title: Northern Sydney Institute of TAFE Dunbar Building, Demolition Stage 1

title: Dunbar Building Demo Stage 1 Tender Docs.zip

title: Dunbar Building Demo Stage 1 Drawings.zip

description:
NOTE - This is a Selective Tender.

Demolition Stage 1 includes the demolition and disposal of existing windows, ceilings, linings, walls, furniture and all services on three levels of the building – the roof, level 4 and level 5.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Ray Bain 0410 430 302.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

Casbee Pty Limited, 4 Stanton Road, Seven Hills  NSW  2147

Matt Dalley Demolition Pty Ltd, Unit 4, 19-21 Wilson Street, Botany  NSW  2019

RMA Demolitions Pty Limited, T/ARoss Mitchell & Associates, 95 Asquith Street, Silverwater  NSW  2128

S & A Contracting Pty Ltd, D3/ 27-29 Fariola Street, Silverwater  NSW  2128

Tender responses from the above pre registered tendering companies ONLY will be accepted.


scheme: UNSPSC

description: Vehicle safety and security systems and components

title: RFP for Truck Mounted Attenuators

status: complete

RFTAccess: Open

title: tfnsw-RFQ-Attenuators_A-C.PDF

format: application/pdf

documentType: tenderNotice

title: Truck Mounted Attenuators RFP_ D.DOCX

title: RFP Addendum for Truck Mounted Attenuators_RFP Reference WS3102482976.pdf

format: pdf

documentType: amendments

rationale: Withdrawing RFP until further notice

tenderType: Request for Proposals

description:
Truck Mounted Attenuators

Transport for NSW (TfNSW) requires three truck mounted attenuators (TMAs) to help ensure the safety of TfNSW workers and the public on and around road worksites

eTenderStatus: published

inheritanceType: RFT

scheme: xNSWRegions

Identifiers:
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
South West Sydney
Central West
Orana/Far West
Riverina/Murray
Illawarra
Southern Highlands

submissionMethod: written ElectronicSubmission

procurementMethod: selective

addressForLodgement: Responses can only be lodged electronically via New South Wales Government's eTendering portal at: https://www.tenders.nsw.gov.au/  Hard copy submission is not an option.

eTenderProcurementMethod: Request for Proposals

initiationType: tender


description: Banking and investment

title: Transaction Banking Datasets

title: P22-4092 Tender Documents.zip

format: zip

title: P22-4092 - Addendum 1 - Q and A.pdf

rationale: P22-4092 - Addendum 1 - Q&A

title: P22-4092 - Addendum 2 - Q and A.pdf

rationale: P22-4092 - Addendum 2 - Q&A

tenderType: Open Tenders

description:
The Intelligence, Data and Evidence (IDE) team within Strategy, Corporate and Performance, is seeking a vendor to supply aggregated and de-identified banking transaction data at a localised level across NSW. Access to this data will enable the IDE team to develop analysis and analytics to support other business units within RNSW by providing:

•Insights into consumer spending trends within regional communities

•Insights of how natural disasters such as floods or bushfires affect the local regional economies, and

•A timely economic feedback loop to identify the impact and effectiveness of Government interventions and responses

IDE is seeking transaction banking data provided:

•With sufficient coverage across the Local Government Areas of regional NSW

•At least monthly with a minimal lag from the time of the transaction

•With sufficient detail to identify the time at which the transaction occurred and the location where the transaction took place

•Via API or similar functionality to enable us to implement automation, integration and for use in our bespoke analytics.

Submissions will be assessed on the granularity and specifics of data provided.

name: Strategy, Delivery & Perfomance (Regional NSW)

procurementMethod: open

eTenderProcurementMethod: Open Tenders


description: Building and Facility Construction and Maintenance Services

title: Dungog Hospital Redevelopment

currency: AUD

title: RFT-10019901 Vol 1 Dungog Hospital Redevelopment - Specification Final.ZIP

title: RFT-10019901 Vol 2 Dungog Hospital Redevelopment - Drawings Final.ZIP

title: 2. RFT-10019901 GC21 Tender Schedules.DOCX

title: RFT-10019901 Addendum 01.PDF

format: PDF

title: RFT-10019901 Addendum 01 Attachments.ZIP

format: ZIP

rationale: Addendum 01 - Minutes of pre-tender meeting and asbestos report.

title: RFT-10019901_Addendum_03.PDF

title: RFT-10019901_Addendum 3_Attachments.ZIP

rationale: Administrative Amendment 01 - Upload files for Addendum 03 that did not publish

title: RFT 10019901_Addendum_02.PDF

title: RFT 10019901_Addendum 2_Attachments.ZIP

rationale: Addendum 02 - Responses to RFIs and updated electrical specification

title: RFT-10019901_Addendum_04.PDF

rationale: Addendum 04 - Architects notice to tenderers

rationale: Addendum 03 - Revised Conditions of Tendering , Tender Schedules and Schedule of Contract Information. Architects notice.

tenderType: Selective Tenders

description:
The extent of works for this contract includes but is not limited to:

Internal refurbishment works for wards, staff stations & the Emergency Department at Dungog Hospital.

The works comprise all work shown on the drawings and included in the specification.

Identifiers:
Far North Coast
Mid North Coast
New England
Central Coast
Hunter
Cumberland/Prospect
Nepean
Northern Sydney

addressForLodgement: Tenderers are to lodge their tender response via this website including acknowledgement of any addenda issued. Addenda are also to be noted on the tender form in the space provided. If you have a problem lodging your response, please contact 1800 NSW BUY (1800 679 289) before the advertised closing time for the tender.

submissionMethodDetails:
Tenders are invited from the companies listed under:

Axis Constructions Pty Ltd

Kingston Building (Australia) Pty Ltd

Graph Builders Pty Ltd

O'Donnell & Hanlon Pty Ltd

Tender responses from the above tendering companies ONLY will be accepted.

OBTAINING RFT DOCUMENTS:

SOFTCOPY DOCUMENT

Only a downloadable SOFTCOPY version of the RFT is available.

First time visitors to this web site who wish to OBTAIN a copy of this RFT will need to Self-Register on this web site to gain access to any documents.

To obtain this RFT/EOI and any FUTURE related Amendments that may be issued, you must download to your own computer all the files provided (including from time to time any Amendments), by clicking on the DOWNLOAD A SOFT COPY link at the bottom of this page and follow the on-screen instructions.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

Your completed Tender response is to be lodged electronically via this web page.

Click on the Lodge a Response link at the bottom of this page and follow the on-screen instructions.
 Electronic Tender Box Security
 During the lodgement process all submitted responses received successfully are encrypted by the system for security and stored securely in the web site “electronic tender box”. All responses that are received can only be accessed, un-encrypted and opened after the RFT has officially closed. This is done though a controlled Tender Opening process managed by the Agency’s Tender Opening Committee.

Tender Response confirmation & receipt
 A detailed system generated electronic receipt is issued for all responses received successfully.

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2007 (or more recent) or equivalent.

Microsoft Excel 2007 (or more recent) or equivalent.

OTHER REQUIREMENTS:

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer and Firefox web browsers.

The minimum requirements are IE version 8 or later with Cipher Strength = 128bit.

Your web browser MUST be set to accept cookies. You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

eTenderProcurementMethod: Selective Tenders

conditionsForParticipation: A mandatory site meeting will be held at Dungog Hospital, 58 Hospital Road, Dungog at 11:00 am on Thursday 21 February 2019. Attendance at the meeting is compulsory. Tenders received from contractors not in attendance at the site meeting will not be considered for acceptance.


description: Building and facility maintenance and repair services

title: Maitland High School - Fitness Laboratory

title: 1002344_Specification_Final.pdf

title: 1002344_03_Tender_Schedules.doc

format: application/msword

region: NSW

countryName: AUSTRALIA

streetAddress: 311 New England Highway, Rutherford

legalName: C & W Constructions Pty Ltd

streetAddress: 85 Fletcher Street, Adamstown

legalName: R T Parker Pty Ltd

streetAddress: Unit 5/11 Kinta Drive, Beresfield

legalName: RTC Commercial Pty Ltd

streetAddress: 25 Old Punt Road, Tomago

legalName: Williams River Steel Pty Ltd

description:
The extent of works for this contract includes but is not limited to:

Colorbond shed, sports flooring, security and electrical works. The contract also includes Optional Additional Works of a 10,000 litre rainwater tank for Maitland Public School.

The works comprise all work shown on the drawings and included in the specification.

addressForLodgement:
Street Address: Level 2, 117 Bull Street, Newcastle West (mail sent to this address will be returned by Australia Post as being undeliverable)

Postal Address: PO Box 2297, Dangar NSW 2309

Fax: (02) 4908 4879

submissionMethodDetails:
Tenders are invited from those companies prequalified in Hunter-New England Region for Building Works between the amounts of $50,001 and $100,000.

C & W Constructions Pty Ltd, Rutherford

RTC Commercial Pty Ltd, Beresfield

Williams River Steel Pty Ltd, Tomago

RT Parker Pty Ltd, Adamstown

Tender responses from the above prequalified tendering companies ONLY will be accepted.

OBTAINING THE RFT:

SOFTCOPY DOCUMENT

A soft copy of the RFT can be obtained from this Web Site. To download, click on the DOWNLOAD A SOFTCOPY link at the bottom of this advertisement and follow the on screen instructions.

EXHIBITED HARDCOPY

An exhibited hardcopy of this RFT is available for public viewing at the NSW Public Works, Level 2, 117 Bull Street NEWCASTLE WEST NSW 2302, during normal business hours.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

When you have completed your response, you can lodge it electronically via this website. You must be a registered user in order to submit a response. Click on the LODGE A RESPONSE link at the bottom of this page and follow the on-screen instructions.

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

OTHER REQUIREMENTS:

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 6.0 or later with Cipher Strength = 128bit.

