - Public View Detailed

title: DJ 2015 - 36_Tender documents.zip

format: zip

documentType: tenderNotice

title: DJ 2015 - 36 - Addendum 1.zip

documentType: amendments

rationale: Addendum 1

tenderType: Selective Tenders

description: Fit-out works to be undertaken at 20 Lee Street Haymarket. Works to be done on Levels 5 & 6. Each floor will be completed in stages being Stage 1 and stage 2 as per drawings and specifications provided.

eTenderStatus: published

inheritanceType: RFT

scheme: xNSWRegions

Identifiers:
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

submissionMethod: written ElectronicSubmission

procurementMethod: selective

submissionMethodDetails: Soft copy

eTenderProcurementMethod: Selective Tenders

initiationType: tender


description: Switchgear systems

title: 33KV INDOOR SWITCHGEAR AT TAREE SUBSTATION

RFTAccess: Open

title: Part 1 Technical Specification.zip

title: Part 2 Commercial Requirements...zip

title: Part 3 Drawings.zip

title: Part 4 Reference Documents.zip

title: Returnable Documents..zip

title: RFT Preview Document

format: application/pdf

rationale: Refer to Additional Details / Instructions. Amendment of the Extend of Work in C1429 Summary of Specification.

title: Addendum No 1...zip

rationale: Issue of Addendum No 1

title: 1429 Addendum No 2.zip

rationale: Issue of Addendum No 2

tenderType: Open Tenders

description:
TransGrid requires new 33kV indoor switchgear with a combined control/protection system to be installed in a switchgear building at TransGrid’s Taree substation.

The Work under the Contract as detailed in this Specification covers all works necessary for the design, provision of interfacing information, manufacture, test at Works, provision of “As Manufactured” drawings for the switchgear and switchgear accessories, transport and delivery to the nominated Site and subsequent erection for the 50Hz, 33kV indoor switchgear. The Concept Drawings provide additional information in relation to the intention of the Work.

The Work also includes the provision of all design, services, labour, materials, consumables, equipment and supervision necessary for the completion of Works.

procurementMethod: open

submissionMethodDetails:
Extent of Work (RFT Preview Documents - Amendment of C1429 Summary of Specification)

TransGrid requires new 33kV indoor switchgear with a combined control/protection system to be installed in a switchgear building at TransGrid’s Taree substation. The acceptable type of switchgear includes GIS and Air/SF6 Encapsulated Metal Clad Switchgear. Outdoor air insulated switchgear is not accepted. The control/protection IEDs will be provided by TransGrid.

The Work under the Contract as detailed in this Specification covers all works necessary for the design, provision of interfacing information, manufacture, test at Works, provision of “As Manufactured” drawings for the switchgear and switchgear accessories, transport and delivery to the nominated Site and subsequent erection for the 50Hz, 33kV indoor switchgear. The Concept Drawings provide additional information in relation to the intention of the Work.

The Work also includes the provision of all design, services, labour, materials, consumables, equipment and supervision necessary for the completion of Works.

General ratings of the switchgear are specified in the table below:

Switchbay

Number of Switchbay

Fault Rating / kA

Load Current (Continuous) / A

33kV Line/Feeder bay

6

25

2000

33kV Transformer bay

2

25

2000

33kV Bus Bar

2

25

2500

X/R Ratio = 14

eTenderProcurementMethod: Open Tenders


description: Architect associations

title: Tweed Heads South Public School and Alstonville Public School - New Lifts and Integration Works

title: 1500340 Consul RFT.doc

format: application/msword

title: 1500340 Tweed Heads Sth PS and Alstonville PS New Lifts Int Works.zip

title: 06 THSPS Sched of Works.pdf

title: 07 APS OT Report.pdf

title: 08 APS AsbestosRegister.pdf

title: 09 THSPS AsbestosRegister.pdf

title: 1500340 Add 01 notif.pdf

format: pdf

title: 1500340 Att04 Likorall.pdf

title: Addendum 1 APS.zip

title: Addendum 1 THPS.zip

rationale:
Addendum No. 1

Addendum No. 1 is to be bound into the tender documents.

description:
This is a selective RFT. The selected firms are listed below.

1 x new lift and minor refurbishments at each School to meet accessibility standards.

timeframeDelivery: 6 weeks

submissionMethodDetails:
NOTES TO PARTICIPATING FIRMS
 To access the RFT files and to lodge a response you must use the Access PassCode provided to you by the contact officer.

 Obtaining the RFT Documents
 Click on the DOWNLOAD A SOFT COPY - Free  link at the bottom of the page, use the Access Passcode provided to gain access, then register your firm in the system (if not previously  registered), and follow onscreen instructions to download the RFT document files provided.

Lodging a Response

*Electronic Submissions ONLY via NSW Government etendering website: https://tenders.nsw.gov.au

As the tenderer you must be a current Registered user of this web site.
 Click on the blue LODGE ON RESPONSE link at the bottom of this page, using the Access Passcode, then using your registered system  Login Username and Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Electronic Tender Box Security
 During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.
 All responses that are received successfully can only be accessed, decrypted, retrieved and opened after the RFT has officially closed.

RFT Response - receipt/confirmation
 A detailed system generated electronic receipt is issued for all submitted responses files received successfully.

Software Requirements
 To be able to view the requirements within the RFT you will require the following software to be installed on your PC:
 * Adobe Acrobat Reader  5.0 (or more recent) - Please click here
 Adobe Acrobat Reader  to be taken to their free download site now.
 * Winzip  7.0 (or more recent) or equivalent - Please click here
 Winzip    to be taken to their free evaluation download site now.
 The RFT may also requires the following software:
 * Microsoft - Word 2003
 * Microsoft - Excel 2003

Other requirements:
 Internet connection to lodge completed tender response
 The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation:
Tender responses will ONLY be considered from the selected prequalified firmst listed below:

*  Tom Bond & Associates Architect - ABN: 42 814 173 328

*  Oceanarc Architects Byron Bay - ABN: 56 757 486 448

*  Graeme Barr Architects - ABN: 11 460 964 006


description: Environmental management

title: Monitoring and Evaluation Tool for Regional Waste Strategies- EOI

title: M and E tool EOI Doc  12 05 15.doc

title: Appendix 1- Blank Survey questions 2012-13.pdf

title: Appendix 2- LG Survey User Guide 2010-11 .pdf

title: Appendix 3- Sample Historic 5yr Data .xlsx

region: QLD

countryName: AUSTRALIA

streetAddress: PO Box 222, Browns Plains

legalName: Amtac Professional Services Pty Ltd

Graham A Brown & Associates

region: NSW

streetAddress: 1st floor, 7 Newcomen Street, Newcastle

legalName: Archdall Investments Pty Ltd

SmarterSoft

streetAddress: Suite 16A, Level 2, 428 George Street, Sydney

legalName: AREANET Pty Ltd

ASPECT Studios Pty Ltd

region: VIC

streetAddress: Level 1, 30 - 32 Easey Street, Collingwood

legalName: ASPECT Studios Pty Ltd

Australian Survey Research

streetAddress: Level 1, 600 North Road, Ormond

legalName: Australian Survey Research

streetAddress: 22 Eleventh Avenue, Sawtell

legalName: Coffs Coast Environmental Services

Consilium Waste Consulting

region: WA

streetAddress: 3/8 Norman Street, St James

legalName: Consilium Waste Consulting

Data Agility Pty Ltd

streetAddress: Level 1, 115 Collins Street, Melbourne

legalName: Data Agility Pty Ltd

streetAddress: Ground Floor, 302 Burwood Road, Hawthorn

legalName: Datalink Internet Systems Pty Ltd

streetAddress: 225 George St, Sydney

legalName: Deloitte

Dialog Information Technology

streetAddress: Level 5, 107 Mount Street, North Sydney

legalName: Dialog Pty Ltd

streetAddress: 3 Frederick St, Petersham

legalName: East River Software Pty Ltd

streetAddress: 680 George Street, Sydney

legalName: Ernst & Young

region: Wellington

countryName: NEW ZEALAND

streetAddress: Level 6, Eagle Technology House, 135 Victoria St,

legalName: FINNZ

streetAddress: B2, 12-14 Solent Circuit Norwest Business Park, Baulkham Hills

legalName: integrum Management Systems

streetAddress: Level 1, 204 Clarence St, Sydney

legalName: Kinesis PTY LTD

KINSHIP digital

streetAddress: lvl 8, 153 Walker St., North Sydney

legalName: KINSHIP digital Pty Ltd

Leith Consulting Services

streetAddress: 313 Pacific Highway, Lindfield

legalName: Leith Consulting Services Pty Ltd

streetAddress: 37 Merivale Street, South Brisbane

legalName: Mandalay Technologies

streetAddress: 11, Pennant Hills

legalName: Metreco

Mike Ritchie and Associates

streetAddress: Suite 413, 19 Roseby Street, Drummoyne

legalName: Mike Ritchie and Associates

streetAddress: Level 25/100 Miller St, North Sydney

legalName: Object Consulting Pty Ltd

Predictive Analytics Group

streetAddress: 7/175 Collins Street, Melbourne

legalName: Predictive Analytics Group

streetAddress: Darling Park, Sydney

Gaia Resources

streetAddress: First Floor, Building B, 661 Newcastle Street, Leederville

title: ME tool EOI amendment 1 re closing date 18 Jun 15.doc

rationale: Amdment Number 1 - Closing date has been extended to: 10:00am on Thursday 2 July 2015

title: ME tool EOI addendum no  3.doc

title: Attachment 1 Briefing session QandA Final 22 06 15.docx

title: Attachment 2 Information Session presentation 17 06 15.pptx

rationale:
Amendment number 3:

Attachment 1 - Q&A

Atthachment 2 - Presentation

title: M and E tool EOI amendment 4 re ICT list.doc

rationale: Amendment Number 4

title: Tender Amendment Notification.doc

title: SMCFC-Location-Map.pdf

rationale: Amendment number 1 - An Industry briefing session will be held on Wednesday 17 June 2:30 to 4:30pm. A location map is attached to this amendment notice.

tenderType: Expression of Interest for Specific Contracts

description:
To develop a monitoring and evaluation (M&E) tool for the regional waste strategies. The proposed M&E tool will help the EPA and regional waste groups to assess the performance of the 14 regional waste strategies.

