title: Supply of up to 6 no. used vans

description: Supply of up to 6 no. used vans - Supply of up to 6 no. used vans (1)Year 2010 or 2011 Make: Ford, Citroen, Peugeot or similar Model: Connect, berlingo or partner or similar Colour: white or CCC yellow Mileage: ideally less than 100000 kilometres Condition:very good Include for supply of a hitch and for the vans to come branded in normal Council livery(as attached) and flashing beacon, fire extinguisher, first aid kit etc. Note: if the vans are 2009 they are still acceptable but ideally they should be 2010-2011 The cargo area should be screened from the passenger area. I will accept a mix of make and model of vans.


currency: EUR

documentType: awardNotice

title: Sharepoint Developer Resources

scheme: CPV

title: SPD2014 — RFT for Sharepoint Developer resources.

description: The Department of Transport, Tourism and Sport (The Department) invite tenders for the supply of a) an on-site SharePoint Developer and b) a draw-down service to provide additional Sharepoint development and support services. The draw-down service should also be in a position to support MS Dynamics CRM 2011. The developers will work with the Department's Business and Information Systems Development (BISD) SharePoint Team. This team is currently based at our offices at 25 Clare Street, Dublin 2.

awardCriteria: priceOnly

procurementMethod: open

awardCriteriaDetails: PRICE: 100

mainProcurementCategory: services

street: Leeson Lane

postalCode: Dublin

countryName: IE

Spanish Point Technologies Ltd

street: 30/32 Sit John Rogerson's Quay

initiationType: tender


documentType: tenderNotice

description: OCT132763 - Provision of Road Diesel and Petrol for Louth Local AuthoritiesProvision of Road Diesel and Petrol for Louth Local Authorities

mainProcurementCategory: works


description: JAN075088 - Tender for the supply, delivery and installation of Pharmaceutical RefrigeratorsTender for the supply, delivery and installation of Pharmaceutical RefrigeratorsNOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=44248.


title: Wastewater Treatment Plant Bundle

description: MAY343875 - Wastewater Treatment Plant BundleSupply and installation of Mechanical & Electrical Equipment for two new Wastewater Treatment PlantsNOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=435612.


description: JUN152718 - Construction of Bleacher Seating for Sports FacilityScope of Works: The proposed new works comprise of the provision of precast concrete bleacher seating along an existing embankment adjacent to the long jump in the outdoor Athletics Track.Works will comprise of the following;1. Temporary removal of existing metal post and mesh fence, with reinstatement on contract completion.2. Protection of all existing athletic grounds finishes and fixtures.3. Excavation of pad foundations.4. Provision and installation of precast concrete raker beams, bleacher seating sections and infills.5. Provision and installation of precast concrete access steps and infill wall panels.6. Guard rails to balcony and stairs.7. Access footpaths and drainage.8. Reinstatement.Full details of the project can be found in the attached tender documentation which may be downloaded directly from the e-tenders website, or alternatively, may be obtained upon written request (e-mail will suffice) from Ms. Trudy Stack: tstack@ait.ieNOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=130871.


title: Egg and Larval

title: Underwater TV

title: Acoustics

title: Biological Sampling

title: ITT19-047 - Survey Support Services

description: ITT19-047 - Survey Support ServicesThe Marine Institute, a semi State body, wishes to invite tenders under an open procedure with the objective of putting a Multi-Supplier Framework Agreement in place for the supply of Survey Support Services for one year from 1st January 2020 to 31st December 2020. The detailed data and information required and collated by Fisheries Ecosystems Advisory Services (FEAS) for stock assessment includes: • The length distribution of landings • A profile of the age structure of landings • Fishery Catch information • The number of boats fishing in a particular area over time • The catch, time spent fishing, gears used (fleet activity) • Information on the annual landings into each port • Data from various research surveys carried out by FEAS At present a requirement exists for Survey Support Services in 4 Lots. Tenderers are invited to bid for one or more Lots. Each Lot will be evaluated separately. LOT 1 - Biological Sampling LOT 2 - Acoustics LOT 3 - Underwater TV LOT 4 - Egg and Larval


measure: electronicBids

title: The supply of ICT Remote Access Solution

description: The supply of ICT remote access solution to enable staff to access corporate resources on the department’s network.

title: The Supply of ICT Remote Access Solution

awardCriteria: ratedCriteria

mainProcurementCategory: goods

Department of Social Protection

street: College Road

postalCode: IE

Agile Networks Ltd

street: Suite 9, Plaza 212

postalCode: Blanchardstown Corpo


name: Our Lady of Victories Infant School (Dublin)

description: New Standalone Building at Our Lady of Victories Infant SchoolNew Standalone Building at Our Lady of Victories Infant School consisting of 2no. mainstream classrooms, accessible WC, office, associated circulation area; all together with associated site works.


description: Invitations to tender are invited from suitably qualified Fire Safety Design Consultants for the proposed new 1000 pupil post primary school for the Curragh Community College, Magee Barracks, Kildare Town, Co. Kildare.Refer to the enclosed tender documents for further details on project brief and scope of services required.

title: ADAPT 3A - Fire Safety Design Consultancy Service for Curragh Community College

Department of Education and Skills

street: Marlborough Street

postalCode: Dublin 1


title: notice to building contractors

description: OCT092571 - notice to building contractorsCOMHAIRLE CATHRACH CHORCAI CORK CITY COUNCIL Notice to Building Contractors Tenders are invited from competent building contractors for construction of extensions at:1. No.14 Ballinure Avenue, Mahon, Cork (Bedroom and shower room extension) D.T.11332. No 1 Rockwood, Skehard Road, Cork (Two storey extension) D.T 12153. No. 52 Thorndale Estate, Dublin Hill, Cork (Bedroom and bathroom extension) O/C 1644. No. 3 Nutley Road, Mahon, Cork (Single storey extension) D.T 11145. No. 90 Ballinderry Park, Mayfield (Bedroom and bathroom extension) D.T. 1185 in accordance with tender documents prepared by Don O'Carroll Architects (No. 1), Michael R. F. Casey (Nos. 2 & 5), James Leahy & Associates (No. 3), Mulcahy Ralphs Architects (No. 4) and City Architect's Department. Tender documents may be obtained from the City Architect's Department, Floor 2, City Hall, Anglesea Street, Cork, on payment of 10.00EUR for each project.Tenders and Schedule of Rates in separate sealed envelopes endorsed 'Tenders for extension at (stating location)' and also bearing each tenderer's name will be received by City Manager, Cork City Council, Reception Desk, City Hall, Cork, not later than 4.00 p.m., on Friday, 26th Oct 2007. Only tenders accompanied by a completed Schedule of Rates will be considered. The lowest or any tender will not necessarily be accepted and it will be a condition for the award of the contract that the Main contractor/Nominated Sub-Contractor and all Sub-Contractors appointed be required to produce for inspection by Cork City Council either a valid C2 certificate, a Tax Clearance Certificate, or in the case of a contractor resident outside the State, a statement from the Revenue Commissioners as to suitability for appointment on tax grounds. Tenderers must be insur


description: NOV134041 - Audio Visual and Event Production ServicesTourism Ireland advertised to appoint the services of an Audio Visual/ Production Services supplier to assist in the delivery of its ongoing programme of corporate and industry events on the island of Ireland for the period of two years commencing October 2009. NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=104999.


description: Engineering Consultancy Services for Arthurs Quay Park to Condell Road Cycle Lanes & Wickham Street to Clare Street Cycle LanesLimerick City and County Council seeks to appoint a multi-disciplinary engineering consultancy (the “Consultant”) to undertake the necessary designs, planning documents, land acquisition/CPO documentation if applicable, construction tender documentation, contract administration, site supervision and Project Supervisor Design Process (PSDP) role for Each of the following Projects; • Arthurs Quay Park to Condell Road Cycle Lanes • Wickham Street to Clare Street Cycle Lanes The Consultant’s services will be required for the following stages of Each of the above Projects; • Stage (i) Preliminary • Stage (ii) Design • Stage (iii) Tender • Stage (iv) Construction • Stage (v) Handover of Works


description: OCT107962 - Oldcastle Sewerage Scheme-Site Investigations ContractMeath Co Council invites tenders from suitably qualified & experienced Site Investigation contractors to carry out ground investigations for the proposed Oldcastle Sewerage Scheme. The proposed contract is based on the Engineers Ireland Conditions of Contract for Works of Civil Engineering Construction.The extent of the works includes the following:(a) 64 No. Trial Pits(b) 24 Nr. Boreholes(c) 840m Slit Trenches(d) Soil sampling and testing(e) Provision of factual reports.In addition the Contractor will be responsible for the performance of duties as Project Supervisor Construction StageThe work will mainly be carried out within & around the town centre in Oldcastle,Co Meath. The majority of the investigation sites are located in the public road & in private lands. NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=72455.


title: Short descriptionUofG/BUILD1539/2022 - Provision of Air Conditioning Maintenance and Call Out ServiceDetailed descriptionThe University of Galway is seeking to establish a single operator framework agreement for the provision of maintenance on Air Conditioning units and to provide a call out service. The successful tenderer may also be required to supply and fit replacement or additional units. Full details of requirements are provided in the tender documents which are available for downloading from the eTenders portal. Type of Contract: Services

description:
UofG/BUILD1539/2022 - Provision of Air Conditioning Maintenance and Call Out Service
The University of Galway is seeking to establish a single operator framework agreement for the provision of maintenance on Air Conditioning units and to provide a call out service. The successful tenderer may also be required to supply and fit replacement or additional units. Full details of requirements are provided in the tender documents which are available for downloading from the eTenders portal.


title: EPA Environmental Reporting 2005

description: JUL040570 - EPA Environmental Reporting 2005In accordance with its general environmental objectives, the EPA is seeking assistance in establishing systems and procedures for monitoring and reporting its environmental impact and performance in the following areas:- energy, water, material and resource consumption;- emissions (to air, water and land, as appropriate) management and impact;- waste generation, management and impact;- impact of travel (by road, rail and air); - impact of specific EPA activities (e.g. environmental monitoring functions, laboratory activities etc.); and- other areas as may be apparent to the EPA or the tenderer (as may be identified in tender documents or agreed during the course of the project).The EPA is also seeking assistance in preparing an Environmental Report for the calendar year 2005 with a view to periodic and regular reporting for future years.NOTE: Further information relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=14338.


