title: Provision of SPECT/CT Gamma Camera System at RHC

title: Provision of Associated Enabling Works for SPECT/CT Gamma Camera System at RHC

title: Provision of SPECT/CT Gamma Camera System at Forth Valley Royal Hospital

description: Provision of SPECT/CT Gamma Camera System At Royal Hospital for Children

Maintenance and Support (Commercial)

type: cost

description:
Provision of enabling (turnkey) works associated with SPECT/CT Gamma Camera System at Royal Hospital for Children.
 The existing equipment shall be disconnected, removed from site and disposed of unless otherwise instructed by the Board.
 The design shall take account of the current room layout and departmental operations modifying the space to meet current design standards and existing patient flow arrangements. Pre-installation works shall be through a turnkey arrangement which will be required to prepare the installation to a clinical operational standard, this is expected to include, but not be limited to re-wiring, plumbing, ventilating, chilling, lead lining, decoration etc. Provision for data and telecommunication shall be made in liaison with Board representatives. Dedicated central server rooms are distributed across the building for the purpose of networked resiliency and bidders should confirm any requirements for networking and data integration with these facilities.
 Pre-installation work may include the following:
 -	Any required radiation protection works as necessary
 -	Re-wiring and provision of appropriate power supplies and distribution systems to comply with electrical legislation
 -	UPS/IPS systems and re-wiring
 -	Earth bonding system and re-wiring
 -	Levelling of floors if required
 -	Finishing of floors, walls and ceilings
 -	Dry lining, room decoration and fitments
 -	Cleaning of room prior to handover
 -	Provision of new or extended plumbing, ventilation, heating and cooling, where necessary
 -	Upgrading or the addition of IT and telecommunication infrastructure where necessary

description:
Royal Hospital for Children
 1345 Govan Road, Govan
 G51 4TF

description:
Forth Valley Royal Hospital
 Stirling Road, Larbert
 FK5 4WR

description: Provision of SPECT/CT Gamma Camera System and Associated Enabling Works For NHS Greater Glasgow & Clyde, Provision of SPECT/CT Gamma Camera System for NHS Forth Valley

title: Invitation to Tender

title: NHS GGC Terms and Conditions Goods & Services

title: Prompt Payment Question

title: Proposed Award Criteria - SPECT-CT Gamma Camera System Lot 1 RHC

title: Proposed Award Criteria - SPECT-CT Gamma Camera System Lot 2 - Turnkey RHC

title: SPD Additional Information SPECT-CT

title: SPD PCS SPECT-CT Gamma Camera System Lot 1

title: SPD PCS SPECT-CT Gamma Camera System Lot 2 - turnkey RHC

title: Specification - SPECT-CT Gamma Camera System Lot 1 - equipment RHC

title: Specification - SPECT-CT Gamma Camera System Lot 2 - Turnkey RHC

title: SPECT-CT Pre-acquisition Questionnaire

title: SPECT-CT Tender Evaluation Matrix (Lot 1 and Lot 2)

title: SPPQ - SPECT-CT Tender

title: Supplementary GDPR Provisions (addendum to T&Cs)

title: 1.5.22 Picture Archiving and Communication System v4 25-04-21

title: 1.5.23 Dicom statement intergration performa

title: 1.5.25 Equipment Standards

title: 1.5.27 IRMER17+IRR17 equipment compliance proforma v0.4

title: 2.1.3 FINAL - FORTH VALLEY SPECT CT Gamma Camera Specification 28.04.23

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_a_2016

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_b_2016

title: 2.1.5 GAMMA_CAMERA_PET_SCANNER_part_c_2016

title: 2.1.7 Scoring FVRH Spect CT v3 28.04

title: 2.1.12 Lot 3 KEP-R(77)L-0-RAD092-01_Iss8

title: 2.1.14 Turnkey Survey Sheet

title: 3.2.3 FV Trade In

title: Lot 3 NHS FV ITT Response Form

title: SPD Additional Information SPECT-CT Lot 3 NHS FV

title: SPD SPECT-CT Gamma Camera System Lot 3 NHS FV

title: National Services Scotland Framework Terms and Conditions

streetAddress: Glasgow Royal Infirmary

description:
Gareth Miller (Commodity Manager - Capital Equipping)
 Sophie Connelly (Commodity Officer - Capital Equipping)
 Gerry Mather (Project Manager - Property and Capital Planning)

awardCriteriaDetails: Tenderers can bid on all three (3) Lots for both equipment and turnkey. We reserve the right to award the Lot for equipment only and turnkey only, should it be deemed acceptable by the co-operating Health Boards. In the event where Lot 1, Lot 2 and Lot 3 are awarded to different suppliers, the successful bidders of Lot 1, Lot 2 and Lot 3 are expected to work together in a collaborative, constructive manner that benefits both parties and to the benefit of NHS stakeholders.

performanceTerms:
3 year manufacturer's warranty on Lot 1.
 10 year maintenance on Lot 1.
 Description of Added Value Features (FOC) for Lot 1.

NHS Greater Glasgow and Clyde

locality: Glasgow

postalCode: G4 0SF

streetAddress: Procurement Department, Glasgow Royal Infirmary, 84 Castle Street

description: Health

legalName: NHS Greater Glasgow and Clyde

NHS Forth Valley

locality: Stirling

postalCode: FK9 4SW

streetAddress: Trust Headquarters, Carseview Castle Business Park

legalName: NHS Forth Valley

name: Glasgow Sheriff Court and Justice of the Peace Court

postalCode: G5 9DA

streetAddress: 1 Carlton Place

NHS Greater Glasgow and Clyde

description: Health

Siemens Healthcare Limited

locality: Camberley

postalCode: GU15 3YL

streetAddress: Park View, , Watchmoor Park,

legalName: Siemens Healthcare Limited

description:
This tender is a joint venture between NHS Greater Glasgow and Clyde (GG&C) and Forth Valley.
 Scoring for Lot 1 and Lot 2 will be conducted by NHS GG&C.
 Scoring for Lot 3 will be conducted by National Services Scotland (NSS) and NHS Forth Valley.
 (SC Ref:742658)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

rel: canonical

status: complete

description: Renewal in 4 years

description: Fife Council intend to establish a framework agreement with multiple suppliers for the repair, supply and fit of Hydraulic Hoses (inclusive of a suitable breakdown call-out facility). The Contract will provide a service for a variety of Council fleet vehicles including refuse vehicles, sweepers and gritters. Bidders are required to provide a climate change plan in response to SPD question 4C7

Quality

type: quality

type: price

variantPolicy: notAllowed

scheme: CPV

title: EF0064 Framework agreement for the provision of repair, supply and fit of hydraulic hoses for vehicle and plant

format: text/html

description: The repair, supply and fit of Hydraulic Hoses for Vehicles and Plant Equipment

documentType: contractNotice

title: TN info - EF0064

title: Climate change plan - EF0064

title: Fife Council Terms and Conditions - Purchase of Services

format: application/pdf

title: TN2 - EF0064

title: Price schedule - EF0064

title: TN1 - EF0064

documentType: awardNotice

description:
II.2.11) Information about options
 Please note the following amendment for question 11.21.11 Information about options:
 Fife Council may require additional purchases under this contract which have not been specifically detailed in the "specification" however any additional purchases will be in full accordance with the requirements of Regulation 72 of the Public Contract (Scotland) Regulations 2015.

description: Deadline changed

label: Time limit

label: Conditions for opening of tenders

scheme: CELEX

description: 3-4 years

electronicInvoicingPolicy: allowed

reviewDetails:
Economic operators should approach the contracting authority in the first instance. However, the only formal remedy is to apply to the courts:
 An economic operator that suffers, or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session

procurementMethod: open

type: suitability

description: The relevant selection criteria will be included in the SPD Scotland module.

type: economic

type: technical

mainProcurementCategory: services

procurementMethodDetails: Open procedure

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Bankhead

scheme: COFOG

description: General public services

legalName: Fife Council

name: Kirkcaldy Sheriff Court and Justice of the Peace Court

locality: Kirkcaldy

postalCode: KY1 1XQ

description: General public services

MacAulay Plant Services Ltd

locality: Shotts

postalCode: ML7 5PG

streetAddress: Unit 2, 59 west Benhar Road

scale: sme

legalName: MacAulay Plant Services Ltd

Bowen Fluid Engineering Ltd

region: UK

locality: Rosyth

postalCode: KY11 2WP

streetAddress: Unit 3, Forties Gateway , Barham Road

legalName: Bowen Fluid Engineering Ltd

Pirtek Glasgow

postalCode: G32 8RG

streetAddress: Block 12 Unit 2 Clydesmill Drive, Cambuslang Investment park

legalName: Pirtek Glasgow

currency: GBP

status: active

description:
Economic operators may be excluded from this competition if they are in breach of any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 (SC Ref:753319)

initiationType: tender

scheme: EU-OJ


id: Software for Housing Management & Finance

description: Option to extend by up to 36 months

description: Single Stage open tender, evaluation based on 30% price / 70% quality. Top three evaluation scorers invited to interview.

description: 17 Bridge St, Linwood, Paisley PA3 3DB

description: Software for areas including tenancy, income management, reactive repairs, planned investment, tenant safety/compliance, complaints handling, factoring, finance, GDPR compliance

title: Tender Information

reviewDetails: Interviews held on 3rd and 9th August. Scoring complete and winning tenderer notified 25/08/2023.

mainProcurementCategory: goods

Linstone Housing

roles: buyer centralPurchasingBody

locality: Linwood

postalCode: PA3 3DB

streetAddress: Bridge Street

description: Housing and community amenities

legalName: Linstone Housing

Leadership Team

locality: Paisley

streetAddress: 17 Bridge Street

legalName: Leadership Team

Linstone Housing

description: Housing and community amenities

Designer Software Ltd

locality: Milton Keynes

postalCode: MK5 8FT

streetAddress: 11 Whittle Court, Davy Avenue

legalName: Designer Software Ltd

Linstone Housing Association

legalName: Linstone Housing Association

description:
Attached document gives detailed requirements
 (SC Ref:747679)


description: Dear Supplier,We are inviting quotes for 710_1230 - Galloway Skip Hire, South Region.Please read through the brief attached for full details of the requirement.Yours Sincerely,Faye Russell

title: Award of 710_1230 - Galloway Skip Hire

description: Agricultural, forestry, horticultural, aquacultural and apicultural services