The proposal includes integrating the Annual Local Government Waste and Resource Recovery (WARR) Data Return Survey into the M&E tool. Local Government officers will complete the data survey by accessing the M&E tool. The integration of the data return survey with the M&E tool will allow waste coordinators to track changes in actual waste and recycling tonnage data against completed actions in their strategies. The EPA and local council officers will also have access to the data from the survey through the tool.
The M&E tool will also include a searchable database for the Better Waste and Recycling Fund projects.

Identifiers:
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney


description: Lease and rental of property or building

title: Out of School Hours Care Facility - Gillieston Public School

title: Attachment D  RFT 1010012519821612 PART A -Tender Conditions.pdf

title: Attachment E   RFT 1010012519821612 Part B- Statement of Requirements.pdf

title: Attachment F   RFT 1010012519821612- Part C- Tender Response Schedules.doc

title: Gillieston OSHC Site plan.pdf

title: Gillieston PS - Licence Agreement.pdf

description:
Applications are invited for the opportunity to provide services to establish and operate an Out of School Hours Care and Vacation Care Facility at Gillieston Public School.

See Attachment B of the Guide for Selection of Community Users of School Facilities available at the following link:-

http://www.dec.nsw.gov.au/our-services/schools/community-use-of-school-faciliti

Identifiers:
Central Coast
Hunter

addressForLodgement: Via Tenders NSW only

submissionMethodDetails:
OSHC services are regulated by the Department of Education Early Childhood Education & Care Directorate. Please refer to the Department of Education internet for more information:-

http://www.dec.nsw.gov.au/our-services/children-and-youth

Only information submitted on Response Schedules will be assessed.

Please do not include any attachments unless requested in the Response Schedules.

conditionsForParticipation:
Only information submitted on Response Schedules will be assessed.

Please do not include any attachments unless requested in the Response Schedules.

Interested tenderers responding to this RFT must ensure that they (including associated entities in any other State in Australia and proposed staff) are able to comply with all conditions of this RFT document and all relevant Regulations and Acts including Privacy Act at all times. This is a mandatory condition and applies throughout the tender process and duration of the Agreement entered into by the Tenderer if successful. Any non-compliance issue occuring during any stage of the tender process may result in rejection of the proposal by the Department and/or termination of the Agreement if the latter is executed.


title: Out of School Hours Care Facility - Rathmines Public School

title: Attachment D    RFT1010012522591614  PART A -Tender Conditions V1.pdf

title: Attachment E    RFT1010012522591614  Part B- Statement of Requirements V1.pdf

title: Attachment F    RFT1010012522591614 Part C- Tender Response Schedules.doc

title: Rathmines PS OSHC Site plan.pdf

title: DoE - OSHC Licence Proforma Nov 14.pdf

description:
Applications are invited for the opportunitity to provide services to establish and operate an Out of School Hours Care and Vacation Care Facility at Rathmines Public School.

See attachment B of the Guide for Selection of Community Users of School Facilities available at the following link:-

http://www.dec.nsw.gov.au/our-services/schools/community-use-of-school-faciliti

submissionMethodDetails:
OSHC Services are regulated by the Department of Education Early Childhood Education & Care Directorate. Please refer to the Department of Education internet for more information:-

http://www.dec.nsw.gov.au/our-services/children-and-youth


description: Residential building construction services

title: LAHC - Construction of 3x4 bedroom single cottages at Minto

title: GC21 Notice to Tenderer  07 03 13.doc

title: 01.1 Project Specific Documents - Part 1.pdf

title: 01.2 Project Specific Documents - Part 2.pdf

title: 02 Standard Documents.pdf

title: 03 Drawings - Architectural.pdf

title: 04 Drawings - Hydraulic Survey.pdf

title: 05 Drawings - Landscape Structural.pdf

title: 06 Returnable Tender Form and Schedules.doc

Berlina Projects

streetAddress: Unit 1/ 27 Toohey Road, Wetherill Park

legalName: Berlina Homes Pty Ltd

Southern Vale Constructions

streetAddress: 14/151 Hartley Road, Smeaton Grange

legalName: Big G trading Pty Ltd

streetAddress: 42 Beresford Avenue, Greenacre

legalName: E Galasso Pty Ltd

streetAddress: 38 Oakleigh Ave, Thornleigh

legalName: H & N Khamis PTY LTD

description: Construction of 3x4 bedroom single cottages at156A Eagleview Rd (Job number: BGMEN), 196 Eagleview Rd (Job number: BGMEP) & 196A Eagleview Rd (Job number: BGMEQ), Minto

addressForLodgement: Electronic tender responses through this site ONLY

submissionMethodDetails:
THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

Suppliers who wish to be invited to join this register when it is refreshed, should direct their email to Suppliers.Panels@facs.nsw.gov.au .   Please include your company address and contact person details.

DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / trading name / postal address / email address etc )

Steps for submitting your tender:

1.     Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)

conditionsForParticipation: Access to this RFT documentation is restricted to selected tenderers.  Those tenderers have been issued with the special Access Passcode (10 alphanumeric character) required by this RFT


description: Civil engineering

title: Construction of Gross Pollutant Traps and Myrtle Brush Park, Berkeley Vale and Oleander Street, Canton Beach

title: 1 RFT GPT Berkeley Vale and Canton Beach CPA264742.pdf

title: 1 Return Sched - Berkeley Vale and Canton Beach CPA264742.docx

title: 2 Spec and Drawings-Berkeley Vale and Canton Beach CPA264742.pdf

title: 3 Part 5 EIA GPT CPA264742.zip

title: 4 Geotech Report GPT CPA264742.zip

title: 5 Arborist Report GPT CPA264742.zip

title: 6 Safety in Design Report GPT CPA264742.zip

Deloma Pty Ltd

streetAddress: 5 McAdam st, Aberdeen

legalName: Deloma Pty Ltd

streetAddress: 110 Stenhouse Drive, Cameron Park

legalName: Gongues Constructions

Kerroc Constructions Pty Ltd

streetAddress: 12 Immaculata Place, Tumbi Umbi

legalName: Kerroc Constructions Pty Ltd

streetAddress: suite 1/16 Church st, Terrigal

legalName: Scape Constructions

description:
Supply and construct three Gross Pollutant Traps in accordance with Design Plans and Specification.  Two (2) GPT’s are proposed at Berkeley Vale, and one (1) GPT is proposed at Canton Beach   All work to be completed within 12 weeks from award of contract in a safe, cost effective and environmentally responsible manner.

Due in part to the approximate 20km geographic separation, each site is being treated as a Separable Portion under this Contract:

• Separable Portion No.1 - Myrtle Brush Park at Berkeley Vale (2 GPT’s)

• Separable Portion No.2 - Oleander Street at Canton Beach (1 GPT)

The Contractor is expected to coordinate the construction of all GPT’s simultaneously, so the works are completed within the specified timeframe (12 weeks).

The Key Deliverables for this project include:

Preconstruction activities and documentation

Locate and protect utility services prior to works

Supply and implement effective safety and environmental controls, and monitor during works.

Remove and dispose one (1) mature Cabbage Palm tree from Canton Beach GPT site.

Construct suitable temporary all-weather vehicular access to worksite (during works), including any necessary culverts for adequate surface water flow.

Construct permanent all-weather vehicular access to GPT (site 1) at Berkeley Vale in accordance with the Specification and supplied Project Drawings.

Setout works.

Partially cut and demolish existing channel wall and floor, and other items identified in the supplied set of Project Drawings.

Carry out all necessary earthworks to achieve design levels for the new GPT system in accordance with the supplied set of Project Drawings.

Transport and disposal of waste material and excess spoil to licenced landfill or recycling facility by Contractor.

Supply, install and maintain suitable dewatering and trench/excavation support necessary for the works.

Supply, install and maintain suitable acid sulphate soil and water management procedures and equipment, if necessary for the works.

Supply and construct all Concrete components for the new GPT system in accordance with the supplied set of Project Drawings, including but not limited to concrete weirs, side walls, GPT floors, pads, slabs, ramps, sumps, etc.

Supply/Fabricate and Install all Steelwork components for the new GPT system in accordance with the supplied set of Project Drawings.

Supply and install floating booms (Berkeley Vale GPT site only).

Construct new permanent concrete driveway (and new kerb and gutter access) in accordance with the supplied set of Project Drawings.

Supply and install new safety fencing and gates in accordance with the supplied set of Project Drawings.

Restore the construction sites, storage area/s, and adjacent roadway to pre-construction condition or better.