title: Communications and Event Coordinators

title: Financial and Energy Contracting Advisors

title: Project Delivery Experts

title: Project Evaluation Specialists

title: Energy Management Specialists

description: RFT 119001 - Award Notice-Multi-Party framework agreements in five Lots for the provision of advisory services direct to Public Bodies on behalf of SEAIThis RFT was to invite proposals from suitably qualified services providers to provide advisory services directly to public bodies through SEAI’s Public Sector Programme and to support SEAI in the development and implementation of this programme, with the objective of concluding a total of five Frameworks to establish frameworks of experts comprising categories or ‘Lots’, as follows: Lot 1: Energy management (EM) specialists will undertake several diverse roles, including supporting Public Bodies to develop, continually improve and implement their energy management programmes. They will also facilitate the delivery of SEAI’s wider suite of services to Public Bodies and provide specialist advanced expertise in specific defined energy management fields to Public Bodies. Lot 2: Project evaluation specialists will identify, quantify and analyse opportunities for energy saving projects within Public Bodies, with an emphasis on projects that go beyond behavioural change and low-hanging fruit. Lot 3: Project delivery experts will mentor Public Bodies directly on the delivery of energy projects by assisting them through formal project development processes. Lot 4: Financial and energy contracting advisors for energy projects will provide specialist advice to Public Bodies, and directly to SEAI, with respect to the financing and energy contracting of energy projects (in particular Energy Performance Contracting and Local Energy Supply Contracting), and especially large-scale energy efficiency projects. Lot 5: Communications and event coordinators will assist SEAI with the dissemination of energy management best practice to the PS through inter alia networking, events and working groups. For more information, please refer to the award notice published on the OJEU.


description: 71064 St. Louis Community School - New Two-Storey Extension to Existing Community Secondary SchoolConstruction of a new two-storey extension comprising seven general classrooms, a multi-purpose hall, sanitary accommodation and other ancillary rooms, including interface works, alterations and modifications to the existing school building together with associated services and site works.


description: Supply, delivery, installation and commissioning of Equipment for a Post Primary School We are inviting tenders for the supply, delivery, installation & Commissioning of Equipment for St Raphael's College. Please see attached documents for details. The project is subject to the availability of funding. All submissions must be returned by hard copy only and clearly marked EquipmentTender. On appointment the supplier should contact the School Principal to schedule specific delivery dates. Please note that the supplier will be responsible for the removal and disposal of all packaging off-site. All equipment must be delivered to room as instructed by the School Principal. The tender is broken down into 11 lots.


description: APR024194 - Mayo Group Water Schemes - DBO Bundle No. 1 - Advance Works ContractProvision of Reservoirs, Pipelines and Access Roads


name: The University of Dublin Trinity College

title: Supply and Maintenance of Photocopiers

description: FEB033339 - Supply and Maintenance of PhotocopiersThe University of Dublin, Trinity College, seeks tenders for the supply and maintenance of photocopiers for a period of not more than four years.NOTE: Further information relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=4046.


description: The contracting entity intends to procure material supplies framework agreement for the supply of assorted workshop gases and bulk hydrogen to all of ESB Generating Stations and ESB Networks Ltd depots throughout the island of Ireland. (ROI and UK).The winning contractor of this project is required to provide a delivery and collection service nationwide.

title: GWM 12815 – Hydrogen and Assorted Gases Supply Framework

description: The contracting entity intends to procure material supplies framework agreement for the supply of assorted workshop gases and bulk hydrogen to all of ESB Generating Stations and ESB Networks Ltd depots throughout the island of Ireland. (ROI and UK).The winning Contractor of this project is required to provide a delivery and collection service nationwide.

procurementMethod: selective

Electricity Supply Board (ESB)

street: 27 Fitzwilliam Street Lower


name: National University of Ireland, Galway (NUI Galway)

title: Engineering study

title: ENGSTUDY - Engineering study

description: ENGSTUDY - Engineering studyTo conduct an Engineering study with a view to reducing energy consumption in NUI Galway on 5 selected projects.


description: The proposed Marina Park Phase 2 is situated between Cork City South Docklands and Blackrock Village. The scheme aims to provide an ‘eco-park’ and an area of high-quality public realm and landscape, while protecting and enhancing the natural heritage and biodiversity of the area. The scheme aims to improve public accessibility and amenities through the site. It includes the restoration and protection of historical structures and the creation of points or interest and park attractions such as “Nature” zones in the park, accommodating picnic areas, adventure play areas, preserved marshland zone and several architectural heritage sites.

title: Marina Park Phase 2

Cork City Council

street: City Hall


title: Ballymun-Finglas

title: Artane-Whitehall

title: Donaghmede

title: Clontarf

title: Cabra-Glasnevin

title: North Inner City

title: South West Inner City

title: South East Inner City

title: Ballyfermot-Drimnagh

title: Kimmage-Rathmines

title: Pembroke

title: City-wide

description: Local Area Term Maintenance Framework for Dublin City CouncilDCC wishes to establish twelve (12) frameworks agreements for each of the eleven (11) housing areas plus one (1) city wide area to carry out maintenance and refurbishment works under the terms of the Public Works Term Maintenance and Refurbishment Works Contract and under the direction of the Housing Maintenance Section as follows: Lot 1 - Ballymun-Finglas Lot 2 - Artane-Whitehall Lot 3 - Donaghmede Lot 4 - Clontarf Lot 5 - Cabra-Glasnevin Lot 6 - North Inner City Lot 7 - South West Inner City Lot 8 - South East Inner City Lot 9 - Ballyfermot-Drimnagh Lot 10 - Kimmage-Rathmines Lot 11 - Pembroke Lot 12 - Citywide for further information please see attached documentation.

Dublin City Council

name: Senior Executive Officer Procurement Unit


description: SD/32/17 - The removal and environmental disposal of existing floor covering and the supply and fitting of new carpet tiles to the Department of Social Protection, Ballina, Co. Mayo.The removal and environmental disposal of existing floor covering and the supply and fitting of new carpet tiles to the Department of Social Protection, Ballina, Co. Mayo. Tender documents may be downloaded from the website and are available in PDF format only. Please send all tender related queries to furniture@opw.ie.


name: Cavan and Monaghan Education and Training Board

title: Window Replacement Virginia College

description: OCT279756 - Window Replacement Virginia CollegeReplacement of a selection of single glazed synta pulvin windows and supply and fit new upvc double glazed windows. Windows are located at ground floor and upper floor levels and are in a variety of building types from 1960s to 1980s.


description: AUG065247 - Corrugated Steel Culverts - Contract Award NoticeTenders were invited from competent and experienced suppliers for the design, supply, delivery and site advice / supervision for corrugated galvanised steel plate arch culverts at ;1. Drumnafinnagle, Kicar, Co. Donegal. 2. Galwolie, Brockagh, Ballybofey, Co. DonegalThese culverts are to be constructed by Donegal County Council in 2006 as part of the planned road realignment projects in these areas.NOTE: Further information relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=37966.


title: Short description2023 TETB 019 - Supply and Delivery of Electronic Security Systems ConsumablesDetailed descriptionThe Supply and Delivery of Electronic Security Systems Consumables Type of Contract: Supplies

description:
2023 TETB 019 - Supply and Delivery of Electronic Security Systems Consumables
The Supply and Delivery of Electronic Security Systems Consumables


description: AUG374635 - Project Supervisor Design Process Lissenhall N.S.To design and supervise the building of an additional mainstream classroom at Lissenhall N.S. from pre-planning stage to project completion.NOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=484833.


description: Description of the ProjectDonore National School is a primary school under the patronage of the Catholic Bishop of Meath.Please see attached Project Brief & Schedule of Additional AccommodationIn summary, the project will comprise:• 2 Classroom SEN Base                        359.0 m2• Giving a floor area (incl circulation and internal walls) of:         459.5 m2Giving a Gross Floor Area of (including circulation, internal walls & stairs)   460.0 m2Also:• Secure Hard and soft play area     100 m2• Sensory Garden         100 m2• 6 parking spaces

title: Civil Structural Engineering Services for Additional Accommodation at Dun Uabhaur NS, Donore, Co Meath

Donore National School

street: Donore National School, Staleen

postalCode: Co. Meath


title: Request for Tender for the Supply and Installation of Audio Visual Equipment for the Health Service Executive

title: Request for Tender for the Supply and Installation of Audio Visual Equipment.

description: The Office of Government Procurement (OGP), on behalf of the Health Service Executive (HSE), requests tenders for the supply, installation, commissioning, support and maintenance of Audio Visual equipment to a newly refurbished building in Tullamore, Co. Offaly.

awardCriteriaDetails:
Product Quality and technical merit of the proposed solutions to meet the specified technical and functional requirements: 300
Quality and comprehensiveness of the proposal to meet the requirements of this RFT in terms of: 300
Delivery Timescales for installation and commission: 100
Cost: 300

The Office of Government Procurement

street: 3A Mayor Street Upper

Image Supply Systems

street: Liberty Lane, Camden Row, Dublin 8


description: JUN039389 - Design Team Consultants for new 16-classroom primary school in Portarlington, Co LaoisCivil/Structural Engineering, Mechanical & Electrical Engineering, & Quantity Surveying Services are sought for a PARTIAL PRE-TENDER SERVICE, and a FULL POST TENDER SERVICE for the construction of a 16-classroom Generic Repeat Design primary school in Portarlington, Co Laois. (Architectural services will be provided in-house by the Department of Education & Science). The Generic Repeat Design schools are fully designed and detailed standard 8, 12 and 16 classroom schools. The successful candidate will be provided with a full set of tender documents for the superstructure in electronic soft format (detailed architectural, structural and services drawings, structural engineering manual and calculations, bill of quantities complete with take-off backup, mechanical, electrical and lift specifications, architectural specification, etc.) It is envisaged that the partial pre-contract service will be substantively work on site specific elements and co-ordination of site specific elements with the Generic Repeat Design. Applications are invited from suitably qualified Consultants (as listed above) who wish to be included on short-lists from which submissions will be sought for Design Team services for this project.The consultants will be separately assessed and individually appointed. NOTE: Further information relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=13441.