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation: This tender panel was formed on 04/11/2010.


title: York Public School – Vision Works.

title: 1002354_Addendum1 111010.ZIP

streetAddress: Unit 1, 78 Ferndell Street, Granville

legalName: AGM Construction Pty Ltd

streetAddress: Unit 5, 6 Herbert Street, St Leonards

legalName: Buildcorp Asset Solutions Pty Limited

streetAddress: Level 1, Grandview Street, Pymble

legalName: Cash McInnes Projects Pty Ltd

streetAddress: 14 Mary Parade, Rydalmere

legalName: Mono Constructions Pty Ltd

streetAddress: Suite 4, 16 Rob Place, Vineyard

legalName: Zadro Constructions Pty Ltd

title: 1001595_York PS_Addendum 1.pdf

title: York PS 1001595 Specification.ZIP

title: York PS 1001595 Drawings.ZIP

rationale:
Addendum No.1 - Please disregard previous documents uploaded on the eTendering website under this RFT 1001595.  The correct RFT documents is attached.

Please complete and return the acknowledgment below to the Contact Person prior to close of tender.

title: York PS Addendum _2.ZIP

rationale:
Addendum No.2 - Bind the attached Addendum No.2, consisting of 3 pages into the copy of the Tender Documents.  Please complete and return the acknowledgment to the Contact Officer prior to close of tender.

Pre-tender meeting minutes & discussion notes.

Technical Specification requirements.

description:
NOTE - This is a Selective Tender.

Installation of tectile indicators, handrails, concrete and highlight painting.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Jim Paton 02 9852 0216.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

AGM Construction Pty Ltd, Unit 1, 78 Ferndell Street, Granville NSW 2142

Buildcorp Asset Solutions Pty Limited, Unit 5, 6 Herbert Street, St Leonards NSW 2065

Cash McInnes Projects Pty Ltd, Level 1, Grandview Street, Pymble NSW 2073

Mono Constructions Pty Ltd, 14 Mary Parade, Rydalmere NSW 2116

Zadro Constructions Pty Ltd, Suite 4, 16 Rob Place, Vineyard NSW 2765

Tender responses from the above pre registered tendering companies ONLY will be accepted.


title: Gosford Service Centre: Shop front fitout.

title: 1301171_Commercial_Contractual Clauses.zip

title: 1301171_Gosford Service Centre.zip

title: 1301171_Addendum No 1.zip

rationale:
Addendum No.1

Issue of Security Specification

Gallagher Channel Partners-NSW June 2013 Approved CARDAX installers refer security scope of works Gosford

Provisional Sum Confirmation

Signage

title: 1301171_Addendum No 2.zip

rationale:
Addendum No.2

Refer to attached Addendum No.2

description:
NOTE - This is a Selective Tender.

Building work includes demolition, minor alterations and additions, laying new carpet, new plasterboard partitions and modification and extensions to existing electrical and mechanical installations.  Work includes coordination and acting as the principal contractor for the Installation of joinery, signage and furniture and equipment arranged by the principal and paid from monetary allowances in the contract.

Please note a Non Mandatory Meeting is to be held at Gosford Service Centre on Friday 9th August 2013 at 10.30 am.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Pat Timmins 0419 252 630.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The invited firms are:

1.        Ibex Interiors Pty Ltd, Unit 1, 29-31 Whyalla Place, Prestons NSW 2170

2.        Intact Projects Pty Ltd, Unit 9, 15/17 Gartmore Avenue, Bankstown NSW 2200

3.        ISIS Group Australia Pty Limited, Level 4, 29 Christie Street, St Leonards NSW 2065

4.        New England Constructions Pty. Ltd., Level 21, Tower 2, 101 Grafton Street, Bondi Junction NSW 2022

5.        Renascent Sydney Pty Ltd, 127 Victoria Avenue, Chatswood NSW 2067

Only Electronic Responses will be considered from the above listed invited firms.


description: Software

title: Student Administration and Learning Management Solution (EOI)

title: EOI_SALM_DETPD0906_18MAY2009 .doc

streetAddress: 48 Pirrama Road, Pyrmont

legalName: * Accenture

region: WA

streetAddress: LEVEL 8, 182 ST. GEORGES TCE, PERTH

legalName: * CSG

SunGard Higher Education

streetAddress: Lv 12 - 9 Hunter Street, Sydney

legalName: * SunGard Higher Education International Ltd

Tribal Education

region: Hessle

countryName: UNITED KINGDOM

streetAddress: Vision House, Hesslewood Country Office Park,

legalName: * Tribal

title: Addenda 1 EOI DETPD0906.doc

format: doc

rationale:
NOTE: While trying to publish the attached addendum, an operator error occurred and the published Expression of Interest was accidently cancelled online. The EOI is still valid.

Addendum No 1 - Responses to questions raised by interested parties by 5 June 2009.

title: Addenda 2 EOI DETPD0906.pdf

rationale: Addendum No. 2. Issued for download 10-6-09.

title: Addenda 3 EOI DETPD0906.pdf

rationale: Addendum No. 3. Issued for download 11-6-09. Final addendum.

tenderType: Expression of Interest For Pre-Qualification

description:
The NSW Department of Education and Training (DET) is seeking Expressions of Interest (EOI) in order to assess market capability and capacity for its requirement for a modern, integrated, fully functional Student Administration and Learning Management (SALM) solution for DET.

DET welcomes responses from product vendors, partnerships, consortia and integrators. This could include those vendors who offer a wide range of SALM functionality as well as those who offer specialised or niche solutions appropriate for DET’s needs.

The EOI forms part of a strategy to review business processes and develop best practice approaches with an end goal of improved integration of line of business applications and the provision of a more robust and reliable DET business systems platform.  The EOI will therefore inform a longer-term DET systems implementation strategy, the first stage of which focuses on student administration solutions.

addressForLodgement: Electronic uploads only. All other enquiries via email to Contact Officer.


description: Civil engineering

title: Invitation to Tender - Pavement Rehabilitation .docx

description: Terrace Falls Road, Hazelbrook - Pavement Rehabilitation Design and Construction Works.

multiAgencyAccessType: All Agencies

submissionMethodDetails:
Tender documents must be accessed and lodged online at

https://360providers.apetsoftware.com.au/Public/PublicJobs.aspx?Code=bmccpro3

(“Electronic Tender Box)

conditionsForParticipation:
Council may refuse to consider any Tender which does not meet the Mandatory Criteria.

The Mandatory Criteria are:

The Tenderer and any nominated subcontractor(s) must not be bankrupt or insolvent.

Tenderers must provide details of instances where, within five (5) years prior to submitting their Tender, they have been found guilty of breaching any Act or Regulation, including but not limited to:

·           Workplace Relations Act 1996 (Cth)

·           Industrial Relations Act 1996 (NSW)

·           Work Health & Safety Act 2011 (NSW) and/or its predecessor Occupational Health & Safety Act 2000 (NSW)

·           Workplace Injury Management & Workers Compensation Act 1998 (NSW)

·           Equal Opportunity for Women in the Workplace Act 1999

·           Disability Discrimination Act 1992 (Cth)

·           Human Rights (Sexual Conduct) Act 1994 (Cth)

·           Racial Discrimination Act 1975 (Cth)

·           Sex Discrimination Act 1984 (Cth)

·           Age Discrimination Act 2004 (Cth)

·           Anti-Discrimination Act 1977 (NSW)

·           Disability Services Act 1986 (Cth)

·           Fair Work Act 2009 (Cth)

·           Crimes Act 1914 (Cth)

·           Criminal Code Act 1995 (Cth)

All Tenderers must supply evidence of the insurances required under the Contract.

All Tenderers must comply with the NSW Government Code of Practice for Procurement (Code) that is current at the date of issue of this Request for Tender.   The ability of a Tenderer to demonstrate compliance with the Code is an essential condition of these Conditions.


title: Dunheved High School - Electrical Upgrade

title: DunhevedHSTenderSchedules.doc

DJ Staniforth & Co

streetAddress: 12 Raglan Road, Auburn

legalName: Budstar Pty Ltd

Harnleigh Air & Electrical

streetAddress: 8/7 Production Avenue, Taren Point

legalName: Harnleigh Pty Ltd

JR Electrical

streetAddress: Unit 4, 18 York Road, Ingleburn

legalName: J & R McCue Industries Pty Limited

streetAddress: 3/42 Leighton Place, Hornsby

legalName: Macaya Pty Ltd

streetAddress: 1/57 Jack Williams Drive, Penrith

legalName: Stowe Australia Pty Limited

description:
NOTE - This is Selective tender.

The work under the contract includes the Pad-mount Substation, New Service / Consumer Mains, New Sub-mains to outer Blocks, New Distribution Boards to outer Blocks, RCD installation on all circuits as required by SAA Wiring Rules.

Tenders are invited from those companies pre-registered in Sydney Basin for Building Electrical between the amounts of $250,001 and $500,000

The Selected Tenderers are:

Budstar Pty Ltd t/a DJ Staniforth & Co, 12 Raglan Road, Auburn NSW 2144

Harnleigh Pty Ltd t/a Harnleigh Air & Electrical, 8/7 Production Avenue, Taren Point NSW 2229

J & R McCue Industries Pty Limited t/a JR Electrical, Unit 4, 18 York Road, Ingleburn NSW 2565

Macaya Pty Ltd, 3/42 Leighton Place, Hornsby NSW 2077

Stowe Australia Pty Limited, 1/57 Jack Williams Drive,  Penrith NSW 2750

Tender responses from the above pre-registered tendering companies ONLY will be accepted.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

Only a Hardcopy of the whole document is available - and a softcopy of the returnable schedules is available for downloading by following the instructions below.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

An electronic version of the returnable schedules can be downloaded from this web site free of charge.

To obtain the provided schedules form this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered by telephoning Jeffery Vallance on 02 9852 0190 between the hours of 8.30am and 5.00pm, Monday to Friday

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Jeffery Vallance on 02 9852 0190

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Microsoft Word 97 (or more recent) or equivalent.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.


description: Occupational health or safety services

title: Consultancy Services for Work Health and Safety Management System.pdf

title: Appendix 1 Camden Council Audit Report 2012.pdf

title: Memo - Black and White.pdf

rationale: Additional Information

description:
Consultancy Services for Work Health and Safety Management System.

