description:
PPE Ref 9542 Direct Provision of MOVPE reactor Cleanroom Maintenance.
 This order is for the annual contribution toward costs associated with maintaining a cleanroom environment.
 Internal Procurement Policy Exception (PPE) Form completed

procurementMethodRationale: Procurement Regulation 33.1.b.II Competition is absent for technical reasons

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

University of Glasgow

postalCode: G12 8QQ

streetAddress: Procurement Office, Tay House

description: Education

legalName: University of Glasgow

Sivers Photonics

locality: Blantyre

postalCode: G72 0BN

streetAddress: 4 Stanley Boulevard

legalName: Sivers Photonics

name: Glasgow Sheriff Court & Justice of the Peace Court

postalCode: G5 9TW

awardID: PPE Ref 9542

description: (SC Ref:719190)


measure: bids

measure: smeBids

measure: foreignBidsFromEU

measure: foreignBidsFromNonEU

measure: electronicBids

rel: canonical

title: Fume Cupboards and Fume Hoods

title: Analysers

title: Balances, Scales and Weights

title: Fridges, Freezers and Chillers

title: Laboratory/Cleanroom Furniture

title: General Lab Equipment

status: complete

description: CPI have a requirement for the ongoing supply of general lab equipment. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

Range of Equipment

type: quality

type: price

variantPolicy: notAllowed

title: Analysers

description: CPI have a requirement for the ongoing supply of analysers. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

title: Balances, Scales and Weights

description: CPI have a requirement for the ongoing supply of balances, scales and weights. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

title: Fridges, Freezers and Chillers

description: CPI have a requirement for the ongoing supply of fridges, freezers and chillers. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

title: Fume Cupboards and Fume Hoods

description: CPI have a requirement for the ongoing supply of fume cupboards and fume hoods. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

title: Laboratory/Cleanroom Furniture

description: CPI have a requirement for the ongoing supply of laboratory/cleanroom furniture. Please download the tender pack from https://www.publiccontractsscotland.gov.uk/Default.aspx for more information.

region: UK

scheme: CPV

title: 2423 - General Lab Equipment

currency: GBP

title: 2423 - General Lab Equipment

format: text/html

description: CPI have a requirement for the ongoing supply of general lab equipment. Please download the tender pack on https://www.publiccontractsscotland.gov.uk/Default.aspx for further information.

documentType: contractNotice

title: 2423 - Tender Pack

format: application/x-zip-compressed

title: 2423 - General Lab Equipment

documentType: awardNotice

title: 2423 - General Lab Equipment

scheme: CELEX

procurementMethod: open

mainProcurementCategory: goods

procurementMethodDetails: Open procedure

Centre for Process Innovation Limited

roles: buyer centralPurchasingBody

locality: Redcar

postalCode: TS10 4RF

streetAddress: Wilton Centre

scheme: COFOG

legalName: Centre for Process Innovation Limited

name: Glasgow Sheriff & Justice of the Peace Court

locality: Glasgow

postalCode: G5 9DA

North England Laboratory Supplies

streetAddress: Cumbie Way, Aycliffe Industrial Park, Aycliffe Industrial Park

Medline Scientific

streetAddress: Unit 3 Tower Industrial Park, Warpsgrove Lane, Chalgrove

Wolf Laboratories

streetAddress: Colenso House, Deans Lane, Pocklington, York

title: Fume Cupboards and Fume Hoods

title: Analysers

title: Balances, Scales and Weights

title: Fridges, Freezers and Chillers

title: Laboratory/Cleanroom Furniture

description: (SC Ref:728451)


title: Software to monitor carbon usage

description: two additional 12 months period extension options

description: This lot is to provide OT Hardware to connect manufacturing assets. For more information please refer to the tender documentation.

variantPolicy: allowed

description: This lot is to provide Hardware to connect existing building assets to a carbon monitoring solution. For more information please refer to the tender documentation.

description: This lot is to provide Software to integrate/integration of data from MMIC systems to a carbon monitoring dashboard. For more information please refer to the tender documentation.

title: Software to monitor carbon usage

description: This lot is to provide Software to monitor carbon usage. For more information please refer to the tender documentation.

description:
This tender is for the delivery of a Integrated Carbon Monitoring and Building Control Solution. This tender is split into 4 lots which are as follows.
 Lot 1 – OT Hardware to connect manufacturing assets
 Lot 2 – Hardware to connect existing building assets to a carbon monitoring solution
 Lot 3 – Software to integrate/integration of data from MMIC systems to a carbon monitoring dashboard
 Lot 4 – Software to monitor carbon usage
 Please download the tender documents on https://in-tendhost.co.uk/uk-cpi/ for more information.

documentType: economicSelectionCriteria

documentType: technicalSelectionCriteria

description: Extension due to late response to clarifications

label: Time limit

label: Conditions for opening of tenders

electronicInvoicingPolicy: allowed

name: Glasgow Sheriff Court and Justice of the Peace Court

Siemens

locality: Farnborough

postalCode: GU14 7BF

streetAddress: Pinehurst, 2 Pinehurst Road

scale: large

legalName: Siemens

Atos IT Services UK Limited

locality: London

postalCode: WC1V 6EA

streetAddress: Second Floor, MidCity Place,, 71, High Holborn

legalName: Atos IT Services UK Limited

streetAddress: Sheriff Clerk's Office PO Box 23 1 Carlton Place

status: active

title: Software to monitor carbon usage

description: (SC Ref:729650)


description: Purchase of an X-Ray Cabinet irradiator to carry out genome stability/DNA damage experiments utilizing ionising radiation.

name: Ability to penetrate more dense 3D structures.

description: Western General Hospital campus.

title: High-power X-Ray Irradiator for dense 3D structures including organoids and mini brain systems

description: High-power X-Ray Cabinet Irradiator for use in more dense 3D structures, including organoids and "mini brain" systems

procurementMethod: limited

procurementMethodDetails: Award procedure without prior publication of a call for competition

procurementMethodRationale: The critical benefit of the machine being purchased is the high energy system and tube power which enables better penetration and dose distribution in more dense 3D structures, including organoids and "mini brain" systems.

University Of Edinburgh

locality: Edinburgh

postalCode: EH1 1HT

streetAddress: Charles Stewart House, 9-16 Chambers Street

description: Education

legalName: University Of Edinburgh

Xstrahl Ltd

locality: Brownhills

postalCode: WS8 7DG

streetAddress: Unit 2, Maybrook Industrial Estate, Maybrook Road

scale: sme

legalName: Xstrahl Ltd

name: Edinburgh Sheriff Court and Justice of the Peace Court

roles: reviewBody mediationBody

postalCode: EH1 1LB

streetAddress: Sheriff Court House, 27 Chambers Street

University Of Edinburgh

description: Education

description: (SC Ref:729386)

initiationType: tender


description: Brandon Street & YMCA, Motherwell has been included within the New Supply programme to produce 48 new walk up flatted residential units for North Lanarkshire Council’s social rented housing stock. These new social housing will be in the form of 2 new L shaped 3 storey blocks to form 42nr flats at 303 Brandon Street and the conversion of former YMCA building to form 6nr flats.

title: New Build Social Housing at Brandon Street, Motherwell

description: Provision of (up to 48 nr) new build social housing units at the Brandon Street site in Motherwell.

reviewDetails: An economic operator that suffers, or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session.

mainProcurementCategory: works

North Lanarkshire Council

locality: Motherwell

postalCode: ML1 1AB

streetAddress: Civic Centre, Windmillhill Street

description: General public services

description: Economic affairs

legalName: North Lanarkshire Council

CCG (Scotland) Ltd

postalCode: G32 8NB

streetAddress: 1 Cambuslang Road, Cambuslang Investment Park

legalName: CCG (Scotland) Ltd

Scottish Courts

legalName: Scottish Courts

description:
Award against framework: SXL NBRC 1518 Framework Lot 5 (41 units and over)
 (SC Ref:719270)


description: Fife Council may require additional purchases under this contract which have not been specifically detailed in the "specification" however any additional purchases will be in full accordance with the requirements of Regulation 72 of the Public Contract (Scotland) Regulations 2015.

description: The contract will be for the period of 3 years with the option to extend for up to 12 months if requried.

description:
The Fife Health and Social Care Partnership (“the Partnership”/H&SCP) requires to commission a Care at Home Service from a variety of external care providers. Fife’s Health and Social Care Partnership is committed to personalisation and outcome-based services for individuals of all ages and abilities and is seeking to appoint a range of partner organisations to deliver outcome focused support to young people, adults and older people with a range of identified support needs throughout Fife, under a flexible Framework agreement.
 Any partner organisations must be able to demonstrate experience and commitment to innovatively work with individuals within existing self-directed support policies and approaches. They must also evidence strong skills in working with families of individuals.
 Objectives for the Framework are to ensure that individuals have access to support that aspires to the highest level of quality and promotes the right of each individual to direct their own support. Key elements of success from desirable organisations include robust evidence of promoting and delivering:
 - personal preferences
 - fluctuating levels of required support
 - an organic service to reflect individual’s achievement of outcomes
 -continuity and consistency in provision of individual outcome focussed support
 - creative approaches that ensure outcomes are
 developed which promote ordinary lives
 - innovative combinations of natural, paid and
 technological support
 - support that enables and supports approaches to risk
 The Provider will provide practical and personal care over 24 hours a day and 365 days a year to the Supported Person living in their own home and will be in line with the service aims and objectives specified within this document.
 The purpose of the Service Specification is to set out the minimum standards required to ensure that a consistent quality of service is provided to all Supported Persons who are assessed by the Partnership as requiring a Care at Home Service.. This Framework will be a flexible Framework which re-opens at regular periods throught the lifetime of the Contract.

description: Fife

title: Flexible Framework for the Provision of Care at Home for Adults and Older People

title: TN INFODOC - SC0005

format: application/pdf

title: TN1 SC0005

title: TN2 SC0005

title: Social Care Home Care T&Cs

streetAddress: Fife House, Glenrothes or staff home address if working from home.

description: Pasha Keir, Niki Hutchison and/or Duaa Ali.

description: There will be an ongoing requirement for external Care at Home Services, it is envisaged that the next time this will go out to full open tender will be 3 years (or 4 years with extension) after Contract award date. As this is a flexible framework this Contract will be re-opened at regular intervals throughout the Contract lifetime to allow new Care Providers to submit a bid to join the Framework.

reviewDetails:
Economic operators should approach the contracting authority in the first instance. However, the only formal remedy is to apply to the courts:
 An economic operator that suffers, or is at risk of suffering, loss or damage attributable to a breach of duty under the Public Contracts (Scotland) Regulations 2015 or the Procurement Reform (Scotland) Act 2014, may bring proceedings in the Sheriff Court or the Court of Session.

type: suitability

description: Providers are required to hold the relevant registration to provide the services detailed in the Service Specification.