Supply Work as Executed drawings

Identifiers:
Mid North Coast
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney

submissionMethodDetails: No site establishment or works are permitted at the Canton Beach GPT site until 1 February 2016 due to the GPT being located within the Canton Beach Tourist Park.


description: Immunohistochemistry autostainer

title: 940 Immunohistochemistry Advanced Staining Devices.zip

description:
 DRAFT FOR COMMENT ONLY

Supply and delivery of Immunohistochemistry Advanced Staining Devices to NSW Health and other eligible clients.

multiAgencyAccessType: All Agencies


description: Sewage pumping station

title: Upgrade of Sewage Pump Station WS11

title: RFT - Upgrade of SPS WS11 - CPA261063.pdf

title: Attachment 1- RFT Returnable Schedule - Upgrade of SPS WS11.docx

title: Attachment 2 - Specification - Upgrade of SPS WS11.pdf

title: Attach 2 - Specification - Appendix A B C D E COMBINED.pdf

title: Attach 2 - Specification - Appendix F G H I J COMBINED.pdf

title: Attach 2 - Specification - Appendix K L COMBINED.pdf

title: Attachment 3 - Drawings.pdf

Eire Constructions Pty Ltd

streetAddress: 28 Birralee Drive, WAUCHOPE

legalName: Eire Constructions Pty Ltd

Gongues Construction Pty. Ltd.

legalName: Gongues Constructions Pty. Ltd.

streetAddress: L3, 49-51 Stead Street, South Melbourne

legalName: Leed Engineering and Construction Pty Ltd

McNamee Constructions Pty Ltd

streetAddress: P O Box 332, Wyong

legalName: McNamee Constructions Pty Ltd

title: Addendum 1 - Upgrade SPS WS11 - CPA261063.pdf

rationale:
This Addendum consists of:

Item A) Minutes from Pre-Tender Meeting for Contract CPA/249912

Item B) Response and Clarifications to Questions raised during advertising of the Tender for Contract CPA/249912

Item C) Safety in Design Risk Assessment

title: Addendum 2 - Upgrade SPS WS11 - CPA261063.pdf

title: Addendum 3 - Upgrade SPS WS11 - CPA261063.pdf

title: Addendum 4 - Upgrade SPS WS11 - CPA261063.pdf

rationale:
This Addendum consists of:

Item A) Response and Clarifications to Questions raised during advertising of the Tender for Contract CPA/249912

Item B) Revised Electrical Drawings

title: Addendum 5 - Upgrade SPS WS11 - CPA261063.pdf

title: Addendum 6  - Upgrade SPS WS11 - CPA 261063.pdf

rationale:
This Addendum Consists of:

Item A) Minutes from Pre-Tender Meeting for Contract No CPA/261063

description:
Wyong Shire Council’s Sewage Pumping Station (SPS) WS11 is scheduled for an upgrade to address a number of service deficiencies including insufficient emergency storage, odour issues and reliability of the existing emergency relief system.

SPS WS11 is located in Apex Park, Wyong at street address 150 Pacific Highway Wyong, NSW 2259. Access to the site is via an access road that connects North Road and Cutler Drive. The pumping station receives the discharge from a gravity catchment as well as 26 subsidiary stations and then pumps some 5.2 km along a rising main to the inlet works of the Wyong South wastewater treatment plant.

Full details of the scope of work and any exclusions are included in the attached Specification (Attachment 2) and Drawings (Attachment 3).

A mandatory pre-tender meeting will be held at SPS WS11, Apex Park Wyong, commencing at 10 am on Tuesday, 9 June 2015. Tenderers who attended the previous pre-tender meeting for Contract No. CPA/249912 do not need to attend.

This is lump sum contract based on AS2124-1992 General Conditions of Contract. The contract period for completion is 52 weeks from the date of the Letter of Acceptance of the Tender.

The tendered lump sum must include all costs necessary to provide the works under the Contract including without limitation the cost of all personnel, materials, plant and equipment, fuel, consumables, mobilisation, demobilisation, support systems, overheads, profit, travelling time, expenses, disbursements, fees and charges and all other associated costs.

The fee and rates are fixed and not subject to escalation or review

Council is seeking to use this Request for Tender as a basis for entering into a Contract with the Preferred Tenderer.

This Request for Tender was previously advertised as Contract No. CPA/249912 – Upgrade of Sewage Pump Station WS11 between December 2014 - February 2015. Changes made to the original Request for Tender documents have been marked in bold and RED, which include significant changes to the Evaluation Criteria (Clause 2.5.12). Attachment 2 – Specification, is unchanged from the original tender.

Identifiers:
QLD
VIC
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands


description: Management and Business Professionals and Administrative Services

title: Industry Briefing for External Providers: NSW Public Sector Aboriginal Employment Strategy 2014 - 2017

id: Industry Briefing -Aboriginal Employment Strategy-1

title: 12967287-1-200519659.pdf

rationale:
Notice for briefing registration:

If you are interested in attending the briefing, please follow the link to the registration page: www.psc.nsw.gov.au/aesbriefing

rationale: Note change of online content.

rationale:
Notice: Registrations to attend this event have now closed however we are providing a live web cast for the event. Please register here to receive details about the live web cast service.

Dear Colleagues

The Public Service Commission (PSC) is inviting all external providers of HR services and other relevant services, whether on a prequalified scheme or not, to an industry briefing on Friday, 15 June 2015.

This briefing will provide the opportunity to hear directly from the Deputy Commissioner of the PSC regarding the recently released NSW Public Sector Aboriginal Employment Strategy 2014 2017 and the initiatives within this Strategy. The briefing will also address:

·        How the NSW Public Sector Aboriginal Employment Strategy may change the way you provide services to the Government Sector.

·        Modernising the statutory arrangements to promote workforce diversity and the importance of workforce diversity.

·        Procurement of services in the NSW Government Sector and the Prequalification Scheme.

Registrations to attend this event have now closed however we are providing a live web cast for the event. Please register here to receive details about the live web cast service.

Details of the briefing are:

Date:      Monday, 15 June

Time:     9.00am to 10.30am

Place:    The Mint, 10 Macquarie Street, Sydney NSW 2000

RSVP:    Closes at 9:00am on 12 June

There will be an opportunity to send through questions via the web cast during Q & A time.

We look forward to receiving your RSVP.

Kind Regards

Aboriginal Workforce Development Team

tenderType: Notice

description:
Dear Colleagues

The Public Service Commission (PSC) is inviting all external providers of HR services and other relevant services, whether on a prequalified scheme or not, to an industry briefing on Friday, 15 June 2015.

This briefing will provide the opportunity to hear directly from the Deputy Commissioner of the PSC regarding the recently released NSW Public Sector Aboriginal Employment Strategy 2014 2017and the initiatives within this Strategy. The briefing will also address:

How the NSW Public Sector Aboriginal Employment Strategy may change the way you provide services to the Government Sector.

Modernising the statutory arrangements to promote workforce diversity and the importance of workforce diversity.

Procurement of services in the NSW Government Sector and the Prequalification Scheme.

We are exploring the option of providing a live web cast for the event. Please express your interest in the live web cast via email to the Aboriginal Workforce Development Team.

Details of the briefing are:

Date:      Monday, 15 June

Time:     9.00am to 10.30am

Place:    The Mint, 10 Macquarie Street, Sydney NSW 2000

RSVP:  www.psc.nsw.gov.au/aesbriefing  by Wednesday, 10 June 2015

There will be the opportunity at the briefing to ask questions of the Director, Leadership and Values.

We look forward to receiving your RSVP and welcoming you on the day.

Kind Regards

Aboriginal Workforce Development Team

Identifiers:
ACT
NT
QLD
SA
TAS
VIC
WA
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

addressForLodgement: For more information you can contact Shantala Prior on 02 92725155, or email aboriginalworkforce@psc.nsw.gov.au.<br />If you are interested in attending the briefing, please follow the link to the registration page: www.psc.nsw.gov.au/aesbriefing

submissionMethodDetails:
Refer to the attached Industry Briefing document.

If you are interested in attending the briefing, please follow the link to the registration page: www.psc.nsw.gov.au/aesbriefing

eTenderProcurementMethod: Notice

conditionsForParticipation: This is a notice for an industry briefing.


description: Civil engineering

title: Improvements to Brou & Moruya Waste Management Facilities

title: Brou Landfill Tender Documents.pdf

title: A - EPA Licence No 5881 Brou.pdf

title: B - GS75A-r1-Brou Landfill Geotech Report - Mar 2015.pdf

title: C - 20150511_DC15027_Concept Design Report - excl Cost Estimates.pdf

title: D - DC14237_A Moruya_Brou_16Dec2014 - Document Review- Final.pdf

title: DWGS - Moruya Landfill Earthworks - Detail Design Rev A.pdf

title: DWGS - Brou Landfill Stage 2 Works - Detail Design Rev B.pdf

title: c gc21_ed2_tender_schedules final.doc

title: Addendum No 1 - RFT No 1500107.pdf

rationale:
Addendum 1:  Conditions Of Tendering Clause 5.2  Pre-Tender meeting;

Substiute with : Attendance by tenderers at the pre-tender meeting is NON mandatory.

title: RFT 1500107 - Addendum No 2.pdf

rationale: Addendum 2:  Changes to Earthworks Clause 1.2, Minutes of Pre-Tender meeting, Attendance Sheet and Estimated quantities.

title: Addendum No 3 - RFT No 1500107.pdf

rationale: Addendum 3:  Clarifications for questions raised.

title: Addendum No 4 - RFT No 1500107.pdf

rationale: Addendum 4:  Replace Technical Specification Section 10 Liner with attached substitute for Section 10 Liner.

title: Addendum No 5 - RFT No 1500107.pdf

rationale:
Addendum 5:  Clarfications to Drawing 1503 - C1120B & C1121B.

Extension of Tender closing Date:  The tender closing time/date has been extended to 9.30am Tuesday 11 August 2015 due to the above clarification.

title: Addendum No 6 - RFT No 1500107.pdf

rationale: Addendum 6:  Clarifications to Tender Schedules, CADD Models and Liner Specification.

timeframeDelivery: 20 weeks

addressForLodgement: Electronic Tender box is at -   https://tenders.nsw.gov.au

submissionMethodDetails:
Documentation available for this RFT.

A softcopy only of the whole specification including a separate softcopy of the returnable schedules is available for downloading by following the instructions below.

Obtaining RFT Documentation

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

Softcopy Document

An electronic version of the specification and returnable schedules can be downloaded from this web site free of charge.

To obtain the provided specification and schedules from this web site download all the provided files by clicking on the "DOWNLOAD A SOFT COPY" link at the bottom of this page and following the on screen instructions.

Hardcopy Copy is not available for this Document

Submitting your response - Electronic Lodgement

When you have completed your response you can lodge it electronically via this Web Site.

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC Software requirements:

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

            Adobe ® Acrobat Reader ® 5.0 (or more recent)

            WinZip ® 7.0 (or more recent) or equivalent

Additional software may also be required, including the following, depending on the file types provided:

            Microsoft ® Word 97 (or more recent) or equivalent.

            Microsoft ® Excel 97 (or more recent) or equivalent.

Other requirements

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows – IE version 5.5 or later with Cipher Strength = 128bit.

Cookies.

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

Still having problems?