Consultant to work in partnership with Councils Corporate Safety Team to review, further develop and implement the organisations Health and Safety System

conditionsForParticipation: Standard Conditions of Tender apply


description: Traffic control

title: Provision of Traffic Control

title: RFT Documents - Published.zip

title: Addendum 2.pdf

rationale: Addendum 2 issued 14/02/17

title: Addendum 1.pdf

rationale: Addendum 1 issued 31/1/17 - tender closing date has been extended to Thursday 23/2/17

description: Provision of Traffic Control

Identifiers:
SA
Cumberland/Prospect
Nepean
Northern Sydney
Inner West
South East Sydney
Illawarra
Southern Highlands


description: National Defense and Public Order and Security and Safety Services

title: Security and Guarding Services for Sydney Ferries

RFTAccess: Restricted - Public View Detailed

title: RFT 0900880_eTenders_Pack.zip

streetAddress: 146d Samuel Marsden Road, Orchard Hills

legalName: 000 Security Pty Ltd

streetAddress: 101 Palmer Street, East Sydney

legalName: Business Risks International Pty Ltd

streetAddress: 4/4 Charles Street, Petersham

legalName: E Group Pty Ltd

streetAddress: 34/135 Sailors Bay Road, Northbridge

legalName: Fogl Knight Security Resources Pty Limited

streetAddress: 3 Watkins Place, Currans Hill

legalName: Jones XL Pty Ltd

SNP Security

streetAddress: 937-941 Victoria Road, West Ryde

legalName: Sydney Night Patrol & Inquiry Co Pty Ltd

streetAddress: Unit 17, 13 -15  Wollongong Road, Arncliffe

legalName: Ultimate Security Services Pty Limited

title: 0900880 Addendum No 1.Doc

format: Doc

rationale: Addendum No1 - Details for Mandatory Site meeting on 22 MAy 2009

title: 0900880_Addendum_No2.Doc

rationale: Addendum No 2 - The tender period has been amended.  Tender closing date has been extended to 10th June 2009

title: 0900880_Addendum_No3.doc

rationale: Addendum No 3 -  Notes of the Pre-tender Briefing

title: 0900880_Addendum_No4.Doc

rationale: Addendum No 4 -  Please replace 6.2 Lump Sum Price for each Site (page 23 of RFQ) and 1.2 in Response to Tender Schedule (excel sheet) with the attachment A.

tenderType: Pre-Qualified / Invited

description:
Provision of Security Guard services including foot patrols, static guards and monitoring cameras and Alarm Systems.

Areas to include  Circular Quay Wharf, Manly Wharf and Balmain Shipyard in Sydney

Invitations are from SCCB Contract 0302682

The invited firms are listed below

Mandatory site briefing
Please note a mandatory site briefing will be held on Friday 22nd May 09 at 10.30am.

Where: SF Balmain Shipyard (BSY). 72 Waterview St Balmain (Parking is not abundant - recommend catch Ferry to Thames St Wharf and walk - 10 minutes)

Note:  The inspections will commence from the Balmain Ship Yard, progress to Circular Quay, Ferry to Manly and conclude at the Manly Wharf

submissionMethodDetails:
NOTES TO INVITED FIRMS

To access the RFT document files and to lodge a  response you must  use the Access PassCode  provided to you by the contact officer.

Obtaining the RFT Documents

 Click on the DOWNLAOD A SOFT COPY - Free  link at the bottom of the page, use the Access Passcode provided to gain access, then register your firm in the system (if not already registered), and follow onscreen instructions to download the RFT document files provided.

Lodging a Response

Your completed tender should be lodged as allowed in the RFT Document, however, it may also be lodged electronically via this web page.

As the tenderer you must be a Registered user of this web site.

Click on the blue LODGE ON RESPONSE  link at the bottom of this page, using the Access Passcode, then using your registered system Username / Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Software Requirements

To be able to view the requirements within the RFT you will require the following software to be installed on your PC:

* Adobe  Acrobat Reader  5.0 (or more recent) - Please click here Adobe Acrobat Reader  to be taken to their free download site now.

* Winzip  7.0 (or more recent) or equivalent - Please click here Winzip    to be taken to their free evaluation download site now.

The RFQ also requires the following software:

* Microsoft - Word 2003 (or more recent) or equivalent

Other requirements:

* Internet connection to lodge completed tender response.

The tenderer is responsible for the provision and installation of the necessary software.

eTenderProcurementMethod: Pre-Qualified / Invited

conditionsForParticipation:
Access to this RFT is restricted to invited firms only.

Those Firms (Listed Below) have been issued with the special Access Pass-code  required by this RFT

The invited firms are:

Australian Security Concepts, 3 Watkins Place,
Currans Hill, Campbelltown NSW

Barrington Group of Companies, Suite 6, 7 Anella Ave,Castle Hill  NSW 2154

Business Risk International, 101 Palmer Street
East Sydney NSW 2011

eGroup P/L, Unit 4 /4 Charles St
Petersham NSW 2049

Fogl Knight Security Resources Pty Ltd, Suite 34/135, Sailors Bay Rd Northbridge

Knightguard Protection Services P/L, 1 Pacific Highway, Wahroonga NSW 2076

Pound Enterprises P/L, Shops 3&4, 11/13 The Boulevard, Woy Woy NSW

Shodan Security P/L, 11/202 Harbord Road
Brookvale NSW 2100

SNP Security, 30-32 Richmond Road,
Homebush NSW 2140

Triple 0 Security Services P/L, 146 D Samual Marsden Road. Orchard Hills NSW 2748

Ultimate Security Services P/L, Unit17, 13-15 Wollongong Rd. Arncliffe NSW 2205

Tender will only be accepted form the invited firms listed


description: Underground utilities construction service

title: Q14_13 - Specification  -  1.01.zip

title: Q14_13 - Returnables - 1.01.zip

description: PROVISION OF GROUND LINE MAINTENANCE SERVICES ON TRANSMISSION LINE WOOD POLES AS NOMINATED IN THE TAMWORTH AREA


title: Franklin Public School Tumut, New Toilet Block

title: Franklin PS - Toilet Block Tender.pdf

title: Franklin Tender Photos.pdf

description: A new Toilet Block at Franklin Public School Tumut


title: Cowra High School Toilet Upgrade

title: Documentation.zip

title: Tender Schedules.DOC

streetAddress: 3 Pacific Highway, Mooney Mooney

legalName: Cumnock Constructions Sustainability Pty Ltd

Glenn Healey Constructions

streetAddress: P.O Box 4747, Dubbo

legalName: G.C Healey & T.J Healey

streetAddress: 42-44 Mountbatten Drive, Dubbo

legalName: Paintrite Management Pty Ltd

streetAddress: 1/40 Lawson Street, Blayney

legalName: Peter O'Brien Constructions Pty Ltd

Richard H Clancy

streetAddress: 45 Riverview Lane, Forbes

legalName: Richard H Clancy

streetAddress: 27/6-20 Braidwood Street, Strathfield South

legalName: RMA Construction Group Pty Ltd

Coachwood Constructions

streetAddress: 48 Jensen Road, Griffith

legalName: Stuart R & Bronte John

description: Internal refurbishment of boys and girls toilets and showers at Cowra High School.

addressForLodgement:
This website https://tenders.nsw.gov.au/dsta

or as specified in tender documents

submissionMethodDetails:
Exhibited Hardcopy

An Exhibited hardcopy of this RFT is available for public viewing at NSW Public Works, Riverina Western Region, Level 2, 140 William Street Bathurst NSW, during normal business hours.

Preferred construction during school holidays.


items: Restricted Tender

title: Boggabilla Court House Redevelopment Works

status: Restricted Tender

RFTAccess: Restricted Tender

tenderers: Restricted Tender

tenderType: Restricted Tender

description: Restricted Tender

tenderPeriod: Restricted Tender

eTenderStatus: Restricted Tender

inheritanceType: Restricted Tender

deliveryLocation: Restricted Tender

submissionMethod: Restricted Tender

multiAgencyAccess: Restricted Tender

numberOfTenderers: Restricted Tender

procurementMethod: Restricted Tender

timeframeDelivery: Restricted Tender

coveredProcurement: Restricted Tender

addressForLodgement: Restricted Tender

submissionMethodDetails: Restricted Tender

eTenderProcurementMethod: Restricted Tender

conditionsForParticipation: Restricted Tender


description: Rehabilitation services

title: DECCW-894-2010 - Bourkes Gorge No 1 - Earth Works.pdf

title: DECCW-894-2010 - Tender Schedules.doc

title: DECCW-894-2010-Drawings.zip

title: BG1_Stage2C_Ewks34_Oct2010_Des_RevA.dwg

format: unknown

description:
REHABILITATION OF FORMER SNOWY SCHEME SITE – F2.02 – BOURKES GORGE SPOIL DUMP NUMBER 1

The Works Package includes the rehabilitation stabilisation works associated with the Former Snowy Scheme Site – F2.02 Bourkes Gorge Spoil Dump Number 1. The Package is a part of the wider Program – Rehabilitation of Former Snowy Scheme Sites, located within Kosciuszko National Park, NSW.

addressForLodgement:
Tender responses to be lodged electronically on the NSW e Tendering Public website www.tenders.nsw.gov.au or alternatively hard copy responses can be lodged at the Tender Box Address:

Hand Deliver: NPWS Tender Box, 7A Adelong Road Tumut NSW 2720

Post Delivery: NPWS Tender Box, PO Box 472, Tumut NSW 2720

Business Hours: 8:30am – 4:30pm

conditionsForParticipation:
A mandatory pre-tender meeting will be held on the date, at the time and at the place 10am 1st December, 2010 meet at NPWS Office Khancoban NSW. From which point will travel to site. Expect to be complete by 2pm.