mainProcurementCategory: services

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House, North Street

description: Social protection

legalName: Fife Council

Kirkcaldy Sheriff Court

locality: Kirkcaldy

postalCode: KY1 1XQ

legalName: Kirkcaldy Sheriff Court

Fife Council

description: General public services

description: Social protection

Support and Social Care Network Ltd

postalCode: EH14 2BA

streetAddress: 62 , Longstone Road

legalName: Support and Social Care Network Ltd

Time For You Care

locality: EDINBURGH

streetAddress: 40 Craiglockhart Avenue

legalName: Time For You Care

Avicenna Care Ltd

locality: KIRKCALDY

postalCode: KY2 6RA

streetAddress: 6 McIntosh Parade

legalName: Avicenna Care Ltd

J.C.MICHAEL GROUPS LTD

postalCode: EH6 6EP

streetAddress: 31 Sandport Street

legalName: J.C.MICHAEL GROUPS LTD

EXCEL CARE Pvt Ltd

locality: DUNFERMLINE

postalCode: KY11 8DH

streetAddress: 2, GIB GROVE

legalName: EXCEL CARE Pvt Ltd

Cera Care Operations Scotland Ltd

locality: Alloa

postalCode: FK10 1EX

streetAddress: Lime Tree House, North Castle Street

legalName: Cera Care Operations Scotland Ltd

Heart Link Health Care Services Ltd

region: UKM

locality: Dunfermline

postalCode: KY11 3BZ

streetAddress: Unit 20 , Dunfermline Business Centre, Izatt Avenue

legalName: Heart Link Health Care Services Ltd

Call-in Homecare Ltd

postalCode: EH6 5NP

streetAddress: 2 ANDERSON PLACE, Bonnington Bond (Suite 70), 2 Anderson Place

legalName: Call-in Homecare Ltd

ACS Care at Home

locality: Lochgelly

postalCode: KY5 9AF

streetAddress: 93 High Street

legalName: ACS Care at Home

Oran Homecare

locality: Cupar

postalCode: ky115 4HS

streetAddress: Eden Park House, Eden Park

legalName: Oran Homecare

Gibson Training and Care Ltd

streetAddress: Unit 14 Fife Renewables Innovation Centre, Ajax Way

Mitchell & Murdoch Care Ltd.

streetAddress: Office 9 Algo Business Centre, Glenearn Road

ION Care and Support Services Ltd

streetAddress: Axwell House, 2 Westerton Road, East Mains Industrial Estate

Constance Care Limited

streetAddress: Suite 1 Munro Business Park, 15 Munro Place

1st Homecare

streetAddress: Unit 14B, Dickson Street, Elgin Industrial Estate

The Richmond Fellowship Scotland

streetAddress: 3 Buchanan Gate Business Park, Cumbernauld Road, Stepps

Thistle Care solutions

streetAddress: Suite 9 Business Incubator Kirkcaldy, Myregormie Place

Kenylink Services Ltd

streetAddress: Office 18/27 Kirkcaldy Business Incubator Centre ,Myregormie Place, Kirkcaldy

description:
Contract Start Date 01/06/2023.
 (SC Ref:734046)


name: Social Care and Social Work Improvement Scotland (Care Inspectorate)

title: CEO/Director roles

title: Head of/Senior Operational staff roles

title: CEO/Director roles

description: 2 x 12 months

description: Provision of search and selection services for CEO/Director roles within both the Care Inspectorate and SSSC. It is anticipated that the value of the framework will not exceed 170,000GBP excluding VAT, for the life of the agreement, across both lots, including any extension options, actual spend will be determined by requirement as and when identified.

title: Head of/Senior Operational staff roles

description: 2 x 12 months

description: Provision of search and selection services for Head of/Senior Operational staff roles within both the Care Inspectorate and SSSC. It is anticipated that the value of the framework will not exceed 170,000GBP excluding VAT, for the life of the agreement, across both lots, including any extension options, actual spend will be determined by requirement as and when identified.

title: Search & Selection Framework

title: Search & Selection Framework

description: Provision of search and selection services for senior roles within both the Care Inspectorate and SSSC

title: ITT - Search & Selection

title: Search & Selection Framework

awardCriteriaDetails:
Lot 1 CEO/Director roles
 Lot 2 Head of/Senior Operational staff roles

description: January 2027

locality: Dundee

postalCode: DD1 4NY

streetAddress: Compass House, 11 Riverside Drive

description: Social protection

Dundee Sherriff Court

postalCode: DD1 9AD

streetAddress: 6 West Bell Street

legalName: Dundee Sherriff Court

description: Social protection

Livingston James Ltd

postalCode: G2 5SG

streetAddress: 218 St Vincent Street

legalName: Livingston James Ltd

title: CEO/Director roles

title: Head of/Senior Operational staff roles

description:
It is anticipated that the value of the framework will not exceed 170,000GBP excluding VAT, for the life of the agreement, across both lots, including any extension options, actual spend will be determined by requirement as and when identified.
 (SC Ref:730044)


name: The Common Services Agency (more commonly known as NHS National Services Scotland) ("NSS")

description: The Authority shall be entitled, at its option, to continue this Agreement beyond the Initial Term for five (5) twelve (12) Contract Month periods subject to giving not less than six (6) Contract Months’ notice to the Contractor.

description:
As part of the equipment replacement programme at SCRM it has been identified that the Class II Microbiological safety cabinets within the Grade B cleanrooms require replacement The contract will cover for the provision of the new equipment and maintenance.
 3x 1.2 metre Microbiological Safety Cabinets and
 2x 1.8 metre Microbiological Safety Cabinets.

title: Microbiological Safety Cabinets

title: Microbiological Safety Cabinets

description:
Replacement of Class II Microbiological safety cabinets within the Grade B cleanrooms.
 3x 1.2 metre Microbiological Safety Cabinets and
 2x 1.8 metre Microbiological Safety Cabinets.

title: Microbiological Safety Cabinets

type: economic

description:
As per Section 4B of the SPD Bidders must provide information on Economic and Financial Standing in the section of the SPD relating to this.
 4B (1.71.2) – Last 3 years’ turnover
 4B (1.71.5) - Last 3 years turnover
 Insurance Requirements:
 4B (1.72.12)
 Employer's (Compulsory) Liability: Five Million Pounds Sterling (GBP 5,000,000)
 Public Liability: Five Million Pounds Sterling (GBP 5,000,000)
 Product Liability: Five Million Pounds Sterling (GBP 5,000,000)

type: technical

description:
As per Section 4C (question 1.74.2 - 4C.1.2) of the SPD Bidders must provide information on Services in the section of the SPD relating to this.
 Question Description
 Please provide relevant examples of supplies and/or services carried out during the last three years as specified in the Contract Notice:
 (Examples from both public and/or private sector customers and clients may be provided)

postalCode: EH12 9EB

streetAddress: Gyle Square (NSS Head Office), 1 South Gyle Crescent

description: Health

Sheriff Court House

postalCode: EH1 1LB

streetAddress: 27 Chambers Street

legalName: Sheriff Court House

roles: buyer centralPurchasingBody reviewBody

description: Health

Scientific Laboratory Supplies Ltd.

locality: Newhouse

postalCode: ML1 5UH

streetAddress: Biocity Scotland, Bo'ness Road

legalName: Scientific Laboratory Supplies Ltd.

description: (SC Ref:728221)

scheme: EU-OJ


description: The works consist of the following: replace existing windows; installation of new heating system and associated Electrical Works; replace existing Distribution Board; replace the existing skirting trunking (and associated containment) and replace existing blinds as set out in the works information and drawings, specifications and documents.

description: Dunfermline Police Station. 2 Holyrood Place, Dunfermline, KY12 7PA

title: PROC 22-1837 - Provision of Dunfermline Police station window & electric heating upgrade (Phase 1).

description: The site is Dunfermline Police Station, and comprises of replacement windows and electric heating (identified on the Condition Surveys).

description: Electronically via Public Contract Scotland Tender by authorised Procurement Specialist after the tender deadline.

performanceTerms: During the period of the Contract Agreement, the Contractor shall monitor and measure their performance and will be required to attend contract and supplier management meetings if requested.

description:
SPD Question 4A.1 Trade Registers
 It is a requirement of this tender that if the Tenderer is UK based they must hold a valid registration with Companies House. Where the Tenderer is UK based but not registered at Companies House they must be able to verify to the SPA’s satisfaction that they are trading from the address provided in the tender and under the company name given.
 Tenderers within the UK must confirm if they are registered under Companies House within this question.
 If the Tenderer is based out-with the UK they must be enrolled in the relevant professional or trade register appropriate to their country as described in Schedule 5 of the Public Contracts (Scotland) Regulations 2015.

minimum:
SPD Question 4B5 Insurances
 Employers (Compulsory) Liability Insurance = 10 million GBP in respect of each claim without limit to the number of claims. Tenderers may be required to provide their current Employers Liability Insurance certificate which should include name of the insurers, policy numbers, expiry date and limits for any one incident and annual aggregate caps and the excesses under the policies.
 Public Liability Insurance = 10 million GBP in respect of each claim without limit to the number of claims. Tenderers may be required to provide a copy of their current Public Liability Insurance certificate.
 Professional Indemnity Insurance = 2 million GBP in any one occurrence or series of occurrences arising out of any one event. Tenderers may be required to provide a copy of their current Professional Indemnity Insurance certificate.
 Tenderers may be required to provide a copy of their current Insurance certificate.
 Documentation requested for the above insurances should include name of insurers, policy numbers, expiry date and limits of any one incident and annual aggregate caps and the excesses under the policies.
 SPD Question 4B6 Financial Standing:
 The Authority will access a Credit safe report for a Tenderers organisation and use the information contained within to assist with the assessment of the Tenderer’s economic and financial standing. Tenders are asked to provide their company number within the SPD to allow the Authority to access a Credit Safe Report.
 Within such reports, the risk of business failure is expressed as a score of 30 or below (high risk of business failure). In the event that a company is determined to have a risk failure rating of 30 and below i.e. that the company is considered to have a high risk of business failure, the submission will not be considered further.
 If you are successful in the award of this contract and your risk failure rating falls below 30 then the SPA reserve the right to remove you from this contract. It is the Contractor’s responsibility to ensure that the information held by Credit Safe is accurate and up to date.
 For the avoidance of doubt, the SPA will request a report from Credit Safe following the closing date for the receipt of the Tenders to ensure that the most up to date information is used. Where you are not registered on Credit Safe e.g. charitable organisations or new start companies/ Sole Traders with less than 3 years trading history, discretionary powers are available to the Director of Finance to consider abbreviated accounts along with bankers references etc.
 Tenderers should be aware that any outstanding County Court Judgements will have a detrimental effect on the rating held by Credit Safe and it is your responsibility to ensure that the information held by Credit Safe is accurate and up to date - failure to do so will result in rejection of your submission.
 IMPORTANT NOTE: This requirement is not applicable to Sole Traders/ Charities. Sole Traders/ Charities may be required to provide a bankers reference if successful.

description: It is a requirement of this Contract that Tenderers hold, or can commit to obtain prior to the commence of any subsequently awarded Contract, indicated below:

description:
Tenderer`s will be required to provide evidence of having the necessary capacity and capability to deliver the requirements stated within the tender documents.
 The below requirements will be requested during the tender process:
 SPD Question 4C1 Works
 Tenderer`s will be required to provide evidence of having the necessary capacity and capability to deliver the requirements for the works.
 Two (2) examples of the provision of similar works may be requested and must be from within the last 5 years of work contracts.
 If Tenderers are unable to provide two (2) examples the tenderer may be required to explain why examples cannot be provided.
 Guidance
 The Authority will use the information you provide to evaluate whether your organisation; consortium members and/or named sub-contractors have the relevant professional and technical skills required for this procurement exercise.