title: External Audits

title: APR101197 - External Audits

description: APR101197 - External AuditsExternal Audits


name: St. Augustine's National School (Ballinasloe)

description: St. Augustines NS, Clontuskert - St. Augustine's NS, Clontuskert, Ballinasloe, Co. Galway - Remedial Works to the LPHW Space Heating Installation - EWS 2021Upgrade Works to the LPHW Space Heating Installation, including all associated Builders Attendances and Electrical Works. The works covered by this specification include the provision of a new LPHW Space Heating system throughout the building, including some remedial works to the existing BMS Controls, all associated builder’s attendances and electrical works, etc.


name: Department of Agriculture, Food and the Marine

description: JUL104579 - Request for Tender for Delivery of Computer Applications Training (Microsoft Office 2000)The Department of Agriculture, Fisheries and Food (DAFF) is seeking the delivery of Computer Applications training for its staff. This course should be a highly interactive classroom based programme to be delivered to staff of all grades i.e. administrative, technical and senior/junior management levels.NOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=68627.


measure: smeBids

measure: foreignBidsFromEU

description: IDA Ireland is seeking to appoint a suitable contractor for the provision of Security Services (static guarding and mobile patrols) at IDA South County Business Park for a 3 Year Period subject to performance reviews.

title: 3 year Security Contract (Static Security & Mobile Patrols) at IDA South County Business Park, subject to annual performance reviews

IDA Ireland

street: Three Park Place

postalCode: Hatch Street Upper

P & J Security

street: Portarlington


title: Short description2022 Ardscoil La Salle - Building Services (M&E) Engineering Services for Additional Accommodation at Ardscoil La Salle Raheny Rd. Raheny DublinDetailed descriptionArdscoil La Salle is a post primary school under the patronage of the Le Cheile Schools Trust. Please see attached Project Brief & Schedule of Additional AccommodationIn summary, the project will comprise:Section A: 1 x Music Room 88.6 m2 Giving a floor area incl circulation and internal walls of: 116.0 m2 Section B• 2 Classroom SEN Base 409.0 m2• Giving a floor area (incl circulation and internal walls of: 523.5 m2Giving a Gross Floor Area for Section A & B (including circulation, internal walls & stairs) 690 m2Also:• Secure Hard and soft play area 100 m2• Sensory Garden 100 m2• 6 parking spaces Type of Contract: Services

description:
2022 Ardscoil La Salle - Building Services (M&E) Engineering Services for Additional Accommodation at Ardscoil La Salle Raheny Rd. Raheny Dublin
Ardscoil La Salle is a post primary school under the patronage of the Le Cheile Schools Trust. Please see attached Project Brief & Schedule of Additional Accommodation In summary, the project will comprise: Section A:  1 x Music Room 88.6 m2  Giving a floor area incl circulation and internal walls of: 116.0 m2 Section B • 2 Classroom SEN Base 409.0 m2 • Giving a floor area (incl circulation and internal walls of: 523.5 m2 Giving a Gross Floor Area for Section A & B (including circulation, internal walls & stairs) 690 m2 Also: • Secure Hard and soft play area 100 m2 • Sensory Garden 100 m2 • 6 parking spaces


title: Onsite IT Support Services - Dublin

description: MAY338155 - Onsite IT Support Services - DublinTourism Ireland is seeking a service provider for the next 2 years, commencing in October 2011 to assist the ICT department in providing onsite IT support to its Dublin office


title: Window replacement

description: Scoil Nioclais Naofa - Window replacementRE: Tender for replacement of windows at Scoil Nioclais Naofa, Claddagh, Galway. Dear Sirs, We have pleasure in inviting you to tender for the above mentioned project. The project involves the removal of existing windows, provision and installation of new timber and uPVC windows and all associated works. SCHEDULE OF CONTRACT DOCUMENTS:  Schedule of contract documents (this document).  Gerard Carr & Associates Ltd. drawings: o 034/15 ST01 and 034/15 ST02.  Project specification.  Preliminary Health and Safety Statement. Tenders should include for all items in the above mentioned specification documentation/drawings and all additional items (where specific specifications are not given) required to complete the relevant works to a minimum of a standard builders finish in accordance with up-to date building regulations and DOES regulations. Gerard Carr & Associates Ltd. T: 091-515002 / 087-6317648. Directors: Gerard Carr 9 Riasc Na Ri, F: 091-515006. Orla Carr. Old Rahoon Road, E-mail: gcace@eircom.net Galway. Website:www.gcarrassociates.com Company Registration no. 412502 V.A.T. registration no. IE 6432502m Tenders must include: 1. Detailed breakdown of the tender sum. 2. Confirmation that the works will be undertaken and completed during the school summer holidays 2015. 3. A copy of your up to date building contractor’s insurance certificate. 4. Proof of completion of similar type and scale projects. 5. A current tax clearance certificate. 6. Company H&S statement. 7. Confirmation that the provision and installation of blinds are included. 8. Details of product and fitting guarantees. 9. Confirmation that a complete health and safety plan will be handed over to the Project Engineer upon completion. Please return your tender not later than 12.00 p.m. on Friday 26th June 2015. Please do not hesitate to contact us should you have and queries.


name: Kildare European Leader II Company Ltd ( KELT)

title: Blackwood Feeder Baseline Study

description: MAY037129 - Blackwood Feeder Baseline StudyThe purpose of the studies is to provide a more detailed level of knowledge about the ecology and hydrological aspects of the Blackwood Feeder & Reservoir site. This knowledge will be used to inform plans for the long term use and management of the site.These studies are being commissioned to collect baseline data on:-a) the population of vertigo moulinsiana at the site,b) the status of the Annex I habitats at the site,c) the hydrology of the site,d) the effects of grazing at the site,e) the status of the protected species Marsh Fritillary and Otter which have been recorded at the site.f) all birds using the site (including passerines).Notes:I. The main consideration under item (d) is the effect of overgrazing on the feeder portion of the site. Bidders are also asked to address the question of what level of grazing is appropriate for the lake area of the site where it is believed that the cessation of grazing a number of years ago has lead to scrub encroachment and a consequent loss of habitat. Bidders can propose to develop a recommendation based on known best practice or propose a research approach that will arrive at a sustainable solution.II. In relation to items (a), (b) and (e) consultants are expected to identify as far as possible current activities or conditions that are impacting on the current status of the species and where appropriate propose mitigating measures.III. Item (f) is intended to be largely a desk exercise compiling a list of all the birds recorded at the site and any additional information that is available about them.NOTE: Further information and additional documentation relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=11809.


title: Provision of Electrical Probe Stations

description: FEB076398 - Provision of Electrical Probe StationsSupply , installation, commissioning and maintenance of 1 x manual electrical probe station and 1 x semi-automatic electrical probe station.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=45129.


name: Civil & Structural Engineer - DBFL Consulting Engineers

name: Mechanical & Electrical Engineer -Mastercad Ltd.

name: Civil & Structural Engineer - Malone O’Regan

name: Mechanical & Electrical Engineer - J.V Tierney & Co.

name: Boards of Management for individual schools where appropriate

title: Lot No: 1 Title: Consultancy Services for Virginia Mixed NS, Virginia.

title: Lot No: 10 Title: Scoil an Athar Tadhg, Carraig na Bhfear, Co Corcaigh.

title: Lot No: 2 Title: Ardgillan Community College, Castlelands, Dublin Fingal.

title: Lot No: 3 Title: New School at Baile Falbach, Lusk RN 17472M.

title: Lot No: 4 Title: Scoil an Chroí Naofa, St Paul's NS and SN Mhuire, Portlaoise.

title: Lot No: 5 Title: Scoil Mhuire NS, Tullamore.

title: Lot No: 6 Title: Tullamore College, Riverside, Tullamore.

title: Lot No: 7 Title: Scoil Náisiúnta Lusca, Lusk, Co Dublin RN 17961E.

title: Lot No: 8 Title: Scoil Naomh Mhuire/Maree NS, An Gharran, Oranmore.

title: Lot No: 9 Title: Lucan Community College, Esker Drive, Lucan.

title: Consultancy appointments for 10 Primary and Post-primary schools.

description: Separate consultancy appointments for Architectural, Quantity Surveying, Civil/Structural Engineering and Building Services Engineering (Mechanical & Electrical) Services for 10 schools as stated under each Lot.

awardCriteriaDetails:
Quality Marks: 70
Total Price Marks: 30

Department of Education & Skills

street: Portlaoise Road

Architect - Samuel Stevenson

street: 4 Greenwood Avenue, Belfast, BT4 3HR

countryName: UK

QS - Mulcahy McDonagh & Partners

street: 46/48 Pembroke Road

postalCode: Dublin 4

Civil & Structural Engineer - DBFL

street: Herbert House, Harmony Row, Dublin 2

Mechanical & Electrical Engineer - BDP

street: Blackhall Green, Dublin 7

RPS Consulting Engineers

street: Innishmore, Ballincollig, County Cork

Architect - Kennedy Fitzgerald LLP

street: 24 Fitzwilliam Place, D2

QS - Bruce Shaw

street: Kestral House, Clanwilliam Place, Dublin 2

street: 7 Patrick St, Kilkenny

QS John J. Casey & Co

street: 9 Premier Suites, Garter Lane, Saggart, Co. Dublin

street: 2B Richview Office Park, Clonskeagh, Dublin 14

street: The Tannery, 53-56 Cork Street, Dublin 8

Healy Kelly Turner Townsend,

street: Duncairn House, 14 Carysfort Avenue, Blackrock, Dublin

Hayes Higgins Partnership

street: The Arches, Gas House Lane, Kilkenny

Malone Engineering Services Limited

street: 238 Blanchardstown Corporate Park, Ballycoolin, Dublin 15

McCarthy O’Hora

street: Old Church, Church Street, Portlaoise, Co Laois

MJ Turley

street: Red House Patrick Street, Portarlington, County Laois

MRG Consulting Engineers

street: 4 Day Place, Tralee, County Kerry

Noel Lawler Consulting Engineers

street: 7 Patrick Street, Kilkenny

Butler Moffat,

street: Farnham House, 26/27 MacCurtain Street Cork

Mulcahy McDonagh & Partners

street: 46-48 Pembroke Eoad, Ballsbridge, Dublin 4

McCarthy O’Hora Architects Ltd

street: Old Church, Church Street, Portlaoise, Co. Laois

Rogerson Reddan & Associates Ltd

street: 78 Haddington Road, Ballsbridge, Dublin 4

Hayes Higgins Partnership

street: The Arches, Gas House Lane Kilkenny

Semple McKillop

street: Suite 6, Ormeau House, Ormeau Road, Belfast BT7 1SH

Simon J Kelly & Partners

street: Waterside Galway

Davis Langdon

street: Heritage Hall Kirwan’s Lane Galway

Malone O’ Regan

street: 13, Mill Street Galway

Semple& McKillop

street: Monaghan Road Castleblaney Co Monaghan

Butler Moffat Architects

street: Farnham House, 26/27 MacCurtain Street, Cork

Mulcahy McDonagh & Partners

street: 46-48 Pembroke Road, Ballsbridge, Dublin 4

McCarthy O’Hora Architects Ltd

street: Old Church, Church St, Portlaoise, Co. Laois


name: Department of Communications, Energy & Natural Resources

title: Invitation to Tender for Maintenance & Support Personnel.