The Contact Person will be available at that time to answer Tenderers’ queries.


title: High Voltage Network Alterrations and Supply and Installation of Replacement Diesel Generators, Nepean Hospital

amendments: Restricted Tender

description: Restricted Tender

Restricted Tender

Shadiqua Nainar

fax: Restricted Tender


description: Legal services

title: Legal Service Sydney Light Rail Extension (SLRE)

title: RFT SLRE - Legal Services.pdf

streetAddress: 126 Phillip Street, Sydney

legalName: Allens Arthur Robinson

streetAddress: Level 27, AMP Centre, 50 Bridge Street, Sydney

legalName: Baker & McKenzie

Clayton Utz

streetAddress: 1 O'Connell Street, Sydney

legalName: Clayton Utz

streetAddress: Governor Phillip Tower, 1 Farrer Place, Sydney

legalName: Corrs Chambers Westgarth

Henry Davis York

streetAddress: 44 Martin Place, Sydney

legalName: Henry Davis York

streetAddress: Level 65, MLC Centre, 19 Martin Place, Sydney

legalName: Holding Redlich

Hunt & Hunt

streetAddress: 1 Macquarie Place, Sydney

legalName: Hunt & Hunt

Mallesons Stephen Jaques

streetAddress: Level 60 Governor Macquarie Tower 1 Farrer Place, Sydney

legalName: Mallesons Stephen Jaques

streetAddress: level 26, 52 Martin Place, Sydney

legalName: Middletons

Minter Ellison Lawyers

region: VIC

streetAddress: 525 Collins Street, Level 23, Melbourne

legalName: Minter Ellison

streetAddress: Level 18, Grosvenor Place, 225 George Street, SYDNEY

legalName: Norton Rose Australia

streetAddress: Level 18, 321 Kent Street, Sydney

legalName: Sparke Helmore Lawyers

streetAddress: Level 20, 135 King Street, Sydney

legalName: TressCox Lawyers

title: RFT TNSW 2010_008 - Addendum No 1.pdf

rationale: A change has been made to a Tender requirement. Please download the Addendum No 1 document to view this infomation.

description:
The Service Provider will be responsible for providing legal services to the Principal in respect of Sydney Light Rail Extension Stages 1 and 2.

The Principal requires the full range of legal services in relation to the Project.  It is anticipated that these services will primarily be in relation to the development and negoiation of a commercial agreement with the Owner.  The Principal may also require legal services in relation to any planning, environmental, property or statutory interpretation that arise in connection with the Project.

addressForLodgement: eTender Lodgement


description: Building and Facility Construction and Maintenance Services

title: Cabramatta High School: Block Q Canteen Upgrade.

title: 1300321 MW21.zip

title: 1300321 Specifications.zip

title: 1300321 Drawings.zip

title: 1300321 - Addendum No 1.zip

rationale:
Addendum No. 1

refer to addendum No.1 attached, includes extension of closing date to Thursday 28/03/2013

description:
NOTE - This is a Selective Tender.

Upgrade of existing school canteen block.

Please note a Non Mandatory Meeting is to be held at Cabramatta High School on 12/03/13 at 10.00 am

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Kathryn Batger 02 9852 0171.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

All Facility Services Pty Ltd t/as All Facility Services, 11 / 172 Milperra Road, Revesby NSW 2212

Auscorp Constructions Pty Ltd, Suite 107A, 20 Lexington Drive, Bella Vista NSW 2153

Donnelley Constructions Pty Ltd, 1/8 Anella Avenue, Castle Hill NSW 2154

Elite Commercial Solutions Pty Limited, Unit 2, 7 Altair Place, Penrith NSW 2750

John Topalidis t/as JT Constructions, 2 Prout Street, West Hoxton NSW 2171

Tender responses from the above pre registered tendering companies ONLY will be accepted.


title: 06 MW21_tender_schedules 1.doc

title: 03-Att07 BFTA.pdf

title: pack 03.zip

title: pack 01_.zip

title: Addendum No 1.pdf

title: Addendum 1_ drawings.zip

title: addendum 1_schedules.zip

title: Add01Att09 Pre Tender Meeting.pdf

rationale: Addendum 1 consisting of 3 pages

description:
Wollongbar TAFE  Campus Upgrade Vehicle Body Section
- SUMMARY OF WORKS:

Works area 1:
subdivide 2 rooms to provide a new separate area for welding, cutting and grinding.
Works area 2:  replace the light switch ONLY (1 room)
Works area 3:  to subdivide existing room to provide 1 x new Day Tool Store Facility.
Works area 4:  new filtered fresh air supply system in to store area.
Works area 5:  add windows to existing wall (internal) + amend room fabric to accommodate a Paint Spray Booth

timeframeDelivery: 7 WEEKS

addressForLodgement:
Tenders will ONLY  be received by the following submissions:

Hard Copy Submissions to:

NSW Public Works, TENDER BOX,  120 Dalley Street, Lismore 2480

Facsimile Submissions to:

 NSW Public Works TENDER FAX NUMBER (02) 6626 5690

Electronic Submissions ONLY via NSW Government eTendering

 website:   https:// tenders.nsw.gov.au

submissionMethodDetails: NON-MANDATORY MEETING TO BE HELD AT SITE WOLLONGBAR TAFE CAMPUS ON 23/03/2012 AT 11:00 AM

conditionsForParticipation:
TENDERS WILL ONLY BE RECEIVED FROM THE FOLLOWING  SELECTED TENDERERS:

Donnelly & Hughes Pty Ltd
Shed 1, 19 Owens Crescent
ALSTONVILLE  NSW  2477
t:  02 6628 0597

John Larkin Constructions Pty Ltd
227 Houghlahans Creek Road
TEVEN  NSW  2478
t:  02 6687 8294

JVJ Constructions Pty Ltd
28 Collins Lane
CASUARINA  NSW  2487
t:  02 6674 3309

Hucks Building Pty Ltd
535 Cudgen Road
CUDGEN  NSW  2487
t:  02 6674 2515


title: Anson St School & Blayney HS - Trade Training Facility

title: TTC Anson and Blayney.pdf

title: Tender Schedules.doc

title: RFT Preview Document

streetAddress: 127 Keppel Street, Bathurst

legalName: Havenhand & Mather Architects Pty Ltd

streetAddress: 261 Lords Place,, Orange

legalName: John Blackwood Architects Pty Ltd

streetAddress: 16 Telford Street, Newcastle

legalName: Suters Architects Pty Limited

description:
The engagement involves the Architectural and sub-consultant services for the design and documentation of Trade Training Centre facilities for Hospitality, Metal Engineering and Propagation subject streams. The two schools are to be documented as one Minor Works construction tender package.

This RFT is a SELECTIVE TENDER. Only responses from the consultants listed below will be accepted for this RFT:

Havenhand & Mather Architects

John Blackwood Architects

Suters Architects

addressForLodgement:
NSW Department of Commerce

Riverina Western Region

Level 2

140 William Street

Bathurst  NSW  2795

submissionMethodDetails:
Tender responses are to be lodged by the Selective Tenderers as described in the RFT. Electronic Lodgement is available. Selective Tenderers can download a copy of the tender schedules and tender documents from this website.

Additional information may be obtained by telephoning Graeme Erskine on 02 6339 5926


title: Chatham High School - Changeroom Upgrade

title: Chatham HS Changeroom Upgrade Spec.pdf

title: MW21_tender_schedules.docx

title: Chatham HS - Change Rooms - Addendum 1.pdf

rationale:
Addendum #1
Addendum 1 consists of 1 page to be bound into the tender documents regarding clarifications.

description:
Provide clean and modern change room facilities.

**NOTE TO TENDERERS***
Tenders will only be considered from the North Coast Region Prequalified Building Contractors with the Southern Zone from $100-$250k financial range ONLY

timeframeDelivery: 9 weeks

addressForLodgement:
Hard copy submissions to NSW Public Works, TENDER BOX, 120 Dalley Street, Lismore 2480 Facsimile Submissions to: NSW Public Works TENDER FAX NUMBER (02) 6626 5690

*Electronic Submissions ONLY via NSW Government etendering website: https://tenders.nsw.gov.au

submissionMethodDetails:
A non-mandatory Pre Tender site meeting will be held at Chatham High School on Monday 11th March 2013 at 8.30am.

NOTES TO PARTICIPATING FIRMS
To access the RFT files and to lodge a response you must use the Access PassCode provided to you by the contact officer.

Obtaining the RFT Documents
Click on the DOWNLOAD A SOFT COPY - Free  link at the bottom of the page, use the Access Passcode provided to gain access, then register your firm in the system (if not previously  registered), and follow onscreen instructions to download the RFT document files provided.

Lodging a Response
Your completed tender should be lodged as allowed in the RFT Document, however, it may also be lodged electronically via this web page.

As the tenderer you must be a current Registered user of this web site.
Click on the blue LODGE ON RESPONSE link at the bottom of this page, using the Access Passcode, then using your registered system  Login Username and Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Electronic Tender Box Security
During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.
All responses that are received successfully can only be accessed, decrypted, retrieved and opened after the RFT has officially closed.

RFT Response - receipt/confirmation
A detailed system generated electronic receipt is issued for all submitted responses files received successfully.

Software Requirements
To be able to view the requirements within the RFT you will require the following software to be installed on your PC:
* Adobe Acrobat Reader  5.0 (or more recent) - Please click here
Adobe Acrobat Reader  to be taken to their free download site now.
* Winzip  7.0 (or more recent) or equivalent - Please click here
Winzip    to be taken to their free evaluation download site now.
The RFT may also requires the following software:
* Microsoft - Word 2003
* Microsoft - Excel 2003

Other requirements:
Internet connection to lodge completed tender response
The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation:
**NOTE TO TENDERERS***
Tenders will only be considered from the North Coast Region Prequalified Building Contractors with the Southern Zone from $100-$250k financial range ONLY

Access to this RFT documentation is restricted to pre-qualified invited firms only.
Those firms have been issued with the special Access PassCode  required by this RFT


description: Laboratory and Measuring and Observing and Testing Equipment

title: Laboratory Consumables for NSW Health

title: 0801620_LabConsumables_PartA.pdf

title: 0801620_LabConsumables_PartB.pdf

title: 0801620_LabConsumables_PartC.pdf

title: 0801620_LabConsumables_PartF.pdf

title: 0801620_LabConsumables_PartD.pdf

title: Lab Consumables_Part C Final.doc

title: Guide_How to Lodge a Tender.pdf

title: RFT Preview Document

streetAddress: Unit 19,  350-354 Settlement Road, Thomastown

legalName: Bagco Pty Ltd

streetAddress: 4 Research Park Drive / Macquarie University Research Park, North Ryde

legalName: Becton Dickinson Pty Ltd

streetAddress: Unit 25B, Parkview Business Centre, 1 Maitland Place, Baulkham Hills

legalName: Biomerieux Australia Pty Ltd

streetAddress: Unit 1, 21 Huntsmore Road, Minto

legalName: Ebos Group Pty Limited

streetAddress: 26 Heidelberg Avenue, Newington

legalName: Grand Sun International Australia Pty Ltd

streetAddress: Unit D, 120 Hassall Street, Wetherill Park

legalName: H D Scientific Supplies Pty Ltd

streetAddress: Unit 1/46 Sheehan Road, Heidelberg West

legalName: Interpath Services Pty Ltd

streetAddress: 106-116 Epsom Road, Rosebery

legalName: Livingstone International Pty Limited

region: QLD

streetAddress: Unit 1/31 Archimedes Place, Murarrie

legalName: Quantum Scientific

streetAddress: 1st Floor 96 Ricketts Road, Mount Waverley

legalName: Radiometer Pacific Pty Ltd.