Scottish Police Authority

locality: Glasgow

postalCode: G51 1DZ

streetAddress: 1 Pacific Quay, 2nd Floor

description: Public order and safety

legalName: Scottish Police Authority

postalCode: G5 9DA

legalName: Glasgow Sheriff Court and Justice of the Peace Court

description: Public order and safety

Ashwood Scotland Limited

locality: Livingston

postalCode: EH54 8TE

streetAddress: Unit 3 Tailend Court, Starlaw Road

legalName: Ashwood Scotland Limited

streetAddress: 1 Carlton Place

description: (SC Ref:729768)


description: The University of Strathclyde has awarded a Contract for a Project for Switchgear Works at the Curran Building (2022) (UOS-22982-2022). This was tendered via a Quick Quote (QQ) process.

description: University of Strathclyde.

description: The University of Strathclyde has awarded a Contract for a Project for Switchgear Works at the Curran Building (2022) (UOS-24184-2022). This was tendered via a Quick Quote (QQ) process.

reviewDetails: An economic operator that suffers, or risks suffering, loss or damage attributable to a breach of duty under the Public Contract (Scotland) Regulations 2015 (SSI2015/446) (as amended) may bring proceedings to the Sheriff Court or the Court of Session.

University of Strathclyde

postalCode: G1 1XQ

streetAddress: 16 Richmond Street, McCance Building

description: Education

legalName: University of Strathclyde

FES Support Services Ltd

locality: Stirling

postalCode: FK7 8HW

streetAddress: Forth House, Pirnhall Business Park

legalName: FES Support Services Ltd

locality: GLASGOW

description:
In line with 72 - Modification of Contracts During their Term, of the Public Contracts (Scotland) Regulations 2015, this Contract may be modified without a new procurement procedure in accordance with this Part in some cases.
 (SC Ref:719321)


description: software managed service

description: Red Hat licence renewal for 36 months

title: Red Hat Licences

title: Red Hat Licences

description: Red Hat licence renewal - 36 months

description: Red Hat licence renewal - 36 months

Scottish Government

roles: buyer reviewBody mediationBody reviewContactPoint supplier

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

id: Ministry or any other national or federal authority, including their regional or local subdivisions

description: General public services

legalName: Scottish Government

Softcat Ltd

locality: Marlow

postalCode: SL7 1TB

streetAddress: Thames Industrial Est, Field House Lan

legalName: Softcat Ltd

Edinburgh Sheriff Court

roles: reviewBody reviewContactPoint

streetAddress: Sheriff Court House, 27 Chambers Street

legalName: Edinburgh Sheriff Court

description:
Award against framework: Software Value Added Re-seller
 (SC Ref:719332)


description:
Contract with Boxxe Limited for the provision of Analytics software.
 Procurement under the Crown Commercial Services Technology products and Associated Services Framework.

title: Provision of Analytics Software and Support Agreement

description:
Contract with Boxxe Limited for the provision of software.
 Procurement under the Crown Commercial Services Technology Products and Services Framework.

Scottish Police Authority

description: Public order and safety

boxxe Limited

streetAddress: The e-centre, Coopergate Way Business Village

legalName: boxxe Limited

Glasgow Sherriff Court

legalName: Glasgow Sherriff Court

description:
Award against framework: Crown Commercial Services - Technology Products and Associated Services Framework
 Contract with Boxxe Limited for the provision of Analytics Software and Support.
 Procurement under the Crown Commercial Services Technology Products and Associated Services Framework.
 (SC Ref:719348)


description: Option to extend for up to 5 years at 12-month intervals.

description:
This contract is for the provision of Private Rented Accommodation. The contract provides self-contained accommodation within
 Edinburgh for single households / individuals, couples and households with children experiencing homelessness.
 Private Rented Accommodation is for households who have been assessed as homeless and who:
 - Will be able to independently manage in their own accommodation or/and
 - Will be receiving or about to receive a visiting support service to encourage and improve Housing Support skills.
 It is expected that turnover of rooms will be low. It can take up to two years or more for people assessed as homeless to be offered
 alternative accommodation. Average length of stay for Private Rented Accommodation is approximately 18 months though some are significantly longer or shorter than this.

title: CT0627-242 Temporary Accommodation Flexible Purchasing System - PRA

The City of Edinburgh Council

locality: Edinburgh

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

Bruntsfield Management Ltd

streetAddress: 47, Leamington Ter

legalName: Bruntsfield Management Ltd

Sheriff Court

legalName: Sheriff Court

description:
Award against framework: CT0627 Temporary Accommodation & Associated Services Flexible Purchasing System
 Award against framework: CT0627 Temporary Accommodation & Associated Services Flexible Purchasing System
 (SC Ref:718627)
 (SC Ref:719349)


description:
This contract is for the provision of Private Rented Accommodation. The contract provides self-contained accommodation within
 Edinburgh for single households / individuals, couples and households with children experiencing homelessness.
 Private Rented Accommodation is for households who have been assessed as homeless and who:
 - Will be able to independently manage in their own accommodation or/and
 - Will be receiving or about to receive a visiting support service to encourage and improve Housing Support skills.
 It is expected that turnover of rooms will be low. It can take up to two years or more for people assessed as homeless to be offered alternative accommodation. Average length of stay for Private Rented Accommodation is approximately 18 months though some are significantly longer or shorter than this.

title: CT0627-243 Temporary Accommodation Flexible Purchasing System - PRA

The City of Edinburgh Council

description: General public services

Josephs Accommodations Ltd

postalCode: EH12 7BH

streetAddress: 24 Carrick Knowe Road

legalName: Josephs Accommodations Ltd

description:
Award against framework: CT0627 Temporary Accommodation & Associated Services Flexible Purchasing System
 Award against framework: CT0627 Temporary Accommodation & Associated Services Flexible Purchasing System
 (SC Ref:718627)
 (SC Ref:719362)


measure: lowestValidBidValue

measure: highestValidBidValue

description: May take up option of three annual extensions in twelve month increments upon conclusion of the three year initial period of the contract at an approximate additional cost of 30000 GBP excluding VAT.

description: Elderpark Housing Association are seeking to establish a Three Year Measured Term Contract for gutter cleaning, roof inspection services and roof safety system maintenance with a suitably experienced and qualified Contractor. The Contract is intended to commence in February 2023 and will operate for three years at an estimated annual cost of 30000 GBP excluding VAT. Subject to satisfactory performance of the Contract, the duration of the Contract may be extended by twelve month increments for a further three years up to a maximum term of six years from the date of commencement.

description: Govan, Ibrox, Elderpark and Kinning Park, Glasgow

title: Three Year Measured Term Contract for Gutter Cleaning, Roof Inspection Services and Roof Safety System Testing

description: The Three Year Measured Term Contract will involve gutter cleaning maintenance, roof inspection services and roof safety system testing throughout the Govan, Ibrox, Elderpark and Kinning Park areas of Glasgow.

title: Document A

title: Document B

title: Document C

title: Document D

title: Document E

format: application/msword

title: Document F

title: Document G

title: Document H

title: Document I

title: Document J

title: Document K

description: 2026 at the earliest if the optional extensions to the contract period are not applied

performanceTerms:
The performance of the successful Bidder will be monitored through the Key Performance Indicators described within Tender Document H Key Performance Indicators attached to this Contract Notice.
 Where performance falls below the minimum acceptable level during the Contract, the successful Bidder will be required to produce a Remedial Plan for the approval of Elderpark Housing Association.
 Failure to produce a Remedial Plan or implement an approved Remedial Plan will be deemed to be a breach of the Contract, which may lead to the termination of the successful Bidder's Contract.

description: 4A.2 - Where it is required, within a bidder’s country of establishment they must confirm which authorisation or memberships of the relevant organisation(s) are required in order to perform this service. Bidders must confirm if they hold the particular authorisation or memberships.

description:
Question 4B.1.1 - Bidders will be required to have a minimum 'general' yearly turnover of 60000 GBP for the last three years.
 Question 4B.1.2 - Bidders will be required to have an average yearly turnover of a minimum of 60000 GBP for the last three years.
 Question 4B.3 - Where turnover information is not available for the time period requested, the bidder will be required to state the date which they were set up or started trading.
 Questions 4B.5.1 and 4B.5.2 - It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurances indicated below:
 Employer's (Compulsory) Liability Insurance - 10,000,000 GBP Public Liability Insurance - 10,000,000 GBP

description:
4C.8.1 - Bidders will be required to confirm their average annual manpower for the last three years.
 4C.8.2 - Bidders will be required to confirm their and the number of managerial staff for the last three years.
 4C.9 - Bidders will be required to demonstrate that they have (or have access to) the relevant tools, plant or technical equipment to deliver the types of requirements detailed in II.2.4 in the Find a Tender Service Contract Notice or the relevant section of the Site Notice.
 4C.10 - Bidders will be required to confirm whether they intend to subcontract and, if so, for what proportion of the contract.
 SPD (Scotland), Part C Technical and Professional Ability - Bidders responses to Part C of the SPD (Scotland) will be limited to a maximum of fifteen A4 single sided pages, excluding any certification that a Bidder submits in support of their response, which must be completed in English using Arial 11 font

Elderpark Housing Association Limited

postalCode: G51 3AX

streetAddress: 65 Golspie Street

description: Housing and community amenities

legalName: Elderpark Housing Association Limited

A.D.A Construction Consultants Ltd

locality: Paisley

postalCode: PA3 3BB

streetAddress: Pavilion 3, St James Business Park, Linwood Road

name: Glasgow Sherriff Court and Justice of the Peace Court

Elderpark Housing Association Limited

description: Housing and community amenities

Paterson Safety Anchors Ltd

locality: Barrhead

postalCode: G78 1QB

streetAddress: Anchor House, 18 Muriel Street

legalName: Paterson Safety Anchors Ltd

description: (SC Ref:782371)


description: Procurement of consultancy services for specialist ground investigation services.

title: PKC12146 Phase 2 Study - Ground Investigation

description: Appointment of a consultant to undertake ground investigation works to analyse imported waste materials at a site in the Perth & Kinross Council area.

procurementMethodRationale: A number of companies were contacted through a compliant route to market but they showed no interest due to the nature of the site, timescales and value. An alternative supplier was sought directly.