awardCriteriaDetails:
Quality and qualifications of the proposed personnel (referenced by Curriculum Vitae): 55
Cost fo the proposed personnel (including daily rate): 55
A knowledge of the business of Communications, Energy & Natural Resources and experience working in/with the Public Sector: 55
Availability / Time frame to start the work: 55

street: 29-31 Adelaide Road

Compass Informatics Limited

street: Block 8, Blackrock Business Park, Carysfort Avenue, Blackrock


title: RPA7263_Provision of Medical Services

description: MAY226455 - RPA7263_Provision of Medical ServicesRailway Procurement Agency (RPA) is an independent statutory body which was established by the Transport (Railway Infrastructure) Act, 2001 which contains provisions in respect of:- Luas- Metro- Integrated Ticketing System- Exploitation of the benefits of public-private partnerships PPP's) in developing these projects- Other transport related projectsRPA currently employs approximately 280 people. The head office is located on Parkgate Street, Dublin 8 with a project office at Red Cow, Naas Road, Dublin 22. There is a possibility of future site offices in other Dublin locations.RPA has a requirement to make available certain occupational medical services to all employees.NOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=221212.The awarding authority has indicated that it will accept electronic responses to this notice via a 'Tender Submission Postbox' facility. Further details of this facility are available at http://www.etenders.gov.ie/PostBox/Postbox_Explain.aspx?ID=221212.Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems. The postbox closes precisely at the time stated.


title: Fishmongers Ireland - Channel Insight

description: JH/FICI/03/21 - Fishmongers Ireland - Channel InsightFishmongers Ireland - Channel Insight


description: Labour only catering DSE June 17 - Supply of catering staff to site in Blackrock, Co. dublinSchool kitchen requiring catering staff


name: Department of Arts, Heritage, Regional, Rural & Gaeltacht Affairs

description: Visitor and Trafic Management Plan for the Burren National ParkTenders are invited for the drafting of a Visitor and Traffic Management Plan for the Burren National Park to cover the period 2016 - 2030. Prior to the drafting of the plan extensive public consultation will be required. The successful tenderer will be required to have a strong track record and experience in planning, landscape and visitor and environmental management and be a skilled in public communication.


name: Fáilte Ireland-National Tourism Development Authority

description: APR332818 - Prior Information Notice - Various Services (2012 - 2013)Prior Information Notice - Various Services (2012 - 2013)


description: MAY025067 - Supply and Installation of Telephone Systems EquipmentSupply and Installation of Telephone Systems Equipment


description: FD/02/05/378 - Provision of Industrial Cleaning AccreditationProvide accredited training to 200-600 prisoners per year in Industrial Cleaning. Provide training to 10/12 prison staff, to enable staff to deliver accredited training to nominated prisoners. Provide accreditation certification to nominated prisoners. Provide training centre licensing to 12 prisons. Provide audit on an annual basis on the cleanliness and hygiene levels in each prison, reporting on the results and comment on the effectiveness of the IPS Cleaning Strategy).


name: Department of Foreign Affairs and Trade/An Roinn Gnóthaí Eachtracha agus Trádála

description: DEC192095 - Consultancy Support for Development Education Reviews in Irish AidAim of the Reviews:The aim of the reviews is to assist the Development Education Unit (DEU) to identify and prioritise the development education outcomes to which it wishes to contribute. The review findings will inform its approach to policy work and resource allocation for the three year period 2012 -2014. Key priorities areas, specific outputs and outcomes and indicators of success are to be developed following a process of consultation with key stakeholders in the relevant areas. The outcome of each of the proposed reviews will feed into the development of an overall results chain and performance monitoring framework for the remainder of the Development Education Strategy. The overall process will consist of :1. Thematic reviews conducted with priorities and results identified2. The Review of findings from each of the thematic reviews and overall prioritisation agreed –3. Overall results identified and performance measurement framework developed4. Funding guidelines and criteria developedNOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=188872.The awarding authority has indicated that it will accept electronic responses to this notice via a 'Tender Submission Postbox' facility. Further details of this facility are available at http://www.etenders.gov.ie/PostBox/Postbox_Explain.aspx?ID=188872.Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems. The postbox closes precisely at the time stated.


description: Cork County Council Contract for Parking Fines SystemCork County Council Contract for Parking Fines System


name: Edwards Engineering and Maintenance Services Ltd

title: Galvanised Steel Doors and Cabinets for MV/LV Substations

description: Manufacturing and Retro-Fitting of Galvanised Steel Doors and Re-shelling of MV/LV Substations that would cover the entire country.

Electricity Supply Board (ESB)

postalCode: Dublin 2

street: Castlemore

Cumar Baile Mhic Ire Teo T/A Fireblock

street: Udras Industrial Estate, Ballymakeera


Mayo Power Limited

street: Streamstown


title: Clontarf Bridge Rehabilitation

title: Clontarf Bridge Rehabilitation

description: Clontarf Bridge Rehabilitation- Steelwork repair of corrosion damage to all structural elements of the bridge above and below deck level. - Replacement of steelwork crossbeams and bracing over carriageway. - Excavation of existing carriageway surfacing. - Installation of steel bridge deck waterproofing. - Installation of new carriageway surfacing material. - Repainting of road markings. - Installation of new bridge expansion joints in the carriageway. - Replacement of footway surfacing. - Repair of existing parapet railings. - Repainting of entire structure. - Take down existing public lighting, architectural lighting and cabling. - Installation of new lighting elements, cabling in conduits. - Cleaning and repointing of masonry parapets. - Repainting of existing traffic lighting and public lighting poles. - Replacement of existing traffic direction signs attached to the structure. - Traffic management to facilitate all of the above works. - Liaison with all relevant public bodies, environmental bodies and utility companies to facilitate the above works. - Installation of new vehicle containment parapet along Albert Quay between Clontarf Bridge and Eamon DeValera Bridge Routine maintenance works such as removal of vegetation, removal of graffiti, cleaning and jetting of gullys, and sweeping and removal of dirt and debris from the carriageway and footways will be required at the site. Some works may need to be co-ordinated with local authority road repaving contracts, and traffic management will be critical for successful completion of the works.


title: Supply of X86 Processor-Based Servers

description: ESB currently has more than 400 physical hosts, located primarily in ESB’s two datacentres, but also in remote locations across Ireland and the UK. We aim to refresh hardware on a 5 -7 year cycle, depending on the circumstances and the particular requirements of the business unit at that time.

title: Supply of X86 Processor-Based Desktops, Laptops, Thin Clients, and associated peripheral

description: ESB currently has approx. 8000 Laptops / 1,000 Thin Clients and 1000 Desktops.  Hardware refresh takes place on a rolling 3 year basis.  Our Strategic approach is to encourage Smart and Hybrid working, peripherals are supplied for home /office use.

title: Supply of Apple devices ( tablets desktops and laptops) and hardware peripherals

description: ESB currently has approx. 500 non cellular Tablets/laptops/desktops.  Our Hardware vendors need to be an Apple premium reseller.    Our Strategic approach is to encourage Smart and Hybrid working, peripherals are supplied for home /office use

title: SSCON6463 IT End Point & Server Hardware

description: A framework agreement to procure a service supplier for the supply of IT End Point & Server Hardware.

Electricity Supply Board (ESB)

street: 27 Fitzwilliam Street Lower


name: Bord Iascaigh Mhara - Irish Sea Fisheries Board ( BIM )

description: AUG262216 - Production of 5km seeded seaweed collector string/ropeThis tender is for the provision of 5kms of seeded seaweed collector string/rope. The duration of the proposed work is October to December 2011. The methods for the hatchery work are already established and documented. The publications are available from BIM (Ref: BIM Aquaculture Explained No 26. ‘Cultivating Laminaria digitata’ (2011) and BIM Aquaculture Explained No 21. ‘Cultivation of brown seaweed Alaria esculenta’ (2006). This proposed contract is an extension of the project, PBA/SW/07/001(01), Development and demonstration of viable hatchery and ongrowing methodologies for seaweed species with identified commercial potential’. The project was carried out under the Sea Change Strategy with the support of the Marine Institute and the Marine Research Sub-programme of the National Development Plan 2007-2013. Laminaria digitata was included in the list of identified species. In addition, BIM conducted trials on Alaria esculenta previously.NOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=298254.The awarding authority has indicated that it will accept electronic responses to this notice via a 'Tender Submission Postbox' facility. Further details of this facility are available at http://www.etenders.gov.ie/PostBox/Postbox_Explain.aspx?ID=298254.Suppliers are advised to allow adequate time for uploading documents and to dispatch the electronic response well in advance of the closing time to avoid any last minute problems. The postbox closes precisely at the time stated.


title: School Extension

title: Classroom Extension Type of Contract: Works

description: Classroom ExtensionWorks


title: SUPPLY OF P.P.E. and FOOTWEAR.