region: SA

streetAddress: 16 Parkway, Technology Park, Pooraka

legalName: Sarstedt Australia Pty Ltd

Bio-Mediq Dpc

streetAddress: 885 Mountain Highway, Bayswater

legalName: Siemens Healthcare Diagnostics Pty Ltd

Stericorp   Biocorp

streetAddress: 2-16 Wiblin Street, Silverwater

legalName: Sterihealth Limited

streetAddress: 8 Benjamin Street, St Marys

legalName: Techno-Plas Pty Ltd

streetAddress: Level 4, Building B, 11 Talavera Road, Macquarie Park

legalName: Terumo Corporation

Tyco Healthcare Australia

streetAddress: Level 1, 166 Epping Road, Lane Cove

legalName: Tyco Healthcare Pty Limited

Valpak

streetAddress: Unit 36, 1-5 Thew Parade, Cromer

legalName: Valpak (Aust) Pty Ltd

title: 0801620_Addendum3.zip

rationale: Addendum No 3 -  Major Delivery Locations

title: Add 4 Lab Consums.zip

rationale: Addendum No4 - a revised Schedule 6 of Part D

title: 0801620_Notice1.zip

rationale: Notice No 1: Issue of Consolidated Specification Schedule 046 646 Lab Cons Final.xls

title: Addm1- RFT 0801620.doc

rationale: Amendments to conditions

title: 0801620_Addendum_2.zip

rationale: Addendum No 2- various

description: Tender process for a Standing Offer Agreement for the supply and delivery of Laboratory Consumables to NSW Health and eligible customers

submissionMethodDetails:
Tenderer briefing: to be held at 2pm on Wednesday 14 January, 2009 - arrangements should be be made through the Contact Officer to attend

Obtaining the RFT:

There is a full electronic copy of this RFT available for viewing or downloading.

This Web Site -  To download click on the blue Download a Soft Copy Free link at the bottom of this page, & follow the on screen instructions

For downloaded RFT - Software Requirements:

You may require the following software :

* Adobe ® Acrobat ® 70

 * Winzip ® 7.0

 * Microsoft ® Word 2003 or more recent) or equivalent

Lodgement:

Tenders are to be lodged to this tender web site – on this RFT web page go to the blue Lodge a Response link at the bottom of the page, and follow the on-screen instructions


description: Pipeline services

title: Astrolabe Park Stormwater Renewal - Design Development and Construct Contract

title: 4. Appendix A - Schedules of Prices Rates and Provisional Items.zip

title: 7. Appendix D - Drawings.zip

title: 8. Appendix E - OHS.zip

title: 9. Appendix F - Environmental Management EM.zip

title: 10. Appendix G - Community Relations.zip

title: 13. Appendix J - City of Botany Bay Documents.zip

title: 2. RFT 0510025119 Commercial Conditions and Tech Spec.zip

title: 11. Appendix H - CPDMS0023 SW Tec Spec - Civil Works.zip

title: RFT Preview Document

title: Addendum No 8 - RFT No 0510025119 Astrolabe Park Stormwater Renewal.pdf

title: Addendum 8.zip

rationale: Addendum 8 issued 11/03/2015

title: RFT No 0510025119 Astrolabe Park Stormwater Renewal - Addendum No 9.pdf

rationale: Addendum 9 issued 16/03/2015

title: Addendum 1 0510025119.pdf

rationale:
Addendum 1 issued 02/02/15

The tender closing date is Thursday 26/3/2015

title: Addendum No 2 RFT 0510025119 Astrolabe Park Stormwater Renewal.pdf

title: Addendum 2.zip

rationale: Addendum 2 issued 11/02/2015

title: Addendum No 3 - RFT No 0510025119 - Astrolabe Park Stormwater Renewal.pdf

rationale: Addendum 3 issued 13/02/15

title: Addendum No 04 - RFT No 0510025119.pdf

rationale: Addendum 4 issued 23/02/2015 (This addendum clarifies various issues and clauses of the tender documents).

title: Addendum No 5 RFT 0510025119 Astrolabe Park Stormwater Renewal.pdf

title: 150225_APW_DCD_T1 - Standard.zip

title: Models.zip

title: Botany field WQ 2013_14.xls

format: xls

rationale: Addendum 5 issued 25/02/2015

title: Addendum 06 - RFT 0510025119 Astrolabe Park Stormwater Renewal.pdf

rationale: Addendum 6 issued 27/2/2015

title: RFT No 0510025119 Astrolabe Park Stormwater Renewal - Addendum No 07.pdf

rationale: Addendum 7 issued 06/03/2015

description: Construction of twin reinforced concrete pipes each of 2.1 metre diameter and decommission the old existing twin 2X1 metre culvert and restore the wetland.


description: Building and facility maintenance and repair services

title: Hunter Institute Singleton Campus - Bonded Asbestos Removal and Wall Reinstatement Blocks B & D

title: 1002323_Specification_Final.pdf

title: 1002323_02_MW21_Tender_Schedules.doc

streetAddress: 311 New England Highway, Rutherford

legalName: C & W Constructions Pty Ltd

streetAddress: 100 George Street, Singleton

legalName: Jim Gauld's Building Company Pty Ltd

streetAddress: 603 Pacific Highway, Belmont

legalName: Parmenter Jiear Builders Pty Ltd

streetAddress: Unit 5/11 Kinta Drive, Beresfield

legalName: RTC Commercial Pty Limited

description:
The extent of works for this contract includes but is not limited to:

Provide all plant, labour, equipment and materials necessary to complete the bonded asbestos removal and new wall & partition linings to Blocks B and D.

The works comprise all work shown on the drawings and included in the specification.

submissionMethodDetails:
Tenders are invited from those companies prequalified in Hunter-New England Region for Building Works between the amounts of $100,001 and $250,000.

RTC Commercial Pty Ltd, Beresfield

Jim Gauld's Building Company Pty Ltd, Singleton

Australian Demolition Industries Pty Ltd, Cameron Park

Parmenter Jiear Builders Pty Ltd, Belmont

C & W Constructions Pty Ltd, Rutherford

Tender responses from the above prequalified tendering companies ONLY will be accepted.

OBTAINING THE RFT:

SOFTCOPY DOCUMENT

A soft copy of the RFT can be obtained from this Web Site. To download, click on the DOWNLOAD A SOFTCOPY link at the bottom of this advertisement and follow the on screen instructions.

EXHIBITED HARDCOPY

An exhibited hardcopy of this RFT is available for public viewing at the NSW Public Works, Level 2, 117 Bull Street NEWCASTLE WEST NSW 2302, during normal business hours.

SUBMITTING YOUR RESPONSE - ELECTRONIC LODGMENT

When you have completed your response, you can lodge it electronically via this website. You must be a registered user in order to submit a response. Click on the LODGE A RESPONSE link at the bottom of this page and follow the on-screen instructions.

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

Microsoft Word 2003 (or more recent) or equivalent.

Microsoft Excel 2003 (or more recent) or equivalent.

OTHER REQUIREMENTS:

An Internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 6.0 or later with Cipher Strength = 128bit.

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies are not allowed.

The tenderer is responsible for the provision and installation of the necessary software.

conditionsForParticipation: This tender panel was formed on 11/11/2010.


Transport for NSW

name: Attn: Project Information Officer, Infrastructure and Place, TfNSW

description:
The design, supply, transport to site, construction, testing and commissioning of the New Intercity Fleet (NIF) AC Feeders Stage 2 Upgrade project.

The Power Supply Upgrade (PSU) Program is designed to meet expected power requirements for Sydney's future rail network and new fleet of air-conditioned trains.

NIF AC Feeders Stage 2 relates to the upgrade of the following 33 kV feeders:

7Y2 between Sefton Substation and Yagoona Substation;

713 between Yagoona Substation and Revesby Substation; and

EA653 between Revesby Substation and Ausgrid pole PE24544.

The scope of work includes cable modifications, aerial modifications, pole replacements and new conductors.

This engagement has since been varied, including

More Trains, More Services (MTMS) Stage 1 Blacktown Station low voltage (LV) power supply improvement works

changes to the TfNSW Standard Requirements (Works Contracts)

respite costs

Public Health Order - COVID-19-related impacts

supply and delivery of shade cloth

cost and time impacts arising from Protected Industrial Action (PIA)

supply and installation of Bioguard Bandages

supply and delivery of spare composite crossarms

additional padmount works

design and construction of additional poles

design changes

generator supply

compliance with Sydney Trains electrical requirements

additional works required for Geotechnical inspection for poles 95K and 118K and new installation

additional works required to re-open backfilled pole holes.

description: Roads and rail

title: Power Supply Upgrade (PSU) Program - New Intercity Fleet (NIF) AC Feeders Stage 2

status: active

Abergeldie Contractors Pty Ltd

scheme: AU-ABN

legalName: Abergeldie Contractors Pty Ltd

scheme: ACN

otherInformation:
TfNSW Medium Works Contract (Design & Construct)

Original contract price of $22,661,140.00 (excl. GST)
Original Date for Completion of 11-Nov-2022

This contract has been varied:

Variation 01: an additional $187,901.49 (excl. GST)

Variation 02: an additional $28,620.00 (excl. GST)

Variation 03: an additional $20,000.00 (excl. GST)

Variation 04: an additional $1,518.07 (excl. GST)

Variation 05: an additional $30,487.79 (excl. GST)

Variation 06: an additional $40,000.00 (excl. GST)

Variation 07: an additional $6,560.00 (excl. GST)