The City of Edinburgh Council

locality: Edinburgh

postalCode: EH8 8BG

streetAddress: Waverley Court

WASHCO Limited

locality: Newbury

postalCode: RG14 5RU

streetAddress: Unit 11 Arnhem Road

NHS Greater Glasgow and Clyde

postalCode: G12 0YN

streetAddress: Estates Dept

Revinson Fire Limited

locality: Sunderland

postalCode: SR5 2BA

streetAddress: Unit M Camden Street

Fife Council

streetAddress: Fife House

Access UK Ltd

locality: Loughborough

postalCode: LE11 3QF

streetAddress: The Armstrong Building, 10 Oakwood Drive

Scottish Government

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

Lorien Resourcing Ltd

postalCode: EH2 4QZ

streetAddress: Randolph House

University of Stirling

postalCode: FK9 4LA

streetAddress: Finance Office, Room 2Z6

The Media Shop Scotland Ltd

postalCode: g1 3AH

streetAddress: 5 Royal Exchange Square

Angus Council

locality: Forfar

postalCode: DD8 1AN

streetAddress: Angus House

JML Contracts Ltd

locality: Aberuthven

postalCode: PH3 1GX

streetAddress: 4 Strathearn House

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road

QIAGEN Ltd

locality: Manchester

postalCode: M13 0JH

streetAddress: Citylabs 2.0

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

Perth Autism Support

locality: PERTH

postalCode: PH1 5QH

streetAddress: 28-30 Market Street

name: Walk In The Gate Ltd (Trading as The Gate Worldwide)

postalCode: EH6 6SE

streetAddress: Admiral House

Forestry and Land Scotland

locality: Inverness

postalCode: IV3 8NW

streetAddress: Great Glen House

Weir Forestry

postalCode: FK8 3HD

streetAddress: 1 Wester Kepp Cottages

AMD Contract Services Ltd

locality: Dumfries

postalCode: DG2 0BJ

streetAddress: 1 Old Irongray Road

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

Moray Council

locality: Elgin

postalCode: IV30 1BX

streetAddress: High Street

name: Galliford Try Construction Ltd t/a Morrison Construction North East

locality: Aberdeenshire

postalCode: AB21 0AZ

streetAddress: Morrison House, Kingseat Business Park,

ROYAL BANK OF SCOTLAND

locality: EDINBURGH

postalCode: EH2 1AF

streetAddress: 24 ST ANDREW SQUARE

Crown Estate Scotland

postalCode: EH3 9GL

streetAddress: Quartermile Two

Northern Light Consulting Ltd

locality: Fort William

streetAddress: Unit 6B1 Blar Mhor Industrial Estate

NHS Lanarkshire

locality: Bothwell

postalCode: G71 8BB

streetAddress: NHS Lanarkshire Headquarters

John McGeady Ltd

locality: Blantyre

postalCode: G72 0TH

streetAddress: Craighead Industrial Estate

Frank Nicol Farm & Garden Machinery Ltd

locality: Dingwall

postalCode: IV15 9RB

streetAddress: Strathpeffer Rd

Forfend Information Security Limited

locality: Birmingham

postalCode: B1 2LP

Community Integrated Care

locality: Widnes, Cheshire

postalCode: WA8 7SP

streetAddress: 2 Old Market Court

South Ayrshire Council

locality: Ayr

postalCode: KA7 1DR

streetAddress: County Buildings

name: The Common Services Agency (more commonly known as NHS National Services Scotland) (NSS)

name: Procurement - Scottish National Blood Transfusion Service

Hydro Group Ltd

streetAddress: Claymore Avenue, Aberdeen Science and Energy Park

Evident Europe GmbH

streetAddress: Part 2nd Floor Part A, Endeavour House Coopers End Road

name: Bright Digital Marketing LTD (Bright Signals)


name: MINES RESCUE SERVICE (Trading as MRS Training & Rescue)

description: Anticipated to commence on 21st June 2023 until 20th June 2024, with an option to extend for 2 x 12 months extensions until the 20th June 2026 depending on internal demand and availability of budget unless the Contract is terminated in accordance with the provisions of the Service's Terms and Conditions of Contract.

description:
Within the Scottish Ambulance Service we have Special Operations Response Teams (SORT) they respond to:
 - Incidents where their special skills, manpower or equipment would directly benefit patients or the activity of the Service at the scene of an incident
 - Support significant and major incidents
 They are located in three areas:
 - East – based at Newbridge, Edinburgh
 - West – based at Johnstone, Glasgow
 - North – based in Aberdeen
 Looking for a supplier to provide the following courses:
 - Confined Space - High Risk
 - Confined Space Supervisor (Top Man/Women)

region: UKM

title: Confined Space Training

title: Confined Space Training

description:
Within the Scottish Ambulance Service we have Special Operations Response Teams (SORT) they respond to:
 - Incidents where their special skills, manpower or equipment would directly benefit patients or the activity of the Service at the scene of an incident
 - Support significant and major incidents
 They are located in three areas:
 - East – based at Newbridge, Edinburgh
 - West – based at Johnstone, Glasgow
 - North – based in Aberdeen
 We are looking for a supplier to provide Confined Space Training.

documentType: economicSelectionCriteria

documentType: technicalSelectionCriteria

title: Confined Space Training

Scottish Ambulance Service

locality: Edinburgh

postalCode: EH12 9EB

streetAddress: National Headquarters, Gyle Square, South Gyle Crescent

description: Health

legalName: Scottish Ambulance Service

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

Scottish Ambulance Service

description: Health

locality: Crossgates, Cowdenbeath

postalCode: KY4 8DH

streetAddress: MRS Training & Rescue, Main Street

Edinburgh Sheriff Court

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

description: (SC Ref:751268)


description:
The successful contractor will be required to carry out internal alterations and refurbishment of existing Cultural & Leisure Council offices and storage to provide new nursery facilities. The works include creating new nursery classrooms, toilets, staff areas, teachers’ offices and kitchen. Works also include reconfiguration of asphalt car parking into a secure nursery play space to include a canopy and a new flat roof system. The external works also include the extension of the existing car parking as well as the requirement for a retaining wall.. Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 8 and 9 of the Procurement (Scotland) Regulations 2016.
 The works budget for this project is 1,240,000GBP however the Council reserves the right to spend up to 1,480,000GBP.

title: Reconfiguration Works at St John's Primary School for new Early Years Accommodation

description:
The successful contractor will be required to carry out internal alterations and refurbishment of existing Cultural & Leisure Council offices and storage to provide new nursery facilities. The works include creating new nursery classrooms, toilets, staff areas, teachers’ offices and kitchen. Works also include reconfiguration of asphalt car parking into a secure nursery play space to include a canopy and a new flat roof system. The external works also include the extension of the existing car parking as well as the requirement for a retaining wall.
 This procurement will be conducted via the Public Contracts Scotland - Tender portal (PCS-T). We will apply a one stage Open procedure.
 Bidders must self-certify their adherence to the conditions of participation via the SPD (Scotland) in PSC-T, and may be required to submit Means of Proof before contract award. Bidders must refer to the specific requirements listed in Section III in this Contract Notice when completing the SPD in PCS-T.

performanceTerms: SBCC Standard Building Contract With Quantities for use in Scotland (SBC/Q/Scot), 2016 Edition, incorporating Amendment 1, February 2018

description:
Due to the nature of the works it is mandatory that all of the successful contractor’s staff or staffs of a sub-contractor(s) are accredited under the Construction Skills Competence Scheme (CSCS) or the Scottish Construction Operative Registration Executive (SCORE).
 Bidders must confirm if they hold the particular authorisation or memberships.
 Bidders will be required to evidence their current membership / accreditation or the membership / accreditation of their sub-contractor(s) with the following trade associations in order to be considered for this contract.
 SELECT / NICEIC
 Gas Safe
 SNIPEF
 A request for documentation will be issued to all contractors who submit a bid upon receipt of their tender response.
 Failure to be able to evidence accreditation with these institutes will result in the bidder being automatically disqualified from the evaluation process. The Council’s decision on this is final.

description:
Bidders will be required to have a minimum yearly “specific” turnover of 1,500,000 GBP for the last 12 months in the business area covered by the contract.
 The Council reserves the right at its own discretion to seek information from the applicant in accordance with Regulation 61(7) or Regulation 61(8) of the Public Contracts (Scotland) Regulations 2015 to determine the Applicant’s economic and financial standing. East Renfrewshire Council requires to ensure that the economic operator has the necessary economic and financial capacity to perform and complete the contract. In the current difficult economic environment, the Council seeks to ensure that the contractor who undertakes the works has suitable financial strength and capacity to complete these goods, works or services.
 Where an economic operator wishes to be considered for selection under this contract but cannot meet the turnover and/or Credit Safe score of 30 that economic operator must provide financial information which will satisfy the Council that they have an equivalent level of economic and financial standing; and must provide related guarantees or formal assurances to support their right to participate and be considered for any contract award (Regulation 61(8)). Please note that any financial information disclosed should evidence the financial strength of the economic operator tendering, therefore additional supporting information will need to be provided where joint or group accounts are provided in support of a bid to explain to the Council the relevance of that information.
 Where the economic bidder relies upon or intends to reply upon any Key Subcontractors in performance of the contract, then the Council reserves the right to assess the financial strength and suitability the Key subcontractor as part of the qualification process; Where the economic operator relies upon a parent company to provide financial assurance in support of their bid, the Council will also reserve the right to seek financial information on the strength and suitability of the parent company; and
 Where the economic operator relies upon the capacity of other parties in respect of selection and/or performance of the contract, then dependent on the nature of the arrangement the Council may require full disclosure of financial information in support of the bid. For example, where the bidder identifies as a consortium the Council will require that the consortium, as a group, can meet the financial selection requirements contained in the procurement documents. Where a bidder is part of a Consortium, it shall procure the execution and delivery to the Employer of a Consortium Guarantee (in the form provided by the council) executed by each member of the Consortium (acting as Consortium guarantor) in Self Proving Form.
 The Council reserves the right to monitor that the economic operator continues to meet the financial selection requirements upon receipt of the invitation to tender or after evaluation has been completed and prior to any award being made. Economic operators must inform the Council of any changes to any submission made by them in respect of their financial and or economic situation. The Council will further reserve the right to remove any economic operator from the tendering process where they are no longer able to fulfil any of the selection requirements as directed within the procurement documents.
 Further detail is contained within the procurement documents.
 Bidders who cannot meet the required level of turnover will be excluded from this tender.
 It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers Liability Insurance - 5 million GBP
 Public Liability Insurance - 5 million GBP
 Professional Indemnity Insurance - 2 million GBP
 Third Party Motor Vehicle Insurance

minimum:
Bidders will be required to provide three examples of similar projects / works. Examples provided MUST have been undertaken within a LIVE education school setting in the past five years.
 Your response must demonstrate that you have the relevant experience to deliver the work as per the scope of works described within the tender documentation including the Tender Information, Contract Notice, Prelims and BOQ, within a main school building.
 The examples provided must be of a similar value (between 1,00,000GBP - 1,500,000GBP), size and scope and include reference to the works undertaken in relation to internal alterations, refurbishment works, new flat roof system and external works, as per the scope of work provided.
 Bidders must also provide the dates these projects were undertaken including start and end dates in the format MM/YY i.e. 06/19 to 03/20 and the name of the customer / client.
 Responses must be returned in the attachment provided at 1.71.3, no other format will be accepted. Coloured brochures are not acceptable and zip files with additional information should not be submitted as they wont be considered.
 Failure to provide responses relevant to this project will result in your bid being removed without further consultation.
 The Council's decision on this is final.