description: The works, supplies or services can be provided only by a particular economic operator due to absence of competition for technical reasons

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

description: General public services

legalName: Perth & Kinross Council

Millard Consulting

postalCode: DD1 4QB

streetAddress: Seabraes House, 18 Greenmarket

legalName: Millard Consulting

Perth Sheriff Court

streetAddress: Tay Street

legalName: Perth Sheriff Court

description:
Value is estimated due to nature of the requirement.
 (SC Ref:719381)


title: Taxi Vehicle up to 8 seats

title: Accessible vehicles (1-4 wheelchairs)

name: Bodyshop Edinburgh T/A Coach Hire Edinburgh

title: Minibus (9-17 seats)

title: Taxi Vehicle up to 8 seats

description: Notice of contracts awarded from the Scottish Borders CPP Transport DPS - October 2022 to December 2022

title: Accessible vehicles (1-4 wheelchairs)

title: Minibus (9-17 seats)

title: Notice of contracts awarded from the Scottish Borders CPP Transport DPS - October to December 2022

description: Quarterly Notice of contracts awarded from the Scottish Borders CPP Sustainable Transport DPS - October 2022 to December 2022

Scottish Borders Council

locality: Newtown St Boswells

postalCode: TD6 0SA

streetAddress: Council Headquarters

description: General public services

legalName: Scottish Borders Council

Hawick Taxis

locality: Hawick

streetAddress: 25, Galalaw Road

legalName: Hawick Taxis

barc travel

locality: walkerburn

postalCode: eh43 6hg

streetAddress: galashiels road, walkerburn

legalName: barc travel

Neils cabs

locality: galashiels

streetAddress: 11 broom drive

legalName: Neils cabs

locality: East Calder

postalCode: EH27 8DF

streetAddress: Unit 18, Camps Ind Est

Dom's Taxis

postalCode: TD9 8EQ

streetAddress: 20 Kenilworth Avenue

legalName: Dom's Taxis

Peter Hogg of Jedburgh

locality: Jedburgh

postalCode: TD8 6ED

streetAddress: Taxi Yard, Bankend Industrial Estate

legalName: Peter Hogg of Jedburgh

Telford's Coaches Ltd

locality: NEWCASTLETON

postalCode: TD9 0QA

streetAddress: Tweeden Brae

legalName: Telford's Coaches Ltd

name: Jedburgh Sheriff Court and Justice of the Peace Court

postalCode: TD8 6AR

streetAddress: Sheriff Court House, Castlegate

title: Taxi Vehicle up to 8 seats

title: Accessible vehicles (1-4 wheelchairs)

title: Minibus (9-17 seats)

description:
Award against framework: Scottish Borders Community Planning Partnership Sustainable Transport DPS
 Award against framework: Scottish Borders Community Planning Partnership Sustainable Transport DPS
 Lot 1 Taxi vehicle up to 8 seats additional information:
 - Langlee Cabs
 - Westend Taxi's
 (SC Ref:719414)


description: Potential for futureproofing via additional licenses

description:
The roster management system is utilised by approximately 3600 operational employees throughout the whole of SFRS and is a key system to ensuring that every shift has the appropriate number of personnel and skills on duty to crew appliances. The Service is in the process of finalising its specification prior to commencing competition for a new service. In the interim, there is a critical need to continue with the support and maintenance of the current duty system until such time as a new system has been
 procured and implemented to ensure operational effectiveness.. Maximum value over the three year period is anticipated to be no more than 220000 GBP

description: across Scotland

title: Roster Management System Support and Maintenance including the provision of potential additional licenses

description: Support and Maintenance relating to a 5-watch Duty Roster Management System including the provision of potential additional licenses.

reviewDetails: The Scottish Fire and Rescue Service (the Service) must, by notice in writing as soon as possible after the decision has been made, inform all tenderers and candidates of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing system. The Service will incorporate a minimum 10 calendar day standstill at the point information on the contract award is communicated to tenderers. The Service is obliged to comply with the regulations and any eligible economic operator can bring an action in the Sherriff Court or the Court of Session where as a consequence of a breach by the Service, they suffer or risk suffering loss or damage. The bringing of court proceedings during the standstill period means that the SFRS must not enter into the contract, conclude the framework agreement or establish the dynamic purchasing system unless the proceedings are determined, discontinued or disposed of: or the court, by interim order, brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and the remedies that are available to the courts are detailed in the Regulations.

procurementMethodRationale:
The roster management system is utilised by approximately 3600 operational employees throughout the whole of the Service and is a key system to ensuring that every shift has the appropriate number of personnel and skills on duty to crew appliances. The Service is now finalising its requirements in relation to a new Duty Management system with the view to commencing competition within the next three months. In the interim, there is a critical need to continue with the support and maintenance of the current duty system until such time as a new system has been
 procured and implemented to ensure operational effectiveness.

description: The procurement falls outside the scope of application of the directive

Scottish Fire and Rescue Service

locality: Cambuslang

postalCode: G72 7NA

streetAddress: Headquarters, Westburn Drive

description: Public order and safety

legalName: Scottish Fire and Rescue Service

UKG - Ultimate Kronos Group

locality: Bracknell

postalCode: RG12 8FZ

streetAddress: The Capitol Building,  RG12 8FZ

legalName: UKG - Ultimate Kronos Group

Scottish Fire and Rescue Service

description: Public order and safety

postalCode: G5 9TW

legalName: Glasgow Sheriff Court and Justice of the Peace Court

description: (SC Ref:739174)


status: unsuccessful

statusDetails: discontinued

status: cancelled

description:
University of St Andrews – Estates: Main Contractor for Student Accommodation at Gap Site 3 North Haugh
 The University of St Andrews has committed to increase their residential capacity and improve the quality and range of accommodation available for students. This plan will fulfil a commitment to the town that wherever possible, the University will provide modern, university-managed accommodation for students to reduce the pressure on the private housing market within St Andrews.
 Gap Site 3 is a single new-build project within a development programme, which will create 155 No. additional bedrooms at the North Haugh, St Andrews. Gap Site 3 has been designed to build upon the success of the recently developed residences, Powell Hall and Whitehorn Hall. Gap Site 3 will utilise an established high-quality bedroom design and incorporate successful communal and social design elements, to ensure a strong sense of community within the new building. Securing BREEAM “Excellent” and an EPC Rating “A” are key components of the Brief.
 The site is vacant and located between Agnes Blackadder Hall and Andrew Melville Hall. Planning Consent was granted by Fife Council during February 2022.
 The primary structure is proposed to be a concrete frame and the building will primarily take heat from the existing district heating network with an electric back-up system.
 The building is to be delivered using a single-stage design and build method and practical completion of the Works is targeted during May 2025. This approach will facilitate the University’s bedding-in period during Summer 2025, prior to student occupation during September 2025. Careful consideration of the construction methodology will be key as the Works will be undertaken within a live campus environment.
 The estimated cost of construction is 18M GBP.
 The development and funding strategy is currently being considered by the University. The University of St Andrews may therefore not be the contracting entity.. All tenders for the University of St Andrews are administered through our eTendering System (InTend).To Express an Interest please go to our tender website at https://intendhost.co.uk/universityofstandrews
 Please note that 'Notes of Interest' placed via PCS (Public Contracts Scotland) are not automatically accepted

description: Please see SPD Documents.

description: UK - St Andrews

description: Main Contractor for Student Accommodation at Gap Site 3, North Haugh, University of St Andrews.

reviewDetails:
The University of St Andrews will incorporate a minimum of 10 calendar day standstill period at the point of information on the award of the contract being communicated to tenderers. This period allows unsuccessful tenderers to seek further debriefing from the contracting authority before the contract is entered into. Applicants have 2 working days from the notification of the award decision to request additional debriefing and that information has to be provided a minimum of 3 working days before the expiry of the standstill period. Such additional information should be requested from The University of St Andrews.
 If an appeal regarding the award of contract has not been successfully resolved The Public Contracts (Scotland) Regulations 2012 provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rule to take action in the Sheriff Court or Court of Session.
 The anticipated review body in such cases would be:
 Dundee Sheriff Court
 6 West Bell Street
 Dundee
 DD1 9AD
 Telephone: +44 1382 229 961
 Anyone bringing court proceedings against the University of St Andrews must inform the University of St Andrews in advance of the alleged breach and its intention to bring proceedings. Any such action must be brought within 15 days of the date on which a decision is sent to them or published to challenge that decision.
 Proceedings seeking an ineffectiveness order must be brought within 30 days of the publication of the contract award notice in the OJEU, or 30 days from the date of a decision letter to all tenderers concerned, and any candidates concerned, containing a summary of the reason for the recipient being unsuccessful, otherwise 6 months from the date of entering into the contract or concluding the framework agreement.
 Where a contract has not been entered into the Court may, by interim order, suspend the procurement procedure. The court may also set aside a decision or actions taken by the University or order it to amend and document; and/or award damages. However, by express requirement the court may decide not to grant an interim order when the negative consequences of such an order are likely to outweigh the benefits, having regard to a number of considerations.
 If the contract has been entered into the Court may, depending on the nature of the breach: make an ineffectiveness order; impose a financial penalty; shorten the duration of the contract; make any other order considered appropriate to address the consequences of ineffectiveness or shortening the duration or the contract; award damages.

procurementMethod: selective

description: Please see SPD Documents.