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the “FAQ” section under the On-line ?HELP button at the top of this page.

conditionsForParticipation: There is a Non-Mandatory Pre-Tender Site Meeting to be held at Brou Landfill on 23/07/2015 at 10.00am


description: Building and Facility Construction and Maintenance Services

title: Mount Wilson Village Hall Upgrade

title: Invitation to Tender 1.docx

description: Council, through this Request for Tender (RFT) No 2015/16-W028-510, is seeking an experienced Construction Contractor to undertake the construction of new disability accessible toilet facilities, entry additions, external works and fire resistance upgrade to existing building, to the Mt Wilson Hall 34 The Avenue, Mt Wilson in accordance with the attached drawings and Specification.

submissionMethodDetails: Tenders must be accessed and lodged online at http://360prop3.apetsoftware.com.au/Public/BMCCPro3/PublicJobs.aspx(“Electronic Tender Box)

conditionsForParticipation:
The Tenderer and any nominated subcontractor(s) must not be bankrupt or insolvent.

Tenderers must provide details of instances where, within five (5) years prior to submitting their Tender, they have been found guilty of breaching any Act or Regulation, including but not limited to:

·   Workplace Relations Act 1996 (Cth)

·   Industrial Relations Act 1996 (NSW)

·   Work Health & Safety Act 2011 (NSW) and/or its predecessor Occupational Health & Safety Act 2000 (NSW)

·   Workplace Injury Management & Workers Compensation Act 1998 (NSW)

·   Equal Opportunity for Women in the Workplace Act 1999

·   Disability Discrimination Act 1992 (Cth)

·   Human Rights (Sexual Conduct) Act 1994 (Cth)

·   Racial Discrimination Act 1975 (Cth)

·   Sex Discrimination Act 1984 (Cth)

·   Age Discrimination Act 2004 (Cth)

·   Anti-Discrimination Act 1977 (NSW)

·   Disability Services Act 1986 (Cth)

·   Fair Work Act 2009 (Cth)

·   Crimes Act 1914 (Cth)

·   Criminal Code Act 1995 (Cth)

All Tenderers must comply with the NSW Government Code of Practice for Procurement (Code) that is current at the date of issue of this Request for Tender.   The ability of a Tenderer to demonstrate compliance with the Code is an essential condition of these Conditions.


description: Structural engineering

title: LAHC - Common area upgrade works at Liverpool

title: Notice to Tenderer MW21 11 09 13 TEM.doc

title: 01 Project Specific Documents - BGHG6.pdf

title: 02 Standard Documents - BGHG6.pdf

title: 03 Tender Drawings - Survey - BGHG6.pdf

title: 04 Tender Drawings - Hydraulic - BGHG6.pdf

title: 05 Returnable Schedule of Rates - BGHG6.XLS

title: 06 Returnable Tender Forms and Schedules - BGHG6.DOC

streetAddress: suite 3, Level 3, 20 Charles St,, Parramatta

legalName: Austfield Pty Ltd

Grateholt Pty Ltd

streetAddress: 23 Mary Parade, Rydalmere

legalName: Grateholt Pty Ltd

MDP Industrial Services Pty Ltd

streetAddress: 17/74 Corish circle, Eastgardens

legalName: MDP Industrial Services Pty Ltd

streetAddress: 12 Blackwood Road, Merrylands

legalName: Tradelink Construction Pty Ltd

description: Common area upgrade works - Sewer & stormwater replacement works at 63 & 65 Charles Street, Liverpool

submissionMethodDetails:
Additional Details / Instruction

THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

For any enquiries regarding joining the register for future select tenders, please direct your email to Suppliers.Panels@facs.nsw.gov.au

DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / Training name / postal address / email address etc )

Steps for submitting your tender:

1.       Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)


description: Engineering and Research and Technology Based Services

title: Power Supply Upgrade Program - Technical Advisor for the Pre-Concept Design of Granville Substation

title: TPD-14-4121 - Invitation To Tender - ITT.pdf

title: TPD-14-4121 - Tender Schedule.doc

title: Schedule 12 - ASA Matrix.xls

Aecom

streetAddress: 11, 44 Market Street, Sydney

legalName: Aecom Pty Ltd

streetAddress: 116 Military Road (PO Box 538), Neutral Bay

legalName: Aurecon Australasia Pty Ltd

streetAddress: 5 Queens Rd, Melbourne

legalName: Beca

Cardno

streetAddress: Level 9, the forum, 203 pacific highway, st leonards, sydney

legalName: Cardno

GHD

streetAddress: Level 15 133 Castlereagh Street, Sydney

legalName: GHD Pty Ltd

streetAddress: 100 Christie Street, St Leonards

legalName: Jacobs Group (Australia) Pty Ltd

streetAddress: Level 5, 20 Berry Street, North Sydney

legalName: SMEC

title: TPD-14-4121 - Addendum 1.pdf

rationale: Addendum 1 is attached

title: TPD-14-4121 - Addendum 2.pdf

rationale: Addendum 2 is attached

title: TPD-14-4121 - Addendum 3.pdf

rationale: Addendum 3 attached

description:
The Contract is to engage a suitably qualified Technical Advisor to complete the Pre-Concept Design for the Granville Substation.

The services to be provided by the Technical Advisor is outlined as follows:

Development, amendment, completion and confirmation details of proposed operations diagrams (including system, sectioning and reticulation diagrams) with input from TPD into final operating diagrams for acceptance by TfNSW;

Development, amendment, completion and confirmation of building sketches and development of Substation building pre-concept layout drawings with input from TPD;

Development of a technical specification for the Substation and all associated ancillary works. The purpose of the technical specification is to enable the Principal to include this technical specification in the tender for the design and construction Contract of the new Granville Substation;

Preparation of Review of Environmental Factors (REF) study and report; and

Provision of site investigation Services.

timeframeDelivery: March 2015 to July 2015

addressForLodgement: Electronic lodgement only - no password protection. Questions Must be submitted in writing to the email address supplied. Tenderers must submit their response as two (2) separate files only. The first is to consist of the completed "Non-Commercial Schedules" and is to exclude any reference to pricing. The second file is to consist of the completed "Commercial Schedules". Multiple separate documents will not be accepted, unless you obtain prior approval from TfNSW. This ensures that Tenders are complete and accurate, and presented in the manner intended by the Tenderer, and also allows for timely distribution of Tenders to the Tender Assessment Committee.

submissionMethodDetails: The Contract is to engage a suitably qualified Technical Advisor to complete the pre-concept design for the Granville Substation.

conditionsForParticipation:
The Tenderer must demonstrate as a minimum:

Evidence that the Tenderer is an Authorised Engineering Organisation (AEO) or is capable of obtaining Provisional AEO status from the ASA through the tender assessment process, as per Schedule 12;

Evidence that the Tenderer has successfully completed the design of two (2) electrified substations in the last five (5) years where the design engagement was valued over $250,000; and

Evidence that the Tenderer has rail design experience within their proposed team for this project.


description: Information Technology Broadcasting and Telecommunications

title: Telecommunication Tower Structures

title: RFT - Telecommunication Tower Structures 1.0.pdf

title: Attachment 2 - Guideline for Telecommunication Structure.pdf

title: Attachment 1 - Response Schedule.xlsx

title: Attachment 3 - Reference Model.zip

rationale: Attachment 3 - Reference model.

title: DFS14_12789-5 Tender Briefing.pdf

title: DFS14_12789-5 Additional Drawings.pdf

title: RFQ 12798 - Tower and Structures Briefing FINAL.pdf

rationale: Attachments for download

description:
The Authority has recently reviewed its site equipment procurement strategy to support the future strategic direction of operational telecommunications in NSW.

As a result of this review, the Authority is seeking to establish arrangements with suitable suppliers for the following items:

·         DC Power Systems

·         Huts and Outdoor Units

·         Towers

The arrangements will be made on a standing offer basis for a period of 3 years to support both the tactical deployment of new and augmented sites, as well as (subject to funding) the broader Infrastructure Rationalisation Project.

This tender relates to Towers only.

submissionMethodDetails:
OBTAINING RFI DOCUMENTS:
 Only a downloadable SOFTCOPY version of this RFT/RFI is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT/RFI will need to Self-Register to gain access to any documents.

The register link is on the top left hand corner.

 To obtain this RFT/RFI and any FUTURE related Amendments that may be issued, you must download to your computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY - Free link at the bottom of this page and follow the on-screen instructions.

LODGE A RESPONSE:
 Your completed Tender response should be lodged as required by the RFT/RFI documents.
 It can be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.

Electronic Tender Box Security
 During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site  “electronic tender box”.


items: Restricted Tender

title: Legal Aid, NSW - Tenancy Fitout of Level 1, 422 - 426 Peel Sreet, Tamworth, NSW 2340

status: Restricted Tender

RFTAccess: Restricted Tender

amendments: Restricted Tender

tenderType: Restricted Tender

description: Restricted Tender

tenderPeriod: Restricted Tender

eTenderStatus: Restricted Tender

inheritanceType: Restricted Tender

deliveryLocation: Restricted Tender

submissionMethod: Restricted Tender

multiAgencyAccess: Restricted Tender

procurementMethod: Restricted Tender

timeframeDelivery: Restricted Tender

coveredProcurement: Restricted Tender

addressForLodgement: Restricted Tender

submissionMethodDetails: Restricted Tender

eTenderProcurementMethod: Restricted Tender

conditionsForParticipation: Restricted Tender


description: Fishing ship or boat building services

title: Construct Offshore Research Vessel – 2C Certified

title: Part A - Instructions - Construct Offshore Research Vessel - 2C Certified.pdf

title: Part B - Response - Construct Offshore Research Vessel - 2C Certified.docx

title: Contract for Fisheries research boat 020915.pdf

title: Part D - Statement of Requirements - Construct Offshore Research Vessel - 2C Certified.pdf

Swift Marine

streetAddress: 19 Reichert Dve, Molendinar

legalName: Aztech Australia Pty Ltd

F & D Watsons Marine

streetAddress: 52 Wickham Street, Gympie

legalName: Faeden Pty Ltd

streetAddress: 19 Seasands Drive, Redhead

legalName: Seatamer Marine Manufacturing Pty Limited

region: Invercargill

streetAddress: 345 Bluff Road,

legalName: Stabicraft Marine Ltd

Yamba Welding & Engineering Pty Ltd

streetAddress: 4 Angourie Road, Yamba

legalName: Yamba Welding & Engineering Pty Ltd

description:
To design, construct and fit out a 6-6.5m 2C certified research vessel with trailer that is suitable for a range of research purposes within a seven month build timeframe commencing mid October 2015. The vessel must conform to the Australian Maritime Safety Authority – National Standard for Commercial Vessels (NSCV) – Scheme S and the trailer to be registered in NSW.