description: OJEU 10.2016 - SUPPLY OF P.P.E. and FOOTWEAR.Dublin Bus require a supplier of P.P.E. and Footwear. Dublin Bus employs approximately 500 engineering staff in various areas of the company who are required to wear P.P.E. and Safety footwear. The safety garments, footwear and equipment must be suitable for use while performing duties which include driving, general workshop and pit duties. Exposure to oily conditions and inclement weather conditions should also be considered. Delivery will be to seven Dublin locations.


description: The Works comprise the construction of 43 No. Social (Housing) Apartments at Westside Court, Model Farm Road, Cork together with 84 No. Social Apartments and 6 No Social Housing Units at Clover Hill Court, Bessboro Road, Mahon, Cork in one single contract on a Design and Build Basis including associated Mechanical and Electrical Services Installations together with all associated External Works in “live” occupied environments as per the Outline Scheme Drawings, Indicative Specifications and Schedules of Accommodation issued for guidance purposes in association with this Suitability Assessment Questionnaire.Tendering contractors will be required to include for performing the roles of Designer, Main Contractor, Project Supervisor Design Process (PSDP) and Project Supervisor Construction Process (PSCS) for all Design and Construction Disciplines.In particular, the Main Contractor will be required to comply with the code of practice for inspecting and certifying buildings and works as defined in SI No.9 of 2014 Building Control (Amendment) Regulations (BC(a)R) 2014 to include the roles of Design Certifier and Ancillary Certifiers.

title: Westside Court and Clover Hill Court Housing Developments

description: The delivery of 2 No. Social Housing/Apartment Schemes at Westside Court, Model Farm Road, Cork and Clover Hill Court, Bessboro Road, Mahon, Cork in one Single Contract on a Design and Build basis using 2D Panelised and/or 3D Modular or Volumetric construction methods only for Cork City Council

Cork City Council

street: City Hall


description: 1956 Scoil Realt na Mara - Single Classroom Extension to existing schoolSingle Classroom Extension to existing school at Scoil Realt na Mara, Ballycotton, Co. Cork. The successful tenderer will be required to provide the following documents; Certified Turnover for the last 3 years Evidence of up to date contributions to CIF Pension Scheme Evidence of Public Liability & Employers Liability Insurance The completed tender documents shall be returned to the office of Matt O’Mahony & Associates Ltd. on or before 12 noon on Monday, 20th August 2018. The envelope must be clearly marked with the name of the Tender, the name of the Contract, and the Content. Should you wish to visit site please contact Frank O’Mahony on 021 450 6364 to arrange same.


title: Consultancy Services for New Construction Works, Stages (i) to (ii) at Rosehill, Mullagh, Co Cavan

description: Consultancy Services - Consultancy Services for Construction of 8 No Housing Units at Rosehill, Mullagh, Co CavanConsultancy Services including: Lead, Architectural, Structural and Civil Engineering, Building Services Engineering, Quantity Surveying, Project Supervisor Design Process, Design/ Assigned Certifier, and Employer’s Representative Services For proposed Construction Works Stages (ii) to (v) Rosehill, Mullagh ,Cavan For Cavan County Council


description: MAR099215 - Arklow Water Supply Scheme Contract 5 - Site Investigations for Lamberton Distribution MainsThe Works comprising the Contract are as follows:a) 7 No.light cable tool percussive bores with disturbed and undisturbed sampling and in situ testing.b) 7 No. Rotary drilling and coring to recover rock cores.c) 45 No. Slit Trenches in Roads.d) 22 No. Slit Trenches in Grass.e) Approximately 70 No. Non-destructive methods for locating pipes and services between slit trenches/trial pits.f) Lifting of approximately 70 No. manhole covers and the associated surveying and recording of details.g) Sampling and Laboratory testing of rock cores, soli samples and groundwater.h) Provision of Factual Reportsi) Provision of drawings in hard copy and digital format showing position of boreholes, trial pits and slit trenches. NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=62293.


Bord Gais Eireann

street: P.O.Box 51, Gasworks Road


description: FEB200561 - Tender for supply of Surface Dressing ChippingsTender for Supply of Surface Dressing Chippings to South Tipperary County Council for 2011NOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=201573.


name: Dun Laoghaire Institute of Art Design & Technology

title: IADT Fibre Cabling Tender 2018

description: IADT Fibre Cabling Tender 2018 - IADT Fibre Cabling Tender 2018IADT, requires additional fibre multimode 48 core and single fibre 24 core cabling between its two main data centres (Atrium & Carriglea). The fibre cable must of latest standard OM5 for the multimode fibre and the single mode must be OS2. The route for this cabling has been identified and all external ducting is in place. Internal routes have also identified and follow the current path of IADT fibre. All fibres would be terminated LC fibre optic patch panels in both locations. All links are to tested, label and commission and testing documentation to be made available to IADT. Any wall/building penetrations to be fire sealed and certified. As part of this tender IADT also wish to reterminate 60 pairs of ST fibre connections to LC connection (each end) in a number of our comms and data centres. All work can occur during the normal business day up until 10th September 2018 and it is expected that all work will be completed by this date.


description: WCCC/ED/350 - Provision of Specified Fairground Attractions for 2015 Waterford Winterval FestivalWaterford City & County Council requires a suitable qualified company to supply and operate on a Concession basis 4 large pieces of fairground equipment (1 Vintage Carousel, 1 Small Carousel, 1 Helter Skelter & 1 Ferris Wheel) for the Winterval Festival which runs from November 20th until December 23rd 2015


description: Loreto Secondary School is voluntary secondary school under the patronage of the Loreto Education Trust.Please see attached Project Brief & Schedule of Additional Accommodation.In summary, the project will comprise:Section A• 1 x Science Lab                                                88.6 m2• 1 x Prep Area                                                    38.5 m2• Toilets                                                                18.5 m2• Lockers                                                               7.2 m2• Giving a floor area including internal walls and circulation of 198.1 m2Section B• Two Classroom SEN Base                 409 m2Giving a floor area (incl circulation and internal walls of 523.5 m2Giving a Gross Floor Area (including circulation, internal walls & stairs) 722 m2Also:• Secure Hard and soft play area     100 m2• Sensory Garden        100 m2• 6 parking spacesAlso:• Buildings for Demolition:  Prefabs  250 m2INTERIM TEMPORARY ACCOMMODATION• Please note: Once appointed, the Design Team (DT) will be tasked with the provision of interim temporary accommodation (100 m2), including all required statutory approvals and compliances, to be used by the school until such time that the permanent structure has been completed. The DT are to ensure that the location of the interim temporary accommodation does not impede the development of the permanent additional accommodation.

title: Building Service (M&E) Engineering Services for Additional Accommodation at Loreto Secondary School, Letterkenny, Co Donegal.

Loreto Secondary School (Letterkenny)

street: Letterkenny

postalCode: Co. Donegal


description: SEP171195 - Supply & Delivery of 8 Tonne Hydraulic ExcavatorThe OPW invites tenders for the Supply & Delivery of one (1) 8 Tonne Hydraulic Excavator c/w Dipper Arm Extension Stick. Details as to the specification of the unit required are contained in the Tender Documents available on this site.NOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=157212.


description: JUL365035 - Contract for the Supply, Installation and Maintenance of CCTV EquipmentCall Off Contract for the Supply, Installation and Maintence of CCTV cameras for monitoring traffic. Cameras will be located on poles general at junctions throughout Galway City and ling back to Galway City Council's Traffic Control Room.NOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=469152.


description: FEB054195 - Request for Proposals for the Provision of Consultancy ServicesUCD would like to initiate a strategic review of its Research Institutes, with a view to developing business plans that:· Identify key thematic areas of research focus· Build on existing work to develop financial models for future sustainability· Clarify the governance, decision-making structures and relationship of the Institutes to the Schools and College structure of the University· Determine the organisational structure required to optimise research planning, administration and output· Identify the key measures of performance in each InstituteWork has already been completed in some of these areas and it is our expectation that this initiative would build on and consolidate existing outputs.UCD requests proposals from interested parties that can demonstrate a proven track record in one of more of the following areas in this or related sectors:- Developing financial models- Designing organisational structures- Identifying key areas of research focusNOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=27189.


description: WCCC21/200R - 2021 Waterford Bridge Rehabilitation Works2021 Waterford Bridge Rehabilitation Works. Carry out works on 5 number masonry bridges in County Waterford


title: Short descriptionMoyne Community School - Replacement of high-level windows and roof upgrade works to existing schoolDetailed descriptionReplacement of high-level windows and roof upgrade works to existing school building at Moyne Community School, Farmullagh, Moyne, Co. Longford.Type of Contract: Works

description:
Moyne Community School - Replacement of high-level windows and roof upgrade works to existing school
Replacement of high-level windows and roof upgrade works to existing school building at Moyne Community School, Farmullagh, Moyne, Co. Longford.


description: TEN1900269 - ITT for Engineering Consultancy Services for Retaining Walls and Site Works at Townparks/Tullymongan Lower, Cavan (1)ITT for Engineering Consultancy Services for Retaining Walls and Site Works at Townparks/Tullymongan Lower, Cavan Please Refer to Tender Documents for Further Details


description: The archaeological consultancy services will be required: test excavations and surveys [stage (i)]; pre-excavation services [stage (ii)]; excavation and post-excavation assessment services [stage (iii)]; post-excavation and dissemination [stage (iv)]. The on-site services are to be carried out at between Annaghervy, Drummaconor, Drumacaslan, Annagola, Aghalisk, Kilnahaltar, Tullybryan, Brandrum, Ballyleack, Cornecassa Demesne and Tullygrimes townlands, Co. Monaghan.The area is shown on the accompanying contract drawings. The total area subject to the current phase of advance archaeological works is approximately 5.61 hectares.

title: N54 Tullybryan Realignment Tullygrimes to Annaghervy, Archaeological Consultancy Services Contract (Stage (I) and (IV)