procurementMethodDetails: Restricted procedure

University of St Andrews

locality: Guardbridge

postalCode: KY16 0US

streetAddress: Walter Bower House, Eden Campus

description: Education

legalName: University of St Andrews

Dundee Sheriff Court

locality: Dundee

postalCode: DD1 9AD

streetAddress: 6 West Bell Street

legalName: Dundee Sheriff Court

University of St Andrews

locality: St Andrews

postalCode: KY16 9LB

streetAddress: The Old Burgh School, Abbey Walk

description: Education

description:
All tenders for the University of St Andrews are administered through our eTendering System (InTend).To Express an Interest please go to our tender website at https://intendhost.co.uk/universityofstandrews
 Please note that 'Notes of Interest' placed via PCS (Public Contracts Scotland) are not automatically accepted
 (SC Ref:728296)


description: The contract may be extended for a period of up to a further 12 months

description:
The day care support service is designed for older adults, primarily 65 and over, whom following an outcome based "All About Me: What I Need" assessment, have been identified as having needs which are critical or substantial.
 The centre-based service is for older adults living in their own homes, alone or with family, or in sheltered/supported housing settings. The service will provide a person-centred, outcome focused approach through the care and support provided, i.e. quality care which is tailored to individual needs and outcomes. The service will provide care and support which enables individuals to have as good a quality of life as possible by providing meaningful activities, learning opportunities, socialisation, encouraging independence and reablement in order that they can remain as active as possible for as long as possible. The day support service will support the individuals physical and mental health and well-being through a reduction in social isolation and community involvement and engage older people in their local community by providing places in which to socialise, learn or re-learn skills for daily living.
 Those using the service will have a voice in how it is run and which activities are offered. The service will be run by qualified, dedicated and experienced staff, supported by trained volunteers. The service will offer mental stimulation and physical activity sessions suitable for varied abilities and interests, at a level appropriate to the needs of the individual.
 The following is a list of meaningful activity examples which is not exhaustive: Art and craft therapy, seated exercise, music, singing, quizzes, falls prevention, reminiscence sessions, digital engagement, interactive games, music, outings, entertainment, game shows, nail care/manicure, relaxation therapies, reading, discussion groups, gardening, music and movement, musical instruments, outings, individual and group activities.
 Nutritionally balanced meals and snacks will be provided, with individual dietary, religious and cultural needs catered for.
 The day support service shall include working with and assisting the Service User to achieve their activities of daily living. The list includes but is not exhaustive: -
 Assistance/support with maintaining personal hygiene ;
 Addressing continence needs and assisting with continence management including necessary cleaning and safe disposal of waste;
 Support with eating and drinking, including food and/or drink preparation;
 Prompting, supporting or administering non-invasive prescribed medication with parameters defined by WLHSCP approved Medication Management Policy ;
 Achieving maximum mobility, using appropriate equipment where necessary ; and
 Support with managing behaviours which challenge.
 Following a social work assessment, unpaid carers will be supported to help sustain their caring role which may involve an additional day for the individual to attend day support services to offer the carer respite. The specific days and times which the Service will operate will be agreed in the individual service contracts. Whist WLHSCP provides day care in locations across the authority, with service users concentrated in Livingston and considering travelling issues the Building will be required to be located in Livingston.
 The following mandatory criteria must be met :
 Registered with the Care Inspectorate as a Provider of Support Services (not Care at Home) ;
 Adhere to the requirements of the Scottish Social Services Council (SSSC) or other appropriate regulatory body ;
 Provide an accessible and safe building from which to deliver the service, which meets all appropriate legislative and regulatory standards.

description: Livingston

title: Older Peoples Day Care Support Services

title: Older Peoples Day Care Support Services

description:
The day care support service will support the individuals physical and mental health and well-being through a reduction in social isolation and community involvement and engage older people in their local community by providing places in which to socialise, learn or re-learn skills for daily living.
 There is a requirement for the building to be based in Livingston.

title: Older Peoples Day Care Support Services

performanceTerms: Bidders are required to meet and comply with the requirements of the specification.

description:
RE ESPD Q4B.6; West Lothian Council will use Dun and Bradstreet DBAi financial reporting system to assess the financial stability of tenderers. Tenderers with a Failure Score of 50 or above on the DBAi system will be deemed to have evidence satisfactory financial stability. Please note that 49 or less will not be considered as having met this criteria. If a tenderer has a Failure Score of less than 50, the tenderer may be required to submit their last three years accounts.
 In the event that the tenderer is not required to publish accounts and therefore does not have a Dun & Bradstreet or equivalent rating, tenderers should be able to provide financial accounts when requested. The council will then conduct an analysis of the accounts to ensure that there is no significant financial risk. Please note that if you intend on attaching 2 years accounts, these must include financial data over a 3-year period.
 It is recommended that candidates review their own Dun & Bradstreet Score in advance of submitting their tender. If following this review tenderers consider that the Dun & Bradstreet Score does not reflect their current financial status, details of this should be provided, complete with evidence of a good high street credit rating (the equivalent of Dun & Bradstreet score 50) from a recognised credit referencing agency. The council will review any such information as part of the evaluation of Tenderer’s financial status.
 In the event that a firm does not meet the financial criteria for consideration but has a parent company that does, the firm may still be eligible for consideration where their Tender Submission is supported by a Parent Company Guarantee.
 Re ESPD Q4B.5.1a&b; It is a requirement of this contract that bidders hold, or can commit to obtain prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 Employers Liability 5,000,000 GBP (Five Million GBP)
 Public liability 5,000,000 GBP (Five Million GBP)
 Motor Insurance 5,000,000 GBP (Five Million GBP) TPI&D (specifically covering business use and the transportation of passengers for hire/reward

description: RE ESPD Q4C1.2; Bidders will be required to provide examples in the last 3 years that demonstrate that they have the relevant experience to deliver the services as described in part II.2.4 of the Find a Tender Service Contract Notice or the relevant section of the Site Notice. These will be scored on a pass/fail basis.

West Lothian Council

locality: Livingston

postalCode: EH54 6FF

streetAddress: West Lothian Civic Centre, Howden South Road

description: General public services

legalName: West Lothian Council

name: Livingston Sheriff Court and Justice of the Peace Court

streetAddress: Howden South Road

description: General public services

Braid House Day Centre Ltd

postalCode: EH54 6BU

streetAddress: 1a Labrador Avenue, Howden

legalName: Braid House Day Centre Ltd

description: (SC Ref:729050)


description: In response to Audit Scotland's recommendations that the Scottish Government "learn lessons from its experience of recent financial interventions in private companies", external advisors are required to complete an outcome evaluation of Scottish Government's 2017 intervention of BiFab (Project Harris).

title: Evaluation of Project Harris - Lessons Learned on BiFab

Scottish Government

locality: Glasgow

postalCode: G2 8EA

streetAddress: 4 Atlantic Quay, 70 York St

description: General public services

legalName: Scottish Government

Ernst & Young

postalCode: G2 1DY

streetAddress: G1 Building, 5 George Square

legalName: Ernst & Young

Glasgow Sheriff Court

postalCode: G5 9DA

streetAddress: PO Box 23, 1 Carlton Place

legalName: Glasgow Sheriff Court

awardID: Case 02

description:
Award against framework: Framework for the Provision of Commercial Advisors
 (SC Ref:719543)


description: Window and Door Replacement

description: Jubilee Park, Letham

title: Window Replacment, Jubilee Park

title: Window Replacment, Jubilee Park

description: Window and Door Replacement to 16 nr properties and associated remedial works

title: Tender document

title: Drawings

title: general summary

title: Bill No. 1

title: Bill No. 2

title: Instruction to tenderer's

title: SPD

title: PCI

title: Window Replacment, Jubilee Park

description: Refer to procurement documents

minimum:
Employers Liability Insurance 5m GBP
 Public Liability Insurance 5m GBP
 Contractors All Risks Insurance 1m GBP
 State the value(s) for the following financial ratio(s) for each of the last 3 years:
 Current Ratio (Current Assets/Current Liabilities)
 Total net Assets/(Liabilities)
 The acceptable range for each financial ratio is:
 Current Ratio - minimum of 1
 Total Net Assets/(Liabilities) must be positive i.e. a Net Assets position

description:
Economic and financial standing
 Insurance held
 Financial ratios
 (Refer also to procurement documents)

Brownriggs

locality: Stirling

postalCode: FK9 4NF

streetAddress: Unit 16 Scion House, Stirling University Innovation Park

legalName: Brownriggs

Forfar Sheriff Court

locality: Forfar

legalName: Forfar Sheriff Court

Mike Watt Construction

locality: Kirriemuir

postalCode: DD8 4PB

streetAddress: Hillhead Business Park, Cortachy Road

legalName: Mike Watt Construction

description: (SC Ref:729101)


description: Procurement of 2 servers compatible with the Perth & Kinross Council estate plus storage array.

title: PKC12149 Supply of 2 Servers and storage (LAL)

description: Supply of 2 x Servers and storage array compatible with the Council estate. Servers to have 7 years Enhanced Pro Support warranty terms and next business day (NBD) response level.

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

description: General public services

legalName: Perth & Kinross Council

Dell Corporation Ltd

region: UKI

locality: London

postalCode: EC3A 5AF

streetAddress: 1st & 2nd Floor One , Creechurch Place

legalName: Dell Corporation Ltd

Perth Sheriff Court

streetAddress: Tay Street

legalName: Perth Sheriff Court

description:
Award against framework: NHS SBS Digital Workplace Solutions SBS/19/AB/WAB/9411
 (SC Ref:719596)


title: Heavy Goods Vehicles exceeding 7.5 tonnes

description: Roadside repair and recovery of broken down and damaged Heavy Goods Vehicles exceeding 7.5tonnes. The Contractor will provide sufficient Recovery Operators to be able to attend the scene of a recovery anywhere in the Council area normally within 30 minutes in respect of light vehicle recovery and one hour for heavy vehicle recoveries of being notified unless there are exceptional circumstances causing a delay, e.g., severe weather conditions or geographical area.

title: Plant including containers and trams

description: Roadside repair and recovery of broken down or damaged plant including trams. The Contractor will provide sufficient Recovery Operators to be able to attend the scene of a recovery anywhere in the Council area normally within 30 minutes in respect of light vehicle recovery and one hour for heavy vehicle recoveries of being notified unless there are exceptional circumstances causing a delay, e.g., severe weather conditions or geographical area.

title: Cars and Vans(including cars small trailers, small and medium vans up to 3.5 tonnes

description: with two optional 12-month extensions (2 + 1 + 1), undertaken at the sole discretion of the Council.

description: Roadside repair and recovery of broken down and damaged Cars and vans including cars, small trailers, small and medium vans up to 3.5tonnes. The Contractor will provide sufficient Recovery Operators to be able to attend the scene of a recovery anywhere in the Council area normally within 30 minutes in respect of light vehicle recovery and one hour for heavy vehicle recoveries of being notified unless there are exceptional circumstances causing a delay, e.g., severe weather conditions or geographical area.

title: Light Goods Vehicles (including buses) up to 7.5 tonnes

description: Roadside repair and recovery of broken down or damaged light goods vehicles including all buses up to 7.5tonnes. The Contractor will provide sufficient Recovery Operators to be able to attend the scene of a recovery anywhere in the Council area normally within 30 minutes in respect of light vehicle recovery and one hour for heavy vehicle recoveries of being notified unless there are exceptional circumstances causing a delay, e.g., severe weather conditions or geographical area.

description: within the City of Edinburgh Boundaries

description: within the City of Edinburgh Boundaries

description: Within the City of Edinburgh Boundaries.

description: within the City of Edinburgh Boundaries

title: Vehicle Recovery and Repair Framework Agreement

description:
The Fleet and Workshop Services supply the maintenance provision for the Councils fleet of vehicles. It has been identified that roadside repair, recovery of broken down, or damage vehicles are to be placed onto a new Framework Agreement. The majority of these call outs will be for Heavy Goods Vehicles (HGVs) however the fleet is varied, and special consideration will need to be given to our minibus fleet, that carries vulnerable adults, and children.
 Geographical Range will be within the City of Edinburgh Boundaries: Kirkliston, Ratho, South Queensferry, Joppa, up to and including the City Bypass, Balerno round to Hatton, there may be times when vehicles are out with these areas, these will be covered as well.