The beam is not to exceed 2.5m and the cock pit deck area to be a minimum area of 5.5 m2.  The boat is to fitted out with all electrical, mechanical and safety equipment including: two Suzuki or Yamaha 4 stroke motors with stainless steel propellers; Fuel tank with a range of 150-200L; and a davit with a SWL of 100kg.

 The vessel and trailer will need to be delivered, registered and certified by 30/05/2016.

DPI Fisheries

name: James McLeod, Technical Coordinator Fisheries Research


description: Pool or spa heater

title: Heater Upgrade at Max Parker Leisure & Aquatic Centre 25m Indoor Pool

title: RFQ Q34-15-Heater Upgrade Max Parker Leisure  Aquatic Centre-25m Pool.zip

title: Q34-15 Addendum 1.pdf

rationale: Addendum 1

title: Q34-15 Addendum 2.zip

rationale:
Addendum 2

Council will not consider a Quotation lodged by a Respondent who failed to sign the attendance sheet at this briefing, or failed to ensure that a representative of the Respondent signed the attendance sheet on its behalf.

description:
This description of works and the specification are for the mechanical services for there placement of the existing pool heating system on the25m indoor pool at Max Parker Leisure & Aquatic Centre. The intent of the specification is to call for finished work, coordinated, supplied, delivered, installed and tested ready for operation and guarantee to achieve the performance within the guidelines contained herein.

Should the specifications not contain anyparticulars of works, which are nevertheless clearlyto be inferred ,or minor parts which are necessaryfor the completion of the work under the Contract, all such parts shall be supplied and executed by the contractor without charge to the contract.

The works generally include but are not limited to the following components:

(1)         Preliminaries

(a)         Site establishment including temporary 1.8m high fencing around the work area and shade cloth attached it with appropriate safety signage

(b)        Preparation of and submission of a dilapidation report to the Superintendents Representative in the form of a report and photographs of all site features adjacent to the work area prior to the commencement of any work. This report must be provided prior to grant of site possession to Contractor.

(c)         Setting out of the works by as stated in sub-clause 3.2.15 (next section of this document).

(d)        Liaison with public and/or private service authorities and/or companies.

(e)         Protection and/or support of existing services.

(f)         Suppression of dust during installation

(g)        Ongoing maintenance of the work in terms of rectifying any hazards, erosion control, etc during the course of contract to practical completion

(h)         Site clean-up, restoration upon completion of works and disestablishment

(i)          Rubbish and graffiti shall be removed. Any damage to function or appearance of the works shall be rectified by the Contractor without delay at the Contractor's cost.

(2)         Civil Works

(a)         Supply and construction of a concrete slab suitable for the proposed heater units to be fixed to.

(b)        Modification of the existing fence for use around the proposed heater units

(c)         Minor excavation and restoration of turf and any other disturbed areas adjacent to work site.

(3)         Mechanical Works

(a)        Dismantleandremoval ofexistingheatpumpsfromtheexistingplantroom

(b)       Supply, installation, testing, commissioning and certification of  new 2x Rheem HWP60  heat pumps , reconnect to existing power and piping systems and make good of all openings/penetrations and any other disturbed areas

(c)         Wiring of all monitored points to the BMCS system as necessary.

(d)        Disconnect, salvage and deliver to the Superintendent four existing compressors for future use.

The Contractor shall be responsible for the supply of all labour, materials, equipment and services for the complete installation, testing and perfect operation of the systems and works in this section of the Specification.

addressForLodgement:
Method of Lodgement

Electronic lodgement at:

http://360providers.apetsoftware.com.au/Login.aspx

submissionMethodDetails:
Council will conduct a compulsory briefing for potential Respondents to be held as follows:

Time

Date

Location

02.30 PM

Tuesday, 24 February 2015

Max Parker Leisure & Aquatic Centre, Marco Avenue, Revesby- Nearest cross street is Carson St.

Council will not consider a Quotation lodged by a Respondent who fails to sign the attendance sheet at this briefing, or fails to ensure that a representative of the Respondent signs the attendance sheet on its behalf.

In the event that Council deems, at its sole discretion, that an insufficient number of potential Respondents have attended the site meeting to result in a competitive tender, Council reserves the right to open the quotation process to any Respondent and waive the compulsory briefing requirement.

Please note Council is now using APET for all electronic lodgements and lodging by NSW e-tendering will no longer be available.

If your not already registered with Apet360. We strongly recommend that you register online with Apet360 upon down loading the tender documents from e-tendering.

The URL for electronic lodgement ishttp://360providers.apetsoftware.com.au/public/bankstownprod/publicjobs.aspx

Apet users guide has been attached to our documents for lodgement.


description: Building maintenance and repair services

title: LAHC - External upgrade of 17 properties at Bidwill

title: Notice to Tenderer MW21 11 09 13 TEM.doc

title: 01 Project Specific Tender Documents - BGHKU - Retender.pdf

title: 02 Standard Tender Documents - BGHKU - Retender.pdf

title: 03 Drawings - Architectural - BGHKU - Retender.pdf

title: 04 Drawings - Architectural - BGHKU - Retender.pdf

title: 05 Drawings - Details Landscape and Survey - BGHKU - Retender.pdf

title: 06 Returnable Tender Form and Schedules - BGHKU - Retender.doc

ProGroup Management Pty Ltd

streetAddress: Suite 1.03, 32 Delhi Road, Macquarie Park

legalName: ProGroup Management Pty Ltd

Proline

streetAddress: 11-15 Bertram Street,, Mortlake

legalName: Proline Building- Commercial Pty Ltd

streetAddress: 407 Church Street, North Parramatta

legalName: Rapid Construction Pty Ltd

SR Construction Pty Ltd

streetAddress: 8/71A Rhodes St, Hillsdale

legalName: SR Construction Pty Ltd

title: Addendum 1 - Cover Page - BGHKU-Retender.pdf

title: Addendum 1 - Revised Returnable Tender Form and Schedules - BGHKU-Retender.DOC

format: DOC

rationale: RD02 Schedule of Rates to be submitted with Returnable Tender Form and Schedules

description: Tender for the external upgrade of 17 properties in Brightman Crescent and Bunya Road, Bidwill

submissionMethodDetails:
THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

Suppliers who wish to be invited to join this register when it is refreshed, should direct your email to Suppliers.Panels@facs.nsw.gov.au .   Please include your company address and contact person details.

DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / Training name / postal address / email address etc )

Steps for submitting your tender:

1.     Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)


description: Building and Construction Machinery and Accessories

title: Fitout Works and Construction of a covered walkway at BM Theatre and Community Hub at Springwood

title: Invitation to Tender.docx

description:
Fitout Works and Construction of a covered walkway at Blue Mountains Theatre and Community Hub at 102 Macquarie Road, Springwood.

Council, through this Request for Tender (RFT) No 2014/15-W949, is seeking an experienced Construction Contractor to undertake fitout works and construction of a covered walkway at the recently completed Blue Mountains Theatre and Community Hub, 102 Macquarie Road Springwood in accordance with the attached drawings.

The construction works will also include the following:

Covered Walkway; and

Fitout works of a new green room on the lower ground floor directly under the main Galleria space; and

Fitout works for the Springwood Neighbourhood Centre on the lower ground floor under the main Galleria space.

The purpose of the Works is to provide additional green room facilities and additional space for the Springwood Neighbourhood Centre.

submissionMethodDetails: Tenders must be accessed and lodged online at http://360prop3.apetsoftware.com.au/Public/BMCCPro3/PublicJobs.aspx  (“Electronic Tender Box)

conditionsForParticipation:
The Tenderer and any nominated subcontractor(s) must not be bankrupt or insolvent.

Tenderers must provide details of instances where, within five (5) years prior to submitting their Tender, they have been found guilty of breaching any Act or Regulation, including but not limited to:

·        Workplace Relations Act 1996 (Cth)

·        Industrial Relations Act 1996 (NSW)

·        Work Health & Safety Act 2011 (NSW) and/or its predecessor Occupational Health & Safety Act 2000 (NSW)

·        Workplace Injury Management & Workers Compensation Act 1998 (NSW)

·        Equal Opportunity for Women in the Workplace Act 1999

·        Disability Discrimination Act 1992 (Cth)

·        Human Rights (Sexual Conduct) Act 1994 (Cth)

·        Racial Discrimination Act 1975 (Cth)

·        Sex Discrimination Act 1984 (Cth)

·        Age Discrimination Act 2004 (Cth)

·        Anti-Discrimination Act 1977 (NSW)

·        Disability Services Act 1986 (Cth)

·        Fair Work Act 2009 (Cth)

·        Crimes Act 1914 (Cth)

·        Criminal Code Act 1995 (Cth)

All Tenderers must comply with the NSW Government Code of Practice for Procurement (Code) that is current at the date of issue of this Request for Tender.   The ability of a Tenderer to demonstrate compliance with the Code is an essential condition of these Conditions.


description: Landscaping services

title: Tender for Construction of Forecourt Landscaping, Shelly Beach Surf Life Saving Club

title: T130 -A Part 1 - RFT Construction Shelly Beach SLSC Forecourt Landscaping.docx

title: T130-A - Part 2 - RFT Returnable Schedule Shelly Beach Forecourt Landscaping.docx

title: Landscape Specification Rev 1 - Shelly Beach CPA254049.doc

title: Landscape Construction Drawings - Shelly Beach - CPA254049.pdf

title: Civil-Works-Construction-Standard Drawing Concrete Pathway Stairs SD24B print .pdf