Monaghan County Council

street: The Glen

postalCode: Monaghan


description: HSE 10644 - Washer Extractor for Central Laundry at St. Lukes Hospital Clonmel, Co. Tipperary, IrelandThe HSE invites suppliers to submit tenders for the supply, delivery, offloading, installation, validation, commissioning, staff training & after sales, etc. (“turnkey solution”) for a Washer Extractor, related consumables and the associated service provisions at the Central Laundry, St. Luke's Hospital Clonmel, Co Tipperary, Ireland (HSE Area CHO5). The successful tenderer will also be required to undertake associated works, and to decommission, remove and dispose of the existing Washer Extractor.


description: JUN060154 - NON MAJOR RESURFACING CONTRACTS AT VARIOUS LOCATIONS THROUGHOUT DONEGALDonegal County Council seeks expressions of interest from competent Contractors wishing to tender for Non Major Pavement Strengthening Schemes on National and Non-National roads in the county during 2006. The anticpated scope of the works to be carried out from July to November 2006 comprises of the overlaying of a number of sites at 7.0m average width with DBM/HRA Surface Course finish throughout County Donegal. It also includes for the associated Road Construction works and accomodation works.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=33152.


description: AUG125279 - Consultancy Support - SEM Market Modelling 2010/11Consultancy Support - SEM Market Modelling 2010/11


description: UGF014F - PIN – Provision of Fuel Charge Card ServicesThis is a Prior Information Notice (PIN) and not a call to competition. Please do not respond to this notice. This notice is to advise the market that the Office of Government Procurement (OGP) intends to tender for the establishment of a Framework for the Provision of Fuel Charge Card Services to the Irish Public Sector by open competition within the next twelve (12) months.


title: Provison of Maintenance Services for the Spire of Dublin

description: Dublin City Council proposes to award a contract for the provision of maintenance services for the Spire of Dublin. The contract is to have a duration of 5 years.The Spire is a 120 m tall stainless steel monument constructed to commemorate the Millennium. It is situated in the median of O’Connell Street, Dublin, in an area with heavy pedestrian and vehicular traffic. The structure consists of a tapered, hollow, stainless steel tube over a small serviced underground basement. The basement chamber houses mechanical and electrical services as well as drainage for the bronze apron at street level above. Access to the centre of the Spire is from this area via a ladder, and the internal face of the structure accommodates cable trays and other services for the lighting. The Spire’s electricity supply is fed from an underground chamber approx. 50 m north of the Spire. This chamber contains an ESB substation and an electrical room for the Spire. It is accessed via a hatch on the pavement and a spiral staircase.The successful tender must provide maintenance services for the Spire to include but not limited to the following:— structure (including RC basement, stainless steel superstructure, tuned mass dampers, ladders, platforms, connections, etc.);— drainage (including gutters, gulleys, drainage pipes, manholes, sumps, watermains, etc.);— mechanical (including access hatches, lifting equipment, winches and pulleys);— electrical and controls (including motors, pumps, switchgear, lighting, alarms, control and monitoring systems; etc.)— the contract also includes the following:• cleaning and general upkeep the structure and services;• traffic management associated with maintenance tasks;• attendances during monthly meetings with the client and during works carried out by the clients named specialists;• managing activities of all sub-contractors.Refer to the Tender Documents for further details.

title: Provision of Maintenance Services for the Spire of Dublin

description: Dublin City Council proposes to award a contract for the provision of maintenance services for the Spire of Dublin. The contract is to have a duration of 5 years.Please see tender documents for full details.

Dublin City Council

street: Culture, Recreation and Economic Services, Block 4, Ground Floor, Civic Offices, Wood Quay, Dublin 8

Lynch Interact

street: Fonthill Business Park


description: Extension to Rathass Burial Grounds, Kerry County CouncilExtension to Rathass Burial Grounds, Kerry County Council


title: Contract for The Implementation of a Blood Sciences Laboratory Solution

description: This competition concerns a blood sciences laboratory service within the context of the Clinical Directorate of Laboratory Medicine at Beaumont Hospital. The solution comprises a combined automated tracked solution for the pre-analytical, analytical, and post-analytical aspects of a Blood Sciences Laboratory Service, including Chemistry (including ISEs), Immunoassay platform(s), Haematology, Coagulation and Immunology. A contract has now been awarded.

title: The Implementation of a Blood Sciences Laboratory Solution.

description: This competition concerns a blood sciences laboratory service within the broader context of the Clinical Directorate of Laboratory Medicine at Beaumont Hospital. The Contracting Authority envisions that the solution ultimately procured will comprise a combined automated tracked solution for the pre-analytical, analytical, and post-analytical aspects of a Blood Sciences Laboratory Service. At a minimum, it is anticipated that this will include Chemistry (including ISEs), Immunoassay platform(s), Haematology, Coagulation and, if feasible, Immunology. The installed solution must be capable of handling the Contracting Authority's current workload plus expected growth of 8-10 % per annum. The solution must be future-proofed to handle additional workload projections, including those imposed by any service expansion arising in the likely event of Beaumont Hospital being designated as a Hub laboratory, or any other changes brought about under the national laboratory modernisation programme. Full further information is available via the Qualification Questionnaire available to download from www.etenders.gov.ie

Beaumont Hospital

street: Beaumont Road

postalCode: Beaumont

Roche Diagnostics Ltd

street: Charles Avenue, Burgess Hill

postalCode: RH15 9RY


title: RFI - Case Management and Information System for Tusla Social Work Services

description: Case Management and Information System for Tusla Social Work ServicesA. To establish from market operators their capabilities with regard to providing solutions that they have implemented in equivalent or larger sized child related social services agencies in the UK, EU, North America or elsewhere. The solutions must be designed for or be readily capable of: (i) Aligning with the Signs of Safety practice model (ii) Have advanced supports for data privacy with demonstrated capability to adhere to Tulsa’s stringent data privacy by design requirements. ‘ (iii) Include a case management solution to support record keeping, document management, work/process flow, rules/controls and reporting requirements related to the delivery of social services. This should include capabilities for traditional back office working as well as mobile working (iv) Facilitate user self-service and collaboration solutions for external users that children, families, support networks and practitioners can use working together B. To understand what the market can offer with regard to solutions that can minimise disruption to the business and users transitioning from what is familiar to a new system.


description: 19.002 - Service Provider for the Provision of Architectural Technologists to the OPWThe OPW is seeking a Service Provider to provide qualified Architectural Technologists to various OPW District Offices. The offices will initially include: • Dublin – 2 No Positions • Cork Office – 1 No. Position • Limerick Office – 1 No. Position • Waterford Office – 1 No. Position


name: Valour Investment Ltd t/a On-site Refueling

description: Galway City Council wishes to set up a Multi Party Framework for the Supply & Delivery of Hydrotreated Vegetable Oil (HVO) Fuel in Bulk to Galway City Council Stores. The fuel must be of a high quality and conform to BS EN 15940 standard.

Galway City Council

postalCode: College Road

Tria oil Ltd

street: Coarliss P47P285 Caheragh

postalCode: Cork

Certa Ireland Ltd

street: Clonminam Industrial Estate

postalCode: Laois

street: Unit 17 old quarry campus

postalCode: Old Quarry Campus, N


description: Research on Victims’ Experiences with the Garda SíochánaInvitation to tender for a research project which would provide detailed insight into the experiences of victims of crime in respect of their interactions with the Garda Síochána.


description: 2757 - The Provision of Mechanical Contractors’ Services For Maintenance And Small Project WorksBeaumont Hospital intends to establish a framework agreement for the provision of mechanical contractors’ services for maintenance and small project works, as more fully described in the Invitation to Tender document.


name: Laois and Offaly Education and Training Board (Offaly)

title: The Provision of Tower Crane and related Construction Skills Certification Scheme (CSCS ) Training

description: CSCS Training - LOETB - The Provision of Tower Crane and related Construction Skills Certification Scheme (CSCS) TrainingLOETB proposes to engage in a competitive process for the establishment of a single party framework agreement for The Provision of Tower Crane and related Construction Skills Certification Scheme (CSCS) Training. Training at the National Construction Training Centre, Mount Lucas, Daingean, Co. Offaly (under remit of LOETB). The successful tenderer will be contracted, based on the level and occurrence of training required in the training centre, which is currently based on the demand from Department of Employment Affairs and Social Protection, Public and Industry


name: Galway Roscommon Education & Training Board

description: Science Lab, Rosmuc - New Science Lab & Prep Area, Colaiste na bPiarsach, Rosmuc, Co. GalwayConstruction of 1 no. Science Lab & Prep Area with a total of floor area of 127 sqm at Colaiste na bPiarsach, Rosmuc, Co. Galway, including all site works and services and the domolition and removal of 2 no. old prefabs form the site.


description: 6742-4 Portumna CS Fire Alarm - New fire alarm installation to IS 3218 : 2013The work to be carried out shall comprise of the following works, which will require to be carried out during the summer holidays:  Provision of a New “L2/L3” Type Analogue Addressable Fire Alarm System throughout the entire school building in accordance with the requirements of IS 3218: 2013 Code of Practice for Fire Alarm Systems, consisting of Main Fire Alarm panel, 2 number repeater panels, including smoke and heat detectors, manual call points, sounders, door hold open devices, etc. wired in a 2 core x 1.5mm² loop “Prysmian FP Plus” enhanced Fire Alarm cable (rated @ 120 min in accordance with I.S. EN 50200 and BS 8434-2:2003 +A2: 2009), which shall be run in an continuous re-wireable dedicated steel conduit / trunking system.  Provision of all associated Electrical Works consisting of wiring to the panels and power supply units, including the provision of an 50 mm x 50 mm Extra Low Voltage containment / steel trunking system for the wiring associated with the Fire Alarm System, etc.  The contractor is also responsible for all associated builders attendances as required for the above works, including the provision of all openings required in walls and ceilings, etc. temporarily taking down and reinstating ceilings tiles for access to the ceiling voids and making good.  The contractor shall be appointed by the Client under a collateral agreement to the main contract as Project Supervisor for the Construction Stage in respect of the project pursuant to the Safety, Health & Welfare at Work (Construction) Regulations 2013 (S.I. 291 of 2013).