description:
Bidders who intend to use a supply chain to deliver the requirements detailed in the Contract Notice, must confirm they have (or have access to) the relevant supply chain management and tracking systems to ensure a resilient and sustainable supply chain. Bidders must provide a response at SPD Q4.C.4 and this will include confirmation that they have the systems in place to pay subcontractors through the supply chain promptly and effectively, and provide evidence when requested of:
 a) their standard payment terms.
 b) ≥95% of all supply chain invoices being paid on time (in accordance with the terms of contract) in the last financial year.
 Bidders unable to confirm (b) must provide an improvement plan, signed by their Director, which improves payment performance. It should be noted that where a bidder is unable to confirm or provide a satisfactory improvement plan the Council reserves the right to remove you from the process.
 Bidders are required to confirm whether they intend to subcontract and, if so, for what proportion of the contract.
 Bidders who intend to subcontract more than 25% to any individual organisation must ensure the SPD (Scotland) - Subcontractors Supplier Response is completed and uploaded at question 2C.1 of the qualification envelope.

mainProcurementCategory: works

East Renfrewshire Council

locality: Giffnock

postalCode: G46 6UG

streetAddress: Eastwood HQ, Eastwood Park,

description: General public services

legalName: East Renfrewshire Council

name: Paisley Sheriff Court and Justice of the Peace

locality: Paisley

postalCode: PA3 2HW

description: General public services

Fleming Buildings Ltd

locality: Glasgow

postalCode: G66 5ET

streetAddress: 23 Auchinloch Road, LENZIE

legalName: Fleming Buildings Ltd

description:
Prompt Payment-The successful tenderer shall, as a condition of being awarded the contract, be required to demonstrate to the council's satisfaction that all funds due to the tenderer's permitted sub-contractors in respect of these services are paid timeously and that as a minimum invoices rendered by subcontractors shall(unless formally disputed by the tenderer)be paid within 30 days
 of receipt. The successful tenderer shall also impose this condition on its subcontractors in respect of payments due to any sub-sub-contractors, if any.
 The Council reserves the right to request copies of insurance certificates from bidders at any point during the contract period. Failure to supply the information within timeframe requested may result in your bid being rejected & the Council proceeding with the procurement exercise to the next appropriate bidder. Additional information pertaining to this contract notice is contained within the Tender documents. Applicants must ensure they read in line with this contract notice.
 (SC Ref:748802)


description: This procurement is a call off contract awarded under the Scottish Government Managed Print framework, after a further competition process. The contract is for the maintenance and provision of MFDs including delivery, installation, maintenance/refurbishment, collection, removal/storage, re-use and recycling across all of The Scottish Parliament Premises. This award is for a call off contract from a framework agreement

title: Award of Multifunction Devices, Maintenance and Associated Services

Scottish Parliamentary Corporate Body

postalCode: EH99 1SP

streetAddress: The Scottish Parliament, Procurement Services

legalName: Scottish Parliamentary Corporate Body

Capital Document Solutions Ltd.

postalCode: EH7 4NW

streetAddress: 101 MacDonald Road

legalName: Capital Document Solutions Ltd.

Edinburgh Sheriff Court

roles: reviewBody reviewContactPoint

streetAddress: Sheriff Court House  27 Chambers Street

description:
Award against framework: Scottish Government Managed Print Solutions Framework Agreement SP21-046
 This is a call off contract under the Scottish Government Managed Print Solutions Framework
 (SC Ref:730730)


description: Provision of record management and scanning / digitised service from local practices.

title: AA-225-22-CO Onsite Scanning and Document Storage

description: The provision of Records Management, Document Storage and Integrated Solutions.

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: Direct Award from NHS Shared Business Services SBS/21/NL/AWD/10173

description: The procurement falls outside the scope of application of the directive

NHS Ayrshire & Arran

postalCode: KA6 6AB

streetAddress: Eglinton House, Ailsa Hospital, Dalmellington Road

description: Health

legalName: NHS Ayrshire & Arran

On-Site Scanning Ltd

locality: Gourock

postalCode: PA19 1FB

streetAddress: The Faulds Building, Faulds Park

legalName: On-Site Scanning Ltd

Kilmarnock Sheriff Court

locality: Kilmarnock

postalCode: KA1 1ED

streetAddress: St Marnock Street

legalName: Kilmarnock Sheriff Court

description: (SC Ref:730734)


description: 1 x Product Coordinator

title: Award of INTERIM PROFESSIONAL STAFF SERVICES -1 x Product Coordinator

description: 1 x Product Coordinator

description: Supply services of personnel including temporary staff

Glasgow Clyde College

postalCode: G52 3AY

streetAddress: Cardonald Campus

HP Inc UK Ltd

locality: Reading

postalCode: RG6 1PT

streetAddress: Earley West, 300 Thames Valley Park Drive

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House

Alex F Noble & Son Nissan

postalCode: EH20 9FB

streetAddress: Swinton Place, Straiton

Scottish Courts and Tribunals Service

postalCode: EH11 3XD

streetAddress: Saughton House

Morris & Spottiswood

postalCode: G51 3HQ

streetAddress: 54 Helen Street

Forestry and Land Scotland

locality: Dumfries

postalCode: DG1 1QB

streetAddress: Ae Village

CR Contracting North LTD

locality: Aboyne

streetAddress: Laurwood

Dumfries and Galloway Council

postalCode: DG1 2HP

streetAddress: Carruthers House

David Hardie Engineering Limited

postalCode: DG2 0HS

streetAddress: No 1

Scottish Government

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay

Lorien Resourcing Ltd

postalCode: EH2 4QZ

streetAddress: Randolph House

The Lines Between Ltd.

postalCode: EH8 7EH

streetAddress: 3 Piershill Place

Murray Forestry Ltd

locality: Perth

streetAddress: 19 Nicoll Drive

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

name: LHC for the Scottish Procurement Alliance (SPA) on behalf of Cadder Housing Association

locality: Livingston

postalCode: EH54 8AF

streetAddress: 6 Deer Park Avenue

Irvine Civil Engineering Ltd

postalCode: G40 4HW

streetAddress: Unit 22

Social Security Scotland

locality: Dundee

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

Perth & Kinross Council

postalCode: PH1 5PH

streetAddress: 2 High Street

Lead Scotland

postalCode: EH7 6AE

streetAddress: Studio 1.09, St Margaret's House

Getmapping Ltd

locality: Fleet

postalCode: GU51 2UH

streetAddress: Fleet 27, Rye Close

Atkins Limited

locality: Epsom

postalCode: KT18 5BW

streetAddress: Woodcote Grove

WPC Software

locality: Bristol

postalCode: BS30 6DL

streetAddress: Apex House, Kingsfield Lane

WELIN LAMBIE LIMITED

locality: BRIERLEY HILL

postalCode: DY5 1UB

streetAddress: BRITANNIA HOUSE

Denios Ltd

locality: Newport

postalCode: TF10 7DW

streetAddress: Nova House, Suite 1

Fast Track Impact Limited

postalCode: AB54 7XT

streetAddress: St Johns Well, Kinnoir

Kerr Plant Excavations

locality: Tighnabruaich

streetAddress: Auchgoyle House

Headway Ayrshire

locality: AYR

postalCode: KA7 1EZ

streetAddress: Offices 8 & 10, 24 Wellington Square

Barnardo's

postalCode: EH14 1ED

streetAddress: 111 Oxgangs Road North

Sense Scotland

postalCode: G41 1EE

streetAddress: 43 Middlesex Street

Scottish Autism

locality: Alloa

postalCode: FK10 3SA

streetAddress: Hilton House

Aberdeen City Council

locality: Aberdeen

name: Fraser of Allander, University of Strathclyde

University of Stirling

streetAddress: Finance Office, Room 3Z3, Cottrell Building

Inseego Ltd

streetAddress: Park House, Headingley Office Park, 8 Victoria Road

name: Scottish Children's Reporter Administration

boxxe Limited

streetAddress: The e-centre, Coopergate Way Business Village

NHS Greater Glasgow and Clyde

streetAddress: Admin Building, Gartnavel Royal Hospital

name: ALLAN INGRAM INDUSTRIAL CLEANING SERVICES LTD

Campbell Associates Limited

streetAddress: Unit 5, Chelmsford Road Industrial Estate

vermicon

streetAddress: 3 middleburn cottages kirkness cardenden

name: ECG Building Maintenance Ltd (t/a ECG Facilities Services)