title: ITT Documentation

awardCriteriaDetails:
The Framework Agreement will consist of a maximum of four Service Providers per lot. The Service Provider with the lowest fixed hourly rate will be called off first to provide the full range of required services; however, if it is found that further resources are required (or the first supplier is unable fulfil the requirement in its entirety) the second lowest fixed hourly rate Service Provider on the Framework Agreement will be called off to provide the short fall and so on. There is a caveat that the Framework Agreement does not guarantee work.
 Service Providers will be required and must be able to provide a service seven days a week, including during local and national holidays.

performanceTerms: as per the tender specification

reviewDetails: A tenderer that suffers loss as a result of a breach of duty under the Public Contracts (Scotland) Regulations 2015 may bring proceedings in the Sheriff Court or the Court of Session. The City of Edinburgh Council (the Council) will have a minimum standstill period of 10 days before awarding the contract. The communication of the award decision notice will be sent by fax or e-mail to all tenderers with the standstill period commencing on the next day. If proceedings are started in the Sheriff Court or the Court of Session against the Council in respect of the decision to award the contract within the standstill period then the Council is prevented from awarding the contract. Post contract award the Sheriff Court or the Court of Session may (1) award damages provided proceedings are brought within 3 months from the date when the grounds for the bringing of the proceedings first arose (2) be entitled to issue an ineffectiveness order or impose a financial penalty on the Council. A claim for an ineffectiveness order must be made within 30 days of the Contract Award Notice being published in the FTS or within 30 days of the date those who expressed an interest in or otherwise bid for the contract were informed of the conclusion of the contract or in any other case within 6 months from the date on which the contract was entered into.

minimum:
Part IV: Selection criteria - B: Economic and financial standing – Question 4B1a - Tenderers are required to have the following minimum
 “general” annual turnover for the last two financial years:
 a minimum “general” annual turnover of GBP 100,000
 Where a Tenderer does not have an annual turnover of this value, the Council may exclude the Tenderer from the competition or may apply
 discretion seeking supporting evidence to determine the Tenderer’s suitability to proceed in the competition.
 Part IV: Selection criteria - B: Economic and financial standing – Question 4B4 - Tenderers will be required provide the following
 information in response to 4B4
 For Lots 1-4
 Current ratio for Current Year: 1.10
 Current ratio for Prior Year: 1.10
 The formula for calculating a Tenderer’s current ratio is current assets divided by current liabilities. The acceptable range for each financial
 ratio is greater than the requested current ratio. Where a Tenderer’s current ratio is less than the acceptable value, the Council may exclude
 the Tenderer from the competition or may apply discretion seeking supporting evidence to determine the Tenderer’s suitability to proceed in the competition.
 Part IV: Selection criteria - B: Economic and financial standing – Question 4B5b & 4B5c - Tenderers are required to hold, or commit to
 obtaining prior to the commencement of any subsequently awarded contract, the types and levels of insurance indicated below:
 a. Employers (Compulsory) Liability Insurance - GBP 5m
 b. Public Liability Insurance - GBP 10m
 c. Comprehensive Motor Insurance-GBP 5m
 Where a Tenderer does not hold or commit to obtaining the types and levels of insurance indicated, the Council will exclude the Tenderer
 from the competition.

description: This Section refers to Section B of Part IV of the SPD (Scotland).

The City of Edinburgh Council

locality: Edinburgh

postalCode: EH8 8BG

streetAddress: Waverley Court, 4 East Market Street

description: General public services

legalName: The City of Edinburgh Council

Sherriff Court

postalCode: EH1 1LB

streetAddress: Sherriff Court House, 27 Chambers Street

legalName: Sherriff Court

The City of Edinburgh Council

description: General public services

description:
The Selection Criteria & Exclusion grounds assessment will be based on the answers provided in response to the SPD. The following SPD
 questions must be answered by tenderers noting the relating Statement of Requirements as per Appendix 2 in the Instructions to Tenderers:
 Parts I, II and III: All questions
 Part IV B:Questions 4B1a,4B4, 4B5b and 4B5c
 Part IV D: Question 4D1
 It is a mandatory requirement of this Framework Agreement that a prompt payment clause is present in all supply chain Contracts used in the delivery of the requirements. This ensures payment of sub-contractors at all stages of the supply chain within 30 days and includes an obligation to provide a point of contact for sub-contractors to refer to in the case of payment difficulties. This will require active monitoring of payment performance as well as the provision of evidence and reports to the Council on request or as contractually scheduled
 (SC Ref:728600)


description: Bield housing and care is seeking to appoint a Scotland wide supplier for Domestic care and kitchen PPE.

title: Award of Bield Housing and Care Domestic Personal Protective Equipment

description: Protective and safety clothing

Mapleton Consulting Ltd

postalCode: G61 4RR

streetAddress: 27 Abercrombie Drive

Scottish Government

roles: reviewBody buyer

description: General public services

Lamdk Ltd

postalCode: N1 7GU

Venesky Brown Ltd

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road SASA

Duke Electrical Services Ltd

locality: Barnham

postalCode: PO22 0AD

streetAddress: Pollards Nursery

Scottish Qualifications Authority

locality: Midlothian

postalCode: EH22 1FD

streetAddress: Lowden, 24 Wester Shawfair

Page Bros (Norwich) Ltd

locality: Norwich

postalCode: NR6 6SA

streetAddress: Mile Cross Lane

Forestry and Land Scotland

locality: Inverness

postalCode: IV3 8NW

streetAddress: Great Glen House, Leachkin Road

description: Environmental protection

legalName: Forestry and Land Scotland

Murray Peat Contracting

locality: Lairg

postalCode: IV27 4BA

streetAddress: 32 Ord Place

name: Compass Building & Construction Services

postalCode: IV2 3TP

streetAddress: Corrie Lodge Business Centre

Stirling Council

postalCode: FK7 7QA

streetAddress: Teith House: 55, M8. Kerse Rd, Stirling

description: General public services

legalName: Stirling Council

Sportex Group

locality: Grangemouth

postalCode: FK3 9UX

streetAddress: 13-17 Abbotsinch Road

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House

Alex F Noble & Son Nissan

postalCode: EH20 9FB

streetAddress: Swinton Place, Straiton

dunnydeerservices ltd

locality: scotland

streetAddress: dunnydeer home farm insch

NHS Ayrshire & Arran

locality: Ayr

postalCode: KA6 6AB

streetAddress: Eglinton House, Ailsa Hospital

Healios Limited

postalCode: N7 9AH

streetAddress: Unit 4A Tileyard

Consumer Scotland

postalCode: EH8 7AU

streetAddress: Meadowbank House

Collaborate Research

postalCode: SW17 8DL

streetAddress: 28 Moring Road

Everwarm Ltd

locality: West Lothian

postalCode: EH48 2EE

streetAddress: 3 Inchcorse Place

Duncan Wemyss Ltd

locality: Ardgay

postalCode: IV24 3BL

streetAddress: 12 Manse Road

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

name: Prime Industrial & Janitorial Supplies Ltd

locality: Dunfermline

postalCode: KY11 8QF

streetAddress: 3 George Square

DATASEC

locality: Montevideo

streetAddress: Patria 716, Esquina Av. Sarmiento

Critiqom Limited (trading as Adare SEC)

locality: Bellshill

postalCode: ML4 3NJ

streetAddress: Document House

CGF Services

locality: Dumfriesshire

streetAddress: 1 Barras Croft

Highlands and Islands Enterprise

postalCode: IV2 5NA

streetAddress: An Lòchran

Marsh Limited

postalCode: EC3R 5BU

streetAddress: 1 Tower Place West

Scottish Enterprise

postalCode: G2 6HQ

Moray Council

description: General public services

The Highland Council

name: Quantity Surveying Section - Housing & Property Services

University of Glasgow

description: Education

East Lothian Council

description: General public services

name: University Court of the University of Glasgow

University of Stirling

streetAddress: Procurement Services, Finance Office, Room 3Z3, Cottrell Building

description: Education


description: There is an option to procure additional professional services days during the contract term as required for any upgrades, advice or changes required to the solution. The value of this option is up to 50% of the original contract value.

description: This is a contract award notice for a call-off from the Scottish Government Managed Print Solutions Framework SP-21-046. It is for the renewal of existing Kofax Scanning software with support and maintenance by the Crown Office and Procurator Fiscal Service. The solution is integrated with the with Multi Functional Devices and Scanners currently leased under a separate contract.

title: Kofax Scanning Software

title: Kofax Scanning Software

postalCode: EH1 1LB

streetAddress: 25 Chambers Street

description: Social protection

Ricoh UK Ltd.

locality: Northampton

postalCode: NN4 7YL

streetAddress: 800 Pavilion Drive, Northampton Business Park

legalName: Ricoh UK Ltd.

Sheriff Clerk's Office

locality: Glasgow

postalCode: G5 9DA

streetAddress: PO Box 23, 1 Carlton Place

legalName: Sheriff Clerk's Office

description:
Award against framework: Scottish Government Managed Print Solutions SP-21-046
 (SC Ref:719631)


title: Supply of Air Compressor for NIBF2

title: Supply of Air Compressor for NIBF1

title: Supply of Air Compressor for NIBF2

description: Framework for Supply and Installation of Air Compressors as detailed within specification

title: Supply of Air Compressor for NIBF1

description: Framework for Supply and Installation of Air Compressors for scope as detailed within provided specification

region: UKC

title: 2740 - Framework for Supply and Installation of Air Compressors

title: Tender Pack

Centre for Process Innovation Limited

locality: Redcar

postalCode: TS10 4RF

streetAddress: Wilton Centre

legalName: Centre for Process Innovation Limited

postalCode: G5 9TW

legalName: Glasgow Sheriff Court and Justice of the Peace Court

Wearside Pneumatics Ltd

locality: Gateshead

postalCode: NE11 0NH

streetAddress: 311B Foster Court, Team Valley

legalName: Wearside Pneumatics Ltd

postalCode: G2 9DA

streetAddress: PO Box 23 1 Carlton Place

title: Supply of Air Compressor for NIBF2

title: Supply of Air Compressor for NIBF1

description: (SC Ref:731475)


statusDetails: unsuccessful

description: Falkirk Council Area

description: Falkirk Council Area

description: Falkirk

description: Falkirk Council Area

title: Supply, Delivery and/or Installation of Shower Trays and Slip Resistant Flooring to Falkirk Council Housing Properties

description:
The Council propose to enter into a Framework Agreement for the Supply, Delivery and/or Installation of Shower Trays and Slip Resistant Flooring to various locations within the Falkirk Council Area.
 The Framework Agreement will be awarded on a Lot by Lot basis. The Authority at all times reserves the right to award all, some, part or none of the Lots. The framework consists of 4 Lots; it is intended that up to 5 Contractors per Lot are to be appointed.
 Lots -
 Lot 1 Supply and Delivery of Shower Trays, Shower Pumps and Doors, inc Site Survey
 approximate framework term Lot Value GBP 80 000 (2%)
 Lot 2 Supply and Delivery of Shower Trays with Integral Shower Pumps and Doors, inc Site Survey
 approximate framework term Lot Value GBP 40 000 (1%)
 Lot 3 Supply and Installation of Shower Trays, Doors, Gulley Floors and Associated Bathroom Works, inc Site Survey
 approximate framework term Lot Value GBP 3 880 000 (85%)
 Lot 4 Supply and Installation of Slip Resistant Flooring, inc Site Survey
 approximate framework term Lot Value GBP 560 000 (12%)
 Approximate total Contract Value GBP 4 560 000