description: 5761 IDA Roundstone WWTP - IDA Roundstone Business and Technology Park WWTP Works • Construction of an access road up to the works site. • Site preparation works including altering of existing topography (if necessary) to enable formation levels. • Installation of new wastewater treatment system to specialist design, including all ancillary works. • Construction of associated pipework and manhole(s). • Testing and commissioning of the proposed new wastewater treatment system and pipework. • Testing and servicing of the existing pumping station and any pipework which is to be retained. • Decommissioning and removal from site of existing obsolete wastewater treatment systems and redundant pipework, and the removal of any sludge remaining in the existent WWTP to a certified WWTP. • Replacement of the existing broken/rusted flap valve at the outfall. • Operation and maintenance of the plant as agreed with the IDA as per the WWTP O&M outlined in Volume A4 of the Tender Pack.


title: Short description6143: IDA Finnabair Pond - IDA Finnabair Business and Technology Park, Dundalk. Pond Upgrade WorksDetailed descriptionThe Works to be provided by the Contractor as part of his obligations under the contract include but are not limited to the following:• Pond renovation and liner repair works as detailed on drawings• Fencing to pond boundary• Footpath and seating area renovations• Replacement of submersible pump and motor to existing well with associated electrical works.• All ancillary works civil and electrical works• Testing of liner remediation works and evaporation tests.Type of Contract: Works

description: 6143: IDA Finnabair Pond - IDA Finnabair Business and Technology Park, Dundalk. Pond Upgrade WorksThe Works to be provided by the Contractor as part of his obligations under the contract include but are not limited to the following: • Pond renovation and liner repair works as detailed on drawings • Fencing to pond boundary • Footpath and seating area renovations • Replacement of submersible pump and motor to existing well with associated electrical works. • All ancillary works civil and electrical works • Testing of liner remediation works and evaporation tests.


title: Security Services

title: JUL026667 - Security Services

description: JUL026667 - Security ServicesTender for the provision of Security Services at Revenue Computer Centre,St.John's Road, Kilmainham, Dublin 8.


description: NOV094197 - Rental of VHF and UHF Handportables 2007, 2008, 2009Rental of VHF and UHF Handportables 2007, 2008, 2009


description: SEP066850 - Cleaning Services - Amiens Street PremisesFáilte Ireland, the National Tourism Development Authority, established under the National Tourism Development Authority Act, 2003, brings together and builds on the functions previously discharged by Bord Fáilte and CERT. The organisation provides strategic and practical support to develop and sustain Ireland as a high-quality and competitive tourist destination. Fáilte Ireland works in strategic partnership with tourism interests to support the industry in its efforts to be more competitive and more profitable and to help individual enterprises to enhance their performance. This is a contract for contract cleaning services at Fáilte Ireland's Amiens Street premises.See Appendix A in the attached Specification document for full details.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=39171.


description: JUN119623 - New Private Hospital - Main Contractor WorksNew Private Hospital - Main Contractor Works


description: DEC293236 - Supply & Erect 400 Person Kitchen and Dining Complex Lebanon (Middle East)Supply & Erect 400 Person Kitchen and Dining Complex Lebanon (Middle East)


description: LGH1265C - AIT - Supply, Delivery, Installation and Support of a Dynamic Rotational Shear Rheometer with a UV curing system Tenders are sought for the supply, delivery, installation and support of a Dynamic Rotational Shear Rheometer with a UV curing. A Rotational Shear Rheometer which measures liquid viscosity is required. Accessories required as part of this tender include UV Curing unit, Friction Testing Unit, and either Mercury lamp light guide or LED light guide. The Dynamic Rotational Shear Rheometer will be one of the first of its kind in an academic location. Other academics have Rheometers, but they do not have high temperature, UV curing and friction for the fields of teaching & training as well as research & development in one location. This will also open the door to new markets, such as aerospace and replacement of metal parts by Irish companies. The machine will be housed in the APT building which is a part of the Athlone IT main campus.


description: MK/PRSUK/11/17 - ITT for Public Relations (PR) Services in the UK MarketInvitation To Tender for the provision of Public Relations (PR) Services in the UK Market


description: JUN234936 - Audit Services for the Report and Financial Statements of the Accountant of the Courts of JusticeAudit of the Report and Financial Statements of the Accountant of the Courts of Justice.


title: SEP386315 - Cork County Council Odyssey System – Additional Modules.

title: To be deleted.

Cork County Council

street: Carrigrohane Road, County Hall

postalCode: T12 R2NC

Open Sky Data Systems

street: Unit 8 Osprey Business Centre


name: National Standards Authority of Ireland (NSAI)

description: FEB315476 - NSAI - ICT Helpdesk and Network Admin servicesNSAI - ICT Helpdesk and Network Admin services


name: Radiological Protection Institute of Ireland

description: SEP091501 - Gamma Irradiation Unit for Calibration ServiceGamma Irradiation Unit for Calibration Service


title: Banking Services

title: MAR317375 - Banking Services

description: MAR317375 - Banking ServicesEirGrid require the provision of cash management services from an appropriate Bank who has a presence within the Republic of Ireland and Northern IrelandInterested banks should request a copy of tender documents from Anthony Flood via email Anthony.flood@eirgrid.com for full detailsNOTE: To register your interest in this notice and obtain any additional information please visit the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=385692.


description: NCSC2017PSDP - Project Supervisor Design Process Services for the National Children's Science CentreProposed National Children’s Science Centre Development. The development will consist of the refurbishment and restoration of the existing north and part of the east wing of the existing National Concert Hall and the Real Tennis building and the construction of a new four storey over basement extension with a planetarium dome to the west of the north wing at the boundary of the Iveagh Gardens. The construction of a new underground link tunnel with a single storey glazed box roof light will connect the Real Tennis to the north east corner of the National Concert Hall building. A new basement plant room will act as a shared energy centre for the both the National Concert Hall and the National Children’s Science Centre The total floor area of the development is approx. 9117sqm. In order to facilitate the new extension, the following demolitions are required; the existing two storey stone building which houses a workshop, plant area and ancillary items and a maintenance shed located in the north western corner of the site. A section of the boundary wall along the Iveagh Gardens is also to be demolished, allowing for a new access ramp and steps into the Iveagh Gardens. The external works will comprise of hard and soft landscaping, lighting, new steps and ramps to facilitate universal access to the existing north wing and Iveagh Gardens, new railings to Iveagh Gardens, bicycle stands, new surface water attenuation, new foul connection and all associated ancillary works on a site area of circa. 0.837 hectares. The National Concert Hall, Real Tennis Building and Iveagh Gardens are designated Protected Structures (References RPS 2425, 2426 and 7791).


title: AUG260211 - IRL-Dublin: cranes, mobile lifting frames and works trucks fitted with a crane Type of Contract: Works

description: AUG260211 - IRL-Dublin: cranes, mobile lifting frames and works trucks fitted with a craneWorks


title: Bus Hire Framework Agreement

title: 5801 - Bus Hire Framework Agreement

description: 5801 - Bus Hire Framework AgreementIrish Rail is to establish a Framework of suitably qualified, competent bus / coach operators to provide transport for both bus hire as alternate transport to complement rail services during planned works and in the event of unplanned rail disruption.


description: JUL089147 - Supply of Furniture for the Institute of Technology BlanchardstownITB intends to create a panel of suitable Furniture Suppliers from Tenders received. It is intended that, insofar as is possible, the Institute¿s furniture requirements will be purchased from the panel of Suppliers over a three year period to September 2010NOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=49820.


title: Carlow LCDC Single Party Framework for Social Inclusion and Related Services with an initial Call-Off Contract relating to the Social Inclusion and Community Activation Programme (SICAP) 2024 – 2028.

description: Carlow Local Community Development Committee is the contracting authority responsible for this procurement, which involves the award of a Single Party Framework Agreement for Social Inclusion and Related Services, with immediate drawdown of an initial Call-Off Contract relating to the Social Inclusion and Community Activation Programme (SICAP) 2024-2028. This procurement is being run as a series of separate public Competitions, to establish 53 separate Framework Agreements, across 33 LCDC areas. Tenderers may bid for one, some or all of the Framework Agreements (of which there are a total of 53 across the country), but a successful tenderer is prohibited from being awarded more than 5 Framework Agreements in total. This Tender sets out the requirements for Framework Membership, as well as the requirements for delivery of SICAP services in 2024-2028, including legal / contractual terms (as laid out in the Framework Agreement and SICAP Call Off Contract), the SICAP 2024-2028 programme aim, target groups, goals, objectives, outcomes, core areas of work and thematic focus areas (as laid out in the Programme Framework), as well as Key Performance Indicator targets and Local Priority Target Groups specific to this competition, which should be prioritised by tenderers.

Carlow County Council

street: Athy Road


title: IT Managed Support Services.

description:
This tender process is complete.
               EirGrid Group is in the process of implementing the Integrated Single Electricity Market (I-SEM), the next iteration of the all island wholesale electricity market. Due to the requirements of I-SEM as well as existing service desk requirements, EirGrid now needs a fully Managed IT Service Desk.
               Services include but not limited to Service Desk Desktop, Mobility and Meeting Room Services.
               24/ Support Service
               EirGrid intends to establish a single supplier framework for the provision of these services.

EirGrid plc

street: Block 2 - The Oval, 160 Shelbourne Road

Hewlett Packard

street: Liffey Park, Technology Campus

postalCode: Barnhall, Leixlip, C


description: JUL089532 - Remedial Works Scheme for Cootehill Town, Co. CavanWorks carried out to the interior and exterior of the selected houses including work within the curtilage of the site. Improvement and Environmental works outside the curtilage of the site. Exterior work to include: Provision of ramps, windows, doors, fascia, guttering, down pipes, painting and repairs. Interior Work to include: Electrical upgrade, plumbing, heating upgrade, insulation, ventilation, painting and repairs. NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=53260.


description: Glenswilly National School - Extension and Refurbishment to Glenswilly National SchoolExtension and Refurbishment at Glenswilly National School to provide 5no Classrooms, Library, Multi-Purpose Room, 3no Special Education Tuition Rooms, Principal Office, General Office, Staff Room, Toilet & Shower Rooms Extend the existing General Purpose Room, Boiler Room, Circulation with external works to include ballcourts, car parking, access road and bus park etc


description: The HSE plans to establish a national tender for a Home Peritoneal Dialysis Service to include the provision of machines, consumables and other support services for those patients electing to perform PD. The first stage of this process is the request for Service Providers to Express an Interest. Please see attached documentation.

title: HSE 2585 - Request for expressions of interest for the provision and support of a home Peritoneal Dialysis Service.