Fraser Developments Pty Ltd

streetAddress: 3 Bowalla Close, Wallalong

legalName: Fraser Developments Pty Ltd

Glenn Simpson Landscapes Pty Ltd

streetAddress: 39 Hunter Street, Kirrawee

legalName: GLENN SIMPSON LANDSCAPES PTY LIMITED

streetAddress: 5 Arnhem Close, Gateshead

legalName: Michilis Pty Limited

streetAddress: suite 1/16 Church st, Terrigal

legalName: Scape Constructions

title: Addendum 3 - Construction of Forecourt Landscaping Shelly Beach SLSC CPA254049.docx

format: docx

title: TC Univ Spec Sheet Aust 201309.pdf

rationale: Addendum 3: Please see the attached word file and TerraCottem instructions comprising Addendum 3.

rationale: Estimated cost removed from tender information.

rationale: Please note that construction drawings LA.12, LA.13 and LA.3.06 showing the planting plan requirements are not included in the set of drawings provided so far. An addendum will be issued separately that will include these drawings. This is planned to occur prior to the 26th February.

title: Addendum 1 - Construction of Forecourt Landscaping Shelly Beach SLSC CPA254049.docx

title: Updated and Planting Plans – Forecourt Landscaping Shelly Beach SLSC.pdf

title: Instructions-SolarBrick Installations.pdf

title: Plan markup LA.06 showing ground level.pdf

rationale: ADDENDUM 1: Please see Addendum 1 to the contract attached comprising the Addendum 1 word file and three attachments: Updated and Planting Plans, Instructions for SolarBrick, Plan markup LA.06.

title: Addendum 2 - Construction of Forecourt Landscaping Shelly Beach SLSC CPA254049.docx

rationale: Addendum 2: Please see the attached word file comprising Addendum 2.

description: Construct new landscaping works outside and to the north of the Shelly Beach Surf Life Saving Club. Work includes: concrete pathways and pavements, sandstone log walls and edging, sandstone flag paving, new planting and turf.

addressForLodgement: See instructions in RFT documents

submissionMethodDetails: A mandatory pre-tender meeting will be held onsite outside Shelly Beach Surf Club, commencing at 10:30am on Thursday 26th February 2015.


description: Structural engineering

title: LAHC - Road improvement & associated works at Bidwell

title: 01 Invitation for Quotation-BGJXW.DOC

title: 02 Returnable Schedule of Rates-BGJXW.XLS

title: 03 Returnable Statutory Declaration-BGJXW.DOC

streetAddress: 26 Lidco Street, Arndell Park

legalName: Asphalt Laying Services

streetAddress: 15 Penny Place, ARNDELL PARK

legalName: Ozpave (Aust) Pty Ltd

description: Road improvement & associated works at Lot 100 & Lot 106 Carlisle Avenue, Bidwell

addressForLodgement: Electronic quotation responses through this site ONLY

submissionMethodDetails:
THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

For any enquiries regarding joining the register for future select tenders, please direct your email to Suppliers.Panels@facs.nsw.gov.au

DOWNLOADING A SOFT COPY OF QUOTATION DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading Quotation documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download quotation documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / Training name / postal address / email address etc )

Steps for submitting your quotation:

1. Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration, Schedule of Rates and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)


description: Software

title: SharePoint Customer Centre Portal

title: Q46-15 SharePoint Customer Centre Portal.zip

description: Council is seeking quotations from suitably qualified and experienced Respondents for the development and supply of a solution for recording and tracking customer service requests and related information at Bankstown City Council (BCC) based on the SharePoint platform.

addressForLodgement:
Electronic lodgement at:

http://360providers.apetsoftware.com.au/public/bankstownprod/publicjobs.aspx

submissionMethodDetails:
Please note Council is now using APET for all electronic lodgements and lodging by NSW e-tendering will no longer be available.

If your not already registered with Apet360. We strongly recommend that you register online with Apet360 upon down loading the tender documents from e-tendering.

The URL for electronic lodgement ishttp://360providers.apetsoftware.com.au/public/bankstownprod/publicjobs.aspx

Apet users guide has been attached to our documents for lodgement.


description: Residential building construction services

title: LAHC - Construction of 8 two bedroom dwellings at Seven Hills

title: GC21 Notice to Tenderer  07 03 13.doc

title: 01 Project Specific Documents - BGHJP - Retender.pdf

title: 02 Standard Documents - BGHJP - Retender.pdf

title: 03 Drawings - Architectural - BGHJP - Retender.pdf

title: 04 Drawings - Civil and Hydraulic - BGHJP - Retender.pdf

title: 05 Drawings - Electrical Landscape and ESM - BGHJP - Retender.pdf

title: 06 Drawings - Structural and Survey - BGHJP - Retender.pdf

title: 07 Reternable Tender Form and Schedule - BGHJP - Retender.doc

AGM Construction Pty Ltd

streetAddress: 1/78 Ferndell Street, South Granville

legalName: AGM Construction Pty Ltd

Berlina Projects

streetAddress: Unit 1/ 27 Toohey Road, Wetherill Park

legalName: Berlina Homes Pty Ltd

DEGREE CONSTRUCTIONS PTY LTD

streetAddress: 2/18 GREYGUM RD, MT COLAH

legalName: DEGREE CONSTRUCTIONS PTY LTD

NEWBUILD DEVELOPMENTS (AUST) P/L

streetAddress: 2 ESSEX AVE, CASTLE HILL

legalName: NEWBUILD DEVELOPMENTS (AUST) P/L

streetAddress: 10/73-75 Dunmore Street, Wentworthville

legalName: Tradelink Construction Pty Ltd

description: Construction of a General Housing Development consisting of 8 two bedroom dwellings, associated site works,landscaping and site services at 1-3 Jordan St Seven Hills

submissionMethodDetails:
THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

Suppliers who wish to be invited to join this register when it is refreshed, should direct your email to Suppliers.Panels@facs.nsw.gov.au .   Please include your company address and contact person details.

DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / trading name / postal address / email address etc )

Steps for submitting your tender:

1.     Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)


description: Community and social services

title: ADHC Supplier Directory Stage One

title: 1. RFT Cover Page.pdf

title: 2. Guidelines for listing on the ADHC Supplier Directory revised 241213.pdf

title: 3. Supplier Directory Stage One Guidelines for Applicants.pdf

title: 4. FACS Conditions of Tendering.pdf

title: 5. ADHC Funding Agreement.pdf

title: 6. ADHC Supplier Directory Application Form Stage One January 2015.doc

tenderType: Expression of Interest For Pre-Qualification

description:
The ADHC Supplier Directory is a set of guidelines on the engagement and selection of providers to deliver specialist funded services to people with disability. It assists local ADHC staff to advise people with disability, their families and carers about service providers in their area.

The ADHC Supplier Directory includes all specialist disability types currently funded by ADHC. For more information about specialist disability services funded by ADHC, please see: http://www.adhc.nsw.gov.au/sp/delivering_disability_services.

Please note: All applications must be made using the official application form supplied, with required information being supplied on the application form itself, except where additional information, such as certificates of currency or financial reports, is specifically required as part of the application process. Applications that do not fulfil this requirement will be set aside, with no further consideration given.

Applications to be listed on the ADHC Supplier Directory are being run as a continuous rolling tender process, with each tender being open for approximately four weeks. Dates for 2015 are below.

?

Opening

Closing

07 April 2015

24 April 2015

27 April 2015

22 May 2015

25 May 2015

19 June 2015


title: LAHC - Fire Safety Upgrade Works at Sydney Metropolitan Area

title: GC21 Notice to Tenderer  07 03 13.doc

title: 01 Project Specific Documents-LHC5-2015.pdf

title: 02 Standard Documents - LHC5-2015.pdf

title: 05 Returnable Tender Form and Schedules - LHC5-2015.doc

streetAddress: suite 3, Level 3, 20 Charles St,, Parramatta

legalName: Austfield Pty Ltd

streetAddress: 6A/30-32 ARTISAN RD, SEVEN HILLS

legalName: Neo-Way Pty Ltd

title: Addendum 2 - LHC5 2015.pdf

rationale: Amendment to 01 Project Specific Documents – Contract Information and Schedules – Schedule 18 - Schedule of Rates

title: Addendum 1-LHC5-2015.pdf

rationale: Amendment to 01 Project Specific Documents - Contract Information and Schedule - Schedule 17 Work Requirements

description: Fire Safety Upgrade Works as per Fire Risk Management Plan Implementation Manual (FRMPIM) for building template Types 5, 6, 7, 8, 9 & 11 at Sydney Metropolitan Area (GWCA & CSCA)

timeframeDelivery: Access to this RFT documentation is restricted to selected tenderers.  Those tenderers have been issued with the special Access Passcode (10 alphanumeric character) required by this RFT

submissionMethodDetails:
Fire Safety Upgrade Works  at Sydney Metropolitan Area (GWCA & CSCA)

 THIS IS A SELECT TENDER of invited members from a pre-qualified panel register.

Suppliers who wish to be invited to join this register when it is refreshed, should direct your email to Suppliers.Panels@facs.nsw.gov.au .   Please include your company address and contact person details.

DOWNLOADING A SOFT COPY OF TENDER DOCUMENTS AND SUBMISSION OF ELECTRONIC RESPONSES IS ONLY AVAILABLE FOR SELECTED TENDERERS

Steps for downloading tender documents:

1. Click DOWNLOAD A SOFTCOPY- Free to download tender documents

2. Log in if you are existing user or register if you are new user

(Note: If you are existing user, please make sure your company’s profile on eTendering website is up-to-date and the details are the same as on the Returnable tender documents . e.g. business name / trading name / postal address / email address etc )

Steps for submitting your tender:

1.     Click LODGE A RESPONSE at the bottom of the page and follow the instructions to attach your files for lodgement.

It is your responsibility to ensure that you allow sufficient time for the lodgement of your response, as electronic receipt of lodgement is not issued until all the documents are fully uploaded.