West Lothian Council

name: Building Services Surveying and Estimating

name: Morgan Sindall Construction & Infrastructure Ltd


title: Ride-On Triple Cylinder Mowers

title: Ride-on Out Front Rotary Mowers

description: Ride-on 72” Out Front Rotary Mower - 72” Cut

title: Ride-On Triple Cylinder Mowers

description: Ride on 3-Unit-Cylinder Mower, with 83.5” width cut

description: Hilton Depot, Bishopbriggs

description: Hilton Depot, Bishopbriggs

title: Supply and Delivery of Ride-on Mowers

title: Supply and Delivery of Ride-on Mowers

description:
6 x Ride-on Out Front Rotary Mowers
 2 x Ride-on Triple Cylinder Mowers

title: EDC/2022/3550 - Ride On Mowers ITT v2

title: EDC/2022/3550 - Ride On Mowers Terms and Conditions Goods & Services

title: EDC/2022/3550 - GDPR Privacy Notice Procurement

title: Supply and Delivery of Ride-on Mowers

streetAddress: Southbank Marina, Kirkintilloch

description: 4A.1 If required by the member state, bidders are required to be enrolled in the relevant professional or trade registers within the country in which they are established i.e. companies house

minimum:
[LOT 1] 4B.1.2 Bidders will be required to have an average yearly turnover of 480,000 GBP over the past 3 years.
 [LOT 2] 4B.1.2 Bidders will be required to have an average yearly turnover of 120,000 GBP over the past 3 years.
 4B.3 In the case that turnover information is not available for the given period please state the date on which the bidder was set up or started trading.
 4B.5.1, 4B.5.2 and 4B.5.3. It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers Liability – 10,000,000 GBP each and every claim and in the annual aggregate
 Public Liability – 5,000,000 GBP each and every claim and in the annual aggregate
 Unlimited in respect of liability for death / injury.

description: Bidders must respond to SPD Questions 4B.1.2, 4B.1.3, 4B3, 4B.5.1, 4B.5.2, 4B.5.3

minimum: 4C.1. Bidders will be required to provide examples that demonstrate that they have the relevant experience to deliver the goods as described in the Contract Notice or the relevant section of the Site Notice. A minimum of three Contracts of a similar scope and nature which have successfully delivered in the last five years.

description: Bidders must respond to SPD question 4C.1

East Dunbartonshire Council

locality: Kirkintilloch

postalCode: G66 1TJ

streetAddress: Civic & Corporate Headquarters, Southbank Marina,12 Strathkelvin Place

description: General public services

description: Education

legalName: East Dunbartonshire Council

Glasgow Sheriff Court

locality: Glasgow

postalCode: G5 9DA

streetAddress: 1 Carlton Place

legalName: Glasgow Sheriff Court

East Dunbartonshire Council

description: General public services

Reesink Turfcare UK Ltd

locality: St Neots

postalCode: PE19 8JW

streetAddress: 1-3 Station Road

legalName: Reesink Turfcare UK Ltd

title: Ride-On Triple Cylinder Mowers

description: (SC Ref:742863)


description:
WLC wish to set up a Dynamic Purchasing System (DPS) for subsidised local bus services
 For support in tendering please go to
 https://www.supplierjourney.scot/
 https://www.sdpscotland.co.uk/. Re: SPD Q3D.1, 3D.2 & 3D.3 Bidders should answer these questions on Environmental, social and labour law in relation to compliance with the regulations covering Scotland and the UK.
 Police Scotland will be consulted with regards to Serious and Organised Crime checks. Any links to this type of activity may cause your tender to be rejected.

description: All those passing the SPD questions will be admitted to the DPS

description: West Lothian Council area

title: WLC Local Bus Services DPS

title: WLC Local Bus Services DPS

description: Selection stage of Dynamic Purchasing System for subsidised local bus routes

description: Initial DPS open for 30 days then reopened for 10 years. following that further notice will be published

procurementMethod: selective

minimum:
Employer's (Compulsory) Liability: 10 million GBP
 Public Liability: 5 million GBP
 Motor vehicle insurance – Insurance appropriate for the purposes of the business i.e carriage of passengers for hire or reward.

description:
Re SPD question 4B.6 West Lothian Council will use Dun and Bradstreet’s DBAi financial reporting system to assess the financial stability of tenderers. Tenderers with a Failure Score of 50 or above on the DBAi system will be deemed to have evidenced satisfactory financial stability. Please note that 49 or less will not be considered as having met this criteria. If a tenderer has a Failure Score of less than 50, the tenderer may be required to submit their last three years accounts.
 In the event that the tenderer is not required to publish accounts and therefore does not have a Dun & Bradstreet or equivalent rating, tenderers should be able to provide financial accounts when requested. The council will then conduct an analysis of the accounts to ensure that there is no significant financial risk. Please note that if you intend on attaching 2 years accounts, these must include financial data over a 3 year period.
 It is recommended that candidates review their own Dun & Bradstreet Score in advance of submitting their tender. If following this review tenderers consider that the Dun & Bradstreet Score does not reflect their current financial status, details of this should be provided, complete with evidence of a good high street credit rating (the equivalent of Dun & Bradstreet score 50) from a recognised credit referencing agency. The council will review any such information as part of the evaluation of Tenderer’s financial status.
 In the event that a firm does not meet the financial criteria for consideration but has a parent company that does, the firm may still be eligible for consideration where their Tender Submission is supported by a Parent Company Guarantee.
 Should after review of the financial evaluation the tenderer fail, then the tender submission may be rejected.

description:
Provide details of either a valid Public Service Vehicles (PSV) Operators Licence or community bus permit.
 Please note details of individual driver and vehicle licence details will be requested at a later date during the mobilisation period prior contract commencement.

procurementMethodDetails: Restricted procedure

West Lothian Council

postalCode: EH54 6FF

streetAddress: West Lothian Civic Centre, Howden South Road,

description: General public services

legalName: West Lothian Council

Livingston Sheriff Court

legalName: Livingston Sheriff Court

description:
Where there is suspicion that risk may be present, as defined by Police Scotland (PS), WLC will provide PS info on the representatives of the bidder (SPD Part 2B) to allow PS to review & provide feedback on info provided.
 NB: when completing SPD section 1.11 Part 2B, this should be completed using personal information as follows: full name including any middle names as it appears on birth &/or marriage certificate; the day date & month & the location of birth; & home address & postcode. Failure to provide the correct information may result in your bid being excluded from the tender process or an offer of contract being withdrawn should the info prove to be incomplete or incorrect at a later stage.
 If bidders intend to use a supply chain to deliver the requirements detailed in II.2.4 in the Find a Tender Service, Contract Notice or relevant section of the Site Notice, they should confirm they have (or have access to) the relevant supply chain management & tracking systems to ensure a resilient & sustainable supply chain. This will include confirmation that they have the systems in place to pay subcontractors through the supply chain promptly & effectively, & provide evidence when requested of:
 a) their standard payment terms
 b) ≥95% of all supply chain invoices being paid on time (in accordance with the terms of contract) in the last financial year
 If the bidder is unable to confirm (b) they must provide an improvement plan, signed by their Director, which improves the payment performance.
 TUPE – The incoming Contractor is responsible for obtaining legal & professional advice about relevant TUPE implications.
 CONFIDENTIALITY - All information supplied by the Authority must be treated in confidence & not disclosed to third parties except insofar as this is necessary to obtain sureties or quotations for the purpose of submitting the tender. All information supplied by you to the Authority will similarly be treated in confidence except:
 (i) for any information required to be disclosed or otherwise provided by the Authority to any person in order to comply with the Freedom of Information (Scotland) Act 2002 & any codes of practice applicable from time to time relating to access to public authorities’ information.
 The Tenderer shall co-operate, facilitate, support & assist the Authority in the provision of this information. In the event the Authority is required to provide information to any person as a result of a request made to it under such Act &/or codes, the Authority shall adhere to the requirements of such Act &/or codes in disclosing information relating to this Agreement, the Project documents & the Contractor.
 (ii) that references may be sought from banks, existing or past clients, or other referees submitted by the tenderers;
 (iii) for the disclosure of such information with regard to the outcome of the procurement process as may be required to be published in the Supplement to the Official Journal of the European Union in accordance with EU directives or elsewhere in accordance with the requirements of UK government policy on the disclosure of information relating to government contracts.
 The buyer is using PCS-Tender to conduct this PQQ exercise. The Project code is 23758. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 Community Benefits proposals may form part of the award criteria and may be evaluated and become contractual obligations. For further procurement information visit the link below. http://www.westlothian.gov.uk/article/2023/Doing-Business-With-The-Council.
 (SC Ref:730748)


description: The purpose of this ITT is to appoint a single supplier to conduct an equity market gap analysis. The findings will inform Scottish Government and Scottish Enterprise strategy development and future market interventions to support Scotland’s risk capital equity market.

title: Equity Investment Gap Analysis

title: Equity Investment Gap Analysis

title: P24-0012 - Invitation to Tender (ITT)

title: P24-0012 - ITT - Appendix 1 - Off Payroll Working Rules Outcome

title: P24-0012 - ITT - Appendix 2 - Tender Response Document

title: P24-0012 - ITT - Appendix 3 - Monitoring Information

title: P24-0012 - ITT - Appendix 4 - Information Security Questionnaire

title: P24-0012 - SPD - Bidder 'Relevant Contract' Climate Change Plan Template

title: Equity Investment Gap Analysis

reviewDetails:
In the first instance, contact the Head of Facilities Management and Procurement at Scottish Enterprise, with any concerns or enquiries. Email: https://www.scottish-enterprise.com/help/contact-us.
 An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015, may bring proceedings that will be started in the High Court.