Health Service Executive (HSE)

street: Head Office

postalCode: Millennium Park


description: APR035740 - RFT for Supply of Microcomputer Equipment (Servers) to An Garda SíochánaThe Department of Justice Equality and Law Reform on behalf on An Garda Síochána, hereafter referred to as An Garda Síochána, invites tenders for the provision of Computer Equipment (Servers) to An Garda Síochána. This invitation will give rise to an ongoing call-off contract for the supply of servers to the offices and stations of An Garda Síochána up to 31st March 2007.NOTE: Further information relating to this notice is available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=10512.


title: Construction of new school extensions

description: Bishop Galvin National School - Construction of new school extensionsTHE CONSTRUCTION OF A NEW CLASSROOM, A NEW WHEELCHAIR W.C. FOR ASSISTED USERS AND A NEW RESOURCE ROOM TO THE NORTH OF THE EXISTING SCHOOL AND THE CONSTRUCTION OF A NEW STAFF ROOM AND ENTRANCE TO THE EAST OF THE SCHOOL ALONG WITH ALL ASSOCIATED SITE WORKS


description: APR116609 - Stradbally Courthouse/Library & Arthouse (Projected Structure)The works include the proposed refurbishment of the existing Court House building (335m2 – 3605 sq ft) which is a protected structure and a new single storey extension ((210m2 – 2260 sq ft) to provide an Arts Complex with accommodation for artists in residence.The existing building will be refurbished to provide a remodelled library and new library annex, an artist studio and ancillary spaces on the ground floor; and to provide two artists studios, ancillary spaces and storage spaces on the first floor.The new single storey extension will include two artist studios (one a recording studio with a control room), two artist residential apartments, an exhibition area, kiln room and ancillary spaces.Externally the works include refurbishment of the existing building and the provision of new site works to included ramped access, re-arrangement of open areas including traditional walls and railings, a seating area, signage and an external landscaped courtyard to the rear with ESB plant enclosure and bin store.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=82570.


title: Tallanstown NS SWS 2017 Heating Upgrade

description: Tallanstown NS SWS2017 - Tallanstown NS SWS 2017 Heating UpgradeAsbestos removal. Removal of existing heating system, existing boilerhouse equipment and oil tank and bund. Construction of LPG tank compound, installation of new gas-fired boilerhouse equipment, LPHW radiator distribution, GP Hall gas-fired radiant heating and associated controls, electrical and builder's works.


description: JAN052450 - Schedule of Rates for Watermain Pipelaying in the Western Division of Cork County CouncilCork County Council is seeking Schedules of Rates from competent Contractors to undertake watermain pipelaying works at various locations throughout the Western Division. Subsequent minor Contracts will be offered to the Contractors to undertake the various projects based on their Schedule of Rates submitted. The projects involve the laying of 250mm, 200mm, 160mm, 110mm and 90mm watermains in PVC and Ductile Iron, the installation of various valves and fittings and the excavation and disposal of existing watermains. Rates will be sought under three different work classifications:1. 'Work in Urban Environment < 500m in length'2. 'Work in Rural Environment <500m in length'3. 'Work in Rural Environment >500m<1000m in length'Every project will be classified under one of the above and will, for the most part, be on the public road. Further information and the associated documents are available from:Water Services Section,Cork County Council,The Courthouse,Skibbereen.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=24985.


description: 17034 - OFFICE REFURBISHMENT, ELIZABETH FORT, BARRACK STREET, CORKOFFICE REFURBISHMENT- (INCLUDING BUT NOT LIMITED TO) STRIPPING AND DISPOSING OF SOME INTERNAL FIXTURES/FITTINGS/FURNITURE/FLOORING, CLEANING, MAKING GOOD, SURFACE PREPARATION & PAINTING, GENERAL DECORATION, MECHANICAL AND ELECTRICAL INSTALLATION, FITTED KITCHEN INSTALLATION, NEW FLOORING AND VARIOUS ASSOCIATED MISCELLANEOUS WORKS AS OUTLINED AND / OR DESCRIBED IN THE ATTACHED DOCUMENTS


title: General Dried Goods

title: Bakery

title: Beverages (Hot & Cold) & Juices

title: Soups

title: Biscuits

title: Cereals & Convenience, Pasta & Grains

title: Salt, Spices & Herbs, Sauces

title: Tinned Fruit,Tinned Vegetables,Tinned Fish

title: Preserves

title: Desserts

title: Sugar & Sweeteners

description: HSE Ref: 3530 - PRE QUALIFICATION QUESTIONNAIRE (PQQ) RESPONSE DOCUMENT. The Provision & Supply of Ambient Goods to the Health Services Executive and PRE QUALIFICATION QUESTIONNAIRE (PQQ) RESPONSE DOCUMENT. The Provision & Supply of Ambient Goods to the Health Services Executive and organisations funded by the HSE


title: Seirbhís Lónadóireacht - Catering Services.

description: This Invitation to Dialogue (ITD) invites suitably qualified Tenderers to submit an Expression of Interest in respect of the provision of Catering Services ('the Services'). TG4 will assess the Expression of Interests using the Qualification Criteria detailed at section 2 below and Tenderers who meet those requirements and comply with the terms of this ITD will be be selected for inclusion on a shortlist to participate in a competitive dialogue. The period of this contract is for three (3) years with an option to extend for a further two (2) years.

street: Oifigeach Sólathair

postalCode: Baile na hAbhann


Waterways Ireland

street: 2 Sligo Road

postalCode: Co. Fermanagh


title: Expressions of Interest - Bioniche Lab

description: MAY102729 - Expressions of Interest - Bioniche LabLéiriú suime ó chonraitheoirí éagsúla do chonradh tógála le haghaidh saotharlann nua ag Aille, Indreabháin, Co na Gaillimhe.Expressions of interest from Contractors in the construction of a new laboratory and research facilities for a company at Aille, Indrerabhán, Co. na GaillimheNOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=66581.


title: Navigation and Fishing Simulator

description: JUN157236 - Navigation and Fishing SimulatorBIM would like to invite suitable tenders for the supply, installation, staff training and maintenance of a new fishing simulator based at the current site in Greencastle, Co. Donegal. The proposal for this new simulator should be based on the Specification of Requirements set out in Section 2 of this document.NOTE: Further information and additional documentation relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=132794.The awarding authority has indicated that it will accept electronic responses to this notice via a 'Tender Submission Postbox' facility. Further details of this facility are available at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=132794.


description: AUG255495 - Dublin Airport Authorithy Integrated Comms SolutionDublin Airport Authorithy Integrated Comms Solution


description: TRA 12 08 02 011 New Spreaders - Tender for the Supply and Delivery of 2 No. 9m3 Stainless Steel Salt SpreadersPlease refer to attached Meath County Council Tender document - New Salt Spreaders 2016


description: 2636 - 2636 - The Provision of an ENT Endoscopic Stack System , Associated Items and All Related Support The Contracting Authority is employing the open procedure to award a managed equipment service contract of five years’ duration, encompassing the provision of an ENT endoscopic stack system, the provision of other associated equipment and the provision of all related support.


description: 2685 - The Provision of a Laundry Service for Residents' Personal Clothing and Chef UniformsThe provision of a laundry service for Residents' personal clothing; chef uniforms and ad-hoc laundry items.


title: LUAS Impact Study

title: JAN052453 - LUAS Impact Study

description: JAN052453 - LUAS Impact StudyThe Dublin Transportation Office (DTO) intends to carry out a study on two light rail (Luas) lines that opened in Dublin in 2004. The Study will assess the impact of the new lines on transport users, businesses and retailers in terms of behavioral and attitudinal response to Luas.The DTO requires a suitable company or consortium of companies to carry out the after element of this "before/after" study.NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=25275.


description: A Single Party Framework for The Provision of a Pulsed Field Ablation Solution

St Vincent's University Hospital

street: Elm Park


awardCriteriaDetails:
Strategic Insight:
Creativity:
Campaign Management:
Cost:
Philosophy and Cultural Fit:

Irish Blood Transfusion Service

street: National Blood Centre, James's Street

Cawley Nea

street: 41a Blackberry Lane, Rathmines


title: Repayment Scheme for Long Stay Charges

description: FEB052930 - Repayment Scheme for Long Stay ChargesIt has been established that charges for inpatient services were wrongly charged to eligible long stay patients residing in certain public residential facilities. The Health Service Executive (HSE) wishes to engage an external provider with relevant experience and expertise in handling a significant volume of public claims to provide a fair, transparent and well managed scheme for the repayment of these charges. Details of the repayment scheme will be set out in forthcoming legislation. The aim of the scheme will be to ensure that those who are eligible for repayments receive them as promptly as possible with minimum bureaucracy.Priority will be given to those patients who are alive and to the estates of those who were alive on 9thDecember 2004. The repayment scheme will involve some vertification of work completed by the HSE and the calculation of the other repayments due to eligible persons or their estates. The repayment scheme applies to eligible persons who were wrongfully charged.The Health Service Executive (HSE) is inviting suitably qualified service providers to express their interest in assisting with the design of the scheme and its management. In order to express your interest please complete and return the pre-qualification questionnaire available from the www.e-tenders.gov.ie website to the prescribed address to be received no later than 12.00 hrs on Wednesday 22nd February 2006. NOTE: Further information relating to this notice may be available on the eTenders Web Site at http://www.etenders.gov.ie/Search/Search_Switch.aspx?ID=25165.


description: SEP127576 - Tender For The Supply And Delivery of Hydrofluosilicic Acid 10.9% By WeightTender For The Supply And Delivery of Hydrofluosilicic Acid 10.9% By Weight


description: OCT175981 - Supply of management services for Coillte telecommunication radio sitesSupply of management services for Coillte telecommunication radio sites


description: JUL369675 - Tender for Recording the Architectural Heritage of County CavanTender for Recording the Architectural Heritage of County Cavan