The layout and content of the Tender Form, Statutory Declaration and Returnable Schedules shall not be altered except for areas that are required to be completed by the tenderer.

It is recommended that you attempt to lodge your response at least 24 hours prior to closing time so that if you experience difficulties the contact officer nominated may be able to assist in resolving any problems.

Each File Size:  NO MORE THAN 30MB– You can attach up to 5 individual files on each lodgement.  There is no restriction on the number of times you lodge a response in order to submit all of your files but you should identify each files (e.g. file_1_of 6, file_2_of 6 etc)

Accepted File Formats:    Word (.doc), Excel (.xls), Adobe Acrobat (.pdf) and JPEG (.jpg)

Note:    The following documents will be issued on a CD

03 Reference Specifications – version Jan 2015

04 FRMPIM


description: Electrical Systems and Lighting and Components and Accessories and Supplies

title: Lagoon Grass Road Pump Station - Electrical Upgrade

title: Conditionsoftendering1500500.pdf

title: GeneralConditionsofContract1500500.pdf

title: Preliminaries150050.pdf

title: TechnicalSpecification1500500.pdf

title: TenderSchedules.docx

title: TenderSchedules1500500.pdf

title: TItlePage1500500.pdf

title: 1500500 Addendum No. 1.pdf

rationale: Addendum No. 1 is to be bound into the tender documents.

description: Lagoon Grass Road Pump Station (via Lismore) - Electrical Upgrade including design, manufacture & installation of new switchboard, VSDs, telemetry, wiring and control cables and ancillary works

timeframeDelivery: 26 weeks.

addressForLodgement:
ADDRESS FOR LODGEMENT

Tenders will ONLY be considered by the following submissions: Electronic Submissions ONLY via NSW Government eTendering website: https://tenders.nsw.go.au

submissionMethodDetails:
Mandatory pre tender site meeting at Lagoon Grass Road Pump Station (off Bangalow Rd) 10am Wednesday 16/09/2015

 Lodging a Response

  *Electronic Submissions ONLY via NSW Government etendering website: https://tenders.nsw.gov.au

As the tenderer you must be a current Registered user of this web site.
 Click on the blue LODGE ON RESPONSE link at the bottom of this page, using the Access Passcode, then using your registered system  Login Username and Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Electronic Tender Box Security
 During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.
 All responses that are received successfully can only be accessed, decrypted, retrieved and opened after the RFT has officially closed.

RFT Response - receipt/confirmation
 A detailed system generated electronic receipt is issued for all submitted responses files received successfully.

Software Requirements
 To be able to view the requirements within the RFT you will require the following software to be installed on your PC:
 * Adobe Acrobat Reader  5.0 (or more recent)
 * Winzip  7.0 (or more recent) or equivalent

The RFT may also require the following software:
 * Microsoft - Word 2010
 * Microsoft - Excel 2010

Other requirements:
 Internet connection to lodge completed tender response
 The tenderer is responsible for the provision and installation of the necessary software.


description: Forestry

title: MAJOR SEALED ROAD PATCHWORKS & SPRAYED BITUMINOUS SURFACING WORKS ON SEALED RD NETWORK IN THE TUMUT MANAGEMENT AREA

title: Parts A D1516A B.pdf

title: Parts E   F 1516 parcel A.pdf

title: Parts E  F 1516 -parcel B.pdf

title: Part G 1516 A B Pricing submission.pdf

description:
Forestry Corporation of NSWintends to engage the services of a suitably experienced and competent Contractor(s) for the provision of works to complete Works Parcel A (Patchworks & Primer seal) & Works Parcel B (Sprayed bituminous sealing works) to be carried out on sealed road locations in the Tumut Management Area.

Works Parcel A consists of preparation and primer seal of up to 50 road sections.

Works Parcel B consists of sprayed bituminous sealing works on both continuous road sections and primer seal sections. All works are within a 60 km radius of Tumut

The contractor shall provide all necessary labour, plant, material, equipment and safety apparatus to perform the full scope of work.

The contract will be a schedule of rate/Lumpsum contract and the details of the services required are described in the techinical specification of the tender document and the respective scope of works, site details and site plans.

timeframeDelivery:
Works Parcel A is targeted for completion by 31 December 2015

Works Parcel B is targeted for completion by 31 March 2015

addressForLodgement:
(Hand Deliveries and Couriers only, must be lodged at Reception)

Forests NSW

The Tender Box

FNSW Tender 1516

121-131 Oratava Ave

West Pennant Hills NSW 2125

(or by Mail Lodgement)

Forests NSW

The Tender Box

FNSW tender 1516

PO BOX 100

Beecroft NSW 2119

Or via e-tendering website

submissionMethodDetails:
Works Parcel A and B may be bid on as stand-alone projects or combined where proponents can demonstrate ability to complete both parcels.

Part G-Sections of the document needs to be printed out, fill in the details and return with all other documentation as required.

Submissions by tenderers for non-price attributes shall be limited to no more than 20 single sided A4 pages.

conditionsForParticipation: Applicants for FCNSW Sealed Roads Maintenance tender must have experience in similar project, be available within the timelines outlined for each Works Parcel and have appropriate equipment and resources to complete the works program.


description: Pavement marking service

title: SUPPLY AND INSTALLATION OF PAVEMENT MARKINGS AT VARIOUS LOCATIONS WITHIN NSW

title: Tender Docs.zip

title: tender submission.zip

streetAddress: 25 Stennett Road, Ingleburn, Sydney

legalName: Allstate Linemarking Services Pty Ltd

streetAddress: Lot 6 Yarrandale Road, Dubbo

legalName: Central West Linemarking

Capital Lines and Signs

streetAddress: 19 Wycombe Street, PO Box6376, Queanbeyan

legalName: CL&S PTY LTD

streetAddress: PO Box 140, PADSTOW

legalName: Combined Traffic Management Pty Ltd

Complete Linemarking Services Pty Ltd

streetAddress: 14 Toohey Road, WETHERILL PARK

legalName: Complete Linemarking Services Pty Ltd

Guidance Road Management

streetAddress: PO Box 2010, Taren Point

legalName: Guidance Road Management

Avante Linemarking

streetAddress: 113 Dunheved Circuit, StMarys

legalName: Gumbay Holdings Pty Ltd

Mark Edwards

streetAddress: 53b Pacific Street, Caringbah

legalName: J&M Roadmarking

Statewide Linemarking

streetAddress: 7 Corporation Place, P.O Box 8022, Orange

legalName: Not Art Pty Ltd

Oz Linemarking Pty Ltd

streetAddress: 42 Nicole Way, Dandenong South

legalName: Oz Linemarking

Longlife Linemarking

streetAddress: Unit 1/16 Essex St, Minto

legalName: Ozlinemarking (NSW) Pty Ltd

Red Squirrel Pty Ltd

streetAddress: 11409 Escort Way, Forbes

legalName: Red Squirrel

SprayLine

streetAddress: 26 Fowler Road, Dandenong South

legalName: Roads Corporation t/a SprayLine

Santana Line Marking Services

streetAddress: 10 Turbo Road, Kings Park

legalName: Santana Group of Companies Pty Ltd

MAINTRAX

streetAddress: 14/28 GARLING RD, KINGSPARK

legalName: STATE WIDE RPM'S PTY LTD

streetAddress: 9-11 Tipping Rd, Kewdale

legalName: Supalux Pty Ltd

Wollongong Linemarking Services Pty Ltd

streetAddress: 29 Ruddock Street, PO BOX 183, CORRIMAL

legalName: Wollongong Linemarking Services Pty Ltd

streetAddress: 92-94 Redfern Street, Wetherill Park

legalName: Workfroce Road Services Pty Ltd

title: Addendum 1.zip

rationale:
Addendum No.1:

G1 Job Specific Requirement (Revision 1)

Schedule of Rates (Revision 1)

Measurement & Payment Note (Revision 1)

Technical direct TD2009 SR02 Dragon’s Teeth at School Zones

TMAs: Guidelines for the use of TMAs in NSW

RAMS Linear Referencing

Roads List by Regions

Schedule of Classified Roads and State and Regional Roads

Regional Maps with highlighted Newell Highway

Revised Tender Submssion Package

title: Addendum 2.zip

rationale:
Addendum 2 and Clarification

Schedule od Rates (Revision 2)

Measurement & Payment notes (Revision 2)

RMS QA Specification R110

RMS Delineation Guide, Section 9

UA & RA Arrow figures

rationale: Amendment

title: 04 Measurement and Payment.pdf

rationale: Updated Measurement and Payment notes

rationale: Amendment

title: Pre-Tender meeting minutes.zip

rationale:
Pre-tender meeting minutes.

Please note the tender closing date is extended to 9th Oct 2015.

description:
The scopes of work generally comprise of the following but not limited to:

• Preparation of the existing pavement surface including removal of existing pavement markings & priming.

• Supply and application of transverse pavement markings.

• Supply and application of Longitudinal line marking.

• Supply and application of Retroreflective Raised Pavement Markers

• Implementation of site specific Traffic Management.

• Implementation of site specific Environmental Controls.

• Supply of 20 days dry retro-reflectivity test results on completed works.

• Removing or masking of existing pavement markings.

• Control of traffic.

All Tenderers must comply with the NSW Government Code of Practice for Procurement and must be an acceptable legal entity.

Attendance is mandatory to submit a conforming tender. A pre-tender meeting is scheduled to be held at 9:30am on Monday, 21st Sep 2015 at the 129A Orchardleigh St, Yennora NSW 2166.