Variation 08: an additional $93,704.00 (excl. GST)

Variation 09: an additional $7,335.15 (excl. GST)

Variation 10: an additional $70,048.94 (excl. GST)

Variation 11: an additional $63,575.14 (excl. GST)

Variation 12: an additional $42,260.11 (excl. GST)

Variation 13: an additional $224,908.91 (excl. GST)

Variation 14: an additional $4,223,700.37 (excl. GST)

Variation 15: an additional $46,607.52 (excl. GST)

Variation 16: an additional $80,262.68 (excl. GST)

Variation 17: an additional $78,143.36 (excl. GST)

Extension of Time: an additional $270,000.00 (excl. GST) and revised Date for Completion of 9-Jan-2023

Extension of Time: revised Date for Completion of 15-Mar-2023

Extension of Time: revised Date for Completion of 29-Mar-2023

Extension of Time: revised Date for Completion of 30-Jan-2024

Variation 18: N/A

Variation 19: an additional $64,216.14 (excl. GST)

Variation 20: an addtiional $44,252.61 (excl. GST)

Variation 21: an additional $14,328.91 (excl. GST)

Variation 22: an additional $241,695.18 (excl. GST)

Other payment: an additional $900,000 (excl. GST)

Variation 23: an additional $96,633.46 (excl. GST)

Variation 24: an additional $77,739.70 (excl. GST)

The disclosed contract value represents the contract price plus an additional 10% for GST. This value may be overstated if GST does not apply to all parts of the contract.

valueDescription: A project to be undertaken

evaluationCriteria:
Evaluation Criteria	Weighting

1. Tenderer's demonstrated capacity, relevant experience in similar  projects and size and ability to undertake the Works including experience, capability and availability of Key Resources, Subcontractors and Suppliers.
	20%

2. Understanding of the Project requirements including issues and risks, and Tenderer’s Methodology including Program of deliverables
	30%

3. Compliance with Statutory requirements including:

(i) Environmental;

(ii) Work Health and Safety;

(iii) Quality and Workplace Relations; and

(iv) Social Procurement, Workforce Development Commitments and Sustainability Approach.
	15%

4. Pricing – Lump Sum and Schedule of Rates
	35%

otherPrivateSector: Not Applicable

descriptionServices: Not Applicable

isAtsiOwnedBusiness: N

descriptionContractor:
TfNSW Medium Works Contract (Design & Construct):

• Clause 2.12(b) Third Party Agreements

• Clause 3.5 Latent Conditions

• Clause 6 Variations

• Clause 7.3 Provisional Sum Work

• Clause 8.5 Acceptance of Work (relating to Defects)

• Clause 10.1 Rate of Progress

• Clause 10.10 Extension of Time

• Clause 10.13 Delay Damages

• Clause 10.14 Suspension

• Clause 10.18 Direction to Compress

• Clause 13.3 Reinstatement

• Clause 16.12 Right of Set-Off

descriptionRenegotiated: Not Applicable

eTenderProcurementMethod: Multi-Stage

locationOfWork: Not Applicable

applicableIndustrialInstruments: Not Applicable


title: COROWA COURT HOUSE - REPAIR AND RECTIFICATION WORKS

description: Restricted Tender


description: Election organization services

title: Conduct the 2012 Council Election

title: FCCREOI04FY12.zip

description: The primary requirement of the proposed contract is the delivery of the 2012 Council election, in full compliance with the applicable legislation.

eTenderProcurementMethod: Expression of Interest For Pre-Qualification

conditionsForParticipation:
The Conditions for Participations are:

(a)               The Respondent must not be bankrupt or insolvent.

(b)               The Respondent must not have had significant deficiencies in performance of any substantive requirement or obligation under a prior contract of like nature.

(c)                The Respondent warrants that it has not, within the last 3 years, been found guilty of breaching any Act or Regulation which breach might be considered contrary to the values and principles of good corporate citizenship. Such Acts include, without limitation; Workplace Relations Act 1996 (Cth), Industrial Relations Act 1996 (NSW), Occupational Health & Safety Act 2000 (NSW), Workplace Injury Management & Workers Compensation Act 1998 (NSW), Equal Opportunity for Women in the Workplace Act 1999, Disability Discrimination Act 1992 (Cth), Human Rights (Sexual Conduct) Act 1994 (Cth), Racial Discrimination Act 1975 (Cth), Sex Discrimination Act 1984 (Cth), Age Discrimination Act 2004 (Cth), Anti-Discrimination Act 1977 (NSW), Disability Services Act 1986 (Cth).

(d)               Council’s policy is to engage in the highest standards of ethical behaviour and fair dealing. Council requires the same standards from those with whom it contracts. Respondents acknowledge Council’s Statement of Business Ethics (attached), as adopted by Council in accordance with the Local Government Act 1993 (NSW). The respondent acknowledges that they have read, understood and agree to comply with the requirements referred to therein.

(e)               Council reserves the right to undertake a Financial and Performance assessment on all short-listed respondents. Council utilises a comprehensive business analysis report produced by Corporate Scorecard Pty Ltd. The Respondent agrees to cooperate fully and provide the data as may be reasonably required to complete this assessment.


description: Electronic counters

title: Visitor Counters Sydney Olympic Park

title: 1 - MMW -Contract-visitor counters - January 2023.pdf

title: 2 - MMW -Contract-visitor counters.docx

title: 3 - Appendix A - SOPA Work Permit Guidelines.pdf

title: 4 - Appendix B - Sections 8-9 RLMP - Works and Development on Remediated Lands.pdf

title: 5 - Appendix C -Protection of Trees Guidelines.pdf

title: 6 - SOPA Visitor Counter locations new and existing.pdf

title: RFT Preview Document

Aldridge Traffic Systems Pty Ltd

streetAddress: 12-14 Leeds Street, Rhodes, Sydney

legalName: Aldridge Traffic Systems Pty Ltd

MetroCount

streetAddress: 15 O'Connor Close, North Coogee

legalName: Microcom Pty Ltd

SAGE Automation

streetAddress: SAGE Automation - New South Wales, 111A Union St, McMahons Point

legalName: SAGE AUTOMATION

title: Visitor Counters Sydney Olympic Park -  addendum no. 1.pdf

rationale: Addendum No 1

description: Suppy and installation of 7 no. visitor monitoring counters to count pedestrians and bicycles

Identifiers:
Cumberland/Prospect
Inner West

submissionMethodDetails:
Submit tenders electronically only through www.tenders.nsw.gov.au

Submit all completed tender schedules as a single combined pdf file.

Submit all supporting information as a single combined pdf file.

Hard copy tenders will not be accepted.

Do not send tenders to any SOPA officer, including email copies.

Tenders that do not comply with the above requirements may be deemed non-conforming and be passed over.


description: Professional engineering services

title: Panels for Provision of Design Services

title: APR_08-04083_Part_A.pdf

title: APR_08-04083_Part_B.doc

title: APR_08-04083_Part_C.pdf

title: APR_08-04083_Part_D.pdf

title: APR_08-04083_Part_E.pdf

title: zAddendum_No_2_APR_No_08-04083.doc

title: SMS-06-EN-0559 Distribution  Labelling of the High Voltage Distribution System.pdf

title: Attachment E3_8 - Panel Matrices.zip

rationale: Addendum No 2 is issued to extend the closing date, issue the Competencies & Skills matrices as spreadsheets and issue an outline of the requirements for Panel No. 34.

title: zAddendum_No_1_RFT_No_08_04083.doc

title: Attachment E3_8_1_PANEL 32-Competency v Skills Matrix.pdf

title: Attachment E3_8_2_PANEL 32-Competency v Skills Matrix .pdf

title: RC_003_Prof_Serv_RFP_Parts_C_E.pdf

rationale: Issue of Revised Competence vs Skills Matices for Panel 32 and issue of a 'Master' set of Contract Terms.

description:
Rail Corporation New South Wales (RailCorp) is embarking on a programme to upgrade the rail infrastructure throughout the RailCorp network in New South Wales.

The Engineering Division of RailCorp is pursuing a Business Plan where it extends its Design Resources and Capabilities through the use of external resources to meet the increasing demand for design activities. To achieve this aim the Engineering Division, through its Project Delivery area is preparing to expand a series of Design Panels.

The following are broad categories of stakeholders’ areas, each requiring external Professional & Technical Services resources to balance out peak demand for Design & Documentation and Program Management.

The Panels to be expanded are: -

Panel 30 (Transmission Lines (HV Aerial Lines))

Panel 31 (Cable Route)

Panel 32 (Earthing & Bonding)

Panel 32A (HV Protection)

Panel 33 (OHW)

Panel 34 (High/Low voltage Distribution)

Panel 28 (Survey Design Services)

Organisations not currently on one or more of the above listed Panels are invited to register for inclusion for one or more of the above design panels of railway-experienced and qualified Designers for a thirty six (36) month period, with up to two (2) possible extensions of twelve (12) months each.  Existing Panel members will be separately invited to confirm their interest in remaining on the Panels for which they are currently registered.

name: Transport Asset Holding Entity of New South Wales

addressForLodgement:
Tender Box

Rail Corporation New South Wales

Reception Area, Level 9, Sydney Central Building

477 Pitt Street, Sydney  NSW 2000


title: Cooler Classrooms Program at Caringbah High School and Bundeena Public School – Thermal Comfort Indoor Air Quality Works (Package 20, Tranche 20-21B)

title: PART1of3_RFT-10040641_Caringbah HS_Bundeena PS_Tr20-21B_P20.zip

title: PART2of3_RFT-10040641_Caringbah HS_Bundeena PS_Tr20-21B_P20.zip

title: PART3of3_RFT-10040641_Caringbah HS_Bundeena PS_Tr20-21B_P20.zip

title: Addendum No.1 _RFT-10040641_Package 20.pdf

title: Addendum drawings for change of locataions.pdf

title: RFT-10040641-Pre-Tender Site Meeting Notes Caringbah.pdf

title: RFT-10040641-Pre-Tender Supplementary Notes_Rev2.pdf

rationale: RFT-10040641 Addendum No.1 formally issues the Pre-Tender Meeting Notes, the Supplementary Technical Notes Revision No.2, and coordination details for the mechanical design at Caringbah HS.

description: Cooler Classrooms Program at Caringbah High School and Bundeena Public School – Electrical Upgrade Works and Thermal Comfort Indoor Air Quality Works (Package 20, Tranche 20-21B).

addressForLodgement: NSW Government eTender website ONLY.

submissionMethodDetails:
Before deciding to participate in this Request for Tender (RFT) and submit a tender, prospective tenderers shall thoroughly review the MW21 Conditions of Tendering in the attached RFT documents, including Section 2 – Tenderer Eligibility, Clause 4.3 – Aboriginal Participation and Clause 8.1 – Evaluation of Tenders.