title: TCC02123 Shower Trays Slip Resistant Flooring ITT

title: TCC02123 Appendix A Pricing Schedule

title: TCC02123 Appendix B Certifications Summary

title: TCC02123 Appendix C Boundary Map of Falkirk Area

title: TCC02123 Document 1 Compliance Schedule

title: TCC02123 Document 2 Account Management Details

title: TCC02123 Document 3 Framework Agreement (multi party)

title: Fair Work First QA5

title: Fair Work First QB5

title: Fair Work First QC5

title: Fair Work First QD5

title: SPD (Scotland) Standardised Statements v1.1

description:
The Council Framework Agreement for the Supply, Delivery and/or Installation of Shower Trays and Slip Resistant Flooring to various locations within the Falkirk Council Area.
 The Framework Agreement will be awarded on a Lot by Lot basis. The Authority at all times reserves the right to award all, some, part or none of the Lots. The framework consists of 4 Lots; it is intended that up to 5 Contractors per Lot are to be appointed.
 Lots -
 Lot 1 Supply and Delivery of Shower Trays, Shower Pumps and Doors, inc Site Survey
 Lot 2 Supply and Delivery of Shower Trays with Integral Shower Pumps and Doors, inc Site Survey
 Lot 3 Supply and Installation of Shower Trays, Doors, Gulley Floors and Associated Bathroom Works, inc Site Survey
 Lot 4 Supply and Installation of Slip Resistant Flooring, inc Site Survey

streetAddress: Falkirk

description: Tender Opening Committee comprising Council Procurement Adviser

description: April 2027

description: It is a requirement of this tender that if the Bidder is UK based they must hold a valid registration with Companies House. Where the Bidder is UK based but not registered at Companies House they must be able to verify to the Council’s satisfaction that they are trading from the address provided in the tender and under the Company name given.

minimum:
Public Contracts Regulations 2015 state that before awarding the contract, the Contracting Authority shall require the tenderer(s) to submit up to date supporting documents. This includes the insurance requirements stated in the Qualification Envelope (SPD within PCS):
 Employer’s (Compulsory) Liability Insurance = 10 000 000 GBP.
 Product and Public Liability Insurance = 10 000 000 GBP.
 Professional Indemnity Insurance = 2 000 000 GBP.
 Bidders who do not meet the criteria above may be excluded from further participation in this procurement exercise.

description:
The Selection Criteria is outlined in the online PCS Qualification Envelope (SPD):
 Bidders will be required to state the annual turnover of the bidding entity for the last 3 years.
 Where turnover information is not available for the time period requested, the bidder will be required to state the date on which they were set up / started trading.
 A Creditsafe credit scoring check will be ran on registered Company Name and Company Number provided by the bidder. Where the resulting Credit Rating score is less than 30/100, the Bidder may be excluded from the tender process unless suitable financial information is provided that give satisfactory assurances to the Council regarding financial risk in appointing the bidder to the proposed Framework.

minimum:
Any recorded fail shall result in your submission being non compliant and excluded from the process.
 For details of any relevant weighted scoring methodology elements for online SPD PCS module Section / Part 4D, and for ITT Award Criteria, including how each individual element is scored, please refer to Scoring of Submissions, scorecard system within ITT documentation.
 Exclusion: Economic operators may be excluded from this competition if they are in any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015. Please refer the ITT and related documentation on PCS.

description:
The Participant / Bidder must hold a UKAS (or equivalent), accredited independent third party certificate of compliance in accordance with ISO 45001:2018 (or equivalent) or have, within the last 12 months, successfully met the assessment requirements of a construction-related scheme in registered membership of the Safety Schemes in Procurement (SSIP) forum. As outlined in PCST Qualification Envelope (SPD) section 1.74.1
 OR
 The Participant / Bidder must provide responses in relation to 4D.1.4 A through to K in the document SPD (Scotland) Standard Statements v1.1

Falkirk Council

locality: Larbert

postalCode: FK5 4RU

streetAddress: 4 Central Park, Central Boulevard

description: Housing and community amenities

legalName: Falkirk Council

name: Falkirk Sheriff Court and Justice of the Peace Court

locality: Falkirk

postalCode: FK1 4AR

streetAddress: Sheriff Court House, Main Street, Camelon

description: Housing and community amenities

Adaptocare Limited

postalCode: G40 3DX

streetAddress: 244 Nuneaton Street

legalName: Adaptocare Limited

Nicholls & Clarke

locality: Romford

postalCode: RM8 1SP

streetAddress: 41-51 Freshwater Road

legalName: Nicholls & Clarke

General & Technical Flooring Servi

locality: Livingston

postalCode: EH54 8SH

streetAddress: Unit 3, Rankine Square, Deans Industrial Estate, Deans, Deans Industrial Estate, Deans

legalName: General & Technical Flooring Servi

LAWRIE (FURNISHINGS) LIMITED

locality: Inchinnan

postalCode: PA9 4RX

streetAddress: UNIT 4 Maritime Court, 8 Cartside Ave, 8 Cartside Ave

description:
Where required, scoring of Selection Criteria, including but not limited to Quality Assurance Schemes (SPD 4D) as outlined in the Qualification Envelope (SPD) on PCS, will be evaluated using the scorecard system detailed in the ITT document (Scoring of submissions).
 (SC Ref:746731)


description: Bield housing is seeking to appoint a supplier for kitchen and domestic janitorial products to our developments throughout Scotland via the Scotland Excel 12-18 Framework for Supply and Delivery ofJanitorial Products Lot 2

title: Award of Bield Housing and Care Janitorial Products

description: Cleaning products

Mapleton Consulting Ltd

postalCode: G61 4RR

streetAddress: 27 Abercrombie Drive

Scottish Government

description: General public services

legalName: Scottish Government

Lamdk Ltd

locality: London

postalCode: N1 7GU

Venesky Brown Ltd

locality: Edinburgh

postalCode: EH1 2AS

streetAddress: 4a Rutland Square

Scottish Government- SASA

postalCode: EH12 9FJ

streetAddress: 1 Roddinglaw Road SASA

Duke Electrical Services Ltd

locality: Barnham

postalCode: PO22 0AD

streetAddress: Pollards Nursery

Scottish Qualifications Authority

locality: Midlothian

postalCode: EH22 1FD

streetAddress: Lowden, 24 Wester Shawfair

Page Bros (Norwich) Ltd

locality: Norwich

postalCode: NR6 6SA

streetAddress: Mile Cross Lane

Forestry and Land Scotland

locality: Inverness

postalCode: IV3 8NW

streetAddress: Great Glen House, Leachkin Road

description: Environmental protection

Murray Peat Contracting

locality: Lairg

postalCode: IV27 4BA

streetAddress: 32 Ord Place

postalCode: IV2 3TP

streetAddress: Corrie Lodge Business Centre

Stirling Council

locality: Stirling

postalCode: FK7 7QA

streetAddress: Teith House: 55, M8. Kerse Rd, Stirling

description: General public services

Sportex Group

locality: Grangemouth

postalCode: FK3 9UX

streetAddress: 13-17 Abbotsinch Road

Fife Council

locality: Glenrothes

postalCode: KY7 5LT

streetAddress: Fife House

Alex F Noble & Son Nissan

postalCode: EH20 9FB

streetAddress: Swinton Place, Straiton

dunnydeerservices ltd

locality: scotland

streetAddress: dunnydeer home farm insch

NHS Ayrshire & Arran

postalCode: KA6 6AB

streetAddress: Eglinton House, Ailsa Hospital

Healios Limited

postalCode: N7 9AH

streetAddress: Unit 4A Tileyard

Consumer Scotland

postalCode: EH8 7AU

streetAddress: Meadowbank House

Collaborate Research

postalCode: SW17 8DL

streetAddress: 28 Moring Road

Perth & Kinross Council

locality: Perth

postalCode: PH1 5PH

streetAddress: 2 High Street

Everwarm Ltd

postalCode: EH48 2EE

streetAddress: 3 Inchcorse Place

Duncan Wemyss Ltd

postalCode: IV24 3BL

streetAddress: 12 Manse Road

Harvey Nash Limited

postalCode: EH1 3EG

streetAddress: Waverley Gate

postalCode: KY11 8QF

streetAddress: 3 George Square

DATASEC

streetAddress: Patria 716, Esquina Av. Sarmiento

Critiqom Limited (trading as Adare SEC)

postalCode: ML4 3NJ

streetAddress: Document House

CGF Services

streetAddress: 1 Barras Croft

Moray Council

description: General public services

University of Glasgow

description: Education

East Lothian Council

description: General public services

University of Stirling

description: Education


description: Call off from Transport Scotland LATIS Framework Lot 1

title: Deployment of Personnel to Transport Strategy and Analysis

description: Transport Scotland require a deployed staff member to support the work of the Strategic Transport Planning team in business case development and management of appraisals.

Transport Scotland

locality: Glasgow

postalCode: G4 0HF

streetAddress: Buchanan House, 58 Port Dundas Road

legalName: Transport Scotland

AECOM

postalCode: E1 8FA

streetAddress: Aldgate Tower, 2 Leman Street

legalName: AECOM

Sheriff Clerk's Office

postalCode: G5 9DA

streetAddress: PO Box 23, 1 Carlton Place

description:
Award against framework: MFA for Transport and Land-use Modelling, Transport Appraisal and Planning Services
 (SC Ref:719681)


description: 12 month extension for the provision of Paediatric oral nutritional supplements and enteral feeds in hospital and community settings.

title: AA-216-22-TW Provision of Paediatric Homecare Services Lot 1 - Using NP512/WoS/05000

description: Extension to the current contract providing Paediatric Enteral Feeds and Homecare Services using Framework NP512/WoS/05000

procurementMethodRationale: Extension to purchases from National Framework NP512/WoS/05000

description: Extreme urgency brought about by events unforeseeable for the contracting authority/entity and in accordance with the strict conditions stated in the directive

NHS Ayrshire & Arran

locality: Ayr

streetAddress: Eglinton House, Ailsa Hospital, Dalmellington Road

description: Health

legalName: NHS Ayrshire & Arran

Nutricia Ltd

locality: Trowbridge

postalCode: BA14 0XQ

streetAddress: Newmarket Avenue, White Horse Business Park

legalName: Nutricia Ltd

Kilmarnock Sheriff Court

locality: Kilmarnock

postalCode: KA1 1ED

streetAddress: Sheriff Court House, St Marnock Street

legalName: Kilmarnock Sheriff Court

description:
12 month extension until 30th January 2024
 (SC Ref:719684)


description: This procurement was concerned with the purchase and installation of additional electric car chargers at Old Viewforth.

title: Electric Car Chargers at Old Viewforth

title: Electric Car Chargers at Old Viewforth

Stirling Council

postalCode: FK7 7QA

streetAddress: Teith House: 55, M8. Kerse Rd, Stirling

description: General public services

Connected Kerb Ltd.

streetAddress: 20 Midtown, 20 Procter Street

legalName: Connected Kerb Ltd.