Tenderers shall confirm their attendance to the pre-tender meeting by 17 Sep 2015 to the email address: frank.wang@rms.nsw.gov.au

name: Transport for NSW (Transport Infrastructure Projects)

addressForLodgement: The tenders shall be submitted to the E-Tender. Tenderers shall write the subject line clearly stating the Title "Tender for Contract no. RMS.15.3554.0990 - Supply and Installation of Pavement Markings at various locations within NSW.

submissionMethodDetails:
Important information

To obtain a copy of the full tender documentation payment is not required. Complete all of the following steps:

1. Select the link below, DOWNLOAD A SOFT COPY. Log in or register.

 2. Download the documents by clicking on the file name. Please read & follow the instructions and note that you will need WinZip to unzip the files.

conditionsForParticipation: It is a requirement of this contract that Contractors must have Painting Contractor Certification Program (PCCP) Accreditation by CSIRO for the Class of work they will be performing.


description: Building and Facility Construction and Maintenance Services

title: Gilmore Building - Electrical and Security works associated with new security front desk

title: Tender Document.zip

title: Addendum No.1.pdf

title: Optional Additional Works_0.pdf

rationale:
Addendum No. 1

Refer to attached Addendum No.1

tenderType: Pre-Qualified / Invited

description:
NOTE - This is an Invited tender.

Electrical and Security works associated with new security front desk at 55 Morehead Street Redfern under agreement 1301665

A pre-tender meeting will be held on the date, at the time and at the place nominated in the tender advertisement or invitation.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

 OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Paul Kotronakis 02 9852 0285.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

 PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

 OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

 COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

eTenderProcurementMethod: Pre-Qualified / Invited

conditionsForParticipation:
The Invited Tenderers are:

Budstar Pty Ltd   T/as DJ Staniforth

McCall's Services Pty Limited

R W Palmer Electrical Service Pty Ltd

Stacey Electrical Pty Ltd

Wollondilly Electrical Contracting & Sales Pty Ltd

Tenders from the above contractors ONLY will be accepted.

Electronic Responses will only be considered on this project.


description: Bridge painting service

title: Luskintyre Bridge Repainting

title: Tender Docs.zip

title: Tender Submission.zip

streetAddress: 158 Garretts Road, .., Longford

legalName: Asset & Facility Management Pty Ltd

Cormac Metal Spray

streetAddress: 12 Samantha Place, Smeaton Grange

legalName: Cormac Contracting Pty Ltd

streetAddress: 463 - 467 Harris Street, Ultimo

legalName: Eptec Services Pty Ltd

HBS Group

streetAddress: Head office 17 Abbott St Fairfield 3078, Melbourne

legalName: HBS Group

streetAddress: 140 Bullsgarden Road, Gateshead

legalName: KGB Protective Coatings Pty Ltd

Mastertec Industrial and Maintenance

streetAddress: Level 1 Riverside Plaza, 45 River Street, Mackay

legalName: Mastermyne Group Ltd

mcelligott partners

streetAddress: 2-6 hume rd, nth laverton

legalName: mcelligott partners

RMP Abrasive Blasting

streetAddress: 7 Hudson Place, Mulgrave

legalName: Ray's Machinery Painting Pty Ltd

VT Industrial Coatings

streetAddress: 23 Molloy Street, Toowoomba

legalName: VT Industrial Coatings

title: Clarification.zip

rationale:
Clarification 1

Luskintyre Bridge Portable Traffic Lights T.C.P.

B1780 Luskintyre Bridge Draft Evaluation Assessment

title: Clarification 2.pdf

rationale: Clarification 2

rationale: Amendment

title: Amendment 1.zip

rationale: Pre-tender Meeting minutes

description:
Luskintyre Bridge is located over the Hunter River on Luskintyre Road, approximately three kilometres north of the New England Highway at Luskintyre, near Lochinvar, NSW. The site is located within the Maitland Local Government Area (LGA). The bridge was constructed to improve access to the northern side of the Hunter River and comprises one of only two surviving examples of an early steel Pratt truss bridge in NSW. The bridge is listed as an item of environmental heritage under the Maitland Local Environmental Plan 2011 (LEP), as well as an item of State Heritage Significance under the RMS Heritage and Conservation Register.

In order to extend the life of the major structural metal items of Luskintyre Bridge, the existing Protective Coating System applied to the metal members of the bridge will be removed back to the bear metal substrate and recoated with a new Protective Coating System. These members include but are not limited to Trusses, Girders, Cross Girders and piers & truss bracing. The coating system currently on the bridge contains a high concentration of lead.

The works required under this contract involves the complete removal of the existing coating system and the application of a new coating system to all metal elements on the bridge. The final colour of the bridge is to be ‘RMS Bridge Grey’.

All Tenderers must comply with the NSW Government Code of Practice for Procurement and must be an acceptable legal entity.

Attendance is mandatory to submit a conforming tender. A Pre-tender meeting for this contract will be held at 10:00 am on Tuesday, 22 September at Lochinvar School of Arts, 134 New England Highway, Lochinvar NSW 2321.

Identifiers:
Far North Coast
Mid North Coast
New England
Central Coast
Hunter

addressForLodgement: The tenders shall be submitted to the E-Tender. Tenderers shall write the subject line clearly stating the Title "Tender for Contract no. RMS.15.2120.1531 Luskintyre Bridge Repainting

submissionMethodDetails:
Important information

To obtain a copy of the full tender documentation payment is not required. Complete all of the following steps:

1. Select the link below, DOWNLOAD A SOFT COPY. Log in or register.

2. Download the documents by clicking on the file name. Please read & follow the instructions and note that you will need WinZip to unzip the files.


title: FACS TRIM Consolidation and Upgrade - Amendment 002

description: Restricted Tender


title: NSW Land and Housing Corporation Maintenance Program 2014/2015

description: Restricted Tender

Restricted Tender

Brandon Hayden

mobile: Restricted Tender


description: Security guard services

title: Security Services

description:
Sydney Trains (ST), including NSW TrainLink, is soon to release a request for proposal (RFP) for the provision of security services for the next eight years (4+2+2).

Scope Headlines:

Security Officers to provide security at Maintenance Centres, Stabling Yards, Stations and the rail corridor and at Special Events when requested.

Mobile, static and foot patrols of ST and NSW TrainLink locations, partnering with ST Security and NSW Police.

The option of providing Canine (Dog Handling) and other specialist security services, e.g. alarm monitoring

Employ Mobility Technology to improve the detection and reporting of security incidents and the management of Security Officers.

Supplier Capacity:

Capable of managing a large body of employed Security Officers who are motivated and actively looking to improve security outcomes by protecting our customers, our assets and our operations.

Able to identify opportunities to improve security outcomes and reduce costs by identifying and deploying security technologies and continuous improvement initiatives.

Possess a dedicated, highly committed management team, who implement systems that assure the performance and quality of service delivery.

Capable of prioritising the health and safety of their employees, and pro-active in the development of Security Officer competency and understanding of ST and NSW TrainLink work environment.

Request for Proposal to be released in 4th quarter of 2015

Identifiers:
Central Coast
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Illawarra

submissionMethodDetails:
This is for information only.

Request for Proposal to be released in 4th quarter of 2015.

Please keep visiting etender website.


description: Land leases

title: Moree Development Opportunity

title: PART A B C and D - DTIRIS14-154 EOI Documents.pdf

title: PART E - DTIRIS14-154 EOI Response form.docx

title: ATTACHMENT 1- DTIRIS14-154Draft Standard Lease.pdf

title: ATTACHMENT 2 -   Draft Contract Special Conditions.pdf

GW & ND McDonald

streetAddress: Bolwarra, MOREE

legalName: GW & ND McDonald

Serbian Orthodox Church

streetAddress: 14 Renwick Street, Alexandria, sydney

legalName: Metropolitanate of Serbian Orthodox Church of Aust and NZ

title: Tender Addendum 1.docx

title: Tender Addendum 2.docx

title: Tender Addendum 3.docx

rationale: Map added

description:
This EOI is an opportunity for interested parties to submit proposals that will contribute to community development and commercial development in Moree and district.

The land has been identified for development possibilities in recent years.  It is likely that the area will be suitable to a range of community development and commercial development opportunities.  Where possible, the assessment process will take into account the likelihood of the land being able to accommodate more than one land use proposal.

The option of a lease, and if required an agreement to lease, is available under section 34A of the Crown Lands Act 1989 for a term to be negotiated.  Rent will be determined at a commercial market value.  Costs of subdivision, plan lodgement, and title creation will be borne by the proponent.

The option to purchase the land, and if required an agreement to purchase, is available under section 34 of the Crown Lands Act 1989.  The purchase price will be determined at market value or/ and as negotiated.  Costs of subdivision, plan lodgement, and title creation will be borne by the proponent.

A general assessment process will take place following the receipt of submissions.  It is anticipated that a preferred proponent or proponents, will be identified with a view to negotiating a Lease Agreement or Sale Agreement.

Catchment Management Authority

name: David Baber - Projects Manager, Regional Projects West

addressForLodgement:
Each intending Proponent must lodge its EOI via the NSW Trade & Investment electronic tender box at www.tenders.nsw.gov.au before the Closing Time, 2.00pm on Friday 3rd April 2015.

NSW Trade & Investment will not accept late submissions, and its judgment as to the time an EOI has been lodged will be final.

NSW Trade & Investment may, by written notice, extend the Closing Time, in which case, such new Closing Time will apply equitably to all intending Proponents.  Lodgement of an EOI by the Closing Time is entirely an intending Proponent's responsibility.

All EOI responses are to be lodged at:

www.tenders.nsw.gov.au

submissionMethodDetails:
For further information contact:

Mr David Baber

Projects Manager, Regional Projects West

Trade & Investment, Crown Lands

45 Wingewarra Street

DUBBO  NSW  2830

T: 02 6883 3326

M: 0427 629 288

E: david.baber@crownland.nsw.gov.au

eTenderProcurementMethod: Expression of Interest for Specific Contracts


title: Kendall Building - Electrical and Security works associated with new security front desk

title: Tender Document.zip

title: Addendum No.1.pdf

title: Optional Additional Works_0.pdf

rationale:
Addendum No.1

Refer to attached Addendum No.1

description:
NOTE - This is an Invited tender.

Electrical and Security works associated with new security front desk at 43 Morehead Street Redfern under agreement 1301665

A pre-tender meeting will be held on the date, at the time and at the place nominated in the tender advertisement or invitation.