The ONE on-site mandatory pre-tender meeting for this RFT Package details are:  Caringbah High School on Friday 26/03/2021 at 10:00AM

Preregistration: tenderers are requested to advise the Contact Person via email of their intention to attend the on-site mandatory pre-tender meeting before 5PM on Monday 22/03/2021. The Contact Person’s details are included in both this notice and provided in the RFT’s Conditions of Tendering, Clause 1.1.

As stated in the RFT’s Conditions of Tendering, Clause 5.3 – Pre-tender Meeting/s, attendance by tenderers at the pre-tender meetings is mandatory. Tenders submitted by tenderers who fail to attend the pre-tender meeting will be passed over – tenderers must attend ALL the mandatory PTMs where more than one is arranged.

The mandatory pre-tender meeting will be held only at the abovenamed school. Tenderers are strongly encouraged to separately arrange site visits to this RFT Package’s remaining school where a PTM is not being arranged, to familiarise themselves with the site and the CCP scope of works. This will be further discussed at the abovementioned mandatory pre-tender meeting.

Due to the current COVID-19 pandemic, only one person representing the tenderer is to attend the above on-site mandatory pre-tender meeting.

All attendees at the mandatory pre-tender meeting are to wear a suitable face mask and observe current social distancing requirements and any other specific COVID-19 safety requirements of the school.


title: Beresford Road Public School: Construction of new access toilet.

title: 1102026_Contract.zip

title: 1102026_Technical Specification.zip

title: 1102026_Drawings.zip

title: 1102026_Appendice A.zip

title: 1102026_Addendum No.1.zip

rationale:
Addendum No.1

Pre-tender site meeting minutes

Drawing

MW21 contract information

title: 1102026_Addendum No 2.zip

rationale:
Addendum No.2

Geotechnical Report

description:
NOTE - This is a Selective Tender.

Construction of new access toilet and associated works.

submissionMethodDetails:
DOCUMENTATION AVAILABLE FOR THIS RFT

A softcopy of the RFT document and returnable schedules is available for downloading by following the instructions below. Hardcopies/CD of the RFT Document will be available for additional charge.

OBTAINING RFT DOCUMENTATION

First time visitors to this web site who wish to download or order documents will need to self-register on this web site to gain access to the documents.

SOFTCOPY DOCUMENT

A soft copy of the RFT Document and Returnable Schedules can be downloaded from this web site free of charge.

To obtain the RFT Document from this web site download all the provided files by clicking on the DOWNLOAD A SOFT COPY link at the bottom of the page and following the on-screen instructions.

HARDCOPY DOCUMENT

This can be ordered on line via this website at an additional cost.

EXHIBITED HARDCOPY

An Exhibited hardcopy of this RFT is available for viewing by contacting Paul Devaise 02 9852 0166.

SUBMITTING your RESPONSE - ELECTRONIC LODGEMENT

When you have completed your response you can lodge it electronically via this Web Site

You must be a registered user in order to submit a response.

Click on the "LODGE A RESPONSE" link at the bottom of this page and follow the on-screen instructions.

PC SOFTWARE REQUIREMENTS

To be able to open and read/view the downloaded files for this RFT you may require certain software to be installed on your PC:

·          Adobe Acrobat Reader 8.0 (or more recent) - Please click http://www.adobe.com  to be taken to a free download site.

·          WinZip 10.0 (or more recent) or equivalent - Please click http://www.winzip.com  to be taken to a free evaluation download site now.

·          Microsoft Word 2003 (or more recent) or equivalent.

·          Microsoft Excel 2003 (or more recent) or equivalent.

The tenderer is responsible for the provision and installation of the necessary software.

OTHER REQUIREMENTS

An internet connection to lodge completed responses.

This web site has been optimised for the Microsoft Internet Explorer web browser.

The minimum requirements are as follows - IE version 5.5 or later with Cipher Strength =128bit

COOKIES

Your web browser MUST be set to accept cookies.

You will not be able to Register or access the documents if cookies not allowed.

STILL HAVING PROBLEMS

Having problems with logging in, responding, downloading, opening or viewing files, please refer to the FAQ under the On-line ?HELP button at the top of this page.

conditionsForParticipation:
The Selected Tenderers are:

Avant Constructions Pty Ltd, 4 Tattersall Road, Blacktown NSW 2148

Cash McInnes Projects Pty Ltd, Level 1, Grandview Street, Pymble NSW 2073

Elite Commercial Solutions Pty Limited, Unit 2, 7 Altair Place, Penrith NSW 2750

Maincom Pty Limited, 6/119 Coreen Ave, Penrith NSW 2750

ProGroup Management Pty Limited, Suite 103, 32 Delhi Road, Macquarie Park NSW 2113

Tender responses from the above pre registered tendering companies ONLY will be accepted.


description: Business and corporate management consultation services

title: RFQ - SCM0005 - External consultant for cultural change strategic framework

title: WSLHD_196166 - Request for Quotation - Culture Change.pdf

title: WSLHD_196166 - Response Schedules - Culture Change.docx

title: WSLHD_196166 - Addendum 3.pdf

rationale: Addendum 3 contains responses to some requests for clarification.

title: WSLHD_196166 - Addendum 2.pdf

rationale: Addendum 2 contains responses to some requests for clarification.

title: WSLHD_196166 - Addendum 4.pdf

rationale: Addendum 4 contains a final set of responses to requests for clarification. No further requests for clarification will be accepted.

title: WSLHD_196166 - Addendum 1.pdf

title: 2019 WSLHD Culture Strategy FINAL 2019-11-05.pdf

rationale: Addendum 1 contains responses to some requests for clarification. Further responses will follow in due course.

description: HealthShare NSW, on behalf of Western Sydney Local Health District, invites quotations for the provision of consultancy services to implement the Cultural Change Strategic Framework.

name: HealthShare NSW - Local Tender and Contracts

Identifiers:
Nepean
Inner West
South West Sydney

addressForLodgement: Quotations must be lodged electronically via this eTendering portal.

submissionMethodDetails: Respondents must be cleared for full pre-qualification (not just base level) on the Performance and Management Services panel (SCM0005) for their quotations to be considered.


description: Building and Facility Construction and Maintenance Services

title: Westport High School - External Painting

title: Westport HS External Painting Spec.pdf

title: MW21_tender_schedules.docx

title: MW21_tender_schedules.docx

format: docx

title: Addendum No 1 contract 1202250.pdf

rationale:
Addendum #1
Addendum 1 is to be bound into the tender documents regarding pre-tender meeting minutes, clarifications, additions and deletions.

title: Addendum No 2 contract 1202250.pdf

title: Addendum 2 Photos.zip

rationale:
Addendum #2
Addendum 2 is to be bound into the tender documents regarding clarifications.  Please note the closing date has been extended and will now close on Thursday 28th March 2013 at 9.30am.

description: External Painting and Minor Repairs at Westport High School

submissionMethodDetails:
Approved Mandatory Meeting to be held at Westport High School on 12th March 2013 at 9.30am.

Obtaining the RFT Documents
Click on the DOWNLOAD A SOFT COPY - Free  link at the bottom of the page, use the Access Passcode provided to gain access, then register your firm in the system (if not previously  registered), and follow onscreen instructions to download the RFT document files provided.

Lodging a Response
Your completed tender should be lodged as allowed in the RFT Document, however, it may also be lodged electronically via this web page.

As the tenderer you must be a current Registered user of this web site.
Click on the blue LODGE ON RESPONSE link at the bottom of this page, using the Access Passcode, then using your registered system  Login Username and Password and follow the on-screen instructions to be taken to the lodging screen to submit your electronic tender response.

Electronic Tender Box Security
During the lodgement process all submitted responses are encrypted for security and stored securely in the “electronic tender box”.
All responses that are received successfully can only be accessed, decrypted, retrieved and opened after the RFT has officially closed.

RFT Response - receipt/confirmation
A detailed system generated electronic receipt is issued for all submitted responses files received successfully.

Software Requirements
To be able to view the requirements within the RFT you will require the following software to be installed on your PC:
* Adobe Acrobat Reader  5.0 (or more recent) - Please click here
Adobe Acrobat Reader  to be taken to their free download site now.
* Winzip  7.0 (or more recent) or equivalent - Please click here
Winzip    to be taken to their free evaluation download site now.
The RFT may also requires the following software:
* Microsoft - Word 2003
* Microsoft - Excel 2003

Other requirements:
Internet connection to lodge completed tender response
The tenderer is responsible for the provision and installation of the necessary software.


description: Infrastructure building and surfacing and paving services

title: Construction of Skate Park Facility

title: RFT 070809.zip

description: Tenders are invited for the Construction of a new skate park at Corner of Hosking St and Borrowdale Way Cranebrook NSW 2749.

timeframeDelivery: Construction to be completed by June 09 Contract to be issued February 09

addressForLodgement:
Tender Lodgement

Tenders must be lodged either electronically at this web address or manually by being placed in the tender box no later than the advertised closing time, 2pm on Tuesday 20th January 2009.  Penrith City Council's Tender Box is located in the foyer of Council's Civic Centre 601 High Street Penrith NSW 2750.

submissionMethodDetails:
Documentation

A complete set of documents are included in the Zip file titled RFT 070809, the files comprise the Tender documents including, electronic response schedule (ERF) along with Appendixes 1 through to 7.