Scottish Enterprise

postalCode: G2 6HQ

streetAddress: Atrium Court, 50 Waterloo Street

description: Economic affairs

legalName: Scottish Enterprise

streetAddress: Sheriff Clerk’s Office, PO Box 23, 1 Carlton Place,

legalName: Glasgow Sheriff Court and Justice of the Peace Court

Scottish Government

roles: mediationBody reviewContactPoint buyer

postalCode: G2 8LU

streetAddress: 5 Atlantic Quay, 150 Broomielaw

id: Ministry or any other national or federal authority, including their regional or local subdivisions

description: General public services

legalName: Scottish Government

Scottish Enterprise

description: Economic affairs

RSM (Quick Quote contact)

locality: London

postalCode: EC4A 4AB

streetAddress: 6th Floor, 25 Farringdon Street

legalName: RSM (Quick Quote contact)

streetAddress: PO Box 23 1 Carlton Place

Scottish Government

roles: buyer centralPurchasingBody reviewBody mediationBody reviewContactPoint

locality: Edinburgh

postalCode: EH6 6QQ

streetAddress: Victoria Quay,

description: General public services

description: Environmental protection

description:
This is a relevant climate change contract, bidders are required to complete and return the attached Climate Change Plan template.
 (SC Ref:736315)


description:
CPI is delivering SONNET (Smart Connected Technology Innovation Programme), a GBP 3.8M project funded by the European Regional Development Fund to support SMEs in the Northeast of England. The project runs until June 2023.
 The project aim is to bring regional SMEs up to date with the latest in Digital and Internet of Things (IoT) technologies, to support the development of products and services, with a particular focus on the health sector. The key audience comprises innovative SMEs active in technology development applicable to the health sector; innovation leads with the health sector; and other stakeholders in government and funding bodies.

variantPolicy: allowed

region: UKC

title: 5G Playbook

title: 5G Playbook

description: CPI is a leading independent technology innovation centre and a founding member of the UK Government’s High Value Manufacturing Catapult, which supports businesses and academia to help them overcome innovation challenges in the development of next generation products and processes by providing the facilities, in depth technical expertise and innovation support to enable ideas, research and knowledge to be translated into commercial business propositions.

title: 2881 - Tender Pack

format: application/x-zip-compressed

title: 5G Playbook

Centre for Process Innovation Limited

locality: Redcar

postalCode: TS10 4RF

streetAddress: Wilton Centre

legalName: Centre for Process Innovation Limited

name: Glasgow Sheriff & Justice of the Peace Court

streetAddress: Sheriff Clerk's Office, 1 Carlton Place

Wander Films Limited

locality: Middlesbrough

postalCode: TS1 1PQ

streetAddress: 23-25 Albert Road

legalName: Wander Films Limited

name: Glasgow Sheriff & Justice Of The Peace Court

description: (SC Ref:736008)


name: Crown Office and Procurator Fiscal Service

description: Option for a 6 month extension if required.

description: Putting in place professional, robust and effective project management mechanisms and documentation to control, manage and deliver assigned IT and digital projects successfully

description: Glasgow/Edinburgh

title: INTERIM STAFF SERVICES – Application Project Manager

description: COPFS are contracting the services of an Application Project Manager. The primary purpose of this project management role is to lead, oversee and ensure the successful delivery of application, infrastructure and cloud projects.

postalCode: EH1 1LA

streetAddress: Crown Office, 25 Chambers Street

description: Social protection

Venesky-Brown Recruitment

postalCode: EH1 2AS

streetAddress: 4A Rutland Square

scale: large

legalName: Venesky-Brown Recruitment

Sheriff Clerks Office

legalName: Sheriff Clerks Office

description: (SC Ref:730771)


description: UCI Cycling World Championships is looking for an experienced Production Services for Furniture, Fixtures and Equipment (FF&E),Soft Shell Walling and Power supply to support in key events within Glasgow during the Championships time.

title: UCI Cycling World Championships 2023 - Production Services (FF&E,Soft Shell Walling and Power)

title: Schedule 1 - SOR

title: Schedule 2 - Summary of Costs

title: Schedule 3 - Look Book

title: Schedule 5 - Form of Contract

title: Schedule 6 - SPD

title: Schedule 7 - Pricing and Invoicing

title: Schedule 4 - Award Questionnaire

title: Invitation to Tender

streetAddress: Remote - Glasgow

description: Kirsty Strowes - Procurement Manager

2023 Cycling World Championships Ltd

postalCode: EH6 6JH

streetAddress: C/O VisitScotland, Ocean Point One, 94 Ocean Drive

legalName: 2023 Cycling World Championships Ltd

Edinburgh Sheriff Court

legalName: Edinburgh Sheriff Court

description:
NOTE: To register your interest in this notice and obtain any additional information please visit the Public Contracts Scotland Web Site at https://www.publiccontractsscotland.gov.uk/Search/Search_Switch.aspx?ID=730768.
 The buyer has indicated that it will accept electronic responses to this notice via the Postbox facility. A user guide is available at https://www.publiccontractsscotland.gov.uk/sitehelp/help_guides.aspx.
 Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems.
 (SC Ref:730768)


description: SASA is a Division of the Scottish Government Directorate for Agriculture, Food and Rural Communities. As the Certifying Authority it is responsible for the management and administration of the Seed Potato Classification Scheme (SPCS).Before seed potatoes can be marketed they must be inspected and their containers sealed with an official label that confirms the details of the potatoes and that they meet the required standards. Growers apply for the appropriate quantity of labels and these are printed at the Directorate’s Area Offices located in Inverurie (Aberdeenshire), Perth and Inverness. At these offices the details of the seed potato consignment are printed onto the front of the labels using thermal transfer printers and then despatched to, or collected by, the grower.

title: Award of Seed Potato Labels & Printer Consumables

procurementMethod: direct

procurementMethodDetails: The contract is awarded to a single supplier without competition.

description: Agricultural, farming, fishing, forestry and related products

Glasgow Clyde College

postalCode: G52 3AY

streetAddress: Cardonald Campus

HP Inc UK Ltd

locality: Reading

postalCode: RG6 1PT

streetAddress: Earley West, 300 Thames Valley Park Drive

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House

Alex F Noble & Son Nissan

postalCode: EH20 9FB

streetAddress: Swinton Place, Straiton

Scottish Courts and Tribunals Service

postalCode: EH11 3XD

streetAddress: Saughton House

Morris & Spottiswood

postalCode: G51 3HQ

streetAddress: 54 Helen Street

Forestry and Land Scotland

locality: Dumfries

postalCode: DG1 1QB

streetAddress: Ae Village

CR Contracting North LTD

locality: Aboyne

streetAddress: Laurwood

Dumfries and Galloway Council

postalCode: DG1 2HP

streetAddress: Carruthers House

David Hardie Engineering Limited

postalCode: DG2 0HS

streetAddress: No 1

Scottish Government

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay

Lorien Resourcing Ltd

postalCode: EH2 4QZ

streetAddress: Randolph House

The Lines Between Ltd.

postalCode: EH8 7EH

streetAddress: 3 Piershill Place

Murray Forestry Ltd

locality: Perth

streetAddress: 19 Nicoll Drive

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

locality: Livingston

postalCode: EH54 8AF

streetAddress: 6 Deer Park Avenue

Irvine Civil Engineering Ltd

postalCode: G40 4HW

streetAddress: Unit 22

Social Security Scotland

locality: Dundee

postalCode: DD1 4BF

streetAddress: 3rd Floor, Agnes Husband House

Venesky Brown Ltd

streetAddress: 4a Rutland Square

Perth & Kinross Council

postalCode: PH1 5PH

streetAddress: 2 High Street

Lead Scotland

postalCode: EH7 6AE

streetAddress: Studio 1.09, St Margaret's House

Getmapping Ltd

postalCode: GU51 2UH

streetAddress: Fleet 27, Rye Close

Atkins Limited

postalCode: KT18 5BW

streetAddress: Woodcote Grove

WPC Software

postalCode: BS30 6DL

streetAddress: Apex House, Kingsfield Lane

WELIN LAMBIE LIMITED

postalCode: DY5 1UB

streetAddress: BRITANNIA HOUSE

Denios Ltd

postalCode: TF10 7DW

streetAddress: Nova House, Suite 1

Fast Track Impact Limited

locality: Aberdeenshire

postalCode: AB54 7XT

streetAddress: St Johns Well, Kinnoir

Kerr Plant Excavations

streetAddress: Auchgoyle House

South Ayrshire Council

locality: Ayr

postalCode: KA7 1DR

streetAddress: County Buildings

Headway Ayrshire

postalCode: KA7 1EZ

streetAddress: Offices 8 & 10, 24 Wellington Square

Barnardo's

streetAddress: 111 Oxgangs Road North

Sense Scotland

streetAddress: 43 Middlesex Street

Scottish Autism

streetAddress: Hilton House

University of Stirling

streetAddress: Finance Office, Room 3Z3, Cottrell Building

Inseego Ltd

streetAddress: Park House, Headingley Office Park, 8 Victoria Road


description: These Funds will run for two financial years from July 2023 until June/July 2025 and provide up to 35.7M to 137 organisations. The Contract will cover the administration of the 2 year funding period between July 2023 to June 2025 and associated pre and post-funding activities.

description: Scotland

title: The Children Young People Families Early Intervention Adult Learning Empowering Communities and CYPFAL Third Sector Funds

description: The Scottish Government's (SG) Promoting Children and Families Wellbeing Unit is seeking a Service Provider knowns as Service Provider from here forward to undertake the administration of the Children Young People and Families Early Intervention & Adult Learning and Empowering Communities (CYPFEI and ALEC) Third Sector fund, which has been running since 2016 and the new Children, Young People, Families and Adult Learning Third Sector Fund (the Fund), both of which will provide core funding to organisations who are delivering activities, projects and support that are targeted towards positive outcomes for children, young people and families.

minimum:
Employers Liability Insurance in accordance with any legal obligation at the time being in force
 Professional Indemnity Insurance 2,000,000 GBP
 Public Liability Insurance Liability Insurance 2,000,000 GBP
 Such insurances must be maintained for the duration of the Contract and for a minimum of 5 years following the expiry or termination of
 the Contract as appropriate

description:
Bidders must demonstrate a Current ratio of no less that 1.0
 Current Ratio will be calculated as follows:
 net current assets divided by net current liabilities.
 There must be no qualification or contra-indication from any evidence provided in support of the bidders economic and financial standing.