Stirling Sherrif Court

legalName: Stirling Sherrif Court

description:
Award against framework: ESPO (636_21) Vehicle Charging Infrastructure 2 Framework
 (SC Ref:719687)


title: Asbestos Removal Works (Licensed)

title: Asbestos Removal Works (Non-Licensed)

title: Asbestos Removal Works (Licensed)

description:
1. Any such variation may include(but shall not be restricted to) additions, omissions, alterations, substitutions to the Services and changes in quality, form, character, kind, timing, method or sequence of the Services.
 2. Save as otherwise provided herein, no variation of the Services as provided for in clause 1 hereof shall be valid unless given or confirmed in the form of an order given by the Client. All such orders shall be given in writing provided that if for any reason the Client
 shall find it necessary to give any such order orally in the first instance the Supplier shall comply with such oral order which must be confirmed in writing by the Client within 2 working days of the giving of such oral order by the Client, failing which the variation made by such oral
 order shall cease to have effect on the expiry ofthe said 2 working day period.
 3. Where any such variation ofthe Services made in accordance with clause 1 and 2 has affected or may affect the costs incurred by the Supplier in providing the Services, the Supplier will notify the Client in writing of the effect which it has had or may have had on the said
 costs and such notification shall be considered by the Client, who shall take all ofthe facts into account and may authorise such alteration to the sums to be paid to the Supplier in accordance with the provisions of the Contract as are, in the Client’s opinion, appropriate and
 reasonable in the circumstances.
 4. The Cost of each variation will be accumulated to a maximum of 50% of the original Contract Value, after which a new procurement may be required

description: The Contract will commence in April 2023 and is for an initial period of two (2) years. SBHA, may extend the Contract on one occasion for a period of twelve (12) months. The maximum possible term of the Contract is three (3) years.

description:
Scottish Borders Housing Association (SBHA) is seeking to award a contract for the Provision of Asbestos Removal Works.
 The works are to be split into two Lots-
 1.	Lot 1 – Licensed Asbestos Removal Works
 2.	Lot 2 – Non-Licensed Asbestos Removal Works
 Tenders may be submitted for one or both Lots although SBHA envisage 2 separate suppliers being awarded a separate contract for each Lot.
 The anticipated contract value of each Lot is as follows-
 Lot 1 - 200,000GBP. Excluding VAT for the maximum term of the whole Contract.
 Lot 2 - 50,000.00GBP Excluding VAT for the maximum term of the whole Contract.. Refer to Tender Documents

title: Asbestos Removal Works (Non-Licensed)

description:
Change to Contract Requirements
 2.1 The Customer may order any variation to any part of the Works that for any other reason shall in the Customer’s opinion be desirable. Any such variation
 may include (but shall not be restricted to) additions, omissions, alterations,substitutions to the Works and changes in quality, form, character, kind,timing, method or sequence of the Works.
 2.2 Save as otherwise provided herein, no variation of the Works as provided for in Condition 2.1 hereof shall be valid unless given or confirmed in the form of an order given by the Customer. All such orders shall be given in writing
 provided that if for any reason the Customer shall find it necessary to give any such order orally in the first instance the Supplier shall comply with it. It must
 then be confirmed in writing by the Customer within 2 working days, failing which the variation made shall cease to have effect on the expiry of the said 2 working day period.
 2.3 Where any such variation of the Works made in accordance with Condition 2.1 and 2.2 has affected or may affect the costs incurred by the Supplier in providing the Works, the Supplier will notify the Customer in writing of the effect which it has had or may have had on the said costs. Provided that such costs do not exceed 50% of the original value of the Contract, and, do not alter the overall nature of the Contract. Such notification shall be considered by the Customer, who shall take all of the facts into account and may authorise such alteration to the sums to be paid to the Supplier in accordanceSBHA 4 Contract Terms & Conditions
 with the provisions of the Contract as are, in the Customer’s opinion, appropriate and reasonable in the circumstances

description: The Service will commence in April 2023 and is for an initial period of two (2) years. SBHA, may extend the Contract on one occasion for a period of twelve (12) months. The maximum possible term of the Contract is three (3) years

description:
Scottish Borders Housing Association (SBHA) is seeking to award a contract for the Provision of Asbestos Removal Works.
 The works are to be split into two Lots-
 1.	Lot 1 – Licensed Asbestos Removal Works
 2.	Lot 2 – Non-Licensed Asbestos Removal Works
 Tenders may be submitted for one or both Lots although SBHA envisage 2 separate suppliers being awarded a separate contract for each Lot.
 The anticipated contract value of each Lot is as follows-
 Lot 1 - 200,000GBP. Excluding VAT for the maximum term of the whole Contract.
 Lot 2 - 50,000.00GBP Excluding VAT for the maximum term of the whole Contract. Refer to Tender Documents

description: Scottish Borders region at various Domestic, Non Domestic and Commercial properties of SBHA

title: Provision of Asbestos Removal Works

title: Provision of Asbestos Removal Works

description: Scottish Borders Housing Association (SBHA) are seeking to award a contract for the provision of asbestos removal works. Lot 1 Licensed Works and Lot 2 Non-Licensed Works

title: Tender Response Document

title: SPD Document

title: SBHA Terms & Conditions

title: Invitation To Tender

title: SBHA Customer Service Standards

title: Asbestos Removal Specification

title: Appendix 2 Community Benefits Form Lot 1

title: Appendix 2 Community Benefits Form Lot 2

title: Appendix 1 Pricing Schedule Lot 1

title: Appendix 1 Pricing Schedule Lot 2

title: Tender Response Document

title: SPD Document

title: Invitation To Tender

title: Provision of Asbestos Removal Works

streetAddress: SBHA Head Office

description: In accordance with SBHA procedures

performanceTerms: As set out in the ESPD and Tender Response Questions

description:
General standards: The works shall comply with all current Codes of Practice,
 Statutory Requirements and Building Regulations and British Standards.
 The Works will be carried out by qualified and competent tradespersons to undertake
 work with asbestos or have their staff trained to this level before mobilisation. Where evidence of certified training has not been presented by the mobilisation date the contract will be withdrawn.
 Contractors must comply with:
 The Health and Safety Act 1974
 The Control of Asbestos Regulations 2012
 The Management of Health and Safety at Work Regulations 1999 (MHSWR)
 HSG 227 Managing Asbestos in premises
 HSG 264: Asbestos: The Survey Guide
 HSG 248: Asbestos: The Analysts Guide for Sampling, Analysis and Clearance
 Procedures
 HSG 247 – The Licensed Contractors Guide.
 For Lot 1 (Licensed Works) the Contractor must hold (as a minimum), a current ,
 valid HSE license in accordance with Regulation 8 of the Control of Asbestos
 Regulations 2012 for the duration of the Contract.
 The Contractor must declare to SBHA, within 1 day of notification of any new
 suspensions, restrictions or additional conditions placed on their HSE license.
 The Contractor must also declare and provide details of any suspensions, restrictions
 or additional conditions placed on their license in the last 3 years.
 For both Lots the Contractor or their designated sub‐contractor must hold a valid UK
 waste carrier license for the duration of the Contract
 The Contractor must declare any new suspensions, restrictions or additional
 conditions placed on their own or their sub-contractor waste carriers license or waste management license immediately to SBHA.
 These will be evaluated on a PASS/FAIL basis.
 Failure to meet any of these criteria will result in a Fail and the Tender response will not be evaluated further

Scottish Borders Housing Association

locality: Selkirk

postalCode: TD7 5DT

streetAddress: South Bridge House, Whinfield Road

description: Housing and community amenities

legalName: Scottish Borders Housing Association

Selkrk Sheriff Court

postalCode: TD7 4LE

streetAddress: Sheriff Court House, Ettrick Terrace

legalName: Selkrk Sheriff Court

Scottish Borders Housing Association

description: Housing and community amenities

Enviraz (Scotland) Limited

postalCode: G52 4LT

streetAddress: 23-29 Kelvin Avenue, Hillington

legalName: Enviraz (Scotland) Limited

title: Asbestos Removal Works (Licensed)

title: Asbestos Removal Works (Non-Licensed)

description:
As set out in the Tender Documents.
 The Single Procurement Document (Scotland) must be completed by all bidders.
 The Section IV Selection criteria will be evaluated on a pass/fail basis.
 Whilst no other elements of the SPD are scored or weighted any information requested should be provided in full, the absence of which
 may result in your bid being excluded.
 Refer to Tender Documents for full information on scoring criteria
 (SC Ref:742097)


description: 12 months - subject to performance

description: Open Tendering

title: Rosehill Housing Co-op - Grounds Maintenance Services 2023-2026

description: Grounds Maintenance Services to Properties in the Rosehill areas of Glasgow.

title: Tender Documentation

title: Tender Amendments in relation to Grounds Maintenance Services

description: Details given in Contractors Application Pack

Reid Associates

postalCode: G3 7NB

streetAddress: 13 Sandyford Place

description: Housing and community amenities

legalName: Reid Associates

Glasgow Sheriff Court

streetAddress: Sheriff Clerk's Office, PO Box 23, 1 Carlton Place, Glasgow,

legalName: Glasgow Sheriff Court

Reid Associates

description: Housing and community amenities

Caledonian Maintenance Services Ltd

postalCode: G51 4SN

streetAddress: 68 Bogmoor Place, Shieldhall

legalName: Caledonian Maintenance Services Ltd

Glasgow Sheriff Court

streetAddress: 1 Carlton Place

description: (SC Ref:728554)


description: The University has awarded a contract for the renewal of Blackboard Ally. This was conducted through a call off from the NHS Digital Workplace Solutions Framework Agreement (SBS/19/AB/WAB/9411).

title: Provision of Blackboard Ally

title: Provision of Blackboard Ally

University of the Highlands and Islands

postalCode: IV3 5SQ

streetAddress: 12b Ness Walk

description: Education

legalName: University of the Highlands and Islands

TET Limited

locality: LONDON

postalCode: NW10 7SE

streetAddress: Unit D9, Friarsgate Business Park, Whitby Avenue

legalName: TET Limited

name: Inverness Sheriff and Justice of the Peace Court

postalCode: IV1 1AH

description:
Award against framework: Digital Workplace Solutions Framework Agreement (SBS/19/AB/WAB/9411)
 Direct Award via the NHS Digital Workplace Solutions Framework Agreement(SBS/19/AB/WAB/9411) for the Provision of Blackboard Ally software.
 (SC Ref:719839)