Tenderers are required to submit their response using the electronic forms provided.


description: Arts and crafts equipment and accessories and supplies

title: 3 Public Art projects for the Auburn Town Centre

tenderType: Expression of Interest for Specific Contracts

description:
Q-2013-005 – 3 Public Art Projects for the Auburn Town Centre

Auburn City Council is seeking Expressions of Interest from suitably qualified and experienced artists for:

 3 Public Art Projects for the Auburn Town Centre

 Closing Time: 12noon Thursday, March 28, 2013

 Expressions of Interest documents are available free-of-charge by accessing the following website:
 http://360providers.apetsoftware.com.au/Public/PublicJobs.aspx?Code=auburnatm

 Responses must be lodged either electronically at the above web address or by being placed in the Tender Box by the closing time.

 Auburn Council’s Tender Box is located at Council’s Customer Service Counter, 1 Susan Street, Auburn. Responses lodged in the Tender Box must be submitted in a sealed envelope marked “Q-2013-005 – 3 Public Art Projects for the Auburn Town Centre”.

 Note: Project briefing sessions will be held as detailed in the invitation document.

 The canvassing of Councillors or Council staff could lead to automatic disqualification from the tender process.

 John Burgess GENERAL MANAGER


title: Dubbo TAFE Myall Street Consolidation Works

description: Restricted Tender

Restricted Tender

Graeme Erskine

mobile: Restricted Tender


description: Lease and rental of property or building

title: Opportunity to provide a Uniform Shop at Sherwood Ridge PS

title: Tender Documents.zip

title: SINSW-21 - 9169 Addendum 2.pdf

rationale: See attached Addendum 2 regarding gross sales

title: SRPS Revised Addendum 1- Uniform Shop.pdf

rationale: Answers to 2 x questions raised by a potential tenderer

description: Selection of a suitably qualified and experienced operator to supply Sherwood Ridge public School with school uniforms in accordance with the school’s uniform policy and operate a uniform shop for the period of three (3) years plus and option to renew for a period of two (2) years. Please note the School’s current student population for the 2021 school year is 793 students.

addressForLodgement: E- tenders Website

submissionMethodDetails:
Mandatory Site Inspection date, time and location.

20 April 2021 at 10:00 am

Report to Administration – Block A

Sherwood Ridge PS

34 Rosebery Rd,

Kellyville NSW 2155

Samples of the current uniform will be available for inspection at this time.

Please note: Your Tender response will not be considered if you are unable to attend the site inspection.

conditionsForParticipation: Attendance of the mandatory site meeting on 20 April 2021 at 10:00AM.


description: Garbage collection or destruction or processing or disposal

title: Waste and Resource Recovery Processing and Disposal Services

title: T79-18 Documentation.zip

title: T79-18 Addendum 1.zip

rationale: Addendum 1

title: T79-18 Addendum 2.pdf

rationale: Addendum 2

description:
Council is seeking Tenders from suitably qualified and experienced Tenderers for the receipt, processing and/or disposal of General Waste, Recyclables, Organics and Bulky Waste.

A full description of the nature and extent of the services required by Council are set out in Section 3 of this Request.

Tenderers are to note that the Tenders being sought are for the four separable areas and Tenderers are able to submit for one or more or all of the areas. Following evaluation of the Tenders, Council may enter into up to four separate contracts for these services.

addressForLodgement:
Preferred Method of Lodgement	Electronic lodgement at:

http://360providers.apetsoftware.com.au/public/bankstownprod/publicjobs.aspx

submissionMethodDetails:
10:00 a.m. Tuesday, 22 May 2018, Kelso Waste Management Facility,

265 Bransgrove Road, MILPERRA.

Only tenderers that are tendering for the Organics service are required for this meeting.

All attendees must carry a mobile phone and wear appropriate PPE: including safety boots, hi-vis clothing or vest and long trousers.

The entire Kelso Waste Management Centre is non-smoking.

Council will not consider a Tender lodged by a Tenderer for the Organics service who fails to sign the attendance sheet at this briefing, or fails to ensure that a representative of the Tenderer signs the attendance sheet on its behalf.


description: Temporary engineering services

title: Invitation to Quote - Consultancy for Air-Conditioning Renewal.docx

description: Design Consultancy Services for the air-conditioning renewal works at Springwood Library 102-108 Macquarie Road, Springwood.

submissionMethodDetails:
Quotes must be accessed and lodged online at

https://360providers.apetsoftware.com.au/Public/PublicJobs.aspx?Code=bmccpro3

(“Electronic Tender Box)

conditionsForParticipation:
The Conditions for Participation are mandatory requirements, which describe minimum standards that Suppliers must meet for their Quotes to be considered. If Suppliers do not meet the Conditions of Participation, they will be excluded from the evaluation process.

The Conditions for Participation are:

Suppliers must be an acceptable legal entity. It is Council’s policy not to trade with any organisation that does not hold a registered ABN;

Suppliers must not be bankrupt or insolvent;

Suppliers must declare and provide details of any occurrence, within 5 years prior to submitting a Quote, where the Supplier has been found guilty of breaching any Act or Regulation.

Suppliers must have the minimum level of insurance cover specified in the Contract; and

Suppliers must comply with the New South Wales Government Code of Procurement.


description: Community and social services

title: ADHC Supplier Directory Stage One

title: 1. ADHC.13.35N RFT document.pdf

title: 2. Guidelines for listing on the ADHC Supplier Directory revised 241213.pdf

title: 3. Supplier Directory Stage One Guidelines for Applicants.pdf

title: 4. FACS Conditions of Tendering.pdf

title: 5. ADHC Funding Agreement.pdf

title: 6. ADHC Supplier Directory Application Form Stage One January 2015.doc

description:
The ADHC Supplier Directory is a set of guidelines on the engagement and selection of providers to deliver specialist funded services to people with disability.  It assists local ADHC staff to advise people with disability, their families and carers about service providers in their area.

The ADHC Supplier Directory includes all specialist disability types currently funded by ADHC. For more information about specialist disability services funded by ADHC, please see: http://www.adhc.nsw.gov.au/sp/delivering_disability_services.

Please note: All applications must be made using the official application form supplied, with required information being supplied on the application form itself, except where additional information, such as certificates of currency or financial reports, is specifically required as part of the application process. Applications that do not fulfil this requirement will be set aside, with no further consideration given.

Applications to be listed on the ADHC Supplier Directory are being run as a continuous rolling tender process, with each tender being open for approximately four weeks. Dates for 2015 are below.

Opening

Closing

2 February 2015

27 February 2015

2 March 2015

27 March 2015

30 March 2015

24 April 2015

27 April 2015

22 May 2015

25 May 2015

19 June 2015


description: Specialized educational services

title: LeadSmart Stage 2 – Development of Curriculum Aligned Education Programs

title: V1_AS_Part AandB_TenderConditions-andSOR.DOC

title: V1_S_PartC-TenderResponse.doc

title: LeadSmart Flip Book v3.pdf

title: LeadSmart Flip Book IND v3.pdf

title: IMG_0702.JPG

title: Tender_1291_addendum1.doc

rationale: Please download addendum number 1

title: Tender_1291_addendum2.doc

rationale: Please download addendum number 2

description:
In February 2015 the NSW Government announced that over $13 million had been allocated to address lead exposure issues in Broken Hill over the five years commencing 1 July 2015. The funding was allocated in response to ongoing detections of elevated blood lead levels in children living in Broken Hill. The funding is being used to establish a rejuvenated Broken Hill Environmental Lead Program (BHELP) with the aim of addressing this important issue.

This program has been developed in partnership between the NSW Environment Protection Authority (EPA) and NSW Health and has a focus on children, particularly Aboriginal children who have been shown to have higher incidences of elevated blood lead levels. The funding is focused on establishing long term sustainable solutions to ensure that children aged 1 to 4 years in Broken Hill meet the National Health Medical Research Council (NHMRC) target for blood lead levels into the future.

Public education and awareness programs are a key focus area of the BHELP strategy to address the lead issue in Broken Hill.

The stage one LeadSmart Community Engagement Strategy was developed to support the key objectives of the BHELP and focussed on raising awareness of the lead issue and the simple and practical ways to reduce lead exposure – particularly amongst children aged 0-4 years.  The campaign included television, radio and Facebook advertising campaigns, printed educational materials and a dedicated website www.leadsmart.nsw.gov.au.

The stage one LeadSmart Community Engagement Strategy was in market from October 2016 to March 2017.  Evaluation of the stage one campaign has shown that it was extremely effective in cutting through with the Broken Hill community - positively influencing awareness and conversation on the lead issue and on how locals can reduce lead exposure.

The intent of this request for quotation is to engage a suitable supplier to develop NSW Department of Education, curriculum aligned education programs that will form part of the stage 2 LeadSmart community engagement strategy.  The aim of the stage 2 strategy is to engage with the local community through the development and delivery of targeted education programs to key audience groups.  The objectives of the strategy is to change behaviours, build capacity and empower so that target groups / individuals (and through the individual the broader community) have the skills and confidence to address the lead issue into the future

addressForLodgement: Lodgement: https://tenders.nsw.gov.au

submissionMethodDetails: Please refer to the RFQ Documents


title: Sydney Olympic Aquatic Centre utility/competition and training pool remediation works

description: Restricted Tender

Sam Eisenhauer

url: Restricted Tender

submissionMethodDetails: Restricted Tender


description: Drainage services

title: RFT T36-15 Salt Pan Creek Catchment.zip

description:
Council is seeking Tenders from suitably qualified and experienced Respondents for Salt Pan Creek Catchment Drainage Pipe and Pit Condition Assessment and Reporting.

A full description of the nature and extent of the services required by Council are set out in Section 3 of this Request.

Services will include inspection of stormwater drainage infrastructure assets (conduits and structures), verification of existing data, and collection of missing/additional relevant data, condition assessment and the provision of condition assessment reports. Condition assessment will also include the investigation of the structural and serviceability issues in stormwater pipes, ranging from 600 mm and above in diameter and reporting of the inspection results and recommendations on defect repairs. The condition assessment is limited to conduits ranging from 600mm and above in diameter.

submissionMethodDetails:
Please note Council is now using APET for all electronic lodgements and lodging by NSW e-tendering will no longer be available.

If your not already registered with Apet360. We strongly recommend that you register online with Apet360 upon down loading the tender documents from e-tendering.

The URL for electronic lodgement is http://360providers.apetsoftware.com.au/public/bankstownprod/publicjobs.aspx

Apet users guide has been attached to our documents for lodgement.