Scottish Government

roles: buyer mediationBody reviewContactPoint

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

description: General public services

name: Edinburgh Sheriff Court and Justice of the Peace Court

locality: EDINBURGH

postalCode: EH1 1LB

roles: buyer centralPurchasingBody mediationBody reviewContactPoint

description: General public services

Corra Foundation

postalCode: EH11 3AF

streetAddress: Riverside House, 502 Gorgie Road

legalName: Corra Foundation

streetAddress: Sheriff Court House, 27 Chambers Street

description:
Question Scoring Methodology for Award Criteria outlined in invitation to tender
 0 Unacceptable Nil or inadequate response. Fails to demonstrate an ability to meet the requirement
 1 Poor Response is partially relevant but generally poor. The response addresses some elements of the requirement but contains insufficient/limited detail or explanation to demonstrate how the requirement will be fulfilled.
 2 Acceptable Response is relevant and acceptable. This response addresses a broad understanding of the requirement but may lack details on how the requirement will be fulfilled in certain areas.
 3 Good Response is relevant and good. The response is sufficiently detailed to demonstrate a good understanding and provides details on how the requirements will be fulfilled.
 4 Excellent Response is completely relevant and excellent overall. The response is comprehensive, unambiguous and demonstrates a thorough understanding of the requirement and provides details of how the requirement will be met in full.
 Tenderers are also asked to confirm that they will pay staff that are involved in the delivery of services under the contract, at least the real Living Wage they will meet standards on payment of subcontractors.
 Tenderers who do not pass these questions will not be subject to Commercial Analysis. As a result the tender will not be considered further.
 Bidders must complete the SPD (Scotland) to demonstrate adherence to the Exclusion and Selection Criteria for this procurement.
 If there are named subcontractors or technicians upon which the bidder will rely to meet the selection criteria, these named parties must complete and reattach the SPD Supplier Response Form attached to SPD
 (SC Ref:747169)


description: Tender Procurement Process

title: Peatland ACTION - UAVCOR01 - UAV/LiDAR survey of a degraded peatland site - Corrour Estate - Highlands

title: UAVCOR01 - Statement of Requirements

title: UAVCOR01 - Shape Files

streetAddress: Digital

description: Peatland ACTION Administrator

submissionMethodDetails: Submissions by email only

NatureScot

roles: buyer centralPurchasingBody reviewBody

postalCode: EH12 7AT

streetAddress: Silvan House

description: Environmental protection

legalName: NatureScot

description: Environmental protection

id: If funding achieved - potentially Finzean Estate

Caledonian Climate Partners

locality: Forfar

streetAddress: East Memus

legalName: Caledonian Climate Partners

description:
All details contained within the Statement of Requirements
 (SC Ref:743875)


title: Lot 5 - Curriculum, Consultancy and Virtual Learning

description: Option to extend by a further period of up to 5 years in increments at the discretion of SLC, subject to satisfactory performance, financial standing and availability of funding.

description:
Provide learning, support or assessment services primarily in Literacy, Numeracy and, Health and Wellbeing including, but not limited to, the use of standardised diagnostic assessment and screening tools.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 8 - Tracking, Monitoring and Assessment

description:
To support education establishments with solutions to manage assessment information.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 11 - Specialist Intervention Services

description:
Provide services which provide specific interventions within the school day to support children and young people by diversifying the curriculum and offering learning activities which go beyond the core business of the school curriculum while at the same time linking closely with a Curriculum for Excellence through the broad general education and senior phase. The services to be provided will focus on activities that re-engage children with learning.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 12 - General Educational Services

description:
This lot will provide for general educational services that do not fall within the specification of the other Lots.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 6 - Adult learning

description:
Be responsible for the delivery of learning opportunities to support learners develop new skills, improve employability and life chances.
 .
 For some call of contracts awarded under this Lot there may be a requirement for personnel providing services to have an appropriate Adult Learning/Community Learning and Development qualification and to be CLD Standards Council registered. These possible requirements are referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 4 - Cultural Education Services

description:
Provide specific support to children , young people and adults by seeking to develop English language skills and validate their skills within a structured learning environment.
 .
 For some call of contracts awarded under this Lot there may be a requirement for personnel providing services to have an appropriate TEFL qualification or a comparable qualification in developing English language skills. These possible requirements are referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 3 - Community and Family Engagement

description:
Provide professional assistance, guidance and support in engaging young people, parents, carers and wider community in learning through activities.
 .
 For some call of contracts awarded under this Lot there may be a requirement for personnel providing services to have an appropriate Community Learning and Development qualification and to be CLD Standards Council registered. These possible requirements are referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 2 - Counselling, Support and Advice services

description:
Provide professional assistance, guidance and support in resolving Service Users personal or psychological problems, and promoting good mental wellbeing. This will include one to one counselling.
 .
 For some call of contracts awarded under this Lot there may be a requirement for staff providing counselling to have a recognised qualification in counselling and also there may be a requirement for personnel involved in the provision of some services to be COSCA/BACP registered. These possible requirements are referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 7 - Youth Work

description:
Enable young people to develop holistically, working with them to facilitate their personal, social and educational development, to enable them to develop their voice, influence and place in society and reach their potential.
 .
 For some call of contracts awarded under this Lot there may be a requirement for personnel providing services to have an appropriate Youth Work/Community Learning and Development qualification and to be CLD Standards Council registered. These possible requirements are referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 10 - Professional Learning

description:
Provide career long professional learning and development opportunities for all staff. Provide learning and development opportunities for volunteers.
 .
 For some call of contracts awarded under this Lot there may be a requirement for the provider to hold the relevant qualifications/accreditations to provide the services. This possible requirement is referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 9 - Awards and Certification

description:
Ensure that learners have access to accredited and non-accredited awards that improve life chances, compliment their personal development and can help them progress towards work and/or further study.
 .
 For some call of contracts awarded under this Lot there may be a requirement for the provider to hold the relevant accreditations to deliver the award. This possible requirement is referred to in the Specification.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

title: Lot 1 - Activity Based and Residential Learning

description:
Support and encourage learners to manage their own learning to develop skills, improve performance and maximise potential.. This PSA will remain open to new applicants for the full term.
 All staff involved in the delivery of the services must have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

description: South Lanarkshire

title: Educational Services Procured Services Arrangement (PSA)

description: This procurement is Phase 6 of the South Lanarkshire Council established multi Lot, multi provider Procured Services Arrangement (PSA). The aim of the PSA is to allow SLC Education Resources and all SLC schools to contract compliantly with providers who will deliver all forms of educational services. These will include services funded by Pupil Equity Funding, Access to Counsellors Mental Health Funding, Council budgets and other education funding.

description: Sealed sequential opening for applications

description: Currently 2 times per annum.

description:
SPD Question 4A.1 Trade Registers
 It is a requirement of this tender that if the Applicant is UK based they must hold a valid registration with Companies House. Where the Applicant is UK based but not registered at Companies House they must be able to verify to the Councils satisfaction that they are trading from the address provided in the tender and under the company name given.
 If the Applicant is based out-with the UK they must be enrolled in the relevant professional or trade register appropriate to their country as described in Schedule 5 of the Public Contracts (Scotland) Regulations 2015.
 .
 SPD Question 4A.2 Authorisation/Membership
 Where it is required, within a Applicant’s country of establishment they must confirm which authorisation or memberships of the relevant organisation(s) are required in order to perform this service.
 Applicants must confirm if they hold the particular authorisation or memberships.

minimum:
The Council will apply the following levels to the ratios to evaluate a Applicants financial status:
 Profitability - If a company makes a profit then it is a pass for this ratio;
 Liquidity - If greater than or equal to one then it is a pass for this ratio;
 Gearing - If less than or equal to 100% it is considered a pass for this ratio.
 .
 SPD Question 4B.5 Insurance
 The Applicant must confirm that they have or will commit to obtain prior to the commencement of the contract, the following levels of Insurance Cover:
 Employer’s Liability Insurance covering the death of or bodily injuries to employees of the Applicant arising out of and in the course of their employment in connection with this contract to the level of 10000000 GBP in respect of each claim, without limit to the number of claims.
 .
 Public Liability Insurance covering the death of or bodily injury to a person (not an employee of the Applicant) or loss of or damage to property resulting from an action or failure to take action by the Applicant to the level of 5000000 GBP in respect of each claim, without limit to the number of claims.
 .
 Professional Indemnity Insurance covering the failure of the Applicant to use the skill and care normally used by professionals providing the services described in this tender to the level of 5000000 GBP in respect of each claim, without limit to the number of claims.
 Providers will not be required to hold Professional Indemnity Insurance as a mandatory requirement for appointment to the PSA. Providers may be required to have/put in place Professional Indemnity Insurance for specific call offs awarded under the PSA and will be advised of this requirement at the point of call off.

description:
SPD Question 4B.4 Economic and Financial Standing
 The Council will use the following ratios to evaluate a Applicants financial status:
 Profitability – this is taken as profit after tax but before dividends and minority interests;
 Liquidity – this is calculated as current assets less stock and work in progress, divided by current liabilities;
 Gearing– this is calculated as the total external secured borrowing (short term and long term) divided by shareholder funds expressed as a percentage.
 .
 Applicants must provide the name and value of each of the 3 ratios within their response to SPD question 4B.4.
 The Council requires Applicants to pass 2 out of the 3 financial ratios above.
 Where 2 out of the 3 ratios cannot be met, the Council may take account of other factors (including those listed below) when assessing financial viability and the risk to the Council, providing that the Applicant can supply evidence to substantiate any of the mitigating criteria when requested to do so. The following list is not exhaustive and other criteria may be considered where proposed by a Applicant as mitigating factors:
 Would the Applicant have passed the checks if prior year accounts had been used?
 Were any of the poor appraisal outcomes "marginal"?
 Does the Applicant operate in a market which, traditionally, requires lower liquidity or higher debt finance?
 Does the Applicant have sufficient reserves to sustain losses for a number of years?
 Does the Applicant have a healthy cashflow?
 Is the Applicant profitable enough to finance the interest on its debt?
 Is most of the Applicant's debt owed to group companies?
 Is the Applicant's debt due to be repaid over a number of years, and affordable?
 Have the Applicant's results been adversely affected by "one off costs" and / or "one off accounting treatments"?
 Do the Applicant's auditors (where applicable) consider it to be a "going concern"?
 Will the Applicant provide a Parent Company Guarantee?
 Is the Applicant the single supplier/source of the Goods/Works/Services in the marketplace?
 The Council will request submission of and assess the Applicants financial accounts, and may use financial verification systems to validate the information provided.
 .
 The Council will not carry out a financial appraisal of Applicants until the value of all Call off Contracts awarded to the Applicant reaches 50,000 GBP, at which point Applicants who have been appointed to the PSA will be required to re-submit their financial ratios as detailed in the Contract Notice and supply copies of their 2 most recent years audited accounts, within 2 working days of being requested to do by the Council, to allow the Council to carry out a financial appraisal. Applicants must pass the financial appraisal when it is carried out or their appointment to the PSA may be terminated.
 .
 SPD Question 4B.5 Insurance
 The Applicant must confirm that they have or will commit to obtain prior to the commencement of the contract, the following Insurances:
 Employer’s Liability Insurance
 Public Liability Insurance
 *Professional Indemnity Insurance
 *Providers will not be required to hold Professional Indemnity Insurance as a mandatory requirement for appointment to the PSA. Providers may be required to have/put in place Professional Indemnity Insurance for specific call offs awarded under the PSA and will be advised of this requirement at the point of call off.

description:
SPD Question 4C.1.2 Technical and Professional Ability
 With reference to the nature and details of the services to be supplied under the PSA Lots, 3 relevant examples, of a similar size and nature, are to be provided of services delivered by the applicant in the last 3 years.
 If multiple Lots are being applied for, Applicants must provide 3 examples of experience for each Lot being applied for.
 .
 SPD Question 4C.6 Technical and Professional Ability (Qualifications)
 It is a mandatory requirement of this tender that all the applicants staff who will be involved in delivering services under the PSA have the relevant PVG Scheme Membership in terms of the Protection of Vulnerable Groups (Scotland) Act 2007.
 It is a requirement of this PSA that Applicants recommended for appointment complete and submit, when requested to do so by the Council, the PVG Declaration in the general attachments area, prior to appointment to the PSA.
 .
 SPD Question 4D.1 Quality Assurance Schemes
 It is a mandatory requirement of this PSA that applicants hold either ISO 90001:2015 Quality Management System or an internal Quality Management System as detailed in Attachment 11 in the SPD General Attachments area.

South Lanarkshire Council

description: Education

description:
SPD Question 2.C.1 Reliance on the capacities of other entities
 Applicants are required to complete a full SPD for each of the entities whose capacity they rely upon
 SPD Question 2.D.1 Subcontractors on whose capacity the Applicant does not rely
 Applicants are required to complete a shortened version of the SPD for each Subcontractor on whose capacity the Applicant does not rely on
 .
 Exclusion Criteria
 Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015.
 SPD Questions 3A – 3C have been identified as mandatory exclusion grounds and SPD Questions 3D have been identified as discretionary exclusion grounds. All the exclusion grounds will be assessed on a PASS/FAIL basis. For the mandatory exclusion grounds a bid will be excluded where the Applicant fails to provide either a positive response or to provide details to the satisfaction of the Council of the self cleansing measures undertaken. .For the discretionary exclusion grounds a bid may be excluded where the Applicant fails to provide either a positive response or if the Council is not satisfied as to the self cleansing measures undertaken.
 .
 Declarations and Certificates
 The applicants recommended to join the PSA will provide the undernoted certificates, declarations and/or completed questionnaires to evidence their compliance with the relevant questions within the Qualification Envelope.
 All certificates, declarations and questionnaires can be found within the Attachment area of PCS-T.
 SPD Question 2D.1 	Prompt Payment Certificate
 SPD Question 3A.1-.8 	Serious and Organised Crime Declaration
 SPD Question 3A.6 	Modern Slavery Act 2015 Declaration
 SPD Question 3D.3	Human Rights Act Declaration
 SPD Question 3D.11 	Non-Collusion Certificate
 SPD Question 4B.5.1 	Insurance Certificates
 SPD Question 4C.6	Protection of Vulnerable Groups Scotland) Act 2007 Declaration
 Declaration Section 	*Form of Tender
 *The ‘Form of Offer to Tender’ must be completed and uploaded within the relevant question in the Commercial Envelope.
 .
 In the case of this PSA procedure this information will be requested by the Council when applicants are recommended for appointment to the PSA prior to the issue of any mini competitions or Direct Awards under the PSA.
 .
 Other declarations and questionnaires may require to be completed for future mini competitions, these will be issued as required with the mini competition ITTs.
 .
 Failure to provide this information or in the event that the information provided does not support or evidence the statements made within the SPD will invalidate the application.
 .
 Please note, the alternative review body to the local Sheriff Court detailed in VI.4.1 is:
 Court of Session
 Parliament House
 Parliament Square
 Edinburgh
 EH1 1RQ
 +44 1312252595
 supreme.courts@scotcourts.gov.uk
 The buyer is using PCS-Tender to conduct this ITT exercise. The Project code is 24079. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2343
 A sub-contract clause has been included in this contract. For more information see: http://www.publiccontractsscotland.gov.uk/info/InfoCentre.aspx?ID=2363
 Community benefits are included in this requirement. For more information see: https://www.gov.scot/policies/public-sector-procurement/community-benefits-in-procurement/
 A summary of the expected community benefits has been provided as follows:
 The Council is committed to securing Community Benefits through its contracts.
 Applicants are required to detail any Community Benefits you wish to offer the Council as part of your application.
 (SC Ref:730793)


description:
The purpose of this service is to support people diagnosed with young onset dementia, their families and carers. This will be through a person-centred, asset-based approach to maintain the best possible quality of life and support to remain independent in their own homes and communities for as long as possible. This will be consistent, flexible care and support as agreed in the individual’s personal support plan and in relation to assessed need.
 The procurement is an open tender with the light touch regime applied.. The contract value indicated is for the full contract term i.e. a potential 8 years in total.

title: Young Onset Dementia Support and Day Opportunities

description:
The purpose of this service is to support people diagnosed with young onset dementia, their families and carers. This will be through a person-centred, asset-based approach to maintain the best possible quality of life and support to remain independent in their own homes and communities for as long as possible. This will be consistent, flexible care and support as agreed in the individual’s personal support plan and in relation to assessed need. This is a citywide service but will encourage people to maintain links within their local communities. The service will provide:
 Day opportunities in a group setting – combination of centre based and community activities
 One to one day opportunities (Community and Home Support Service) that facilitates engagement in activities of person’s choice – this should be provided locally to the individual according to the individual’s preference
 Support Service and Carer and peer support group opportunities
 Volunteer Befriending Service for all ages - this should be provided locally to the individual according to the individual’s preference
 These services should be provided face to face unless the service user requests otherwise or as COVID or other restrictions dictate.

title: CT1080 Instructions to Tenderer

title: CT1080 Specification

title: CT1080 Pricing Schedule

title: CT1080 Tenderers Submission

title: CT1080 T&C's

title: CT1080 Budget Breakdown

title: CT1080 Climate change plan

reviewDetails: An economic operator that suffers or risks suffering loss or damage attributable to a breach of duty under Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or Court of Session. A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the Find a Tender Service or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.

reductionCriteria:
Providers must hold or commit to obtaining the following
 - Tenderers are required to have a min general annual turnover of 466,630 GBP for the last two financial years
 - Employer's (Compulsory) Liability: 5 million GBP
 - Public Liability: 10 million GBP
 - Health and Safety Policy
 - PVG Clearance for all relevant staff
 - Climate Change Plan
 - In addition, providers must satisfy the Council's financial probity assessment, with regards to ratios.
 Further information is included within the SPD and the Invitation to Tender.

awardCriteriaDetails: 80% quality 20% cost

The City of Edinburgh Council

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

Sheriff Court

legalName: Sheriff Court

The City of Edinburgh Council

description: General public services

Alzheimer Scotland

postalCode: EH3 7RN

streetAddress: 22 Drumsheugh Gardens

legalName: Alzheimer Scotland

description:
It is a mandatory requirement of this Contract that a prompt payment clause is present in all Contracts used in the delivery of the requirements. This ensures payment of sub-contractors at all stages of the supply chain within 30 days and includes an obligation to provide a point of contact for sub-contractors to refer to in the case of payment difficulties. This will require active monitoring of payment performance as well as the provision of evidence and reports to the Council on request or as contractually scheduled.
 (SC Ref:760656)


description: Provision of an Audio Conferencing System to support the delivery of Tribunal Jurisdictions. The requirement is for a voice only dial-in conference facility accessible via an inbound Freephone number (mobile and landline), with additional security features.. As per framework guidance, SCTS completed a Desktop Evaluation on the basis of Price Only.

title: Audio Conferencing for Tribunals

title: Audio Conferencing for Tribunals

reviewDetails:
General
 Reference should be made to Part 4 (Sections 37 – 40) of the Procurement Reform (Scotland) Act 2014 and independent legal advice should be sought urgently before any claim is commenced.
 A claimed breach of the public procurement rules is actionable by any economic operator in legal proceedings brought in the Sheriff Court or the Court of Session in Scotland.
 Prior Notice of Proceedings
 Proceedings under this regulation may not be brought unless the economic operator has first informed the contracting authority of —
 (a) the nature of the claimed breach or apprehended breach of the public procurement rules; and
 (b) its intention to bring proceedings in respect of that claimed breach.
 Time Limits for Bringing Proceeding
 Proceedings must be brought within 30 days beginning with the date when the economic operator first knew or ought to have known that grounds for starting the proceedings had arisen unless the court considers that there is a good reason for extending the period within which proceedings may be brought, in which case the court may extend that period for up to a maximum of 3 months from that date.

Scottish Courts and Tribunals Service

postalCode: EH11 3XD

streetAddress: Saughton House, Broomhouse Drive

description: General public services

legalName: Scottish Courts and Tribunals Service

BT

locality: edinburgh

postalCode: EH12 9DH

streetAddress: 1 lochside view, edinburgh business Park

legalName: BT

description:
Award against framework: Network Services 2
 The contract is for an initial period of 3 years, with two optional extension periods of twelve months
 (SC Ref:730802)


description: Scene Connect is administering this contract on behalf of Dundee Renewable Energy Society, a Dundee charity established to develop community owned renewable energy assets. The contract is to design, build, operate and maintain a 2 MegaWatt (MW) Solar Photovoltaic (PV) ground-mounted array; construction of a new site access from the A90; all ancillary electrical infrastructure to connect the site to the point of connection at the James Hutton Institute's Invergowrie campus, including horizontal directional drilling underneath the A90 using the Client's nominated subcontractor; and associated ancillary work.

description: North Bullionfield (Dundee City) and the James Hutton Institute's Invergowrie Campus (Perth & Kinross)

title: Bullionfield Solar Meadow

title: Bullionfield Solar Meadow

title: DRES Procurement - Volume 1 (Tender Requirements)

title: DRES Procurement - Volume 2 (Technical Specification and Scope of Work)

title: DRES Procurement - Volume 3 (Tender Returns)

title: Volume 2, Appendix 1 - DCC Decision Notice

title: Volume 2 - Appendix 1, PKC Decision Notice

title: Volume 2 - Appendix 2, SSEN Connection Offer

title: This Export Limitation Scheme has been submitted to SSEN and approved by their designer (17.04.2023)

title: Zip file containing plans submitted (and consented) for the project planning consent.

format: application/zip

title: Zip file containing plans submitted to Transport Scotland showing detailed site access.

title: Word version of Tender Returns - Volume 3

format: application/msword

title: Word version of Pricing Schedule - Volume 4

title: DRES Procurement - Volume 4 (Pricing Schedule)_v3 (Excel version)

title: Drg. 2104-001 General Arrangement of Solar PV array, as .DWG file

format: application/octet-stream

title: Copy of existing services at JHI from Survey.

title: .DWG file of the new services being installed for the IBH development (under construction on site)

title: Existing SLD and proposed SLD showing upgraded SSEN connection and PV array

title: Drg. 2104-007 CAD Site layout of Solar PV array and elevations, as .DWG file

title: Bullionfield Solar Meadow

Scene Connect Ltd

postalCode: EH6 6BR

streetAddress: 46a Constitution Street

legalName: Scene Connect Ltd

Dundee Sheriff Court

postalCode: DD1 9AD

streetAddress: 6 W Bell St,

legalName: Dundee Sheriff Court

Munro Wilson Ltd

locality: Whitsome

postalCode: TD11 3NB

streetAddress: Glamis House, Main Street

legalName: Munro Wilson Ltd

Dundee Sheriff Court

streetAddress: West Bell Street

description:
Please see tender documents for additional information.
 (SC Ref:765934)


description:
The Contracting Authority reserves the right to request additional deliveries by the successful Tenderer, either intended as partial replacement of supplies or installations or as extensions of existing supplies and installations.
 The Contracting Authority may at its sole discretion exercise this option.

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities.
 SIPBS required the supply, delivery and commissioning of a new autoclave which is vital to support all of SIPBS research and teaching activities. The service provided by this equipment is the autoclaving of biological and clinical waste and safe disposal in accordance with the Control of Substances Hazard to Health Regulations 2002 (COSHH), Genetically Modified Organisms Regulations 2014 (GMO) and The Health Technical Memorandum (HTM07-01) Safe Management of Healthcare Waste.
 The supplier will be required to decommission and remove the existing autoclave system, and additionally install and commission the new system within the existing space.
 There is additional requirement that the new system is sustainable and environmentally conscious. In particular, the system should reduce water, energy consumption and carbon consumption.
 It should be noted that this is the award notice of the contract for the provision of these requirements.. The equipment is to be installed w/c 4th December 2023.

title: Supply, Delivery and Commissioning of Autoclave, Removal and Disposal of Existing Autoclave

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities. SIPBS requires the supply, delivery and commissioning of new autoclave which is vital to support all of SIPBS research and teaching activities.
 It is a requirement that the supplier decommissions and removes the existing autoclave to replace it with the new system supplied.

description:
Strathclyde Institute of Pharmacy and Biomedical Sciences (SIPBS) is a leader in research, teaching and knowledge exchange activities. SIPBS required the supply, delivery and commissioning of new autoclave which is vital to support all of SIPBS research and teaching activities.
 It was a requirement that the supplier decommissions and removes the existing autoclave to replace it with the new system supplied.

minimum:
4B.1.2 It is a requirement of this contract that bidders have a general yearly turnover of 140,000.00 GBP for the last three years.
 4B.5.1-4B.5.3 It is a requirement of this contract that bidders can hold or commit to obtain prior to the commencement of any subsequently awarded contract, the types of insurance indicated below:
 The Contractor shall maintain in force with reputable insurers
 Employer’s (Compulsory) Liability Insurance = 10,000,000.00 GBP
 Public and Product Liability Insurance = 10,000,000.00 GBP
 Professional Risk Indemnity Insurance = 2,000,000.00 GBP
 In respect of any one incident and unlimited as to numbers of claims

description:
4B.1.2
 4B.5.1 – 4B.5.3

minimum:
4C1.2 Bidders are required to provide three (3) examples that demonstrate that they have the relevant experience to deliver the services/supplies as described in part II.2.4 of the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 This will be scored in accordance with the scoring matrix as detailed in the ITT.

University of Strathclyde

locality: Glasgow

postalCode: G1 1XQ

streetAddress: McCance Building, 16 Richmond Street

description: Education

legalName: University of Strathclyde

Glasgow Sheriff Court

postalCode: G5 9TW

streetAddress: 1 Carlton Place

legalName: Glasgow Sheriff Court

University of Strathclyde

postalCode: G1 1QE

description: Education

BMM WESTON

locality: Faversham / Kent

postalCode: ME13 7EB

streetAddress: Brent Hill, Faversham

legalName: BMM WESTON

description: (SC Ref:747988)


description: May take up option of twelve month extensions up to a maximum of two further years (2025-2027) at an estimated value 75000 GBP (excluding VAT) per annum.

description: The procurement is being undertaken in accordance with Regulation 28 'Open Procedure' of the Public Contracts (Scotland) Regulations 2015.

description: Govan, Elderpark, Ibrox, Cessnock and KInning Park, Glasgow

title: Elderpark Housing Association - Landscape Maintenance Contract 2023-2025

description:
The Contract will principally comprise litter picking, grass cutting, leaf collection, tree, shrub bed, planters and hedging landscape maintenance services to existing properties and common landscaped areas throughout Elderpark, Govan, Ibrox, Cessnock and Kinning Park, Glasgow to the areas detailed within the Landscape Architects tender drawings and Elderpark Housing Association’s property address list (refer Tender Document K – Elderpark HA Address List). The Contract may also include an annual tree survey service, tree and stump removal works, and repairs to existing damaged grass areas.
 The Contract may also include Elderpark Housing Association’s ‘helpline’ garden maintenance scheme involving landscape maintenance to gardens of elderly residents. However, this work is provisional and not guaranteed, and Bidder’s rates for the ‘helpline’ garden scheme will not be taken into account in the tender evaluation.The commencement date for the Measured Term Contract is currently estimated to be 1st July 2023 and the completion date is 30th June 2025.
 Subject to satisfactory performance of the Contractor, which will be assessed through measurement of the Key Performance Indicator’s (Refer Tender Document F), it is intended that the Contract will be extended on an annual basis by a maximum of two further years until 2027. Orders for future landscape maintenance services may be placed by Elderpark Housing Association during Year Thee, Year Four or at any point until expiry of the Measured Term Contract (maximum of four years from the date of entering into the Contract).

title: Document A

title: Document B

title: Document C

title: Document D

title: Document E

title: Document F

title: Document G

title: Document H

title: Document I

title: Document J

title: Document K

title: Document L

title: MAP Quantities

title: M01A

title: M02B

title: M03B

title: M04B

title: M05B

title: M06B

title: M07C

title: M08A

description: 2024 at the earliest if the optional 12 month extensions are not applied

performanceTerms:
The performance of the successful Bidder will be monitored through the Key Performance Indicators described within Tender Document F
 Key Performance Indicators attached to this Contract Notice.
 Where performance falls below the minimum acceptable level during the Contract, the successful Bidder will be required to produce a
 Remedial Plan for the approval of Elderpark Housing Association.
 Failure to produce a Remedial Plan or implement an approved Remedial Plan will be deemed to be a breach of the Contract, which may
 lead to the termination of the successful Bidder's Contract.

description:
Please refer to these statements when completing Section 4A of the SPD Scotland.
 4A.1 - If required by the member state, bidders are required to be enrolled in the relevant professional or trade registers within the country
 in which they are established.
 4A.2 - Where it is required, within a bidder’s country of establishment they must confirm which authorisation or memberships of the
 relevant organisation(s) are required in order to perform this service. Bidders must confirm if they hold the particular authorisation or
 memberships

description:
Please refer to these statements when completing Section 4B of the SPD (Scotland) v1.2_0.
 Question 4B.1.1 - Bidders will be required to have a minimum 'general' yearly turnover of 150000 GBP for the last two years.
 Question 4B.1.2 - Bidders will be required to have an average yearly turnover of a minimum of 150000 GBP for the last two years.
 Question 4B.3 - Where turnover information is not available for the time period requested, the bidder will be required to state the date
 which they were set up or started trading.
 4B.5.1 and 4B.5.2 - It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any
 subsequently awarded contract, the types and levels of insurances indicated below:
 Employer's (Compulsory) Liability Insurance - 5,000,000 GBP Public Liability Insurance - 5,000,000 GBP

description:
4C.8.1 - Bidders will be required to confirm their average annual manpower for the last three years.
 4C.8.2 - Bidders will be required to confirm their and the number of managerial staff for the last three years.
 4C.9 - Bidders will be required to demonstrate that they have (or have access to) the relevant tools, plant or technical equipment to deliver
 the types of requirements detailed in II.2.4 in the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 4C.10 - Bidders will be required to confirm whether they intend to subcontract and, if so, for what proportion of the contract. Minimum
 level(s) of standards required:
 SPD Scotland, Part C Technical and Professional Ability - Bidders responses to Part C of the SPD will be limited to a maximum of nine A4
 single sided pages, excluding any certification that a Bidder submits in support of their response, which must be completed in English using
 Arial 11 font

Elderpark Housing Association

postalCode: G51 3AX

streetAddress: 65 Golspie Street

description: Housing and community amenities

legalName: Elderpark Housing Association

A.D.A Construction Consultants

locality: Paisley

postalCode: PA3 3BB

streetAddress: Pavilion 3, St James Business Park, Linwood Road

name: Glasgow Sheriff Court and Justice of the Peace Court

Elderpark Housing Association

description: Housing and community amenities

Digby Landscaping

locality: Renfrew

postalCode: PA2 7EP

streetAddress: 8 Wallace Road, Renfrew

legalName: Digby Landscaping

description:
The award value of 70889.62GBP is the anticipated annual value of the contract excluding VAT
 (SC Ref:805806)